Specifications_FY16_MD_St._Joseph_Harbor_Inner.pdf

FY16 MD St. Joseph Harbor Inner - Ready To Advertise FY16MDSTJOEINNE

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 10 10 REAL ESTATE

01 22 00.00 10 MEASUREMENT AND PAYMENT

01 30 00 CONTRACTOR FURNISHED PLACEMENT FACILITIES

01 33 00 SUBMITTAL PROCEDURES

01 35 13.10 SPECIAL PROJECT PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 45 00.10 10 QUALITY CONTROL SYSTEM (QCS)

01 45 04.00 10 CONTRACTOR QUALITY CONTROL

01 57 20.00 20 ENVIRONMENTAL PROTECTION

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 20 23.13 NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SCOW -

TRACKING PROFILE

35 20 23 DREDGING

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

SECTION 01 10 10

REAL ESTATE

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only or as otherwise designated. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section

01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Additional Property Agreements; G-REO.

Copies of any agreements for Contractor-acquired real estate rights for this project shall be furnished before entering thereon.

Certified Survey Results

Furnish a copy of certified results of surveys which verify areas and limits of Contractor-acquired real estate rights.

1.2 REAL ESTATE

1.2.1 Real Estate Rights

Rights for the use of the placement areas have been obtained and the general limits of the areas are shown on the drawings. All real estate lakeward of the Ordinary High Water Mark is under Federal jurisdiction and no permit or agreements are necessary for work therein except as specified in SECTION 01 35 13 10, "SPECIAL PROJECT PROCEDURES", Paragraph, "Additional Work Proposed and Not Authorized". No other real estate rights have been obtained by the Government for this project.

1.2.2 Additional Real Estate Rights

Any additional property agreements and/or real estate rights desired by the Contractor shall be obtained by the Contractor at its own expense. Such agreements shall clearly relieve the Government of any responsibility for damages or liability resulting from the Contractor's use of such grounds.

1.3 PROJECT/SITE CONDITIONS

1.3.1 Location and Verification

It shall be the Contractor's responsibility to accurately locate the limits of all lands utilized under the contract. The corner and angle points of each area for which rights have been obtained shall be marked with semipermanent markers except where there is an approved existing property marker. Temporary markers shall be placed at points on alignment. The points on alignment shall be marked at stations so that intervals between points do not exceed 200 feet.

SECTION 01 10 10 Page 1

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section --

SECTION 01 10 10 Page 2

SECTION 01 22 00.00 10

MEASUREMENT AND PAYMENT

PART 1 GENERAL

1.1 JOB PAYMENT ITEMS

Payment items for the work of this contract for which contract Job payments will be made are listed in the BIDDING SCHEDULE and described below. All costs for items of work, which are not specifically mentioned to be included in a particular Job or unit price payment item, shall be included in the listed lump sum item most closely associated with the work involved. The lump sum price and payment made for each item listed shall constitute full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for which separate payment is not otherwise provided.

1.1.1 Mobilization and Demobilization [Item No. 0001]

(1) Payment will be made for costs associated with mobilization and demobilization, as defined in Special Clause PAYMENT FOR

MOBILIZATION AND DEMOBILIZATION.

(2) Unit of measure: Job.

1.2 UNIT PRICE PAYMENT ITEMS

Payment items for the work of this contract on which the contract unit price payments will be made are listed in the BIDDING SCHEDULE and described below. The unit price and payment made for each item listed shall constitute full compensation for furnishing all plant, labor, materials, and equipment, and performing any associated Contractor quality control, environmental protection, meeting safety requirements, tests and reports, and for performing all work required for each of the unit price items.

1.2.1 Required Dredging [Item No. 0002]

(1) This item shall include all work as specified in SECTION 35 20 23 DREDGING. The Contract unit price per cubic yard of dredging shall include the cost of removal, conveyance and disposal of all materials as shown on the drawings and as specified herein, except original materials, ledge rock, boulders, cobbles, rock fragments, wrecks, scrap materials, snags, stumps, piles, debris or other material which cannot be removed or buried below the required depth by the plant specified in the accepted bid, or the equivalent of such plant, without blasting or special apparatus. The unit price shall also include the cost of all work required to be performed for the use of the disposal area.

Nothing in this paragraph shall be construed as prohibiting the removal of excepted material by special means at the prices agreed and approved in accordance with applicable provisions of the contract. Costs may also include those associated with use of an

SECTION 01 22 00.00 10 Page 1 upland placement site as specified in SECTION 35 20 23 DREDGING.

When an option has been exercised for increased depth or area at a specific location, all overdepth to 1.0 ft. below the required dredging areas and sideslope quantities associated with the Base Bid dredging areas shall be paid for at the applicable unit costs for the Base Bid AA and AB items. All other quantities dredged will be paid for at the unit costs associated with the option dredge areas.

(2) This item shall also include all work as specified in SECTION

35 20 23 13 "NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SCOW".

The contract unit price per cubic yard for "Dredging," shall constitute full compensation for all labor, equipment, tools, and incidentials necessary to operate and maintain the system as specified herein for the duration of the dredging operations.

