Cooling Tower Replacement

Added: Mar 04, 2014 3:09 pm Modified: Mar 27, 2014 4:18 pmTrack Changes                      COOLING TOWER REPLACEMENT

This project will be a 100% Small Business Set-Aside Competitive.  The contract will be Firm Fixed Price.  The NAICS code is 238220.  Project location is Cookeville US Post Office and Courthouse, 9E Broad Street,  Cookeville, TN  38503.  The Contractor shall provide material, labor, equipment, and supervision to conduct the following work:
 
     Furnish and Install 60 ton cooling tower, dispose of existing tower,
     placement and balancing of new tower, new pad, modificaton of steel
     enclosure, tie in insulated piping to feed the new tower, replacement of
     controls box and controls wiring, connect existing tower drain line to sewer
     per code:

The Contractor should visit the site prior to bidding on this project in order to verify all dimensions and familiarize him/herself with the existing conditions, so that they may obtain a full knowledge of any and all difficulties that may be encountered in execution of the work.  A payment bond and insurance are required. 

The Contracting Officer is Dee Otis Henderson, 404-331-9792.  The Project Manager is Johnathan Sitzlar, 865-545-4330.

Work shall be performed in accordance with all applicable State and Federal codes, and shall be done by a Specialty Contractor skilled in the trade.

All work shall be completed within 60 days after Contractor's receipt of contract award.  If conditions prevent completion within the schedule, the Contractor shall request a time extension in writing, giving specific reasons why an extension should be granted.

The Construction Magnitude is $25,000 to $100,000.  The liquidated damages are $844.37 per day.

Contractors will be required to submit with their offer at least 3 similar contracts for past performance.  Clearances of Contractor personnel is required before work can be started on the project.  Award will be made to the offeror possessing the lowest price.  The low offeror must possess a satifactory Past Performance.