36C24419B0004-007.docx

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

6.

PROJECT NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV.

8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

11. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See _____________________________).

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that t ime. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than _______________________ calendar days for Government accepta nce after the date offers are due will not be considered and will be rejected.

36C24419B0004 X 12-04-2018 542-19-1-5306-0002 542-12-106 36C244 Department of Veterans Affairs Network Contracting Office 4 Construction East 1400 Blackhorse Hill Rd.

Coatesville PA 19320 Department of Veterans Affairs Coatesville VA Medical Center 1400 Blackhorse Hill Rd.

Building 70 - Conference Room Coatesville PA 19320 Lev Stowe | Lev.Stowe@va.gov (717)304-9291 Project #542-12-106, Correct Electrical Deficiencies.

This project shall generally consist of, but not limited to; providing all labor, supplies, transportation, and equipment required to correct electrical deficiencies at the Coatesville VA Medical Center (CVAMC).

All work shall be performed in accordance with (IAW) the Statemen t of Work (SOW), the attached documents, and all Federal, State, and local codes.

Magnitude of Construction: Between $2,000,000.00 and $5,000,000.00.

Project #542-12-106, Correct Electrical Deficiencies.

NAICS: 236220 - Commercial and Institutional Building Construction.

Size Standard: Small Business $36.5M.

This is a Service Disabled Veteran Owned Small Business (SDVOSB) set-aside acquisition.

An Award will be made to the responsive, responsible bidder by way of a Firm-Fixed-Price (FFP) contra ct whose bid constitutes the lowest price to the Government.

All documents for this solicitation will be available on the FedBizOpps website (http://www.fedbizopps.gov). It is the responsibility of the contractor to check this website frequently for updates and amendments to this solicitation.

Interested parties are encouraged to attend the scheduled Site Visit, which will be held at 1400 Blackhorse Hill Rd, Building 70, Coatesville, PA 19320, on 12/19/2018 at 9:00 AM (Local), IAW FAR 52.236-27 - Site Visit (FEB 1995).

The Contractor shal l be responsible for the correct title classification of workers and compliance with all applicable wage and hour laws.

Instruction To Offerors:

Bidders are required to submit sealed bids in accordance with the instructions outlined in Section 13 (below) and by submitting a bid amount on the Bid Schedule, located on Page 3. Electronic submissions are not authorized for any bid requiring a sta mped bid bond. Bid Bonds must be presented in hard copy with raised seal at the time of bid opening. Questions regarding the solicitation must be submitted to the Contract Specialist by email at Lev.Stowe@va.gov, no later than December 26, 2018, at 4:00 PM (EST), after which time questions will not be answered.

This acquisition is under FAR 14 and FAR 36.

X X 52.211-10 X

10:00 AM

01-08-2019 X

14. NAME AND ADDRESS OF OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER

DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28. NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES

OF AMERICA

31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or print) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

**SEE BID SCHEDULE** PAGE 3

36C244 Department of Veterans Affairs Network Contracting Office 4 Construction East 1400 Blackhorse Hill Rd.

Coatesville PA 19320 Austin Payment Center Department of Veterans Affairs PO Box 149971 Austin TX 78714-9971

(877) 353-9791

(512) 460-5429 X Contracting Officer

BID SCHEDULE – Bidders shall provide a price for each item to be considered for award.

BID ITEM #1: BID ITEM #1 SHALL INCLUDE ALL WORK INDICATED ON THE CONSTRUCTION DRAWINGS AND AS DESCRIBED IN THE CONSTRUCTION SPECIFICATIONS.

BID ITEM #2: THIS BID ITEM SHALL INCLUDE ALL OF THE WORK DESCRIBED IN BID ITEM #1, EXCEPT THE WORK IDENTIFIED AS DEDUCT-ALTERNATE No. 1, SPECIFICATION SECTION 26 05 74, CAMPUS WIDE POWER SYSTEM STUDY.