(3) Unit of measure: cubic yard.

1.2.2 Option 1 and 2 Dredging [Items No. 0003 and 0004]

(1) This item shall include all work as specified in SECTION 35 20 23 DREDGING. The Contract unit price per cubic yard of dredging shall include the cost of removal, conveyance and disposal of all materials as shown on the drawings and as specified herein, except original materials, ledge rock, boulders, cobbles, rock fragments, wrecks, scrap materials, snags, stumps, piles, debris or other material which cannot be removed or buried below the required depth by the plant specified in the accepted bid, or the equivalent of such plant, without blasting or special apparatus. The unit price shall also include the cost of all work required to be performed for the use of the disposal area.

Nothing in this paragraph shall be construed as prohibiting the removal of excepted material by special means at the prices agreed and approved in accordance with applicable provisions of the contract. Costs may also include those associated with use of an upland placement site as specified in SECTION 35 20 23 DREDGING.

When an option has been exercised for increased depth or area at a specific location, all overdepth to 1.0 ft. below the required dredging areas and sideslope quantities associated with the Base Bid dredging areas shall be paid for at the applicable unit costs for the Base Bid AA and AB items. All other quantities dredged will be paid for at the unit costs associated with the option dredge areas.

(2) This item shall also include all work as specified in SECTION

35 20 23 13 "NATIONAL DREDGING QUALITY MANAGEMENT PROGRAM SCOW".

The contract unit price per cubic yard for "Dredging," shall constitute full compensation for all labor, equipment, tools, and incidentials necessary to operate and maintain the system as specified herein for the duration of the dredging operations.

(3) Unit of measure: cubic yard.

PART 2 PRODUCTS (Not Applicable)

PART 3 EXECUTION (Not Applicable)

SECTION 01 22 00.00 10 Page 2

SECTION 01 30 00

CONTRACTOR FURNISHED PLACEMENT FACILITIES

PART 1 GENERAL

1.1 AFTER AWARD

1.1.1 Definition

The term "facility" used in this Section refers to all Contractor-furnished features that are proposed by the Contractor in conjunction with execution and performance of dredging and that are not specifically identified in the solicitation document. The facility includes, but not limited to, dredged material placement area(s), dredged material transfer site(s) and/or off-loading site(s), and/or haul roads.

1.1.2 Data

Submit all information and data specified in this Section.

1.1.3 Combination of Contractor/Government-Furnished Placement Areas

If a Contractor-furnished placement area is approved in combination with the Government-furnished placement area, the Contractor shall place dredged material into the Contractor-furnished placement area in the quantity approved by the government.

1.1.4 Expenses

All expenses incurred in complying with requirements for use of a proposed Contractor-furnished placement facility shall be borne by the Contractor, and all operations in connection therewith shall be at the Contractor's risk.

1.1.5 Required Data Needed if No Corps of Engineers Permit(s) Available

A Contractor proposing use of a contractor-furnished placement facility that does not have a Corps of Engineers regulatory permit which covers the dredged material outlined in the contract and proposed placement facility shall furnish the data identified below for each proposed facility. The Cors of Engineers will conduct Section 106 of the National Historic Preservation Act coordination with the appropriate State Historic Preservation Office. No ground impacting work will take place at a contractor furnished disposal site until the contractor is notified by Corps of Engineers that the Section 106 process has been completed and work can proceed.

(1) Name and address of Property Owner(s).

(2) Location, site map, and legal description (or appropriate substitute) of area(s) and haul route(s).

(3) Previous Land Use Information for the last ten year period.

(4) A Topographic Map of the Area outlining the property boundary and specific placement location. The topography may be depicted on a USGS

SECTION 01 30 00 Page 1

Quadrangle sheets (or specific enlargement from the sheet) if the land elevations remain essentially the same as depicted on the sheet. The name, date and latest photograph update to the Quad sheet must be provided if a USGS Quad sheet is used. If areas within the proposed placement location have been filled since the date of the Quad sheet, then new topographic survey is required including surveyor information and preparation date. Cross sections required in item (8) should be depicted on the topographic map.

(5) Photographs showing the area proposed for use.

(6) All data required to assess potential environmental impacts. This information is required in order to determine the necessity for environmental documentation for the proposed use of the site.

Applicable data would include, but not be limited to, a Phase I Environmental Site Assessment of the proposed placement facility prepared in accordance with ASTM E1527 - Standard Practice for Environmental Site Assessments: Phase I Environmental Site Assessment Process.

(7) Capacity of placement area.

(8) Cross section(s) of the proposed fill area depicting existing grade, average depth of fill and final grades over placement area.

(9) Obtain a fully executed Contractor-Furnished Placement Facility Permit. Use the sample permit form attached at the end of this Section.

(10) Documentation of coordination of the use of the proposed placement facility with Federal, State and local agencies having an interest and furnish written approval of these agencies for use of such facilities(s). Applicable agencies are:

Michigan:

(a) Mr. Chris Antieau, Corps Project Coordinator Chief, Michigan Department of Environmental Quality, Great Lakes Shorelands Unit, Water Resources Division, P.O. Box 30473, Lansing, Michigan 48909-7973. As a minimum, a determination that the proposed fill area does not contain regulated wetlands and that the site is not within a regulated floodplain.

