36C24419B0005_1.docx

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

6. PROJECT NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than _______________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

36C24419B0005 X 12-07-2018 646-16-109 00244 Department of Veterans Affairs Network Contracting Office 4

See attached delivery schedule

BILL MATELAN

412-822-3769 THIS SOLICITATION IS FOR PROJECT # 646-16-109, "REPLACE KITCHEN AHU", at the Veterans Affairs Pittsburgh Healthcare Systen (VAPHS) University Drive C, Pittsburgh PA 15206 This solicitation is 100% set-aside for Service-Disabled Veteran Owned Small Businesses (SDVOSB) THE NAICS FOR THIS PROCUREMENT IS 236220 AND THE SMALL BUSINESS SIZE STANDARD IS $33.5 MILLION The Magnitude of Construction Cost is $1,000,000 to $2,000,000 Award will be made (in accordance with FAR 9.104 “STANDARDS”) to that responsible bidder whose bid, conforming to the invitation for bids, is determined to be technically acceptable and which represents the best value to the Government considering only price and the price-related factors included in the invitation

This work is to be performed in accordance with the specifications and drawings developed by the architect, Miller-Remick LLC; which are attached to and made part of this solicitation.

The Contractor shall be responsible for the correct title classification of their workers and compliance with all applicable wage rates ALL BIDS MUST BE RECEIVED NO LATER THAN 2:00 PM on January 8, 2019, when a public bid opening will be held in BLDG 49 Conference Room at VAPHS 1010 Delafield Road, Pittsburgh, PA 15215. Bids may be delivered in person or sent via USPS or a delivery service to: WILLIAM MATELAN / VAPHS / 1010 DELAFIELD ROAD / PITTSBURGH PA 15235 ANY BIDS RECEIVED AFTER THE TIME SPECIFIED WILL BE CONSIDERED NONCOMPLIANT AND INVALID

FAXED AND/OR EMAILED BIDS WILL NOT BE ACCEPTED

X X 52.211-10 X

NO

2:00 PM

01-08-2019 X

14. NAME AND ADDRESS OF OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28. NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or print) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

00244 Department of Veterans Affairs Network Contracting Office 4

Austin Payment Center Department of Veterans Affairs PO Box 149971 Austin TX 78714-9971

(877) 353-9791

(512) 460-5429

Table of Contents

STATEMENT OF BID ITEMS

The Government intends to award a firm, fixed-price contract to the responsive / responsible offeror who submits the lowest offer for BID ITEM 1 / BASE BID.

BID ITEM 1 / BASE BID: (as described in Specification section 01 00 00 / 1.3 / A) All work is to be performed in accordance with the Drawings and Specifications as prepared by the architect, Miller-Remick LLC.

GENERAL CONSTRUCTION: All work as required by drawings and specifications, including general construction, demolition and alteration of existing construction, structural, mechanical, electrical, plumbing, fire protection, hazardous material removal, utility systems, necessary alteration of existing structure and construction, and certain other items. Work includes all labor, material, equipment and supervision to perform the required construction work on this project.

AMOUNT OF BID (NUMERICAL):

AMOUNT OF BID (WRITTEN):

COMPANY NAME:

CONTRACTORS SIGNATURE & DATE:

CONTRACTOR’S PRINTED NAME:

ADDITIONAL INFORMATION FOR OFFERORS

TRAINING

All employees of the general Contractor and Subcontractors shall have the 10-hour OSHA certified construction safety course. The General Contractor’s competent person shall have completed the 30-hour OSHA certified construction safety course. Documentation of training shall be submitted to the Contracting Officer and COR for review and approval prior to any work being performed. There shall be no exceptions to this requirement.

FAILURE TO PRESENT THE PROPER TRAINING DOCUMENTATION UPON THE CONTRACTING OFFICER’S/COR’S REQUEST WILL RESULT IN THE INDIVIDUAL BEING REMOVED FROM THE JOB; THE INDIVIDUAL MAY ONLY RETURN AFTER THE PROPOER DOCUMENTATION HAS BEEN PROVIDED. THERE SHALL BE NO EXCEPTIONS TO THIS REQUIREMENT.

TB TESTING

It is the responsibility of the Contractor to provide TB training annually and a TWO-STEP PPD test annually for all personnel providing services at the VA Medical Center. Proof of TB testing showing a negative indication of TB must be provided to the CO/COR before work may begin.