Award Statement: The bid deducts outlined in the bid schedule above are listed in order of preference. In the event the base bid exceeds the available funding, the government may accept and award one or more deduct items.

STATEMENT OF WORK

FOR

THE CORRECTION OF ELECTRICAL DEFICIENCIES

PROJECT NO. 542-12-106

COATESVILLE VA MEDICAL CENTER

DESCRIPTION:

Correct all electrical deficiencies outlined herein at the Coatesville VA Medical Center (CVAMC).

PLACE OF PERFORMANCE:

The Coatesville VA Medical Center (CVAMC) - 1400 Blackhorse Hill Rd, Multiple Buildings, Coatesville, PA 19320; see drawings for specific locations of performance, and a detailed list of technical requirements at each site.

BACKGROUND:

During one of the earliest phases of modernization to the Coatesville VA Medical Center’s electrical system, Federal Pacific Electric (FPE) installed various equipment throughout the facility that no longer complies with current electrical codes and safety standards.

SCOPE:

The purpose of this project is to correct all electrical deficiencies outlined in this Statement of Work (SOW), including those referenced in the SOW which refer to separate attachments to the contract. The objective is to target all FPE equipment for replacement and modernization as well as all antiquated electrical systems throughout the CVAMC Campus, as listed in Attachment “A” (Drawings); i.e., electrical switchgear, panelboards, circuit breaker panels, bonding and grounding, improper wire sizes, and equipment related to those circuits such as; motors, motor starters, and Automatic Transfer Switches (ATS), etc. Work will include, but is not limited to; drafting Red-Line drawings, cost estimates, and project scheduling and phasing.

GENERAL INFORMATION:

A. Attachments:

1) Attachment A – Drawings

2) Attachment B – Master Construction Specifications

3) Attachment C – Safety and Health During Construction

· The contractor shall refer to the Contracting Officer Representative (COR) for clarification and guidance.

PERFORMANCE REQUIREMENTS:

The contractor shall provide all labor, supplies, transportation, and equipment required to correct all electrical deficiencies at the Coatesville VA Medical Center (CVAMC) in accordance with; the attachments provided, and the sources referenced, while complying with all applicable Federal, State, and local codes, including the Department of Veterans Affairs (VA) requirements outlined herein.

A. Industry Code Compliance:

The contractor shall comply with all applicable National Electrical Codes (NEC), including the National Fire Protection Association (NFPA) 70E - Standards for Electrical Safety in the Workplace, NFPA 99 – Health Care Facility Codes, and Joint Commission requirements.

B. Permits:

The contractor shall obtain all environmental and other necessary permits required prior to the commencement of any work under this contract.

C. Summary of Work:

1) All items listed for each location in Attachment “A”,

2) The specifications referenced in Attachments “A” & “B”,

3) Completing the Campus-Wide Power System Study, referenced in Section 26 05 74 of Attachment “B”,

4) Building 17 Chiller Breaker: Install new 1600 A 480 V, 3 Pole Draw-Out circuit breaker in modified cubicle & provide connection, and new door with escutcheon; refer to Attachment “A”.

D. Construction Barrier:

1) The Pre-construction Risk Assessment (PCRA) and Infectious Control Risk Assessment (ICRA) shall include a solid door entry, full High-Efficiency Particulate Air (HEPA) exhaust, and a barrier from the floor to the ceiling deck (above any acoustic ceiling) when applicable.

2) The contractor shall provide a safety barrier around the construction site / work area, comprised of a plastic barrier and caution tape.

GENERAL REQUIREMENTS:

A. Required Contractor Notifications and Scheduling:

1) Shutdown of Equipment and/or Facility Power: The contractor shall notify the COR two (2) weeks in advance of the need to schedule a shutdown or disconnection of facility power, and/or any power that supplies electricity to any and/or all spaces at the CVAMC.

2) Gaining Access to Secured Areas: The contractor shall notify the COR two (2) weeks in advance of the need to gain access to secured areas if such access is required.