(b) Mr. Scott Hicks, Field Supervisor, U.S. Fish and Wildlife Service, Ecological Services, 2651 Coolidge Road, Suite 101, East Lansing, Michigan 48823. As a minimum, a determination that the site does not impact Federally listed Threatened or Endangered or Candidate species.

(c) Mr. Kenneth Westlake, US Environmental Protection Agency, Region V, Environmental Planning and Evaluation, 77 West Jackson Boulevard, Chicago, IL 60604-3590.

(d) Regulatory Branch, Engineering and Technical Services Division, U.S. Army Engineer District, Detroit, P.O. Box 1027, Detroit MI, 48231.

Minnesota:

SECTION 01 30 00 Page 2

(a) Mr. Dan Breneman, Dan Breneman, Lake Superior Unit, Minnesota Pollution Control Agency,525 Lake Ave. South, Suite 400, Duluth, MN 55802. As a minimum, a determination that the proposed fill area does not contain regulated wetlands and that the site is not within a regulated floodplain.

(b) U.S. Fish and Wildlife Service, Ecological Services, 4101 American Blvd E, Bloomington, MN 55425-1665. As a minimum, a determination that the site does not impact Federally listed Threatened or Endangered or Candidate species.

(c) Mr. Kenneth Westlake, US Environmental Protection Agency, Region V, Environmental Planning and Evaluation, 77 West Jackson Boulevard, Chicago, IL 60604-3590.

(d) Regulatory Functions Branch, Construction-Operations Division, U.S. Army Corps of Engineers, St Paul, 190 Fifth Street East, St Paul MN, 55101.

Wisconsin:

(a) Jim Killian, Wisconsin Department of Natural Resources, PO Box 7921, Madison, WI 53707-7921. As a minimum, a determination that the proposed fill area does not contain regulated wetlands and that the site is not within a regulated floodplain.

(b) U.S. Fish and Wildlife Service, Ecological Services, 2661 Scott Tower Drive, New Franken, WI 54229-9565. As a minimum, a determination that the site does not impact Federally listed Threatened or Endangered or Candidate species.

(c) Mr. Kenneth Westlake, US Environmental Protection Agency, Region V, Environmental Planning and Evaluation, 77 West Jackson Boulevard, Chicago, IL 60604-3590.

(d) Regulatory Functions Branch, Construction-Operations Division, U.S. Army Corps of Engineers, St Paul, 190 Fifth Street East, St Paul MN, 55101.

All States:

(a) Local Permit, if any, including evidence of a Soil Erosion and Sediment Control (SESC) Permit from the appropriate local SESC agency or determination that no SESC permit is required.

1.1.6 Required Data Needed if a Corps of Engineers Permit(s) is Available

A Contractor proposing use of a contractor-furnished placement facility that does have a Corps of Engineers regulatory permit which covers the dredged material outlined in the contract and the proposed placement facility shall furnish the following data for each proposed facility:

(1) The Corps of Engineers Permit(s)

(2) Any applicable State and Local permit(s)

(3) Obtain a fully executed Contractor-Furnished Placement Facility Permit. Use the sample permit form attached at the end of this Section.

SECTION 01 30 00 Page 3

1.1.7 Required Data Submittal, Review and Approval

1.1.7.1 Required Data Submittal if No Corps of Engineers Regulatory Permit(s) Available

The contractor's initial proposal for use of a contractor-furnished placement facility shall be accompanied by all the required data specified under paragraphs 1.1.5. The contractor shall submit the required documents to the Contracting Officer for approval at least 90 calendar days in advance of the proposed placement facility usage to allow for government review, coordination and approval.

1.1.7.2 Required Data Submittal if a Corps of Engineers Regulatory Permit(s) is Available

The contractor's initial proposal for use of a contractor-furnished placement facility shall be accompanied by all the required data specified under paragraphs 1.1.6. The contractor shall submit the required documents to the Contracting Officer for approval at least 30 calendar days in advance of the proposed placement facility usage to allow for government review, coordination and approval.

1.1.7.3 Contracting Officer's Approval

The Contracting Officer's approval of the contractor-furnished placement facility shall be issued by contract modification pursuit to the "Changes" clause. The Contracting Officer's approval modification of the contractor-furnished placement facility shall not adjust the contract price and shall not adjust the contract performance period. The Contracting Officer's disapproval of a contractor-furnished placement facility shall not be subject to the "Disputes" clause and shall not result in a time extension for delays to the contractor.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 30 00 Page 4

SAMPLE

CONTRACTOR FURNISHED PLACEMENT

FACILITY PERMIT

In the consideration of the sum of ____________ dollars and other valuable consideration, the receipt and sufficiency of which are hereby acknowledged the undersigned owner of the premises described, does hereby grant to (insert contractor’s name) permission to (transfer) (dispose of )(convey across) dredge material resulting from operations under contract number ________________ awarded by the U.S.Army Corps of Engineers Detroit District upon the following described property in the County of ______________, State of ____________.