FAILURE TO PRESENT THE PROPER TRAINING DOCUMENTATION WILL RESULT IN THE INDIVIDUAL BEING REMOVED FROM THE JOB; THE INDIVIDUAL MAY ONLY RETURN AFTER THE PROPER DOCUMENTATION HAS BEEN PROVIDED. THERE SHALL BE NO EXCEPTIONS TO THIS REQUIREMENT.

DETERMINATION OF RESPONSIBILITY

A Determination of Responsibility will be accomplished for the apparent awardee prior to processing the award. The above information, along with other information obtained from Government systems, such as the OSHA and EPA online inspection history databases will be used to make the Determination of Responsibility. Failure to affirm being within the guidelines above may result in a determination of “Non-Responsibility” for the bidder/offeror. This requirement is applicable to all subcontracting tiers, and prospective prime Contractors are responsible for determining the responsibility of their prospective Subcontractors.

POST AWARD - SUBCONTRACTOR SAFETY AND ENVIRONMENTAL VIOLATIONS & EMR

This directive is applicable to prime contractors and all subcontracting tiers. IAW FAR 9.104-4 Subcontractor Responsibility Matters, prospective contractors are responsible for determining the responsibility of their prospective subcontractors. After award, prime contractors are responsible for ensuring subcontractors have no more than three (3) serious, one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years and EMR equal to or less than 1.0.

PRIVACY AND CONFIDENTIALITY

Contractors to the Department of Veteran Affairs may be unintentionally exposed to sensitive information. Information maybe overheard, seen on documents or electronic devices, or observed that could potentially violate the privacy and confidentiality of our veterans, employees, volunteers, and their families. Regulations such as, but not limited to the Health Insurance Portability and Accountability Act of 1996 (HIPAA), Freedom of Information Act (FOIA) and Privacy Act of 1974 have been enacted to protect sensitive information from being improperly disclosed. Information should not be divulged or released to anyone unless specifically authorized by this agreement or its attached documents in accordance with the contracted services. Failure to comply with applicable statutes and regulation can result in the termination of this contract and civil and criminal penalties, including fines and imprisonment. All suspected or actual breeches of the privacy and confidential should be reported immediately to the Contracting Officer, Contracting Officer’s Representative (COR) or the Facility Privacy Officer.

KEYS

All keys provided the Contractor or any Subcontractor for use during the project shall be returned to the Contracting Officer's Technical Representative (COR) at completion of the work or upon request. No keys shall be reproduced by the Contractor or any Subcontractor. There shall be a charge for each key that is lost or not returned to the COR.

CONTRACTOR NORMAL WORK HOURS

The Contractor work hours are from 7:00 am to 4:30 pm, Monday through Friday, excluding federal holidays. Federal holidays that fall on a non-work day –Saturday or Sunday—the holiday usually is observed on Monday if the holiday is on Sunday or on Friday if the holiday is on Saturday. The Contractor may request authorization from the Contracting Officer to work an alternate schedule and/or on holidays. This project may require the Contractor to work other than “normal work hours”. Any work done during “other than normal” work hours shall be done at no additional cost to the Government. However, the Contracting Officer reserves the right to deny or authorize the Contractor’s request at his or her discretion considering the best interest of the Government. All federal holidays are observed as non -work days. Federal holidays can be found on the following web site: www.opm.gov/operating_status_schedules/fedhol/2012.asp.

MEETING MINUTES:

The construction contractor shall be responsible for taking complete and accurate minutes of each and every meeting at which a representative of the project design firm is not present. The minutes shall be submitted to the COR and/or the CO for review. The minutes shall become official only after being approved by the COR and/or the CO.

SITE SUPERVISOR:

The Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor. The superintendent shall be a direct employee of the contracting company to which the project is awarded and may not be a subcontractor or employee of any subcontractor. The superintendent must be on site during all normal working hours and/or whenever employees from the contractor and/or any subcontractor are on site. If the supervisor should not be present and on site when anyone is working, the COR will instruct all personnel to stop working and leave the site immediately and to not return until the superintendent is back onsite. Any production time lost because of the lack of a supervisor will the responsibility of the contractor and will incur no additional cost to the VA. If the Contracting Officer determines, at any time during performance of this contract, that the actions and/or performance of the site superintendent does not meet the standards of the VA, the COR, and/or the CO, it shall be the contracting officer’s sole decision and at his sole discretion to require the Contractor to replace the current site superintendent with one who is “satisfactory to the Contracting Officer”.