3) Interference in Performance Requirements: The contractor shall immediately notify the COR if and/or when performance requirements under this contract must be interrupted in support the normal functioning of the facility; e.g., utility services, mealtimes, inspections, the distribution of medication to patients, emergency responses, the passage of facility patients/personnel, etc.

4) Product Literature & Maintenance Requirements: The contractor shall supply the COR with product literature and maintenance requirements (if any) for all items installed under this contract.

B. Cleanup and Disposal:

1) Disposal / Recycling of Trash and Hazardous Waste:

a. All recyclables; e.g., abandoned wire, starters, and related equipment will be recycled by the contractor. The contractor shall provide the COR with a receipt showing that the items listed were recycled appropriately.

SPECIAL CONTRACTOR PROVISIONS: The following provisions shall be adhered to by contractor personnel throughout the duration of this contract:

A. Portable Generators:

1) To minimize time without power, the contractor shall supply an applicable size portable generator to power the load (facility or individual circuits) of the electrical equipment affected.

B. Emergency Escape Lighting:

1) Contractors will provide emergency escape lighting when applicable.

C. Submission of Red-Line Drawings:

1) The contractor shall provide the COR with Red-Line drawings in the following format prior to the completion of the project;

a. One (1) full size drawing (hard copy)

b. Two (2) half size drawings (hard copies)

c. Three (3) CD’s

D. Contractor Storage:

1) The contractor must provide their own storage structure.

SPECIAL CVAMC PROVISIONS:

A. Storage Site:

1) The CVAMC will provide the contractor with a storage site prior to the commencement of all performance requirements and it will be available to the contractor throughout the duration of the contract.

a. The dimensions of the storage site will be large enough to accommodate a 40’ x 12’ shipping container.

b. The COR will provide the contractor with the exact location of the storage site prior to the contractor’s receipt of the Notice to Proceed.

PERFORMANCE SCHEDULE:

A. Working Hours:

1) Work shall be performed Monday through Friday (except Federal Holidays), 7:00 AM (Local) – 5:00 PM (Local).

2) Contractor performance outside of the working hours (off-hours work) previously specified is only authorized after a notification to the COR has been approved.

Table of Contents

LIST OF ATTACHMENTS…….…………………………………………………………………….…47

Construction Wage Rate Requirements Statute, General Decision No. PA180107…………….……47

36C24419B0004

Page 1 of

Page 1 of

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS

INSTRUCTIONS TO BIDDERS

(a) Bidding materials consisting of drawings, specifications and contract forms may be obtained by qualified General (Prime) Contractors interested in submitting bids direct to the Department of Veterans Affairs from www.FBO.GOV

(b) Subcontractors, material firms and others interested in preparing sub-bids may obtain a list of Prime Contractors from www.FBO.GOV via the Interested Vendors Section.

(c) A bid guarantee is required in an amount not less than 20 percent of the bid price but shall not exceed $3,000,000. Failure to furnish the required bid guarantee in the proper form and amount, by the time set for opening of bids, will require rejection of the bid in all cases except those listed in FAR 28.101-4, and may be cause for rejection even then.

(d) If the contract will exceed $150,000 (see FAR 28.102-1 for lesser amount), the bidder to whom award is made will be required to furnish two bonds, a Payment Bond, SF 25A, and a Performance Bond, SF 25, each in the penal sum as noted in the General Conditions of the Specification.

DESCRIPTION OF WORK:

Contractor shall completely prepare site for building operations, including demolition and removal of existing materials, and furnish labor and materials and perform work for “Correcting Electrical Deficiencies”. The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost; any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government. The Contractor agrees to be responsible for the correct classification of workers.

MAGNITUDE OF CONSTRUCTION: $2,000,000.00 to $5,000,000.00

CONTRACTOR RESPONSIBILITY:

Safety or Environmental Violations and Experience Modification Rate:

“All Bidders/Offerors shall submit the following information pertaining to their past Safety and Environmental record. The information shall contain, at a minimum, a certification that the bidder/offeror has no more than three (3) serious, or one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years.

