Sol_140R4022R0007_Amd_0004.pdf

(x)

140R4022R0007 x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Albuquerque NM 87102

R4Q

555 Broadway Blvd NE, Suite 100 Albuquerque Area Office Upper Colorado Region Bureau of Reclamation

Salt Lake City UT 84138

R40

125 South State Street, Room 8100 Regional Office Upper Colorado Region Bureau of Reclamation

06/28/20220004

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

06/28/2022

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

San Acacia Diversion Dam and Isleta Diversion Dam Improvements Design-Build

Amendment 4

Last day for Questions is 7/21/2022 at 5:00 PM Mountain Time

Questions and Answers - see below.

Period of Performance: 10/01/2022 to 09/30/2026

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Mary B. Maestas

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

Amendment 4

140R4022R0007 SADD IDD Improvements Design-Build

Last day for questions is Thursday 7/21/2022 at 5:00 PM

Mountain Time.

Questions and Answers

Question 1: In Amendment 1, the government indicates that proposers can provide previously completed PPQ evaluations for submitted projects. Can those be provided with the proposer’s response, or do we still need to ask the Owner to send the previously completed evaluation directly to the government on our behalf?

Answer 1: You may provide the PPQ as long as it is submitted by the deadline, and it must have current contact information of the official who completed the PPQ form in order for it to be considered acceptable. The government must be able to verify the information presented in the

PPQ.

Question 2: Request for time extension for Request for Qualification

Answer 2: The government will not be extending the due date for Phase One at this time. Due date for Phase One remains 7/25/2022 at 5:00 PM Mountain Time.

Question 3: Can the milestone schedule required in the Phase I proposal be provided in P6 instead of Microsoft Project?

Answer 3: Please provide milestone schedule in a pdf format.