Amendment_003_posted.pdf

(x)

140R6019R0002 x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

Billings MT 59107

R60

PO Box 36900 Regional Office Great Plains Region Bureau of Reclamation

08/29/20190003

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.

Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended,

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

07/19/2019

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

NORTH SIDE / SOUTH SIDE COLLECTION SYSTEM ACTUATOR REPLACEMENT

FRYINGPAN – ARKANSAS, COLORADO

See attachment for changes incorporated by this amendment:

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Gerri Voto-Braun

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

x x 1

Solicitation No. 140R6019R0002

Amendment No. 0003

Description of Changes:

1. In Part I – The Schedule, Section B – The Schedule, remove Continuation of Section B –

Supplies or Services and Prices in its entirety and substitute therefor the attached Revised Section

B.

2. In Part I – The Schedule, Section C – Specifications, remove Section 01 14 12

Work Restrictions in its entirety and substitute therefor the attached Revised Section 01 14 12.

3. In Part I – The Schedule, Section C – Specifications, remove 01 33 00 - Submittals in its entirety and substitute therefor the attached Revised Section 01 33 00.

4. In Part I – The Schedule, Section C – Specifications, remove Section 26 05 10 - Conductors and

Cables in its entirety and substitute therefor the attached Revised Section 26 05 10.

5. In Part I – The Schedule, Section C – Specifications, remove Section 26 05 20 - Grounding and

Bonding in its entirety and substitute therefor the attached Revised Section 26 05 20.

6. In Part I – The Schedule, Section C – Specifications, remove Section 26 05 33 - Raceways and

Boxes for Electrical Systems in its entirety and substitute therefor the attached Revised Section

26 05 33.

7. In Part I – The Schedule, Section C – Specifications, remove 26 21 13 - Single Throw Disconnect

Switch in its entirety and substitute therefor the attached Revised Section 26 21 13.

8. In Part I – The Schedule, Section C – Specifications, remove Section 26 70 10 - Miscellaneous

Electrical Equipment in its entirety and substitute therefor the attached Revised Section 26 70 10.

9. In Part I – The Schedule, Section C – Specifications, remove Section 41 22 32 - Radial Gate

Hoists in its entirety and substitute therefor the attached Revised Section 41 22 32.

For convenience, essential changes on the revised solicitation pages are indicated by a vertical line in the margin where lines or paragraphs changed from the previous version. However, all portions of the revised solicitation pages shall apply whether changes thereon have or have not been indicated.

Acknowledgement: See Block 11 above regarding how to acknowledge this amendment. The

Government must receive the acknowledgement at the place designated for receipt of bids (See Block

10 of the Standard Form 1442).

Receipt of Proposals: The hour and date for receipt of proposals is hereby extended to 12:00 PM

(Mountain Time Zone) on September 04, 2019.

Third Party: If you have given a copy of the solicitation to someone else, please forward this amendment accordingly.

A list of questions from prospective contractors and their respective answers are attached to this amendment and are provided for informational purposes only. Additional answers to questions received will be addressed in a forthcoming amendment. No more questions will be accepted after

4:30 PM on August 29, 2019.

North Side / South Side Amendment No. 0003 Collection System Actuator Replacement Fryingpan – Arkansas, Colorado Solicitation No. 140R6019R0002

Price Schedule Revised B - 1

CONTINUATION OF

SECTION B – SUPPLIES OR SERVICES AND PRICES

NORTH SIDE / SOUTH SIDE

COLLECTION SYSTEM ACTUATOR REPLACEMENT

FRYINGPAN – ARKANSAS, COLORADO

B.1 PRICE SCHEDULE

(a) Offers will be considered for award on the following Price Schedules, but no offer will be considered for award on only a part of the Price Schedules.

(b) Offers are subject to the terms and conditions of this solicitation.

(c) Quantities in Price Schedules, are estimated quantities for comparison of offers only.

Except as provided in the contract clause at FAR 52.211-18, Variation in Estimated Quantity, no claim shall be made against the Government for overruns or underruns. The contract clause at FAR 52.211-18, Variation in Estimated Quantity does not apply to lump sum items.

(d) Price Schedule A, include WBR 1452.232-81, Payment for Mobilization and Preparatory Work, needed separately for each site inspection, in CLIN’s 1 through 15.

(e) Price Schedule B, see the contract clause at WBR 1452.232-81, Payment for Mobilization and Preparatory Work, for CLIN 1.

(f) Definitions:

(1) CLIN – Contract Line Item Number.