All Bidders/Offerors shall submit information regarding their current Experience Modification Rate (EMR) equal to or less than 1.0. This information shall be obtained from the bidder’s/offeror’s insurance company and be furnished on the insurance carrier’s letterhead.

Self insured contractors or other contractors that cannot provide their EMR rating on insurance letterhead must obtain a rating from the National Council on Compensation Insurance, Inc. (NCCI) by completing/submitting form ERM-6 and providing the rating on letterhead from NCCI. Note: Self insured contractors or other contractors that cannot provide EMR rating on insurance letterhead from the states or territories of CA, DE, MI, NJ, ND, OH, PA, WA, WY, and PR shall obtain their EMR rating from their state run worker’s compensation insurance rating bureau.

A Determination of Responsibility will be accomplished for the apparent awardee prior to processing the award. The above information, along with other information obtained from Government systems, such as the OSHA and EPA online inspection history databases will be used to make the Determination of Responsibility. Failure to affirm being within the guidelines above may result in a determination of “Non-Responsibility” for the bidder/offeror. NOTE: Any information received by the Government that would cause for a negative Determination of Responsibility may make the bidder/offeror ineligible for award.

This requirement is applicable to all subcontracting tiers, and prospective prime contractors are responsible for determining the responsibility of their prospective subcontractors.

Contractor shall be required to complete all contract work and schedule a final inspection within the specified contract performance period. Should the Contractor fail to complete the contract work (including scheduling of the final inspection), and it is determined by the Government to be a Contractor-caused delay, the Contractor shall be in default status. If the Government determines it to be in the best interest of the Government to allow the Contractor to continue to perform contract work, the Contractor shall provide equitable consideration in the form of Liquidated Damages from the first day of inexcusable delay through final acceptance by the Government. These damages are associated with the additional time granted for completion and acceptance of contract work. Such agreement shall not be deemed a waiver of the Government’s right to terminate this contract in the event the Contractor fails to complete the contract work (including scheduling of the final inspection) on or before the completion date.

TRAINING: Effective July 31, 2005, all employees of the general contractor and subcontractors shall have the 10-hour OSHA certified construction safety course. The General Contractor’s competent person shall have completed the 30-hour OSHA certified construction safety course. Documentation of training shall be submitted to the Contracting Officer for review and approval prior to any work being performed. Failure to present the proper training documentation will result in the individual being removed from the job; the individual may only return after the proper documentation has been provided. There shall be no exceptions to this requirement.

It is the responsibility of the Contractor to provide TB training annually and a PPD test annually for any employees providing services at the VA Medical Center, Coatesville, PA. The government reserves the right to review the contractor's records. Failure to present the proper training documentation upon the Contracting Officer’s request will result in the individual being removed from the job; the individual may only return after the proper documentation has been provided. There shall be no exceptions to this requirement.

PRIVACY & CONFIDENTIALITY: Contractors to the Department of Veteran Affairs may be unintentionally exposed to sensitive information. Information maybe overheard, seen on documents or electronic devices, or observed that could potentially violate the privacy and confidentiality of our veterans, employees, volunteers, and their families. Regulations such as, but not limited to the Health Insurance Portability and Accountability Act of 1996 (HIPAA), Freedom of Information Act (FOIA) and Privacy Act of 1974 have been enacted to protect sensitive information from being improperly disclosed. Information should not be divulged or released to anyone unless specifically authorized by this agreement or its attached documents in accordance with the contracted services. Failure to comply with applicable statutes and regulation can result in the termination of this contract and civil and criminal penalties, including fines and imprisonment. All suspected or actual breeches of the privacy and confidential should be reported immediately to the Contracting Officer, Contracting Officer’s Representative (COR) or the Facility Privacy Officer.

