B08_Section_C-M_Terms_and_Conditions_9-12-2018.docx

Solicitation 140P8318Q0123 – Attachment 1, READ ME FIRST Replace Windows in Quad-Plex Housing Unit 5 A,B,C,D - BIHO

SECTION C – DESCRIPTIONS/SPECIFICATIONS/STATEMENT OF WORK

STATEMENT OF WORK is incorporated into this solicitation as Attachment no. 5, as referenced in Section J herein Project work consists of replacing twenty-two double-hung metal frame windows in the Five (5) Building at the Big Hole National Battlefield. This building contains the Maintenance office/shop and three (3) efficiency apartments used for numerous park guests including: Volunteers, Natural Resource; inventory and monitoring crews, and Interpretative program presenters.

Project Description Contractor will remove the old windows, enlarge the existing window openings and replace with high efficiency wood and vinyl-clad, double-pane, high-performance gas-filled windows with low-emissivity coatings to reduce heat loss. Each window would be thirteen to twenty-four square feet in size and meet National Fire Protection Association egress standards for windows in residential buildings. This project includes replacing any damaged siding and all trim and paint associated with the window replacement. Exact window measurements will be determined during pre-construction process.

Do to the remoteness of the battlefield a contractor may have to travel a minimum of 240 miles round trip.

The Contractor is to provide all labor, equipment and materials unless otherwise stated in this scope of work. The contractor is responsible for all costs associated with this project, including all travel and per diem, and the disposal if any waste generated by this project. A staging area will be supplied at the construction site. Electrical power, water and restrooms are available.

Specific tasks include:

· Mobilization and cleanup

· Removal and disposal of existing windows

· Installation of new high efficiency windows

.SECTION D – PACKAGING AND MARKING (this section not used)

52.252-2 Clauses Incorporated By Reference (Feb 1998) This RFQ and resulting contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

· Federal Acquisition Regulation (FAR) https://www.acquisition.gov/?q=browsefar

· Department of the Interior Acquisition Regulation (DIAR) http://www.ecfr.gov/cgi-bin/text- idx?SID=e3fdab2f32e71039c0f3823dcff65823&tpl=/ecfrbrowse/Title48/48chapter14.tpl

SECTION E -- INSPECTION AND ACCEPTANCE

Improvement August 1996

SECTION F -- DELIVERIES OR PERFORMANCE

52.211-10, Commencement, Prosecution, and Completion of Work (April 1984)

The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than *90 calendar days. The time stated for completion shall include final cleanup of the premises.

*NOTE: Period of Performance for on-site work is (90 days). The government anticipates making award by (September 24, 2018). After award, the contractor will have from date of award through (December 31, 2018 which is negotiable dependent on weather conditions) to complete all project submittals, and prepare for mobilization. The pre-construction meeting will occur within 15 calendar days of the scheduled on-site start date. The on-site period of performance will be stated in the Notice to Proceed letter, which is typically issued within a few days after the pre-construction meeting.

Project Site Location

Big Hole National Battlefield is located approximately ten miles west of Wisdom, Montana on Highway 43 in Beaverhead County. The park is located about one and one half hours drive from Butte, Montana and about two hours and fifteen minutes from Missoula, Montana. The park’s elevation is 6250 feet. Temperatures range from 20F below zero in the winter to 85F in the summer.

Site Specific Safety Plan

A site specific Safety and Health Plan shall be submitted to the attention of the Contracting Officer within five days of receiving the Notice of Award. The plan shall cover on-site work to be performed by the contractor and all subcontractors. The prime contractor shall be responsible for development, implementation, and oversight of the plan. The plan shall be signed by the Contractor's safety and health manager and the site superintendent. The plan shall establish protocols necessary for recognition, evaluation, and control of hazards associated with each task performed; addressing, in as much detail as possible, anticipated tasks, their related hazards, and anticipated control measures.

Should any unforeseen hazard become evident during the performance of work, the contractor shall bring such hazard to the attention of the COR. Necessary action shall be taken to re-establish and maintain safe working conditions in order to safeguard on-site personnel, visitors, the public, and the environment.