PRICE SCHEDULE A

CLIN Section Supplies or Services Quantity and Unit

Unit Price

Amount

1 35 22 10 Carter Creek Site Inspection For the lump sum of $

2 35 22 10 North Fork Site Inspection For the lump sum of $

3 35 22 10 Mormon Creek Site Inspection

For the lump sum of $

4 35 22 10 North Cunningham Site Inspection

For the lump sum of $

Revised B - 2

PRICE SCHEDULE A

CLIN Section Supplies or Services Quantity and Unit

Unit Price

Amount

5 35 22 10 Middle Cunningham Site Inspection

For the lump sum of $

6 35 22 10 South Cunningham Site Inspection

For the lump sum of $

7 35 22 10 Ivanhoe Site Inspection For the lump sum of $

8 35 22 10 Granite Adit Site Inspection For the lump sum of $

9 35 22 10 Fryingpan Site Inspection For the lump sum of $

10 35 22 10 No Name Site Inspection For the lump sum of $

11 35 22 10 Midway Site Inspection For the lump sum of $

12 35 22 10 Hunter Site Inspection For the lump sum of $

13 35 22 10 Sawyer Site Inspection For the lump sum of $

14 35 22 10 Chapman Site Inspection For the lump sum of $

15 35 22 10 South Fork Site Inspection For the lump sum of $

TOTAL FOR PRICE SCHEDULE A $_________________

Revised B - 3

PRICE SCHEDULE B

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

1 WBR

1452.232-

Mobilization and Preparatory Work

For the lump sum of $

2 02 41 07 Removal and Disposal of Existing Site Features

15 ea $

3 26 05 10 Carter Creek Electrical Equipment

For the lump sum of $

4 26 05 10 Mormon Creek Electrical Equipment

For the lump sum of $

5 26 05 10 Middle Cunningham Electrical Equipment

For the lump sum of $

6 26 05 10 Ivanhoe Electrical Equipment

For the lump sum of $

7 26 05 10 Granite Adit Electrical Equipment

For the lump sum of $

8 26 05 10 Granite Creek Electrical Equipment

For the lump sum of $

9 26 05 10 Fryingpan Electrical Equipment

For the lump sum of $

10 26 05 10 No Name Electrical Equipment

For the lump sum of $

11 26 05 10 Midway Electrical Equipment

For the lump sum of $

12 26 05 10 Hunter Electrical Equipment For the lump sum of $ 13 26 05 10 Sawyer Electrical Equipment For the lump sum of $ 14 26 05 10 Chapman Electrical

Equipment For the lump sum of $

15 26 05 10 South Fork Electrical Equipment

For the lump sum of $

16 35 22 10 Carter Creek Slide Gate Actuators

For the lump sum of $

17 35 22 10 North Fork Slide Gate Actuators

For the lump sum of $

18 35 22 10 Mormon Creek Slide Gate Actuators

For the lump sum of $

19 35 22 10 North Cunningham Slide Gate Actuators

For the lump sum of $

20 35 22 10 Middle Cunningham Slide Gate Actuators

For the lump sum of $

21 35 22 10 South Cunningham Slide Gate Actuators

For the lump sum of $

Revised B - 4

PRICE SCHEDULE B

CLIN Section Supplies or Services Quantity and Unit

Unit Price Amount

22 35 22 10 Ivanhoe Slide Gate Actuators For the lump sum of $ 23 35 22 10 Granite Adit Sleeve Valve

Actuators For the lump sum of $

24 35 22 10 Granite Creek Slide Gate Actuators

For the lump sum of $

25 35 22 10 Fryingpan Slide Gate Actuators

For the lump sum of $

26 35 22 10 No Name Slide Gate Actuators

For the lump sum of $

27 35 22 10 Midway Slide Gate Actuators

For the lump sum of $

28 35 22 10 Hunter Slide Gate Actuators For the lump sum of $ 29 35 22 10 Sawyer Slide Gate Actuators For the lump sum of $ 30 35 22 10 Chapman Slide Gate

Actuators For the lump sum of $

31 35 22 10 South Fork Slide Gate Actuators

For the lump sum of $

32 35 23 50 Mormon Creek Radial Gate Seal Replacement

For the lump sum of $

33 35 23 50 Hunter Radial Gate Seal Replacement

For the lump sum of $

34 35 23 50 Midway Radial Gate Seal Replacement

For the lump sum of $

35 35 23 50 Carter Creek Radial Gate Seal Replacement

For the lump sum of $

36 35 23 50 No Name Radial Gate Seal Replacement

For the lump sum of $

37 35 23 50 Middle Cunningham Radial Gate Seal Replacement

For the lump sum of $

38 41 22 32 Carter Creek Radial Gate Hoist

For the lump sum of $

39 41 22 32 Mormon Creek Radial Gate Hoist

For the lump sum of $

40 41 22 32 Middle Cunningham Radial Gate Hoist

For the lump sum of $

41 41 22 32 No Name Radial Gate Hoist For the lump sum of $ 42 41 22 32 Midway Radial Gate Hoist For the lump sum of $ 43 41 22 32 Hunter Radial Gate Hoist For the lump sum of $

TOTAL FOR PRICE SCHEDULE B $_________________

Revised B - 5

TOTAL FOR PRICE SCHEDULES A and B $_________________

END OF SUPPLIES OR SERVICES AND PRICES

Revised B - 6

This page intentionally left blank.

Work Restrictions

Revised 01 14 12 - 1

SECTION 01 14 12

WORK RESTRICTIONS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in Price Schedules for other items of work.

1.02 WORK RESTRICTIONS

A. Allowable work hours are from 7:00 am to 7:00 pm daily or as approved by the COR.

B. Staging of equipment within close proximity at each diversion site will be allowed.

Contractors shall only use existing roads to access work sites or tunnels. All equipment shall be staged within 25 feet of the work site and no vegetation should be disturbed. No equipment shall be staged in recreation parking or trailhead areas without prior written USFS and Reclamation approval.

C. Fencing of staged equipment is not allowed.

D. Do not interfere with public access to the diversion sites.

E. Available window for the start of design-data-collection work begins approximately the second week of July and extends to November 23, 2019. The Government shall keep the road open to the site(s) – apart from excessive snowfall. Contractor shall be aware that these work locations are subject to extremely variable weather conditions throughout the year.

F. Available window for the start of installation work begins approximately in the second week of July and extends to October 31, and shall be approved by the COR. The Contractor shall be aware that these work locations are subject to extremely variable weather conditions throughout the year. Typically, construction is not feasible after November 1 due to adverse weather conditions that typically exist at many of the sites after that time of year.

