Avenue Street Albert Pipe Liner

St. Tammany Parish Government is requesting sealed quotes for drainage improvement work on Avenue Street Albert in Covington, Louisiana, with quotes due July 28, 2026 at 2:00 p.m. The scope involves cleaning existing pipe and installing pipe liner between addresses 810 and 814 Avenue Street Albert (project R03A021), with a 30-calendar-day completion period from issuance of the Notice to Proceed.

Respondents with an estimated project cost of $50,000 or more must hold an active State of Louisiana contractor's license for Highway, Street, and Bridge Construction and must include their license number on the quote envelope. A performance bond equal to 100% of the project cost is required for projects costing $25,000 or more, with bond costs borne by the contractor.

All labor, materials, equipment, supervision, permits, and applicable taxes must be included in the bid price. The contractor bears responsibility for site restoration, property protection, traffic control, and safety measures. Site familiarization is mandatory. The Parish reserves the right to add, remove, or modify scope as determined necessary and allowed by law.

Liquidated damages range from $500 to $3,000 per calendar day of delay beyond the completion deadline, deducted from the contract price. Pricing must remain firm for the contract term. The contract commences upon the Parish President's written approval and terminates upon satisfactory completion of all services and obligations. Award will go to the lowest monetary quote in compliance with the solicitation.

The inquiry deadline is July 21, 2026, and the addendum deadline is July 23, 2026. Quotes may be submitted via certified mail, hand delivery, or courier to 21454 Koop Drive, Suite 2F, Mandeville, Louisiana 70471, or electronically through BidExpress.