140R2022B0005_Amend_0005_0005.pdf

(x) 140R2022B0005 x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Sacramento CA 95825-1898 2800 Cottage Way, Room E-1815

R20

Division of Acquisition Services Regional Office Mid-Pacific Region Bureau of Reclamation

01/18/20230005

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

11/22/2022

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Rosana Yousefgoarji

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The Solicitation cited in block 9A above, Friant Dam Drum Gate Corrosion Project is hereby amended.

Purpose: The purpose of this amendment is to incorporate the attached revised Sections A & F

The date and time for receipt of offers is hereby unchanged and remains February 10, 2023 at 1300 hours Pacific Standard Time.

The Offeror must acknowledge this amendment by submitting a signed copy of this SF30 along with their proposal.

02/10/2023

Amendment 0005

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED

140R2022B0005

NAME OF OFFEROR OR CONTRACTOR

ITEM NO.

(A)

00010

SUPPLIES/SERVICES

(B)

Delivery: 670 Days After Notice to Proceed

Friant Dam Drum Gate Corrosion Project

Pricing Schedule CLIN 1-19

See following continuation page(s)

Product/Service Code: ZlKA

Product/Service Description: MAINTENANCE OF DAMS

QUANTITY UNIT

(C) (D)

1 AU

UNIT PRICE

(E)

PAGE

OF

AMOUNT

(F)

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR f48 CFRl 53.110

Amendment 0005

Solicitation No. 140R2022B0005 Amendment 00005 Friant Dam Drum Gate Corrosion Project Central California Area Office – California

F-1

SECTION F - DELIVERIES OR PERFORMANCE

Clause Title Date

52.211-13 Time Extensions SEP 2000 52.236-15 Schedules for Construction Contracts APR 1984

52.242-14 Suspension of Work APR 1984

FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND APR 1984

COMPLETION OF WORK

The Contractor shall be required to

(a) commence work under this contract within 7 calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 670 calendar days after the date the Contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises.

FAR 52.211-12 LIQUIDATED DAMAGES – CONSTRUCTION SEP 2000

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,500 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.