G. Contractor shall stage equipment and personnel so that each site can be completed within the construction season it was started.

PART 2 PRODUCTS

Not Used

Work Restrictions

Revised 01 14 12 - 2

PART 3 EXECUTION

END OF SECTION

Submittals

Revised 01 33 00 - 1

SECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in Price Schedules for other items of work.

1.02 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-12 Decimal Inch Drawing Sheet Size and

Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-14 United States National CAD Standards, Version 6

1.03 DEFINITIONS

A. Days: Calendar days.

B. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

C. Submittals: Considered “shop drawings” within the terms of the clause at FAR 52.236- 21, Specifications and Drawings for Construction.

1.04 SUBMITTAL REQUIREMENTS

A. In case of conflict between requirements of this section and requirements included elsewhere in these specifications, requirements included in this section take precedence.

B. General:

1. Prepare in English.

2. Label with contract number and title and RSN.

3. Measurement Units: US Customary Units.

C. Drawings:

1. Minimum Identification in Title Block:

Revised 01 33 00 - 2

a. Contract number and title.

b. Contractor’s or supplier’s title and drawing number.

c. Date.

2. Reserve 3 by 3-inch space next to title block for review stamps.

3. Print Size: D size (22 inches by 34 inches).

4. Draw to scale using computer drafting.

a. In accordance with NIBS NCS.

b. Electronic file format: Compatible with AUTOCAD, Version 2018 or later.

c. Compile using “eTransmit” utility in AUTOCAD.

d. Government will provide electronic AutoCAD format template.

e. Title block and sheet format:

1) As shown on standard drawing 40-D-7102.

2) Government will supply template.

3) Government will supply specific title block information to be used.

f. Show as-built changes, including revision dates, made during installation.

Indicate changes by clouding.

D. Product Data:

1. Mark manufacturer's data for commercial products or equipment, such as catalog cut sheets.

a. Identify manufacturer's name, type, model, size, and characteristics.

b. Illustrate that product or equipment meets requirements of specifications.

c. Mark items to be furnished in a manner that will photocopy (no highlighter).

d. Strike through items that do not apply.

E. Certifications:

1. Certifications by a registered professional: Signed and sealed by registered professional.

2. Manufacturer’s certifications: Signed by authorized representative of manufacturer.

1.05 SUBMITTALS PROCEDURES

A. Submit only checked submittals. Submittals without evidence of Contractor's approval will be returned for resubmission.

Revised 01 33 00 - 3

B. Submit complete sets of required materials for each RSN as specified in “Submittals Required” column in Table 01 33 00A - List of Submittals. A complete set includes all listed items for RSNs with multiple parts.

C. Submit sets specified in “Sets to be sent:” columns in Table 01 33 00A - List of Submittals.

1. Electronic submittals:

a. In Portable Document Format (PDF).

1) Optical Character Recognition (OCR).

2) 508 compliant.

3) RSNs having more than one requirement shall be bookmarked.

4) RSNs with requirements for files other than PDF (e.g. .XER, .PLF, .DWGs, etc.) shall be combined using WINZip.

b. Include RSN transmittal letter.

c. Personally Identifiable Information (PII) shall be encrypted using WINZip or Adobe Acrobat before transmitting electronically.

2. Submit electronic submittals via e-mail, CD/DVD, or thumb drive based on size:

a. The Government can receive e-mails up to 25 MB. However, e-mails over 10 MB should be considered extra-large. E-mailing of electronic submittals exceeding 10 MB should only occur after transmittal of extra-large size e-mail has been verified.

b. Address e-mail of electronic submittals less than extra-large size to:

1) sha-GPR-CONSTSVCS@usbr.gov

c. Electronic submittals that are too large to e-mail shall be submitted on CD/DVD or thumb drive.

d. Submittals received after 5:00 p.m. Mountain Time, shall be documented as received the next business day.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

4. Number of sets for each RSN.

5. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

mailto:sha-GPR-CONSTSVCS@usbr.gov

Revised 01 33 00 - 4

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 14 days after receiving comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

F. Submit each RSN under a separate transmittal letter. Multiple RSNs submitted under a single letter will be returned for resubmittal.

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 28 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return mailing postmark date.

B. Time in Excess of Specified:

1. CO may extend contract completion date to allow additional time for completing work affected by excess review time.

a. Time extension will be to extent that excess review time caused delay to contract completion date.

b. Time extension will not exceed time used in excess of specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of two or more separate submittals or resubmittals will be counted only once in extending contract completion date.

2. No time extension will be allowed if Contractor fails to make complete action submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to extent that:

a. Approval was required under contract,

b. Requests for acceptance were properly and timely submitted and were accepted.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR

52.242-14, Suspension of Work; however, no such delay shall be deemed to be a “suspension order” as the term is used in that clause.

C. Submittal response:

1. Response letter will indicate whether submittal is approved, not approved, acceptable, not acceptable, or acknowledged receipt.

Revised 01 33 00 - 5

a. Revise and resubmit submittals identified as not acceptable.

b. Do not change designs without approval of CO after drawings, documentation, and technical data have been accepted.

1.07 TRANSMITTAL

A. Addresses for codes receiving paper copy submittals listed in Table 01 33 00A - List of Submittals:

1. CO: Bureau of Reclamation, Attention GP-5000, PO Box 36900, Billings MT

59107-6900. Physical address: 2021 4th Avenue North, Billings MT 59101.