KEYS: All keys provided the Contractor or any subcontractor for use during the project shall be returned to the Contracting Officer's Representative (COR) at completion of the work or upon request. No keys shall be reproduced by the Contractor or any subcontractor. There shall be a charge for each key that is lost or not returned to the COR.

CONTRACTOR NORMAL WORK HOURS: The contractor work hours are from 7:00AM to 5:00PM, Monday through Friday, excluding federal holidays. Federal holidays that fall on a non-work day – Saturday or Sunday - the holiday usually is observed on Monday if the holiday is on Sunday or on Friday if the holiday is on Saturday. The contractor may request authorization from the Contracting Officer to work an alternative schedule or on holidays. However, the Contracting Officer reserves the right to deny or authorize the contractor’s request at his or her discretion considering the best interests of the Government. All federal holidays are observed as non work days. Federal holidays can be found on the following web site: http://www.opm.gov/policy-data-oversight/snow-dismissal-procedures/federal-holidays. These days will be identified during the pre-construction meeting.

(End of Clause)

2.1 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision— "Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

"Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of Provision)

2.2 52.209-13 VIOLATION OF ARMS CONTROLS TREATIES OR AGREEMENTS—CERTIFICATION (JUN 2018)

(a) This provision does not apply to acquisitions below the simplified acquisition threshold or to acquisitions of commercial items as defined at FAR 2.101.

(b) Certification. [Offeror shall check either (1) or (2).]

(1) The Offeror certifies that—

(i) It does not engage and has not engaged in any activity that contributed to or was a significant factor in the President’s or Secretary of State’s determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available via the internet at https://www.state.gov/t/avc/rls/rpt/;and

(ii) No entity owned or controlled by the Offeror has engaged in any activity that contributed to or was a significant factor in the President’s or Secretary of State’s determination that a foreign country is in violation of its obligations undertaken in any arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. The determinations are described in the most recent unclassified annual report provided to Congress pursuant to section 403 of the Arms Control and Disarmament Act (22 U.S.C. 2593a). The report is available via the internet at https://www.state.gov/t/avc/rls/rpt/; or

(2) The Offeror is providing separate information with its offer in accordance with paragraph (d)(2) of this provision.

(c) Procedures for reviewing the annual unclassified report (see paragraph (b)(1) of this provision). For clarity, references to the report in this section refer to the entirety of the annual unclassified report, including any separate reports that are incorporated by reference into the annual unclassified report.

(1) Check the table of contents of the annual unclassified report and the country section headings of the reports incorporated by reference to identify the foreign countries listed there. Determine whether the Offeror or any person owned or controlled by the Offeror may have engaged in any activity related to one or more of such foreign countries.

(2) If there may have been such activity, review all findings in the report associated with those foreign countries to determine whether or not each such foreign country was determined to be in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or to be not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. For clarity, in the annual report an explicit certification of noncompliance is equivalent to a determination of violation. However, the following statements in the annual report are not equivalent to a determination of violation:

(i) An inability to certify compliance.

(ii) An inability to conclude compliance.

(iii) A statement about compliance concerns.

(3) If so, determine whether the Offeror or any person owned or controlled by the Offeror has engaged in any activity that contributed to or is a significant factor in the determination in the report that one or more of these foreign countries is in violation of its obligations undertaken in an arms control, nonproliferation, or disarmament agreement to which the United States is a party, or is not adhering to its arms control, nonproliferation, or disarmament commitments in which the United States is a participating state. Review the narrative for any such findings reflecting a determination of violation or non-adherence related to those foreign countries in the report, including the finding itself, and to the extent necessary, the conduct giving rise to the compliance or adherence concerns, the analysis of compliance or adherence concerns, and efforts to resolve compliance or adherence concerns.

(4) The Offeror may submit any questions with regard to this report by email to NDAA1290Cert@state.gov. To the extent feasible, the Department of State will respond to such email inquiries within 3 business days.