(INSERT LEGAL DESCRIPTION OF PROPERTY)

The undersigned owner shall hold and save the Government free from all damages arising from the design, placement, construction, operations and/or maintenance of the dredged material at the transfer or placement site(s) or facilities (described above), except for damages due to the fault or negligence of the Government or its contractors. This provision survives the termination of this permit.

Executed (date)

(SIGNITURE OF OWNER)

SECTION 01 33 00

SUBMITTAL PROCEDURES

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by SD numbers and titles as follows.

SD-01 Preconstruction Submittals

Certificates of insurance.

Surety bonds.

List of proposed subcontractors.

List of proposed products.

Construction Progress Schedule.

Submittal register.

Schedule of prices.

Health and safety plan.

Activity Hazard Analysis.

Work plan.

Quality control plan.

Environmental protection plan.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. (Testing must have been within three years of date of contract award for the project.)

Report which includes findings of a test required to be performed by the Contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports.

Daily logs and checklists.

Final acceptance test and operational test procedure.

SD-07 Certificates

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that product, system or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

SECTION 01 33 00 Page 1

Document required of Contractor, or of a manufacturer, supplier, installer or subcontractor through Contractor, the purpose of which is to further quality of orderly progression of a portion of the work by documenting procedures, acceptability of methods or personnel qualifications.

Confined space entry permits.

Text of posted operating instructions.

1.1.2 Approving Authority

Office authorized to approve submittal; such as

Area Office Field (AOF) Real Estate Office (REO) Engineering, Design and Construction Office (EDC)

1.1.3 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction.

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only or as otherwise designated. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section

01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Submittal register; G

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

SECTION 01 33 00 Page 2

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 1 OF 3 PAGES

FY16 MD St. Joseph Harbor Inner - Ready To Advertise

01 10 10 SD-01 Preconstruction Submittals

1.2.2 G REOAdditional Property Agreements

Certified Survey Results 01 33 00 SD-01 Preconstruction Submittals

GSubmittal register 01 35 13.10 SD-01 Preconstruction Submittals

1.6.2Payrolls and Basic Records

1.6.3 G AOFProgress Chart

SD-07 Certificates Survey Technician's Qualifications

01 35 26 SD-01 Preconstruction Submittals

1.6 G AOFAccident Prevention Plan (APP)

G AOFActivity Hazard Analysis (AHA) G AOFCrane Critical Lift Plan G AOFCrane Operators G AOFSite Layout Plan

SD-06 Test Reports 1.11Notifications and Reports

G AOFAccident Reports Crane Reports

SD-07 Certificates 1.8Confined Space Entry Permit 1.8Hot work permit 1.13License Certificates

1.11.4 G AOFCertificate of Compliance

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P H

C L A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r)

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 2 OF 3 PAGES

01 45 04.00 10 SD-01 Preconstruction Submittals G AOFCorporate Contractor Quality

Control Plan G AOFContractor Quality Control Plan

01 57 20.00 20 SD-01 Preconstruction Submittals G AOFEnvironmental Protection Plan

35 20 23.13 SD-01 Preconstruction Submittals G AOFDredge Plant Instrumentation

Plan G AOFContractor Quality Control Plan

SD-06 Test Reports G AOFData Appropriately Archived e-mail SD-07 Certificates

G AOFLetter of National Dredging Quality Management Program Certification

35 20 23 SD-01 Preconstruction Submittals Sounding Equipment Description and Calibration Data

1.6 G AOFDredging, Conveyance and

Placement Plan

G AOFDredging Placement Safety Plan;

3.1Notice of Start of Dredging;

SD-02 Shop Drawings Submerged Pipeline

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 3 OF 3 PAGES

35 20 23 Soundings SD-06 Test Reports

G AOFDaily Report of Dredging Operations;

SD-11 Closeout Submittals Material Disposal Records

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SECTION 01 35 13.10

SPECIAL PROJECT PROCEDURES

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

U.S. GOVERNMENT CODE OF FEDERAL REGULATIONS (CFR)

33 CFR 320-330 General Regulatory Policies, Permits, Enforcement and Definitions

40 CFR 233 State Program Regulations

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only or as otherwise designated. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section

01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Payrolls and Basic Records

Progress Chart; G-AOF

Contractor shall submit progress chart in accordance with the Contract clause entitled "SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)".

SD-07 Certificates

Survey Technician's Qualifications

Submit the identity and qualifications of the persons assigned to conduct surveys at least ten (10) calendar days in advance of conducting any surveys.

1.3 REGULATORY REQUIREMENTS

1.3.1 Additional Work Proposed and Not Authorized

1.3.1.1 Work Subject to 33 CFR 320-330

Any additional work (not specifically shown on the plans or delineated in the specifications) proposed by the Contractor in or affecting navigable waters, including wetlands (as defined in 33 CFR 320-330, published in the

SECTION 01 35 13.10 Page 1

Federal Register Vol.51, No. 219, Thursday, November 13, 1986) shall not be performed without a Department of the Army Permit. This requirement shall be applicable to all work, permanent or temporary, and/or fill(s).