2. COR: Bureau of Reclamation, Attention: GP-2600, PO Box 36900, Billings, MT

59107-6900. Physical address: 2021 4th Avenue North, Billings MT 59101.

B. E-mail address for electronic submittals listed in Table 01 33 00A - List of Submittals:

sha-GPR-CONSTSVCS@usbr.gov.

1. Submit electronic submittals that are too large for e-mail along with paper copy.

C. Submittals required by specifications, but not listed in Table 01 33 00A - List of Submittals:

1. Submit in accordance with this section.

2. Submit to COR unless otherwise specified.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Revised 01 33 00 - 6

Table 01 33 00A. - List of Submittals ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

1 Insurance-Work on a Government Installation 1452.228-70

1) Written certification that the required insurance has been obtained

2) Current certification of insurance for each subcontractor

Before commencing onsite work

CO 1

electronic

2 Liability Insurance 1452.228-70

Acceptable Certificate of Liability Insurance

Prior to commencement of work under the contract

CO 1

electronic

3 Performance and Payment Bonds - Construction 52.228-15

Performance and Payment Bonds

Within 10 calendar days after award

CO 1

electronic

4 Equal Opportunity 52.222-26

Information required by Executive Order

112246 (SF-100)

Within 30 days following award

CO 1

electronic

5 Reporting Executive Compensation and First Tier Subcontract Awards 52.204-10

Certification that executive compensation and subcontract awards were reported

Within 10 days of each report being submitted

CO 1

electronic

6 Release of Claims 1452.204-70

Release of Claims (DI-137) against the Government

After completion of the work and prior to final payment

CO 1

electronic

7 Implementation of Homeland Security Presidential Directive

(HSPD-12) GP-3

GP-PIV-1 and OF- 306 for each contractor and subcontractor that will be working at the Government Facility

At least 30 days prior to an employee's arrival on-site

CO 1

electronic

8 Labor Standards Data 52.222-11

1) List of subcontractors

2) Statement and acknowledgement Form (SF-1413) for each subcontract

Within 14 days after award of contract

COR 1

9 Payrolls and Basic Records 52.222-08

Copies of all payrolls Weekly for each week of contract performance

CO 1

electronic

Revised 01 33 00 - 7

Table 01 33 00A. - List of Submittals ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

10 Site Security

GP-7

List of contractor and subcontractor employees

At least 10 days prior to arriving at worksite

COR 0 1

electronic

11 Site Security

GP-7

List of vehicles and equipment to be brought onsite

At least 10 days prior to arriving at worksite

COR 0 1

electronic

12 H.3 Schedule of Values

Schedule of Values Within 5 days of pre-construction meeting

COR 0 1

01 14 10-1 Use of Site Land Use and

Landscape Rehabilitation Plan

Submitted and accepted at least 28 days before mobilization

01 14 13-1 Site Access Site Access Plan Submitted and accepted at least 28 days before mobilization

01 14 30-1 Interruption of Service

Interruption of Service Requests

Submitted and accepted at least 28 days before mobilization

01 32 20-1 Construction Program

Baseline Schedule

Submitted and days before mobilization (required for design-data-collection)

01 32 20-2 Construction Program

Updated Schedule

Monthly COR 0 1

01 35 10-1 Safety Data Sheets Complete LHM and

SDS

At least 28 days before jobsite delivery of hazardous material

01 35 10-2 Safety Data Sheets Updated LHM and

SDS

At least 28 days before jobsite delivery of hazardous material not previously listed

01 35 20-1 Safety and Health Safety Program Submitted and days before mobilization (required for design-data-collection)

Revised 01 33 00 - 8

Table 01 33 00A. - List of Submittals ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

01 35 20-2 Safety and Health Monthly Accident Summary Report

01 35 20-3 Safety and Health Respirator User

Documentation Submitted and accepted at least 28 days before mobilization

01 35 20-4 Safety and Health Exposure Assessment Form

Submitted and accepted at least 28 days before mobilization

01 35 20-5 Safety and Health Other Training Certificates

Submitted and accepted at least 28 days before mobilization (required for design-data-collection)

01 35 30-1 Contractor’s Onsite Safety Personnel

Resume Submitted and accepted at least 28 days before mobilization (required for design-data-collection)

COR 0 1

electronic encrypted

01 35 30-2 Contractor’s Onsite Safety Personnel

Safety Inspection Reports

01 46 00-1 Quality Procedures Contractor Quality

Control Program Submitted and accepted at least 28 days before mobilization

01 46 00-2 Quality Procedures Contractors Daily Reports

Weekly COR 0 1

01 46 00-3 Quality Procedures Quality Control

Supervisor Resume Submitted and accepted at least 28 days before mobilization

COR 0 1

electronic encrypted

01 46 00-4 Quality Procedures Contractors Quality Testing Plan

Submitted and accepted at least 28 days before mobilization

01 46 00-5 Quality Procedures Summary Monthly Test Results

Revised 01 33 00 - 9

Table 01 33 00A. - List of Submittals ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

01 57 30-1 Water Pollution Control

Water Management Plan

Submitted and accepted at least 28 days before mobilization

01 74 00-1 Cleaning and Waste Management

Waste Production and Disposal Plan

Submitted and accepted at least 28 days before mobilization

01 74 00-2 Cleaning and Waste Management

Waste Production and Disposal Records

Within 7 days of waste disposal

COR 1

electronic

01 78 30-1 Project Record Documents

Final As-built Drawings

Within 14 days of completion of work

COR 0 1

electronic

02 41 07-1 Removal and Disposal of Existing Features

Removal and Disposal of Existing Features Plan

Submitted and accepted at least 28 days before mobilization

02 80 10-1 General Requirements for Hazardous Materials

Worker Protection Plan

Submitted and accepted at least 28 days before mobilization

02 83 35-1 Removal and Disposal of Equipment with Coatings Containing Regulated Metals

