2-Attachment A - Corporate Profile.pdf
PDF 79 KB Posted
- Attached to
- BVRI - Demolition Services
- Solicitation number
- CPDG-BVRI-Demo-2026
- Issued by
- Maryland
About this file
Corporate Profile for BVRI - Demolition Services
This is a Corporate Profile form used by the Maryland Stadium Authority (MSA) to evaluate qualifications for the Baltimore Vacants Reinvestment Initiative (BVRI) Demolition Services program in Maryland. The form requests comprehensive information from contractors seeking to provide abatement and demolition services, including razing or demolishing structures, abatement of hazardous substances, debris removal, and water and sewer shut-offs. Through this Request for Qualifications (RFQ), the MSA will establish a pool of pre-qualified contractors eligible to participate in subsequently issued Requests for Proposals (RFP) for specific abatement and demolition projects. The form does not specify explicit response dates, due dates, site visits, bidder meetings, award dates, or contract terms within this document itself, as it functions as a qualification template rather than a solicitation notice.
The Corporate Profile form requires offerors to provide detailed financial and operational data including five years of sales volume and project completion records for the regional or local office responsible for the work, as well as Workers' Compensation Experience Modification Rates (EMR) for the past five years. Contractors must disclose any regulatory citations from federal or state OSHA within the last three years, contract failures or breaches with potential judgments exceeding $100,000, civil litigation, criminal investigations, and any incomplete projects within the past five years. Additionally, offerors must provide three project references from different projects with designated contact information. The form requests information on corporate structure, diversity certifications (MBE, SBR), firm history, staffing levels, and designated primary and secondary points of contact for the solicitation.
View the file
Other files
| File | Type | Posted |
|---|---|---|
| 3-Attachment C - Sample RFP.zip | ZIP file | |
| 1-Attachment B - Project Experience Form.xlsx | XLSX spreadsheet | |
| 4-RFQ BVRI-DEMO-2026 20260312.pdf |
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Page 1 of 4 rev. 3/11/2026 - ck
Corporate Profile
General Information
Complete Offeror’s Legal Name:
d/b/a (if any):
Headquarter Address:
Regional Office Address:
Federal Tax ID Number:
SDAT Department ID Number:
eMMA Account Number:
Diversity Programs
MBE Certification Number:
MBE Minority status:
SBR Certification Number:
Primary Point of Contact (for this solicitation)
Name:
Title:
Direct Phone Number:
Email Address:
Mailing Address:
Secondary Point of Contact (for this solicitation)
Name:
Title:
Direct Phone Number:
Email Address:
Mailing Address:
Page 2 of 4 rev. 3/11/2026 - ck
Background Information
Year Founded:
Primary Service Provided:
Number of Years Performing Services:
Number Full Time Employees (Corporate / Regional Office): /
Provide a brief narrative outlining the firm’s history.
Past Performance
Sales Volume
Provide sales volume and project completion data for the most recently completed five-year period. Note that information provided is to be for the regional/local office that would be responsible for completing work under this solicitation.
Volume Annual Sales Completed Projects Largest Project
Safety*
Have you received any regulatory citations (e.g. federal or state OSHA) in the last three years? If so, provide explanation:
Provide your Workers’ Compensation Experience Modification Rates (EMR) for the last 5 years.
2021: 2022: 2023: 2024: 2025:
If EMR not applicable, provide explanation.
* Only applies to construction or demolition companies.
Page 3 of 4 rev. 3/11/2026 - ck
Disclosure of Contract Issues; Litigation; Criminal Investigations
In the last five years, list and discuss any alleged prior or ongoing contract failures (potential judgment/settlement in excess of $100,000), contract breaches (potential judgment/settlement in excess of $100,000), other significant civil litigation, and all criminal litigation or investigations, which involved your firm.
Failure to Complete
In the last five (5) years, disclose any projects that your firm was involved with that were not completed.
Page 4 of 4 rev. 3/11/2026 - ck
Firm References
Provide three (3) references. Note that references are to be from different projects; that is, only one reference per project is allowed. MSA staff members cannot be considered as an Offeror’s reference.
Project Name:
Company Name:
Name:
Title:
Phone Number:
Project Relationship:
Project Name:
Company Name:
Name:
Title:
Phone Number:
Project Relationship:
Project Name:
Company Name:
Name:
Title:
Phone Number:
Email Address:
Project Relationship:
Prepared By:
Name:
Title:
Signature:
Date:
| General Information |
| Diversity Programs |
| Primary Point of Contact (for this solicitation) |
| Secondary Point of Contact (for this solicitation) |
| Background Information |
| Past Performance |
| Failure to Complete |
| Firm References |
File details come from the government source that posted it. Updated .