The Department of the Army Permit shall be approved by the District Engineer or Deputy District Engineer in accordance with the laws of the United States and the regulations promulgated thereunder, including, but not limited to, the Rivers and Harbors Act of 1899, the Clean Water Act and the National Environmental Policy Act of 1969, as amended. Corps employees (Contracting Officer's Representatives (COR) or inspectors) are not delegated authority to authorize such work. Information on making application for such permit(s) may be obtained by contacting one of the offices as listed hereinafter. When applying for information or a permit, a copy of any correspondence should be directed to the Contracting Officer of this contract. If a permit is not obtained, the additional work cannot be accomplished. Any delay in processing the permit will not constitute the basis of a claim under this contract. The fact that the Contractor is performing work under a Department of the Army Contract will give the Contractor no greater rights than any other applicant for a Department of the Army Permit.

MICHIGAN-INDIANA

Regulatory Branch Engineering and Technical Services Division U.S. Army Engineer District, Detroit P. O. Box 1027 Detroit, MI 48231 Telephone: 313-226-6813

1.3.1.2 Work Subject to 40 CFR 233

Any additional work (not specifically shown on the plans or included in the specifications), proposed by the Contractor, in or affecting waters of the United States, including wetlands, in the States of Michigan, Illinois, Indiana, Ohio, Pennsylvania, New York, Wisconsin or Minnesota (as defined in 40 CFR 233, published in the Federal Register, Vol. 49 No. 192, Tuesday October 2, 1984) shall not be performed without a proper regulatory permit. Information on making an application for such permit may be obtained by contacting one of the offices listed hereinafter. When applying for a permit or for information, a copy of any correspondence shall be furnished to the Contracting Officer. If a permit is not obtained, the additional work shall not be performed. Any delay in obtaining or processing the permit will not constitute a basis for a claim under this contract.

STATE OF MICHIGAN

Department of Environmental Quality Land & Water Management Division P.O. Box 30458 Constitution Hall Lansing, MI 48909 Telephone: 517-373-1170

1.4 PROJECT/SITE CONDITIONS

1.4.1 Condition and Use of Project Site

The contract drawings will indicate soundings and elevations at the

SECTION 01 35 13.10 Page 2 dredging and placement site as found in condition surveys made as stated on the contract drawings. A notification of at least five (5) calendar days shall be given to the Contracting Officer prior to bringing any construction equipment or material upon the work site. The Contractor shall be responsible for damages that may be suffered due to its operations. The Contractor shall note CLAUSE titled "PROTECTION OF

EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS."

1.4.1.1 Physical Conditions

The physical conditions shown on the contract drawings are indicative of those that prevailed at the time of the site investigations and may be different than those at the time of construction. Significant variations that would require changes to the plans or specification shall be reported to the Contracting Officer immediately.

1.4.2 Waterways Navigation and Traffic

The Contractor shall acquaint itself with all information and regulations pertaining to navigation and vessel traffic within the waterways at the project site. The Contractor shall coordinate with the U.S. Coast Guard to assure that a "NOTICE TO MARINERS" is issued prior to its work activity at the project site. The completed form shall be sent to the address stated in the Subparagraph entitled "Temporary Lights, Signals and Buoys Required by U.S. Coast Guard". The Government will not undertake to keep the waterways free from vessels or other obstructions, except to the extent of such regulations, if any, as may be prescribed by the Secretary of the Army, in accordance with the provisions of Section 7 of the Rivers and Harbors Act approved 8 August 1917 (see Title 33, U.S.C.A. Sec. 1). The Contractor is required to conduct its work in such manner as to obstruct navigation as little as possible and, in case the Contractor's plant so obstructs a channel as to make difficult or endanger the passage of vessels, said plant shall be promptly moved on the approach of any vessel to such an extent as may be necessary to afford a practicable passage.

Upon completion of the work, the Contractor shall promptly remove its plant, including ranges, buoys, piles, and other marks placed by it under the contract in navigable waters or on shore.

1.4.2.1 Navigation

Information and regulations pertaining to navigation may be obtained from the current issue of the "UNITED STATES COAST PILOT 6," issued annually by the Department of Commerce, National Oceanic and Atmospheric Administration (NOAA). The "UNITED STATES COAST PILOT" may be obtained from National Ocean Survey, NOAA, Distribution Division-C44, Riverdale, Maryland 20840.

1.4.2.2 Traffic

Vessels that may use the waterways at the project site consist of recreational craft and commercial vessels. This traffic may interfere with contract operations and the Contractor shall conduct its work with due regard to and in coordination with the requirements of all navigation.

Information regarding the types and amount of passages made by commercial vessels that may use the waterways at the project site may be obtained from the current issue of the "Waterborne Commerce of the United States, Part 3, Waterways and Harbors, Great Lakes," published by the Department of Army, Corps of Engineers. The Department of the Army publication may be obtained at no charge from the following:

SECTION 01 35 13.10 Page 3

District Engineer, U.S. Army Engineer District, New Orleans, Waterborne Commerce Section, P.O. Box 60267, New Orleans, Louisiana 70160. Phone

504-862-1425, FAX 504-862-1091.