Work performed under this contract shall comply with applicable federal, state, and local safety and occupational health laws and regulations. This includes, but is not limited to, Occupational Safety and Health Administration (OSHA) standards, 29 CFR, Part 1910 and Part 1926. Where the requirements of applicable laws, criteria, ordinances, regulations, and referenced documents vary, the most stringent requirements shall apply.

SECTION G -- CONTRACT ADMINISTRATION DATA

1452.201-70, Authorities and Delegations (September 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without prior authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

APPOINTMENT OF CONTRACTOR REPRESENTATIVE / SUPERINTENDENT

Prior to commencement of work on this contract, the contractor shall provide to the Contracting Officer, the name and telephone number of at least one responsible individual who will serve to respond to operational problems and/or emergencies on a daily basis. The contractor agrees that notice to the designated representative shall constitute notice to the contractor and agrees to be bound by any commitments or representations made by the representative.

DIAR 1452.204-70 Release of Claims—Department of the Interior (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI-137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

CORRESPONDENCE

(a) Copies of all correspondence and written notices between the COR and the Contractor shall be sent to the cognizant Contracting Officer at the address below, or by email. All correspondence sent by email shall state the contract number in the subject line of the email.

(b) Contracting Officer’s Representative (COR) for this contract:

(d) Contracting Officer responsible for solicitation, award, and post-award contract administration:

Ms. Mickey Hopkins National Park Service Olympic National Park 600 East Park Avenue Port Angeles, WA98362 Office Phone: 360-565-3025 Cell Phone: 360-461-8013 Email: Mickey_Hopkins@nps.gov

PUBLIC AFFAIRS COORDINATION

The Contractor shall immediately direct all news/media inquiries concerning this contract to the COR. No statements will be released unless authorized by the Contracting Officer.

ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Contractor’s business invoice (upload your business invoice as an attachment to the IPP invoice before you click “submit” in IPP),

2. Contractor’s signed certification required by FAR clause 52.232-5,

3. Schedule of values for work being performed, and

4. If submitting a final invoice, also attach a signed copy of the Release of Claims form.

Contractor’s failure to attach the required documentation as specified above will result in the IPP invoice being rejected.

NOTE: Content of a proper invoice shall include the following, in accordance with Federal Acquisition Regulation 32.9 – Prompt Payment:

(a) Name and address of the contractor.

(b) Invoice date and invoice number (Contractors should date invoices as close as possible to the date of mailing or transmission).

(c) Contract number or other authorization for supplies delivered or services performed (including order number and contract line item number).

(d) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed.

(e) Shipping and payment terms (e.g., shipment number and date of shipment, discount for prompt payment terms). Bill of lading number and weight of shipment will be shown for shipments on Government bills of lading.

(f) Name and address of contractor official to whom payment is to be sent (must be the same as that in the contract or in a proper notice of assignment).(g) Name (where practicable), title, phone number, and mailing address of person to notify in the event of a defective invoice.

The Contractor must use the IPP website to register, access, and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) prior to the contract award date, but no more than 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

SECTION H -- SPECIAL CONTRACT REQUIREMENTS

DSC-17, Wage Rates (January 1999)

U.S. Department of Labor General Wage Decision no. MT180026 (applicable to Beaverhead County in Montana) is incorporated into this solicitation/contract as Attachment no. 7, as referenced in Section J.

Notice of Required Payment Security (Payment Bond) The successful offeror shall furnish security to guarantee payment to all persons supplying labor or materials in the performance of the contract. NPS prefers that such security be in the form of a payment bond on Standard Form 25A (furnished as part of this solicitation/contract as Attachment no. 9), or in the form of a certified cashier’s check, bank draft, Post Office Money Order, or currency, or United States Government bonds or notes (at par value) deposited in accordance with Treasury Regulations. Money orders and checks shall be drawn payable to: USDI-National Park Service. The penal sum of the payment bond shall equal 100% of the original contract price. A copy of the SF-25A is included as an Attachment to this solicitation, for your reference, as Attachment no. 9.

