Wyatt Elementary School Kitchen Addition & Renovation

Plano Independent School District is requesting proposals for a Construction Manager at Risk (CMAR) One Step Process contract for the Wyatt Elementary School Kitchen Addition & Renovation, with proposals due October 6, 2026 at 2:00 p.m. CT and questions due September 29, 2026 at 4:00 p.m. CT. The contract is subject to prevailing wage requirements per Texas Government Code Chapter 2258 and federal compliance including EDGAR, Davis-Bacon Act, and Buy American provisions.

The scope encompasses complete kitchen renovation—demolition of walls, ceiling, and floor slab; installation of new underground plumbing, concrete flooring, and quarry tile; new walls, ceiling finishes, and all kitchen equipment and serving lines; lights, hood assemblies, and mechanical systems; a new cooler and freezer addition; and new grease interceptor and sanitary line. Main building work includes a new fire alarm system, replacement of the main sprinkler system valve assembly, a new digital marquee sign with masonry enclosure, and new traffic directional signage. The project is located at 8900 Coit Road, Plano, Texas 75025, with a proposed construction schedule from Summer 2027 through December 2027.

The estimated construction budget is $2.4 million. Proposals must be submitted in two parts: electronically through Ionwave and one original hard copy sealed and mailed or delivered to the Plano ISD Purchasing Department. Submissions require a completed Proposal Cover Page (Form A), CMAR Proposal Forms (Forms B and C) with pre-construction services as a lump sum and construction period services and general conditions as percentage amounts, AIA Document A305 Qualification Statement, completed Respondent Questionnaire (Form G), W9 form, and proof of Proposal Bond or Cashier's Check equal to five percent of proposal price.

Evaluation uses weighted criteria: Cost/Price (30 points), Qualifications (20 points), Reputation of Vendor (20 points), Experience (20 points), and Best Meets the District's Needs (10 points). Board approval is anticipated November 10, 2026. Payment and performance bonds are required, and the Owner will disburse all construction payments directly to the CMR for distribution to subcontractors. Liquidated damages apply for late completion.