1.4.3 Existing Vegetation, Structures, Equipment, Utilities & Improvements

General locations of applicable existing utilities, vegetation, structures, equipment and improvements, based upon latest information available to the Government will be shown on the contract drawings. However, it is the Contractor's obligation to establish the exact horizontal and vertical location and size of all existing utility lines which are located within the required work area. The Contractor shall submit a utility locating plan for locating existing utilities and a copy of its utility location findings prior to commencing work on the site. Any utility lines which are not found by the Contractor, but which are known to exist at the project site, shall be reported to the Contracting Officer immediately. The Contracting Officer will have the option of directing commencement of work at the site or requiring the Contractor to submit further plans for locating the utility lines. Once the utilities have been located and marked, the Contractor shall be deemed to have the location made known to it pursuant to CLAUSE titled "PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS." If the Contractor damages any existing utility line, vegetation, structure, equipment or improvement, a report thereof shall be made immediately to the Contracting Officer. In any event, existing utility lines, vegetation, structures, equipment or improvements shall be protected from damage, and if damaged, shall be repaired by the Contractor at its own expense.

1.4.4 Identification of Employees

The Contractor shall be responsible for requiring each employee engaged on the work to wear a hardhat with labeling as required to identify that the person is an employee of the Contractor or to display other identification as may be approved.

1.4.5 Contract Supervision and Representation

The Contractor's local representative shall be available to Government representatives during duty hours, 8 a.m. to 4:30 p.m., on normal working days and shall be available by telephone at other times. The name of the Contractor's representative and the contact telephone number shall be furnished to the Government.

1.4.6 Traffic Control Plan

The Contractor shall control traffic in accordance with its approved plan.

The traffic control plan shall be in detail and size specific for the control of traffic on the public roadways adjacent to the work area.

Coordination of construction traffic with public use of the roadways shall be fully described, including all safety related characteristics.

1.4.7 Temporary Lights, Signals and Buoys Required by Coast Guard

All temporary lights, signals and buoys required by the U.S. Coast Guard must be displayed during the required work. Information regarding required signals, lights, buoys and other requirements may be obtained from the Commander (oan), Ninth Coast Guard District, 1240 East Ninth Street, Cleveland, Ohio 44199-2060, Telephone (216) 522-3990.

SECTION 01 35 13.10 Page 4

1.4.8 Navigation Buoys

1.4.8.1 Relocation of Existing Buoys

If the relocation of existing navigation buoys is required to perform the contract work, the Contractor shall request permission for their relocation from the U.S. Coast Guard through the Contracting Officer. Once relocated, a record shall be maintained of the buoy relocation position(s). The request shall be provided to the Contracting Officer not less than three

(3) weeks prior to need of the buoy relocation. The Contractor shall be responsible for performing the relocation work, which shall be in accordance with U.S. Coast Guard requirements.

1.4.8.2 Temporary Dredging and Construction Buoys

In order to distinguish temporary buoys placed and maintained by the Contractor for dredging or construction purposes from aids to navigation placed by the U.S. Coast Guard, the Contractor's buoys shall be white and the top two (2) feet shall be light green in color. The Contractor shall remove its temporary buoys at the completion of the work.

1.4.8.3 Buoy Markings

If buoys with special markings are needed to indicate the different sides of the navigable channel, prior arrangements shall be made with the U.S.

Coast Guard, through the Contracting Officer.

1.4.9 Layout of Work and Surveys

1.4.9.1 Layout of Work

The following requirements are in addition to the requirements of CLAUSE titled "LAYOUT OF WORK, (APR 1984)." The Government has established bench marks and horizontal control points at the site of the work. Horizontal control points and descriptions of bench marks shall be provided by the Lake Michigan Area Office. The elevations of bench marks are referred to mean water levels indicated on the contract drawings.

1.4.9.2 Surveyor Requirements

From these control points and bench marks, the Contractor shall lay out the work by establishing all lines, grades, range markers and gauges at the site as necessary to control the work. All survey information shall be recorded in accordance with standard and approved methods and in the survey note format approved by the COR. All field notes, sketches, recordings and computations made by the Contractor in performing the layout work shall be available at all times during the progress of the work for ready examination by the Contracting Officer or his or her duly authorized representative and upon completion of the contract work the originals shall be submitted electronically to the Contracting Officer.

1.4.9.3 Adequacy of Layout

The Contracting Officer may require that work be interrupted at any time when location and limit marks established by the Contractor are not reasonably adequate to permit checking the work. Such interruption will be withdrawn upon satisfactory replacement of location and limit marks. Such interruption shall be at no additional cost to the Government and shall not entitle the Contractor to an extension of time for completing the work.