Qualifications Submitted and accepted at least 28 days before mobilization

02 83 35-2 Removal and

Equipment with Coatings Containing Regulated Metals

Removed Coatings Debris Abatement Plan

Submitted and accepted at least 28 days before mobilization

02 83 35-3 Removal and

Equipment with Coatings Containing Regulated Metals

Waste Characterization Report

Within 7 days after completion of Report

02 83 35-4 Removal and

Equipment with Coatings Containing Regulated Metals

Waste Characterization, Handling, and Disposal Plan

Submitted and accepted at least 28 days before mobilization

02 83 35-5 Removal and

Equipment with Coatings Containing Regulated Metals

Recycling Report Within 7 days after completion of Report

Revised 01 33 00 - 10

Table 01 33 00A. - List of Submittals ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

02 83 35-6 Removal and Disposal of Equipment with Coatings Containing Regulated Metals

Manifests, Bills of Lading, Disposal Certificates

Within 7 days after receipt

03 62 20-1 Nonshrink Grout for Equipment and Metalwork

Packaged Non- Shrink Grout Data

Submitted and accepted at least 28 days before starting onsite work

26 05 10-1 Conductors and Cables

Current Inventory Submitted and accepted at least 28 days before starting onsite work

26 05 10-2 Conductors and

Calculations Within 7 days of acceptance of RSN 26 05 10-1 for each installation

26 05 10-3 Conductors and

Approval Data Within 7 days of acceptance of RSN 26 05 10-2 for each installation

26 05 10-4 Conductors and

Test Reports Within 14 days of completion of each installation

26 05 20-1 Grounding and

Bonding Approval Data Submitted and accepted at least 28 days before starting onsite work

26 05 20-2 Grounding and Bonding

Test Reports Within 14 days of completion of each installation

26 05 33-1 Raceways and Boxes for Electrical System Product Data Submitted and accepted at least 28 days before starting onsite work

26 21 13-1 Single Throw Disconnect Switch

Current Inventory Submitted and accepted at least 28 days before starting onsite work

26 21 13-2 Single Throw Disconnect Switch

Calculations Within 7 days of acceptance of RSN 26 21 13-1 for each installation

Revised 01 33 00 - 11

Table 01 33 00A. - List of Submittals ** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative.

RSN

Clause or

Section Title

Submittals required Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

26 21 13-3 Single Throw Disconnect Switch

Approval Data Within 7 days of acceptance of RSN 26 21 13-2 for each installation

35 22 10-1 Slide Gate Actuators, and Stems

Field Surveys Submitted and accepted at least 28 days before starting onsite work

35 22 10-2 Slide Gate Actuators, Design Calculations Submitted and accepted at least 28 days before starting onsite work

35 22 10-3 Slide Gate Actuators, Product Data Submitted and accepted at least 28 days before starting onsite work

35 22 10-4 Slide Gate Actuators, Shop Testing Results Within 14 days of completion of each installation

35 22 10-5 Slide Gate Actuators, Field Test Results Within 14 days of completion of each installation

35 22 10-6 Slide Gate Actuators, Manuals Within 14 days of completion of each installation

COR 0 2 paper +

35 23 50-1 Radial Gate Seals Product Data Submitted and days before starting onsite work

35 23 50-2 Radial Gate Seals Field Quality Testing Results

Within 14 days of completion of each installation

41 22 32-1 Radial Gate Hoists Approval Data Submitted and days before starting onsite work

41 22 32-2 Radial Gate Hoists Final Data Within 14 days of completion of each installation

Revised 01 33 00 - 12

Fryingpan - Arkansas – Colorado Solicitation No. 140R6019R0002

Conductors and Cables

Revised 26 05 10 - 1

SECTION 26 05 10

CONDUCTORS AND CABLES

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Carter Creek Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Carter Electrical Equipment.

B. Mormon Creek Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Mormon Creek Electrical Equipment.

C. Middle Cunningham Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Middle Cunningham Electrical Equipment.

D. Ivanhoe Electrical Equipment:

1. Payment: Lump sum prices offered in Price Schedule B.

a. Includes cost of furnishing materials and performing work required for installing and testing four new enclosed local disconnects.

E. Granite Adit Electrical Equipment:

1. Payment: Lump sum prices offered in Price Schedule B.

a. Includes cost of furnishing materials and performing work required for installing and testing one new enclosed local disconnects.

F. Granite Creek Electrical Equipment:

1. Payment: Lump sum prices offered in Price Schedule B.

a. Includes cost of furnishing materials for two new enclosed local disconnects.

G. Fryingpan Electrical Equipment:

1. Payment: Lump sum prices offered in Price Schedule B.

Revised 26 05 10 - 2

a. Includes cost of furnishing materials and performing work required for installing and testing five new enclosed local disconnects.

H. No Name Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for No Name Electrical Equipment.

I. Midway Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Midway Electrical Equipment.

J. Hunter Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Hunter Electrical Equipment.

K. Sawyer Electrical Equipment:

1. Payment: Lump sum prices offered in Price Schedule B.

a. Includes cost of furnishing materials and performing work required for installing and testing two new enclosed local disconnects.