The following information must be included with the offeror’s bid package:

1. Duns & Bradstreet Number

2. Tax ID Number

3. Copy of the firm's Registration on www.vip.vetbiz.gov

4. Experience Modification Rate (EMR) Certification from Insurance Company and OSHA/EPA violation Information

5. Contractor Immigration Compliance Certification

6. Bid Sheet

NOTICE OF PRE-PROPOSAL SITE VISIT

Interested Contractors are highly encouraged to attend the pre-proposal site visit which will be held on DATE at TIME at the VA Pittsburgh Healthcare System / University Drive C / Pittsburgh PA 15240 / Conference Room AN220.

Interested parties are requested to submit questions and requests for clarification via email to the Contracting Officer no later than DATE, All responses will be posted as an amendment to the solicitation and shall become part of the solicitation and any resulting contract

REMOVAL OF SECTIONS AT TIME OF AWARD

Instructions, Conditions and Other Statements to Bidders/Offers; and Representations and Certifications will be removed as a result of an award, but will be deemed to be incorporated by reference in that award.

FORMAL COMMUNICATION, OFFEROR EXPLANATIONS

All requests by any offeror regarding the meaning or interpretation of the solicitation; proposals; drawings; specifications; etc. must be requested in writing via email and received by the Contracting Officer no later than seven working days before the closing date of the solicitation so that the requested information may be posted to http://www.fbo.gov for the benefit of all potential bidders.

REGISTRATION WITH CONTRACTOR PERFORMANCE ASSESSMENT RATING SYSTEM (CPARS)

As prescribed in Federal Acquisition Regulation (FAR) Part 42.15, the Department of Veterans Affairs (VA) evaluates contractors past performance on all construction contracts that exceed $700,000 and shares those evaluations with other Federal Government contract specialists and procurement officials. The FAR requires that the contractor be provided an opportunity to comment on past performance evaluations prior to each report closing. To fulfill this requirement VA uses an online database, the Contractor Performance Assessment Rating System (CPARS) which is maintained by the Naval Sea Systems Command (NAVSEA). The CPARS database information is shared with the Federal Awardee Performance and Integrity Information System (FAPIIS) database, which is available to all Federal agencies.

Each contractor whose contract award is estimated to exceed $700,000 is required to register with the NAVSEA CPARS database at the following web address: http://www.cpars.gov/cparsmain.htm Registration should occur no later than thirty days after contract award, and must be kept current should there be any change to the contractor's registered representative.

FFor contracts exceeding one year, the contracting officer will evaluate the contractor's performance annually. Interim reports will be filed each year until the last year of the contract, when the final report will be completed. The report shall be assigned in CPARS to the contractor's designated representative for comment. The contractor representative will have thirty days to submit any comments and reassign the report to the VA contracting officer.

Failure to have a current registration with the NAVSEA CPARS database, or to reassign the report to the VA contracting officer within those thirty days, will result in the Government's evaluation being placed on file in the database with a statement that the contractor failed to respond.

SAFETY OR ENVIRONMENTAL VIOLATIONS AND EXPERIENCE MODIFICATION RATE (EMR)

All Bidders/Offerors shall submit the following information pertaining to their past Safety and Environmental record. The information shall contain, at a minimum, a certification that the bidder/offeror has no more than three (3) serious, or one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years.

All Bidders/Offerors shall submit information regarding their current Experience Modification Rate (EMR) equal to or less than 1.0. This information shall be obtained from the bidder's insurance company and be furnished on the insurance carrier's letterhead.

Self-insured Contractors or other Contractors that cannot provide their EMR rating on insurance letterhead must obtain a rating from the National Council on Compensation Insurance, Inc. (NCCI) by completing/submitting form ERM-6 and providing the rating on letterhead from NCCI. Note: Self- insured Contractors or other Contractors that cannot provide EMR rating on insurance letterhead from the state of PA shall obtain their EMR rating from their state run worker's compensation insurance rating bureau.

The “Contractor Pre-Award OSHA Evaluation Form” (included in this section) must be completed and returned with all bids.

COMPLETE & SUBMIT WITH BID

Contractor Pre-Award OSHA Evaluation Form Company Name: ______________________________________________ Address: _____________________________________________________ Telephone: ______________________ Email: _______________________________________________________ Contact: ______________________________________________________

1. Utilizing your OSHA 300 Forms, please complete the following information:

Number of man hours (jobsite and office).

Number of cases involving days away from work, restricted activity, or both (Column H and I of OSHA 300).