SECTION 01 35 13.10 Page 5

1.4.9.4 Verification

The Government may make checks as the work progresses to verify lines and grades established by the Contractor and to determine the conformance of the completed work as it progresses with the requirements of contract specifications and drawings. Such checking by the Contracting Officer or his or her representative shall not relieve the Contractor of its responsibility to perform all work in accordance with the contract drawings and specifications and the lines and grades given therein.

1.5 SEQUENCING AND SCHEDULING

1.5.1 Exclusion of Period in Computing Completion Schedules

No work will be required during the period between 15 December and 01 April inclusive and the days in this period will not be counted when computing the required completion date. The Contractor may perform work, unless otherwise prohibited, during all or any part of this period upon giving prior written notice to the Contracting Officer.

1.5.2 Dredging and Work Period Restrictions

The following work period resrictions apply:

No work is allowed at the project sites during the following Holiday periods:

6:00 p.m. 1 July 2016 to 6:00 a.m. 5 July 2016

(for other restrictions Refer to specification section 01 57 20.00 20 paragraph 3.4.3).

The number of calendar days within which the Contractor is required to complete the work, as established in Clause titled "COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK", is exclusive of the above referenced periods during which dredging is prohibited and the days in these periods will not be counted when computing the required completion date.

1.5.3 Sunday, Holiday And Night Operations

When the Contractor elects to work on Saturdays, Sundays, holidays or nights when not prohibited herein, notice of its intention to do so shall be given to the Contracting Officer not less than forty-eight (48) hours in advance thereof. Adequate lighting for thorough inspection of night operations shall be provided by the Contractor at its expense.

1.5.4 Start Work

The Contractor shall be advised that the airport operations may have an impact on their operations and therefore, the contractor shall become familiar with the airport operation, and coordinate placement operations with the Contracting Officer Representative (COR). Evidence that the Contractor has started mobilization and preparation of submittal register, and other preparatory work will satisfy the requirement that work commence within ten (10) calendar says after receipt of Notice to Proceed.(See Clause titled COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK)

SECTION 01 35 13.10 Page 6

1.6 REPORT REQUIREMENTS

1.6.1 Accident Prevention Plan

Contractor shall submit the Accident Prevention Plan shall be in accordance with Contract Clause entitled "ACCIDENT PREVENTION (NOV 1991) - ALTERNATE 1.

1.6.2 Payrolls and Basic Records

Contractor shall submit payrolls and basic records in accordance with the CLAUSE entitled "PAYROLLS AND BASIC RECORDS ".

1.6.3 Progress Chart

Contractor shall submit progress chart in accordance with the Contract clause entitled "SCHEDULE FOR CONSTRUCTION CONTRACTS (APR 1984)".

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

SECTION 01 35 13.10 Page 7

SECTION 01 35 26

GOVERNMENTAL SAFETY REQUIREMENTS

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AMERICAN SOCIETY OF SAFETY ENGINEERS (ASSE/SAFE)

ASSE/SAFE A10.32 (2012) Fall Protection

ASSE/SAFE A10.34 (2001; R 2012) Protection of the Public on or Adjacent to Construction Sites

ASSE/SAFE Z359.1 (2007) Safety Requirements for Personal Fall Arrest Systems, Subsystems and Components

ASME INTERNATIONAL (ASME)

ASME B30.22 (2010) Articulating Boom Cranes

ASME B30.3 (2012) Tower Cranes

ASME B30.5 (2011) Mobile and Locomotive Cranes

ASME B30.8 (2010) Floating Cranes and Floating Derricks

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 10 (2013) Standard for Portable Fire Extinguishers

NFPA 51B (2014) Standard for Fire Prevention During Welding, Cutting, and Other Hot Work

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

10 CFR 20 Standards for Protection Against Radiation

29 CFR 1910 Occupational Safety and Health Standards

29 CFR 1910.146 Permit-required Confined Spaces

29 CFR 1926 Safety and Health Regulations for Construction

SECTION 01 35 26 Page 1

29 CFR 1926.16 Rules of Construction

29 CFR 1926.500 Fall Protection

CPL 2.100 (1995) Application of the Permit-Required Confined Spaces (PRCS) Standards, 29 CFR 1910.146

33 CFR 83 Navigation and Navigable Waters

1.2 DEFINITIONS

a. Mishap. Any unplanned, undesired event that occurs during the course of work being performed. The term "mishap" includes accidents, incidents and near-misses.

b. "USACE" property and equipment specified in USACE EM 385-1-1 should be interpreted as Government property and equipment.

c. Load Handling Equipment (LHE). Load Handling Equipment includes cranes, derricks, hoists, and power-operated equipment that can be used to raise, lower and/or horizontally move a suspended load.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Accident Prevention Plan (APP); G-AOF

Activity Hazard Analysis (AHA); G-AOF

Crane Critical Lift Plan; G-AOF

Proof of qualification for Crane Operators; G-AOF

Site Layout Plan; G-AOF

SD-06 Test Reports

Notifications and Reports

Submit reports as their incidence occurs, in accordance with the requirements of the paragraph, "Notifications and Reports."