L. Chapman Electrical Equipment:

1. Payment: Lump sum prices offered in Price Schedule B.

a. Includes cost of furnishing materials and performing work required for installing and testing five new enclosed local disconnects.

M. South Fork Electrical Equipment:

1. Payment: Lump sum prices offered in Price Schedule B.

a. Includes cost of furnishing materials and performing work required for installing and testing five new enclosed local disconnects.

1.02 REFERENCE STANDARDS

A. ASTM International (ASTM)

1. ASTM B 8-11(2017) Concentric-Lay-Stranded Copper

Conductors, Hard, Medium-Hard, or Soft

B. Institute of Electrical and Electronics Engineers (IEEE)

1. IEEE C2-2017 National Electrical Safety Code (NESC)

Revised 26 05 10 - 3

C. National Fire Protection Association (NFPA)

1. NFPA 70-2017 National Electrical Code (NEC)

1.03 DESIGN REQUIREMENTS

A. Determine conductor rating based on fused disconnect, gate actuator motor characteristics, and the requirements of NFPA 70.

B. Conductors in good condition and in compliance with NFPA 70 shall be reused.

1.04 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals and Section 01 33 26 - Electrical Drawings and Data.

B. RSN 26 05 10-1, Current Inventory:

1. Inventory of existing wire sizes based on contractor field verification.

C. RSN 26 05 10-2, Calculations:

1. Calculations and recommended conductor sizing.

D. RSN 26 05 10-3, Approval Data:

1. Manufacturer’s data.

E. RSN 26 05 10-4, Test Reports.

1.05 DEFINITIONS

A. Cable: Cable, cables, wire, or wires of one or more insulated conductors.

B. Power Cable: For power loads including receptacle outlets; motors; alternating- and direct-current distribution circuits; heating, ventilating, and air-conditioning and lighting circuits; and cable that is used for controlling heating, ventilating, air-conditioning, and lighting equipment.

C. Control Cable: For control, metering, indication, annunciation, and relaying circuits; and circuits not identified as power circuits.

D. Outdoor Cable: Cable with any portion located outdoors.

1.06 PROJECT CONDITIONS

A. Locations of existing cables indicated on drawings are approximate.

Revised 26 05 10 - 4

PART 2 PRODUCTS

2.01 CABLE

A. Manufactured no more than 24 months prior to Notice to Proceed.

B. Round, except for 2-conductor cable with parallel conductors.

C. Copper conductor: ASTM B 8, class B or C.

D. AWG or kcmil designation.

E. Coverings or insulation: Suitable for installation in vertical position without injury to covering or deformation of insulation when supported in accordance with NFPA 70, article 300-19.

F. Stranded conductors.

G. Cable Color Coding:

1. Three-phase Power Cable:

a. Phase A - Brown.

b. Phase B - Orange.

c. Phase C - Yellow.

2. Control and Instrumentation Cable:

a. In accordance with NEMA WC 57.

b. Colored insulation or jacket compound. Do not apply color coatings to insulation or jacket surface.

H. Conductor Sizes:

1. Determine size of power circuits in accordance with NFPA 70 based on

60 degrees Celsius conductor temperature for sizes No. 1 AWG and smaller and 75 degrees Celsius conductor temperature for sizes No. 1/0 AWG and larger.

2. Determine all other conductor sizes in accordance with: NFPA 70 or use minimum conductor size No. 12 AWG. In event of conflict with NFPA 70 and minimum conductor size, use larger conductor.

2.02 OUTDOOR POWER CABLE

A. Single-conductor or multi-conductor, non-shielded type.

B. UL listed and labeled "UL-TYPE TC" on outer surface per NFPA 70.

C. Suitable for direct burial.

Revised 26 05 10 - 5

2.03 MULTICONDUCTOR CONTROL CABLE

A. Suitable for installation in cable trays and conduit, for direct burial, and for general use.

B. Insulation on Individual Conductors:

1. Type XHHW insulation in accordance with NFPA 70.

2. For No. 12 AWG: 30 mils [0.76 millimeter] thick.

C. Binder tape or jacket covering.

D. Shielding: Conform to NEMA WC 57.

E. Overall flame-retardant covering (jacket) of thermoplastic or neoprene: For cable with No. 12 AWG individual conductors, jacket shall be at least 60 mils thick, except 12-conductor cable shall be at least 80 mils thick.

2.04 INSTRUMENTATION CABLE

A. Twisted pair for transducer output circuits and twisted triad for RTD circuits.

B. Suitable for installation in cable trays and conduit, for direct burial, and for general use.

C. Conductor Size: No. 18 AWG.

D. Conductor Insulation: 600 volts and suitable for operation at an ambient temperature of 105 degrees Celsius.

E. Shielding: Copper or aluminum tape which completely covers pair or triad assembly.

Provide shielding with a tinned, stranded copper drain wire.

F. Jacket:

1. Flame-retardant.

2. 600 volts.

2.05 ACCESSORIES

A. Conductor Markers:

1. White.

2. Self-laminating-vinyl type or heat-shrink type.

3. Marked with conductor designation.

4. Computer generated lettering.

B. Cable Tags:

1. Suitable for outdoor use.

Revised 26 05 10 - 6

2. Shape: Rectangular.

3. Color: White.

C. Terminal Connectors:

1. Heavy-duty, pre-insulated, pressure-crimp-type with ring tongues.

2. Tin-plated copper.

3. Serrated inner barrel.

4. 600-volt-rated nylon insulation.

