Riverside Golf Cart Shed Improvements

The City of Victoria, Texas is requesting sealed proposals for demolition, site work, building, and electrical improvements to the Riverside Golf Cart Shed at Riverside Park Golf Course, with proposals due October 13, 2026 at 10:00 a.m. CST through BidNet Direct.

The scope includes demolition of the existing golf cart shed, removal of concrete slabs and trees, construction of a new 30 feet by 160 feet prefabricated metal building with electrical infrastructure to accommodate 80 Club Cars with battery chargers, and associated site improvements. The engineer's estimated construction cost is $525,000. Construction is projected to commence within 10 days of Notice to Proceed and complete within 120 calendar days. Work must comply with Davis-Bacon wage determinations and the City's standard specifications for public works construction.

Award will be made to the respondent providing the best value using weighted selection criteria: cost (50%), proposed schedule (15%), past performance on similar projects (15%), available resources (5%), overall qualifications and reputation (5%), corporate history and stability (5%), and references (5%).

Respondents must submit a bid bond equal to 5% of proposal cost and, upon award, provide performance and payment bonds each equal to 100% of contract price. Required insurance includes Commercial General Liability ($1 million per occurrence / $2 million aggregate), Workers' Compensation at statutory limits, Business Auto Liability ($1 million), and Excess Liability ($5 million). Liquidated damages are $500 per calendar day for delays beyond the contract completion date. Proposals remain firm for 120 days following submission.

An optional pre-proposal conference is scheduled for September 29, 2026 at 10:00 a.m. CST at the Engineering Conference Room. The successful contractor must obtain all applicable permits and inspections and provide manufacturers' warranties and operations and maintenance manuals for installed equipment.