Accident Reports; G-AOF

Crane Reports

SD-07 Certificates

Confined Space Entry Permit

SECTION 01 35 26 Page 2

Hot work permit

License Certificates

Certificate of Compliance; G-AOF

See paragraph 1.11.4, "Certificate of Compliance"

1.4 REGULATORY REQUIREMENTS

In addition to the detailed requirements included in the provisions of this contract, comply with the most recent edition of USACE EM 385-1-1, and all federal, state, and local laws, ordinances, criteria, rules and regulations. Submit matters of interpretation of standards to the appropriate administrative agency for resolution before starting work.

Where the requirements of this specification, applicable laws, criteria, ordinances, regulations, and referenced documents vary, the most stringent requirements govern.

1.5 SITE QUALIFICATIONS, DUTIES AND MEETINGS

1.5.1 Personnel Qualifications

1.5.1.1 Site Safety and Health Officer (SSHO)

The SSHO must meet the requirements of EM 385-1-1 section 1 and ensure that the requirements of 29 CFR 1926.16 are met for the project. Provide a Safety oversight team that includes a minimum of one (1) person at each project site to function as the Site Safety and Health Officer (SSHO). The SSHO or an equally-qualified Designated Representative/alternate shall be at the work site at all times to implement and administer the Contractor's safety program and government-accepted Accident Prevention Plan. The SSHO's training, experience, and qualifications shall be as required by EM 385-1-1 paragraph 01.A.17, entitled CONTRACTOR SITE SAFETY AND HEALTH OFFICER (SSHO), and all associated sub-paragraphs.

A Competent Person shall be provided for all of the hazards identified in the Contractor's Safety and Health Program in accordance with the accepted Accident Prevention Plan, and shall be on-site at all times when the work that presents the hazards associated with their professional expertise is being performed. Provide the credentials of the Competent Persons(s) to the Contracting Officer for acceptance in consultation with the Safety Office.

1.5.1.1.1 Contractor Quality Control (QC) Person:

The Contractor Quality Control Person can be the SSHO on this project.

1.5.1.2 USACE Dredging Contract Requirements

1.5.1.2.1 SSHO Staffing for USACE Dredging Contracts

a. Dredging contracts may include several project sites; this contract will require a minimum of one full time SSHO(s) assigned per project site. SSHO may be collateral duty in specific conditions listed below.

b. Example of one dredging project site is reflected in each of the following:

SECTION 01 35 26 Page 3

(1) a mechanical dredge, tug(s) and scow(s), scow route, and material placement site; or

(2) a hydraulic pipeline dredge, attendant plant, and material placement site; or,

(3) a hopper dredge (include land-based material placement site - if applicable.)

c. Individual dredging project sites with work force less than 8 employees, the SSHO may be a collateral duty, with the same responsibilities of a full time SSHO.

d. Hopper dredges with USCG-Documented crews may designate an officer as a collateral-duty SSHO instead of having a full-time SSHO if the officer meets the SSHO training and experience requirements.

1.5.1.2.2 SSHO Requirements for Dredging

a. In addition to requirements stated elsewhere in this specification, the SSHO shall be present at the project site, located so they have full mobility and reasonable access to all major work operations, for at least one shift in each 24 hour period when work is being done. The SSHO, or Alternate SSHO, shall be available during all shifts for immediate verbal consultation and notification, either by phone or radio. The SSHO shall be a full-time, dedicated position, except as noted above. The SSHO shall report to a senior project (or corporate) officials.

b. The SSHO shall inspect all work areas and operations during initial set-up and at least monthly observe and provide personal oversight on each shift during dredging operations for projects with many work sites, more often for those with less work sites.

c. For projects with multiple shifts or when SSHO is temporarily off-site for a period longer than 24 hours, an Alternate SSHO will be assigned to insure SSHO coverage for the project at all times work activities are conducted. The Alternate SSHO must meet the same requirements and assume the responsibilities of the project SSHO. The Alternate SSHO position may be a collateral duty.

d. If the SSHO is temporarily off-site for less than 24 hours, a Designated Representative (DR) can be used in lieu of an Alternate SSHO and shall be on the project site at all times when work is being performed. See section 1.5.1.2.3. for DR requirements.

1.5.1.2.3 Designated Representative (DR) Requirements for Dredging

a. Designated Representatives (DR) are collateral duty safety personnel, with safety duties in addition to their full-time occupation, and support and supplement the SSHO efforts in managing, implementing and enforcing the Contractor's Safety and Health Program. DRs shall be individual(s) with work oversight responsibilities, such as masters, mates, fill foremen, and superintendents. DRs should not be positions requiring continuous mechanical or equipment operations, such as equipment operators.

b. If a Definable Feature of Work (DFOW)/activity has multiple sites and a

SECTION 01 35 26 Page 4

RAC of low or medium, a DR shall be appointed for all remote work locations more than 45 minutes travel time from the SSHO's duty location, typically including dredged material placement sites, towing and scow operations, and other operations. A DR may NOT be assigned to projects that have a RAC level of high or extremely high.

c. The DRs will perform safety program tasks as designated by the SSHO and report safety findings to the SSHO/Alternate SSHO.