5. Insulation support sleeve for vibration resistance.

6. UL listed.

7. Compatible with conductor size and type of cable for which it is used.

PART 3 EXECUTION

3.01 INSTALLATION

A. Comply with NFPA 70 and IEEE C2.

B. Install cable without exceeding allowable pulling tensions and sidewall pressures recommended by cable manufacturer.

C. Do not splice multiconductor control cables.

D. Buried cables within fenced yards.

1. Install in accordance with standard drawing 40-D-5370.

E. Buried cables not within fenced yard areas.

1. Depth: 24 inches, minimum.

2. Install by trenching method. Do not plow cables in.

3. Surround cables by 2 inches of sand, minimum.

4. Install polyethylene warning tape 18 inches above cable.

F. Conduit Installation:

1. Do not pull cable into conduits until conduit runs have been cleaned and are free from obstructions and sharp corners.

2. Draw a clean, dry, tight-fitting rag through conduit immediately before installing cable.

3. Install cable to prevent cuts or abrasions in insulation or protective covering, or kinks in cable.

Revised 26 05 10 - 7

4. Block cable opening in sleeves under equipment or passing through blockouts, with silicone-foam, fire-retardant type material in accordance with NFPA 70.

5. Lubricant:

a. Use only as aid to pulling.

b. Soapstone or other suitable material not injurious to cable sheath.

G. Grounding:

1. Provide one nonactive conductor grounded at both ends in each non-twisted pair shielded control cable. Ground shielding of each shielded control cable on both ends directly to equipment ground bus by method indicated on standard drawing 40-D-4335, Figure 8.

2. Ground shielding of twisted pair shielded cables only to source equipment ground bus using pressure crimp type connectors with ring tongues on drain wire.

3. Ground spare conductors by wire jumpers from equipment terminal block points to equipment ground bus.

H. Marking:

1. Mark conductors, whether single-conductor cables or individual conductors of multiconductor control, instrumentation, and power cables at each end with conductor designation on first line followed by cable designation on second line as indicated on approved wiring diagrams.

2. Mark spare conductors of multiconductor cables with cable designation and word

"SPARE".

3. Numerically sequence markings (e.g., 2CSA-CSB-SPARE1).

I. Spare Conductors:

1. Provide spare conductors in accordance with Government-furnished information marked on Contractor's approval wiring diagram drawings.

J. Tagging:

1. Tag multiconductor cables at each end.

2. Attach tags to cable by self-locking cable ties.

3. Mark tags with cable designation.

a. Cable designations: As indicated on approved wiring diagrams.

b. Provide computer-generated lettering.

K. Terminate control and instrumentation wire with terminal connectors.

L. Wiring Methods:

Revised 26 05 10 - 8

1. Form conductors into neat packs, or lace conductors, or tie conductors with self-locking cable ties at termination point of multiconductor cable.

2. Do not combine alternating- and direct-current circuits, or current and potential transformer circuits in same multiconductor cable.

3. Support cable installed in a vertical or inclined plane by cable grips (including hooks). Installed cable with slack spans between supports.

4. Clamp cable entering equipment with commercial type cable clamps.

5. Leave sufficient length cable ends to make connections conveniently to equipment, fixtures, and devices.

6. Retain spare single conductors at each end of a multiconductor cable in a length equal to longest single conductor of multiconductor cable.

7. Run both positive and negative leads of a circuit in same cable.

3.02 CONTRACTOR FIELD QUALITY TESTING

A. Perform testing after installation, but before connection to equipment.

B. Test cables in large groups to minimize number of testing sessions.

C. Notify COR, in writing, of date, time, and cables to be tested at least 5 working days before testing.

D. Perform following tests:

1. Insulation resistance tests for power, control, and instrumentation cables;

a. Measure insulation resistance between each conductor and station ground with all other conductors in same cable or conduit grounded.

b. Test voltage: 1,000 volts direct-current, minimum.

c. Minimum acceptable insulation resistance: R in MΩ = (rated voltage in kV + 1) x 1000/length in ft.

d. Record following test data on test report for each conductor tested:

1) Date of test.

2) Name or names of Contractor's personnel who performed test.

3) Name of Government inspector who witnessed test.

4) Conductor identification.

5) Megohms between conductor and ground.

6) Total length of conductor.

Grounding and Bonding

Revised 26 05 20 - 1

SECTION 26 05 20

GROUNDING AND BONDING

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Carter Creek Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Carter Electrical Equipment.

B. Mormon Creek Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Mormon Creek Electrical Equipment.

C. Middle Cunningham Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Middle Cunningham Electrical Equipment.

D. Ivanhoe Grounding and Bonding for Electrical Systems:

1. Cost:

a. Include cost in prices offered in Price Schedule B for Ivanhoe Electrical Equipment.

E. Granite Adit Grounding and Bonding for Electrical Systems:

1. Cost:

a. Include cost in prices offered in Price Schedule B for Granite Adit Electrical Equipment.

F. Granite Creek Grounding and Bonding for Electrical Systems:

1. Cost:

a. Include cost in prices offered in Price Schedule B for Granite Creek Electrical Equipment.

G. Fryingpan Grounding and Bonding for Electrical Systems:

1. Cost:

Revised 26 05 20 - 2

a. Include cost in prices offered in Price Schedule B for Fryingpan Electrical Equipment.

H. No Name Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for No Name Electrical Equipment.

I. Midway Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Midway Electrical Equipment.

J. Hunter Single Throw Disconnect Switch.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Hunter Electrical Equipment

K. Sawyer Grounding and Bonding for Electrical Systems:

1. Cost:

a. Include cost in prices offered in Price Schedule B for Sawyer Electrical Equipment.

