Amendment_1_15B0007.pdf

W81G6740155878

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

See the "Continuation Page"/"Summary of Changes" section for the purpose of this amendment.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 12

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 04-Sep-2015

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912ES-15-B-0007

X 9B. DATED (SEE ITEM 11)

12-Aug-2015

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

04-Sep-2015

CODE

CONTRACTING DIVISION

USACE - ST. PAUL

180 5TH STREET E SUITE 700

ST. PAUL MN 55101-1678

W912ES 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912ES-15-B-0007

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE

The following have been added by full text:

AMENDMENT 0001

The purpose of this amendment is as follows:

1. Revise the anticipated date that the successful contractor will receive the Notice to Proceed to 10/31/2015 in FAR Clause 52.211-10 Alt. I.

The following specification changes have been made. Note: Specification deletions are shown as strikethrough, additions are shown as underlined.

2. Remove page 195, “ATTACHMENT, DNR – PROTECTED WATERS PERMIT, PLACE HOLDER” of specification and replace with the DNR Protected Waters Permit, 8 pages attached.

3. SECTION 35 31 19.00 13 STONE PROTECTION (RIPRAP AND BEDDING)

Remove existing page 7 of Section 35 31 19.00 13 of specification and replace with the revised Section 35 31

19.00 13 page 7 attached.

4. Extend the bid due date and time.

5. Add liquidated damages for the turf establishment period‐see FAR clause 52.211‐12.

6. Revise the bid schedule, see attached revised bid schedule (changes highlighted in yellow).

7. SECTION 31 00 00.00 03 EARTHWORK

a. Delete the second sentence in paragraph 3.3 as follows:

3.3 EXCAVATION

After topsoil removal has been completed, excavation of every description, regardless of material encountered, within the grading limits of the project shall be performed to the lines and grades indicated. Excavated material from structures 1 or 2 may be needed as random fill for structure 3. All excavated material not used as random fill within the project shall be removed from the site and disposed of properly. Any soil which is disturbed by the Contractor's operations or softened due to exposure to the elements and water, and surplus material shall be disposed of in areas approved for off site storage. Excavations carried below the depths indicated shall be refilled to the proper grade with satisfactory material at the Contractors expense. During construction, excavation and fill shall be performed in a manner and sequence that will provide proper drainage at all times.

8. SECTION 32 92 19.00 13 SEEDING

a. Delete year from paragraph 3.1.2 as follows:

3.1.2 Seeding Time

Seed shall be applied between 20 September and 15 October 2017 for mixture 35-421. No finished construction area shall be left untopsoiled and unseeded during the winter months. When substantially complete areas are not seeded within the specified seeding times for fall planting, a temporary winter cover shall be placed.

All other terms and conditions remain unchanged.

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time has changed from 10-Sep-2015 02:00 PM to 14-Sep-2015 03:00 PM.

SUBCLIN 0011AA

The CLIN description has changed from Granular Fill First 925 CY to Granular Fill First 575 CY.

The pricing detail quantity has decreased by 350.00 from 925.00 to 575.00.

SUBCLIN 0011AB

The CLIN description has changed from Granular Fill Over 925 CY to Granular Fill Over 575 CY.

The pricing detail quantity has decreased by 111.00 from 304.00 to 193.00.

SUBCLIN 0012AA

The CLIN description has changed from Bedding Gradation B3 First 3,475 Ton to Bedding Gradation B3 First 1.365 Ton.

The pricing detail quantity has decreased by 2,110.00 from 3,475.00 to 1,365.00.

SUBCLIN 0012AB

The CLIN description has changed from Bedding Gradation B3 Over 3,475 Ton to Bedding Gradation B3 Over 1,365 Ton.

The pricing detail quantity has decreased by 714.00 from 1,169.00 to 455.00.

SUBCLIN 0015AA

The CLIN description has changed from Boulders First 750 Ton to Boulders First 580 Ton.

The pricing detail quantity has decreased by 170.00 from 750.00 to 580.00.

SUBCLIN 0015AB

The CLIN description has changed from Boulders Over 750 Ton to Boulders Over 580 Ton.

The pricing detail quantity has decreased by 60.00 from 250.00 to 190.00.

SUBCLIN 0025AA

The CLIN description has changed from Granular Fill First 800 CY to Granular Fill First 500 CY.

The pricing detail quantity has decreased by 300.00 from 800.00 to 500.00.

SUBCLIN 0025AB

The CLIN description has changed from Granular Fill Over 800 CY to Granular Fill Over 500CY.

The pricing detail quantity has decreased by 101.00 from 269.00 to 168.00.

SUBCLIN 0026AA

The CLIN description has changed from Bedding Gradation B3 First 2,075 Ton to Bedding Gradation B3 First 9,80Ton.

The pricing detail quantity has decreased by 1,095.00 from 2,075.00 to 980.00.

SUBCLIN 0026AB

The CLIN description has changed from Bedding Gradation B3 Over 2,075 Ton to Bedding Gradation B3 Over 325 Ton.

The pricing detail quantity has decreased by 363.00 from 688.00 to 325.00.

SUBCLIN 0029AA

The CLIN description has changed from Boulders First 600 Ton to Boulders First 460 Ton.

The pricing detail quantity has decreased by 140.00 from 600.00 to 460.00.

SUBCLIN 0029AB

The CLIN description has changed from Boulders Over 600 Ton to Boulders Over 460 Ton.

The pricing detail quantity has decreased by 45.00 from 200.00 to 155.00.