(d) Do not submit an offer unless—

(1) A certification is provided in paragraph (b)(1) of this provision and submitted with the offer; or

(2) In accordance with paragraph (b)(2) of this provision, the Offeror provides with its offer information that the President of the United States has—

(i) Waived application under U.S.C. 2593e(d) or (e); or

(ii) Determined under 22 U.S.C. 2593e(g)(2) that the entity has ceased all activities for which measures were imposed under 22 U.S.C.2593e(b).

(e) Remedies. The certification in paragraph (b)(1) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly submitted a false certification, in addition to other remedies available to the Government, such as suspension or debarment, the Contracting Officer may terminate any contract resulting from the false certification.

(End of Provision)

2.3 52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

(End of Provision)

2.4 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY 2014) (a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

2.5 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Chester County, PA

(End of Provision)

2.6 52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American—Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of Provision)

2.7 52.233-2 SERVICE OF PROTEST (SEP 2006)

Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

Everett Shaver

Hand-Carried Address:

Department of Veterans Affairs Wilkes-Barre VA Medical Center 1111 East End Blvd.

Contracting (049E) Wilkes-Barre PA 18711 Mailing Address:

Everett Shaver Wilkes-Barre VA Medical Center Contracting (049E) 1111 East End Blvd.

Wilkes-Barre PA 18711

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

2.8 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for— December 19, 2018, at 9:00 AM (Local)

(c) Participants will meet at— 1400 Blackhorse Hill Rd. Bldg 70, Coatesville, PA 19320 (End of Provision)

2.9 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html http://www.va.gov/oal/library/vaar/

(End of Provision)

2.10 VAAR 852.233-70 PROTEST CONTENT/ALTERNATIVE DISPUTE RESOLUTION (SEP 2018)

(a) Any protest filed by an interested party shall—

(1) Include the name, address, fax number, email and telephone number of the protester;

(2) Identify the solicitation and/or contract number;

(3) Include an original signed by the protester or the protester’s representative and at least one copy;

(4) Set forth a detailed statement of the legal and factual grounds of the protest, including a description of resulting prejudice to the protester, and provide copies of relevant documents;

(5) Specifically request a ruling of the individual upon whom the protest is served;

(6) State the form of relief requested; and

(7) Provide all information establishing the timeliness of the protest.

(b) Failure to comply with the above may result in dismissal of the protest without further consideration.

(c) Bidders/offerors and Contracting Officers are encouraged to use alternative dispute resolution (ADR) procedures to resolve protests at any stage in the protest process. If ADR is used, the Department of Veterans Affairs will not furnish any documentation in an ADR proceeding beyond what is allowed by the Federal Acquisition Regulation.

(End of Provision)

2.11 VAAR 852.233-71 ALTERNATE PROTEST PROCEDURE (SEP 2018)

(a) As an alternative to filing a protest with the Contracting Officer, an interested party may file a protest by mail or electronically with: Executive Director, Office of Acquisition and Logistics, Risk Management and Compliance Service (003A2C), Department of Veterans Affairs, 810 Vermont Avenue NW, Washington, DC 20420 or Email: EDProtests@va.gov.

(b) The protest will not be considered if the interested party has a protest on the same or similar issue(s) pending with the Contracting Officer.

(End of Provision) PLEASE NOTE: The correct mailing information for filing alternate protests is as follows:

Or for solicitations issued by the Office of Construction and Facilities Management:

2.12 VAAR 852.270-1 REPRESENTATIVES OF CONTRACTING OFFICERS (JAN 2008)

The contracting officer reserves the right to designate representatives to act for him/her in furnishing technical guidance and advice or generally monitor the work to be performed under this contract. Such designation will be in writing and will define the scope and limitation of the designee's authority. A copy of the designation shall be furnished to the contractor.

(End of Provision)

REPRESENTATIONS AND CERTIFICATIONS

3.1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $36.5 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204–7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following…