Notice to the Government of Delays In the event the Contractor encounters difficulty in meeting performance requirements, or when it anticipates difficulty in complying with the contract completion schedule or date, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of any order, the Contractor shall immediately notify the Contracting Officer or the COR, in writing, giving pertinent details; provided, however, that this data shall be informational only in character and that this provision shall not be construed as a waiver by the Government of any delivery schedule or date or any rights or remedies provided by law or under this order. Any request for extension of completion date shall be submitted with a justification, in writing, to the Contracting Officer.

Interpretations of Contract: Notice of Ambiguities

(a) This written contract and any and all identified writings or documents incorporated by reference herein or physically attached hereto constitute the parties' complete agreement and no other prior or contemporaneous agreements either written or oral shall be considered to change, modify or contradict it. Any ambiguity in the contract will not be strictly construed against the drafter of the contract language but shall be resolved by applying the most reasonable interpretation under the circumstances, giving full consideration to the intentions of the parties at the time of contracting.

(b) It shall be the obligation of the Contractor to exercise due diligence to discover and to bring to the attention of the Contracting Officer at the earliest possible time any ambiguities, discrepancies, inconsistencies, or conflicts in or between the specifications and the applicable drawings or other documents incorporated. Failure to comply with such obligation shall be deemed a waiver and release of any and all claims for extra costs or delay arising out of such ambiguities, discrepancies, inconsistencies, and conflicts.

1452.228-70, Liability Insurance – Department of Interior (July 1996)

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

$100,000 each person $250,000 each occurrence $500,000 property damage

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed. The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

Pre-Construction Conference

The Contracting Officer will conduct a preconstruction conference; the contractor will be notified and will be required to attend in person or by phone. The Contracting Officer’s notification will include specific details regarding the date, time, and location of the conference, any need for attendance by subcontractors, and information regarding the items to be discussed.

SECTION I -- CONTRACT CLAUSES

52.252-2 Clauses Incorporated By Reference (Feb 1998) This RFQ and resulting contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses:

· Federal Acquisition Regulation (FAR) https://www.acquisition.gov/?q=browsefar

· Department of the Interior Acquisition Regulation (DIAR) http://www.ecfr.gov/cgi-bin/text- idx?SID=e3fdab2f32e71039c0f3823dcff65823&tpl=/ecfrbrowse/Title48/48chapter14.tpl

Agreements or Statements January 2017

Awards October 2016

Contractors Debarred, Suspended, or Proposed for Debarment October 2015

Management July 2013

Subcontractors December 2013

(Short-Form)

1452.203-70, Restrictions on Endorsements – Department of Interior (July 1996)

The Contractor shall not refer to contracts awarded by the Department of the Interior in commercial advertising, as defined in FAR 31.205-1, in a manner which states or implies that the product or service provided is approved or endorsed by the Government, or is considered by the Government to be superior to other products or services. This restriction is intended to avoid the appearance of preference by the Government toward any product or service. The Contractor may request the Contracting Officer to make a determination as to the propriety of promotional material.

Solicitation 140P8318Q0123 – Attachment 1, READ ME FIRST Replace Windows in Quad-Plex Housing Unit 5 A,B,C,D - BIHO

1452.215-70, Examination of Records by the Department of Interior (April 1984)

(a) For purposes of the Audit and Records - Negotiation clause of this contract (FAR 52.215-2), the Secretary of the Interior, the Inspector General, and their duly authorized representative(s) from the Department of the Interior shall have the same access and examination rights as the Comptroller General of the United States.

1452.236-70, Prohibition Against Use of Lead Based Paint – Department of Interior (July 1996)

(a) Paint containing more than .06 percent by weight of lead in paint, or the equivalent measure of lead in the dried film of paint already applied, shall not be used in the construction or rehabilitation of residential structures under this contract or any resulting subcontracts.