CLIN 1008

The pricing detail quantity has increased by 1,638.00 from 500.00 to 2,138.00.

SUBCLIN 1011AA

The CLIN description has changed from Granular Fill First 2,150 CY to Granular Fill First 1,345 CY.

The pricing detail quantity has decreased by 805.00 from 2,150.00 to 1,345.00.

SUBCLIN 1011AB

The CLIN description has changed from Granular Fill Over 2,150 CY to Granular Fill Over 1,345 CY.

The pricing detail quantity has decreased by 274.00 from 726.00 to 452.00.

SUBCLIN 1012AA

The CLIN description has changed from Bedding Gradation B3 First 2,250 Ton to Bedding Gradation B3 First 1,095 Ton.

The pricing detail quantity has decreased by 1,155.00 from 2,250.00 to 1,095.00.

SUBCLIN 1012AB

The CLIN description has changed from Bedding Gradation B3 Over 2,250 Ton to Bedding Gradation B3 Over 1,095Ton.

The pricing detail quantity has decreased by 394.00 from 759.00 to 365.00.

SUBCLIN 1015AA

The CLIN description has changed from Boulders First 600 Ton to Boulders First 435 Ton.

The pricing detail quantity has decreased by 165.00 from 600.00 to 435.00.

SUBCLIN 1015AB

The CLIN description has changed from Boulders Over 600 Ton to Boulders Over 435 Ton.

The pricing detail quantity has decreased by 12.00 from 157.00 to 145.00.

DELIVERIES AND PERFORMANCE

The following Delivery Schedule item for SUBCLIN 0011AA has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

30-NOV-2017 925 N/A

FOB: Destination

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

30-NOV-2017 575 N/A

The following Delivery Schedule item for SUBCLIN 0011AB has been changed from:

30-NOV-2017 304 N/A

30-NOV-2017 193 N/A

The following Delivery Schedule item for SUBCLIN 0012AA has been changed from:

30-NOV-2017 3,475 N/A

30-NOV-2017 1,365 N/A

The following Delivery Schedule item for SUBCLIN 0012AB has been changed from:

30-NOV-2017 1,169 N/A

30-NOV-2017 455 N/A

The following Delivery Schedule item for SUBCLIN 0015AA has been changed from:

30-NOV-2017 750 N/A

30-NOV-2017 580 N/A

The following Delivery Schedule item for SUBCLIN 0015AB has been changed from:

30-NOV-2017 250 N/A

30-NOV-2017 190 N/A

The following Delivery Schedule item for SUBCLIN 0025AA has been changed from:

30-NOV-2017 800 N/A

30-NOV-2017 500 N/A

The following Delivery Schedule item for SUBCLIN 0025AB has been changed from:

30-NOV-2017 269 N/A

30-NOV-2017 168 N/A

The following Delivery Schedule item for SUBCLIN 0026AA has been changed from:

30-NOV-2017 2,075 N/A

30-NOV-2017 980 N/A

The following Delivery Schedule item for SUBCLIN 0026AB has been changed from:

30-NOV-2017 688 N/A

30-NOV-2017 325 N/A

The following Delivery Schedule item for SUBCLIN 0029AA has been changed from:

30-NOV-2017 600 N/A

30-NOV-2017 460 N/A

The following Delivery Schedule item for SUBCLIN 0029AB has been changed from:

30-NOV-2017 200 N/A

30-NOV-2017 155 N/A

The following Delivery Schedule item for CLIN 1008 has been changed from:

30-NOV-2017 500 N/A

30-NOV-2017 2,138 N/A

The following Delivery Schedule item for SUBCLIN 1011AA has been changed from:

30-NOV-2017 2,150 N/A

30-NOV-2017 1,345 N/A

The following Delivery Schedule item for SUBCLIN 1011AB has been changed from:

30-NOV-2017 726 N/A

30-NOV-2017 452 N/A

The following Delivery Schedule item for SUBCLIN 1012AA has been changed from:

30-NOV-2017 2,250 N/A

30-NOV-2017 1,095 N/A

The following Delivery Schedule item for SUBCLIN 1012AB has been changed from:

30-NOV-2017 759 N/A

30-NOV-2017 365 N/A

The following Delivery Schedule item for SUBCLIN 1015AA has been changed from:

30-NOV-2017 600 N/A

30-NOV-2017 435 N/A

The following Delivery Schedule item for SUBCLIN 1015AB has been changed from:

30-NOV-2017 157 N/A

30-NOV-2017 145 N/A

SECTION 00700 - CONTRACT CLAUSES

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c)

1. Complete the entire work with the exception of the vegetation establishment work, ready for use not later than November 30, 2017;

2. Complete the vegetation establishment work not later than October 1, 2018.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by October 31, 2015. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,723.00. These liquidated damages apply to all work, exclusive of turf establishment.

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $346.00. These liquidated damages apply only to the turf establishment work that must be completed.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

The following have been modified:

52.212-4003 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989) ER 415-1-15

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the CONTRACT CLAUSES: DEFAULT (FIXED-PRICE CONSTRUCTION). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The weather station selected for this analysis was Crookston NW Experimental Station, which has a period of record of 115 years (1900-2014). The actual numbers have been multiplied by 5/7 to account for the workweek.

Anticipated Weather Delay Due to Precip & Temp in Days

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

20 16 9 3 4 5 4 4 3 3 6 17

The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph b, above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the CONTRACT CLAUSES: DEFAULT (FIXED-PRICE CONSTRUCTION).

(End of Summary of Changes)