L. Chapman Grounding and Bonding for Electrical Systems:

1. Cost:

a. Include cost in prices offered in Price Schedule B for Chapman Electrical Equipment.

M. South Fork Grounding and Bonding for Electrical Systems:

1. Cost:

a. Include cost in prices offered in Price Schedule B for South Fork Electrical Equipment.

1.02 REFERENCE STANDARDS

A. ASTM International (ASTM)

1. ASTM B 3-13(2018) Soft or Annealed Copper Wire

2. ASTM B 8-11(2017) Concentric-Lay-Stranded Copper

Conductors, Hard, Medium-Hard, or Soft

Revised 26 05 20 - 3

3. ASTM B 228-11a(2016) Concentric-Lay-Stranded Copper-Clad Steel Conductors

B. Institute of Electrical and Electronic Engineers (IEEE)

1. IEEE 837-2014 Qualifying Permanent Connections Used in

Substation Grounding

2. IEEE C2-2017 National Electrical Safety Code (NESC)

C. National Fire Protection Association (NFPA)

1. NFPA 70-2017 National Electric Code (NEC)

1.03 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 – Submittals and 01 33 26 – Electrical Drawings and Data.

B. RSN 26 05 20-1, As-built Drawings:

1. Specifications drawings indicating “as-built” changes made to grounding systems.

1.04 PROJECT CONDITIONS

A. Locations of existing ground conductors indicated on drawings are approximate.

PART 2 PRODUCTS

2.01 MATERIALS

A. Ground Cable:

1. Annealed Bare-copper Cable:

a. ASTM B 8, class B.

b. Solid wires used in forming the copper cable: ASTM B 3.

2. Copper-clad Steel Cable: ASTM B 228.

3. Concentric stranded.

4. Sizes:

a. As indicated on drawings.

b. Where not shown, minimum sizes:

1) Ground risers and electrode conductors: 4/0 AWG.

2) Equipment grounding conductors:

a) Major equipment: Equal to size to electrode conductors.

Revised 26 05 20 - 4

b) Minor equipment: No. 4 AWG

3) Equipment ground ring bus: Equal in size to largest riser.

4) Electrode interconnecting conductors: Equal in size to electrode conductors.

2.02 ACCESSORIES

A. Cable Connectors:

1. Welded, bolted solderless or compression type.

2. Current-carrying capacity: Equal to cable with which they are used.

3. Connectors for ground cables, including fittings, lugs, bolts, nuts, and washers:

Copper alloy containing not more than 4 percent zinc.

4. Bolted solderless or compression type connectors: IEEE 837.

5. Ground connectors that will be direct buried or embedded in concrete: Listed for direct burial use in accordance with the requirements of UL 467.

2.03 WELDING PROCESS

A. Use Cadweld, Thermoweld, or equivalent exothermic process.

B. Molds and Weld Metal:

1. Use fresh stock from same manufacturer.

2. Weld metal and starting material: No significant quantities of hazardous ingredients.

PART 3 EXECUTION

3.01 INSTALLATION

A. Install in accordance with NFPA 70, IEEE C2, and this Section.

B. Connect equipment, metal conduit, steel structures, metal pull box covers, exposed metal surfaces, and other miscellaneous metalwork to grounding system as indicated on standard drawings 40-D-4334, 40-D-4335, 40-D-4753; and as shown on specification drawings.

C. Ground equipment and miscellaneous metalwork that is required to be grounded, but is not indicated on drawings to grounding system.

D. Connections:

Revised 26 05 20 - 5

1. Make all ground connections between equipment and miscellaneous metalwork, and ground plates of grounding system whether or not such grounding connections are indicated on drawings.

2. Number of grounding connections for equipment may be one, two, or more in some cases.

3. Remove paint, enamel, scale, oil, grease, or other foreign nonconductive material from point of contact on metal surfaces before making ground connections.

4. Repair damaged or removed paint or galvanizing material on metal finishes.

5. Make ground connections that will be direct buried or embedded in concrete:

a. Exothermic process.

b. In accordance with manufacturer's instructions.

Revised 26 05 20 - 6

Fryingpan - Arkansas – Colorado Solicitation No.

Raceways and Boxes for Electrical Systems

Revised 26 05 33 - 1

SECTION 26 05 33

RACEWAYS AND BOXES FOR ELECTRICAL SYSTEMS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Carter Creek Raceways and Boxes for Electrical Systems .

1. Cost:

a. Include cost in prices offered in Price Schedule B for Carter Creek Electrical Equipment.

B. Mormon Creek Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Mormon Creek Electrical Equipment.

C. Middle Cunningham Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Middle Cunningham Electrical Equipment.

A. Ivanhoe Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Ivanhoe Electrical Equipment.

B. Granite Adit Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Granite Adit Electrical Equipment.

C. Granite Creek Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Granite Creek Electrical Equipment.

D. Fryingpan Raceways and Boxes for Electrical Systems.

Revised 26 05 33 - 2

a. Include cost in prices offered in Price Schedule B for Fryingpan Electrical Equipment.

E. No Name Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for No Name Electrical Equipment.

F. Midway Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Midway Electrical Equipment.

G. Hunter Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Hunter Electrical Equipment.

H. Sawyer Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Sawyer Electrical Equipment.

I. Chapman Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for Chapman Electrical Equipment.

J. South Fork Raceways and Boxes for Electrical Systems.

1. Cost:

a. Include cost in prices offered in Price Schedule B for South Fork Electrical Equipment.

1.02…