Days away, restricted, or transferred rate (# of days away, restricted, or transferred cases x 200,000/# of man hours) (DART Rate).

Number of serious, willful, or repeat violations from OSHA within the last 3 years. Please attach explanation for any violations. (Four serious, one repeat, or one willful disqualifies the Contractor.)

Please attach copies of the following documents: OSHA 300 and 300a Forms. These forms can be accessed through the OSHA publications search page: http://www.osha.gov/pls/publications/publication.html.

Signature:

Date:

Printed Name and Title:

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS

2.1 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

(End of Provision)

2.2 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY 2014) (a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

2.3 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

(End of Provision)

2.4 52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American—Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of Provision)

2.5 52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be percent of the bid price or , whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of Provision)

2.6 52.233-2 SERVICE OF PROTEST (SEP 2006)

Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

Hand-Carried Address and Mailing Address:

William Matelan / 1010 Delafield Road / 90C-A / Pittsburgh, PA 15215

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

2.7 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for—

11:00 AM ON THURSDAY, DECEMBER 13, 2019

(c) Participants will meet at—

FMS CONFERENCEROOM AN220 / GROUND FLOOR AT UD

(End of Provision)

2.8 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html http://www.va.gov/oal/library/vaar/

(End of Provision)

2.9 VAAR 852.228-72 ASSISTING SERVICE-DISABLED VETERAN-OWNED AND VETERAN-OWNED SMALL BUSINESSES IN OBTAINING BONDS (DEC 2009) Prime contractors are encouraged to assist service-disabled veteran-owned and veteran-owned small business potential subcontractors in obtaining bonding, when required. Mentor firms are encouraged to assist protégé firms under VA's Mentor-Protégé Program in obtaining acceptable bid, payment, and performance bonds, when required, as a prime contractor under a solicitation or contract and in obtaining any required bonds under subcontracts.

(End of Clause)

2.10 VAAR 852.233-70 PROTEST CONTENT/ALTERNATIVE DISPUTE RESOLUTION (SEP 2018)

(a) Any protest filed by an interested party shall—

(1) Include the name, address, fax number, email and telephone number of the protester;

(2) Identify the solicitation and/or contract number;

(3) Include an original signed by the protester or the protester’s representative and at least one copy;

(4) Set forth a detailed statement of the legal and factual grounds of the protest, including a description of resulting prejudice to the protester, and provide copies of relevant documents;

(5) Specifically request a ruling of the individual upon whom the protest is served;

(6) State the form of relief requested; and

(7) Provide all information establishing the timeliness of the protest.

(b) Failure to comply with the above may result in dismissal of the protest without further consideration.

(c) Bidders/offerors and Contracting Officers are encouraged to use alternative dispute resolution (ADR) procedures to resolve protests at any stage in the protest process. If ADR is used, the Department of Veterans Affairs will not furnish any documentation in an ADR proceeding beyond what is allowed by the Federal Acquisition Regulation.

(End of Provision)

2.11 VAAR 852.233-71 ALTERNATE PROTEST PROCEDURE (SEP 2018)

(a) As an alternative to filing a protest with the Contracting Officer, an interested party may file a protest by mail or electronically with: Executive Director, Office of Acquisition and Logistics, Risk Management and Compliance Service (003A2C), Department of Veterans Affairs, 810 Vermont Avenue NW, Washington, DC 20420 or Email: EDProtests@va.gov.

(b) The protest will not be considered if the interested party has a protest on the same or similar issue(s) pending with the Contracting Officer.

(End of Provision) PLEASE NOTE: The correct mailing information for filing alternate protests is as follows:

Or for solicitations issued by the Office of Construction and Facilities Management:

2.12 VAAR 852.270-1 REPRESENTATIVES OF CONTRACTING OFFICERS (JAN 2008)

The contracting officer reserves the right to designate representatives to act for him/her in furnishing technical guidance and advice or generally monitor the work to be performed under this contract. Such designation will be in writing and will define the scope and limitation of the designee's authority. A copy of the designation shall be furnished to the contractor.

(End of Provision)

REPRESENTATIONS AND CERTIFICATIONS

3.1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36.5 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204–7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan—Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certifications. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[X](i) 52.204-17, Ownership or Control of Offeror.

[X](ii) 52.204-20, Predecessor of Offeror.

[](iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[](iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

[](v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services—Certification.

[](vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

[](vii) 52.227-6, Royalty Information.

[](A) Basic.

[](B) Alternate I.

[](viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of Provision)

3.2 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision— "Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all…