W911XK-18-B-0008-0002.pdf

W56MES73535370

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

FY18 Maintenance Dredging Duluth-Superior 40th Avenue Placement, MN-WI.

This amendment is being issued to:

1) Delete and replace sections of paragraphs of the Specification for Section 01 35 13.10 Paragraph 1.4.4 “Start Work” and Section 35 20 23 Paragraph 1.11.4 “Shoals”. (Specification are attached)

2) Revised Clause 52.211-10 Commencement, Prosecution and Completion of Work.

3) The responsed date has change from 8 June 2018 to 12 June 2018. Reference changes on the follow ing pages. All other terms and condition remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 06-Jun-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W911XK18B0008

X 9B. DATED (SEE ITEM 11)

09-May-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

06-Jun-2018

CODE

U.S.ARMY ENGINEER DISTRICT, DETROIT

477 MICHIGAN AVENUE, 7TH FLOOR

DETROIT MI 48226-4523

W911XK 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W911XK18B0008

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 08-Jun-2018 02:00 PM to 12-Jun-2018 02:00 PM.

The following have been added by full text:

AMENDMENT 02

CHANGES TO THE SPECIFICATIONS

1. Revise Section 01 35 13.10 Paragraph 1.4.4 “Start Work” to the following:

“Sediment removal operations within the Federal Navigation Channel shall commence no later than 06 August 2018.

Evidence that the Contractor has started mobilization and preparation of submittal register, and other preparatory work will satisfy the requirement that work commence within 10 calendar days after receipt of Notice to Proceed. (See FAR Clause titled COMMENCEMENT, PROSECUTION, AND COMPLETION

OF WORK).”

2. Revise Section 35 20 23 Paragraph 1.11.4 “Shoals” to the following:

“For Dredge Areas 6A, 6B, 8, 14, 15, and 23 In the "shoal tolerance area," a tolerance of 0.0 feet above the required pay prism line will be allowed for acceptance of remaining shoal materials. The shoal tolerance area is defined as the portion of the required dredging area between the tolerance dimension lines (shown on the attached details).

For Dredge Areas 7A, 7B, 7C, 7D, and 7E In the "shoal tolerance area," a tolerance of 0.5 feet above the required pay prism line will be allowed for acceptance of remaining shoal materials. The shoal tolerance area is defined as the portion of the required dredging area between the tolerance dimension lines (shown on the attached details). The allowed shoal materials may be left in place but shall be of such nature that they will not affect navigation. The allowed shoaling shall not be continuous throughout the required dredging area. The limitations for individual shoals are as follows:

a. Maximum width: Maximum width of each remaining shoal area not required to be removed shall be not more than five percent (5%) of the authorized channel width or 5% of the dredge limit width, whichever is less.

b. Longitudinal length: Longitudinal length of each remaining shoal area not required to be removed shall be not more than twenty-five percent (25%) of the authorized channel width or 25% of the dredge limit width, whichever is less.

c. Cumulative width: Cumulative width of remaining individual shoals not required to be removed within the shoal area, at any channel cross section, shall be not more than twenty-five percent (25%) of the authorized channel width or 25% of the dredge limit width, whichever is less.”

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

W911XK18B0008

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use including all exercised options not later than 15 November 2018 for Duluth, MN and Superior WI. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 18 July 2018. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

(End of Summary of Changes)