1489.236-73, Archeological Findings (January 1988)

(a) Petroglyphs, artifacts, burial grounds or remains, structural features, ceremonial, domestic, and archeological objects of any nature, historic or prehistoric, found within the construction area, are the property of and will be removed only by the Government. Should Contractor's operations uncover or his employees find any archeological remains, Contractor shall suspend operations at the site of discovery; notify Contracting Officer immediately of the findings; and continue operations in other areas. Included with the notification shall be a brief statement of the location and details of the findings. Should the temporary suspension of work at the site result in delays, or the discovery site require archeological studies resulting in delays or additional work for Contractor, he will be compensated by an equitable adjustment under the General Provisions of the Contract.

1489.236-79, Conduct of Operations (January 1988)

(a) At all times the Contractor shall conduct their organization in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and with such appropriate regulations as the Superintendent may prescribe. Work on Saturdays, Sundays, Federal holidays or at night may be performed only with the prior consent of the Contracting Officer. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park except with approval of the Contracting Officer.

52.225-09, Buy American Act – Construction Materials (May 2014)

(a) Definitions. As used in this clause- “Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

"Component" means an article, material, or supply incorporated directly into a construction material. "Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material. "Cost of components" means—

(3) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(4) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

"Domestic construction material" means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

"Foreign construction material" means a construction material other than a domestic construction material. “United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference. (1) This clause implements the Buy American Act (41 U.S.C. 10a - 10d) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: none

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American Act applies, use of foreign construction material is noncompliant with the Buy American Act.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Item 1:

Foreign Construction Material

Domestic Construction Material

Item 2:

Foreign Construction Material

Domestic Construction Material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] [*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate is issued).]

SECTION J -- LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

LIST OF ATTACHMENTS

Payment Bond, Form SF-25A

SECTION K -- REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS

52.252-1 Solicitation Provisions Incorporated by Reference (FEB 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): www.acquisition.gov/far 52.204-19 Incorporation by Reference of Representations and Certifications. Incorporation by Reference of Representations and Certifications (Dec 2014)

52.204-8 Annual Representations and Certifications.

ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2017)

(a)

(1) The North American Industry classification System (NAICS) code for this acquisition is 238220 -Fire sprinkler system installation.

(2) The small business size standard is 15 million dollars average annual gross receipts for the past three years.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)

(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certification in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

[_] (i) Paragraph (d) applies.

[_] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)

(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals—Representation. This provision applies to solicitations that include the clause at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $79,507 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

___ (i) 52.204-17, Ownership or Control of Offeror.

___ (ii) 52.204-20, Predecessor of Offeror.

___ (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

___ (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

___ (v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

___ (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

___ (vii) 52.227-6, Royalty Information.

___ (A) Basic.

___ (B) Alternate I.

___ (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM Web site accessed through https://www.acquisition.gov . After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of Provision)

SECTION L – INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS OR RESPONDENTS

52.252-1 Solicitation Provisions Incorporated by Reference.

SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): https://www.acquisition.gov/far/html/52_301Matrix.html (End of provision) 52.203-98 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements — Representation (DEVIATION 2015-02) (FEB 2015) 52.204-7 System for Award Management. SYSTEM FOR AWARD MANAGEMENT (OCT 2016) 52.204-16 Commercial and Government Entity Code Reporting. COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (JUL 2016) 52.204-18 Commercial and Government Entity Code Maintenance. COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (JUL 2016) 52.211-6 Brand Name or Equal (AUG 1999) 52.252-5 Authorized Deviations in Provisions (APR 1984) 52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work.

CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY 2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror’s request for a wage determination for a secondary site of the work.

(End of provision) 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction.

NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror’s attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor’s aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor’s construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor’s compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled “Affirmative Action Compliance Requirements for Construction,” and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor’s goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer’s identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the “covered area” is Big Hole National Battlefield, (BIHO) Big Hole National Battlefield is located approximately ten miles west of Wisdom, Montana on Highway 43 in Beaverhead County.

(End of provision) 52.225-10 Notice of Buy American Requirement—Construction Materials.

NOTICE OF BUY AMERICAN REQUIREMENT—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this…