W911XK-09-D-0006-DN01.doc

Section 00010 - Solicitation Contract Form

MOB/DEMOB

FFP

OMINBUS FUNDS

FOB: Destination

PURCHASE REQUEST NUMBER: W81EU692106930

ACRN AA

CIN: W81EU6921069300001

$50,520.00

DUNKIRK HARBOR DREDGING AREA A

ARRA

ACRN AB

CIN: W81EU6921069300002

$215,000.00

DUNKIRK HARBOR DREDGING AREA B

ARRA

ACRN AB

CIN: W81EU6921069300003

$120,400.00

DUNKIRK HARBOR DREDGING AREA C

ARRA

ACRN AB

CIN: W81EU6921069300004

$86,000.00

DUNKIRK HARBOR DREDGING AREA D

OMNIBUS

ACRN AA

CIN: W81EU6921069300005

$40,530.00

DUNKIRK HARBOR DREDGING AREA E

OMNIBUS

ACRN AA

CIN: W81EU6921069300006

$59,830.00

DUNKIRK HARBOR DREDGING AREA F

OMNIBUS

ACRN AA

CIN: W81EU6921069300007

$86,850.00

DUNKIRK HARBOR DREDGING

OPTION A (ARRA)

ACRN AB

CIN: W81EU6921069300008

$328,592.00

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

DELIVERY INFORMATION

MICHAEL D. ASQUITH

1776 NIAGARA STREET

BUFFALO NY 14207-3199

716-879-4352

CLAUSES INCORPORATED BY FULL TEXT

52.204-11 AMERICAN RECOVERY AND REINVESTMENT ACT-REPORTING REQUIREMENTS (MAR 2009)

(a) Definitions. As used in this clause—

Contract, as defined in FAR 2.101, means a mutually binding legal relationship obligating the seller to furnish the supplies or services (including construction) and the buyer to pay for them. It includes all types of commitments that obligate the Government to an expenditure of appropriated funds and that, except as otherwise authorized, are in writing. In addition to bilateral instruments, contracts include (but are not limited to) awards and notices of awards; job orders or task letters issued under basic ordering agreements; letter contracts; orders, such as purchase orders, under which the contract becomes effective by written acceptance or performance; and bilateral contract modifications. Contracts do not include grants and cooperative agreements covered by 31 U.S.C. 6301, et seq. For discussion of various types of contracts, see FAR Part 16.

First-tier subcontract means a subcontract awarded directly by a Federal Government prime contractor whose contract is funded by the Recovery Act.

Jobs created means an estimate of those new positions created and filled, or previously existing unfilled positions that are filled, as a result of funding by the American Recovery and Reinvestment Act of 2009 (Recovery Act). This definition covers only prime contractor positions established in the United States and outlying areas (see definition in FAR 2.101). The number shall be expressed as “full-time equivalent” (FTE), calculated cumulatively as all hours worked divided by the total number of hours in a full-time schedule, as defined by the contractor. For instance, two full-time employees and one part-time employee working half days would be reported as 2.5 FTE in each calendar quarter.

Jobs retained means an estimate of those previously existing filled positions that are retained as a result of funding by the American Recovery and Reinvestment Act of 2009 (Recovery Act). This definition covers only prime contractor positions established in the United States and outlying areas (see definition in FAR 2.101). The number shall be expressed as “full-time equivalent” (FTE), calculated cumulatively as all hours worked divided by the total number of hours in a full-time schedule, as defined by the contractor. For instance, two full-time employees and one part-time employee working half days would be reported as 2.5 FTE in each calendar quarter.

Total compensation means the cash and noncash dollar value earned by the executive during the contractor’s past fiscal year of the following (for more information see 17 CFR 229.402(c)(2)):

(1) Salary and bonus.

(2) Awards of stock, stock options, and stock appreciation rights. Use the dollar amount recognized for financial statement reporting purposes with respect to the fiscal year in accordance with the Statement of Financial Accounting Standards No. 123 (Revised 2004) ( FAS 123R), Shared Based Payments.

(3) Earnings for services under non-equity incentive plans. Does not include group life, health, hospitalization or medical reimbursement plans that do not discriminate in favor of executives, and are available generally to all salaried employees.

(4) Change in pension value. This is the change in present value of defined benefit and actuarial pension plans.

(5) Above-market earnings on deferred compensation which is not tax-qualified.

(6) Other compensation. For example, severance, termination payments, value of life insurance paid on behalf of the employee, perquisites or property if the value for the executive exceeds $10,000.

(b) This contract requires the contractor to provide products and/or services that are funded under the American Recovery and Reinvestment Act of 2009 (Recovery Act). Section 1512(c) of the Recovery Act requires each contractor to report on its use of Recovery Act funds under this contract. These reports will be made available to the public.

(c) Reports from contractors for all work funded, in whole or in part, by the Recovery Act, and for which an invoice is submitted prior to June 30, 2009, are due no later than July 10, 2009. Thereafter, reports shall be submitted no later than the 10th day after the end of each calendar quarter.

(d) The Contractor shall report the following information, using the online reporting tool available at www.FederalReporting.gov.

(1) The Government contract and order number, as applicable.

(2) The amount of Recovery Act funds invoiced by the contractor for the reporting period. A cumulative amount from all the reports submitted for this action will be maintained by the government's on-line reporting tool.

(3) A list of all significant services performed or supplies delivered, including construction, for which the contractor invoiced in this calendar quarter.

(4) Program or project title, if any.

(5) A description of the overall purpose and expected outcomes or results of the contract, including significant deliverables and, if appropriate, associated units of measure.

(6) An assessment of the contractor’s progress towards the completion of the overall purpose and expected outcomes or results of the contract (i.e., not started, less than 50 percent completed, completed 50 percent or more, or fully completed). This covers the contract (or portion thereof) funded by the Recovery Act.

(7) A narrative description of the employment impact of work funded by the Recovery Act. This narrative should be cumulative for each calendar quarter and only address the impact on the contractor’s workforce. At a minimum, the contractor shall provide—

(i) A brief description of the types of jobs created and jobs retained in the United States and outlying areas (see definition in FAR 2.101). This description may rely on job titles, broader labor categories, or the contractor’s existing practice for describing jobs as long as the terms used are widely understood and describe the general nature of the work; and

(ii) An estimate of the number of jobs created and jobs retained by the prime contractor, in the United States and outlying areas. A job cannot be reported as both created and retained.

(8) Names and total compensation of each of the five most highly compensated officers of the Contractor for the calendar year in which the contract is awarded if—

(i) In the Contractor’s preceding fiscal year, the Contractor received—

(A) 80 percent or more of its annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants) and cooperative agreements; and

(B) $25,000,000 or more in annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants) and cooperative agreements; and

(ii) The public does not have access to information about the compensation of the senior executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986.

(9) For subcontracts valued at less than $25,000 or any subcontracts awarded to an individual, or subcontracts awarded to a subcontractor that in the previous tax year had gross income under $300,000, the Contractor shall only report the aggregate number of such first tier subcontracts awarded in the quarter and their aggregate total dollar amount.

(10) For any first-tier subcontract funded in whole or in part under the Recovery Act, that is over $25,000 and not subject to reporting under paragraph 9, the contractor shall require the subcontractor to provide the information described in (i), (ix), (x), and (xi) below to the contractor for the purposes of the quarterly report. The contractor shall advise the subcontractor that the information will be made available to the public as required by section 1512 of the Recovery Act. The contractor shall provide detailed information on these first-tier subcontracts as follows:

(i) Unique identifier (DUNS Number) for the subcontractor receiving the award and for the subcontractor’s parent company, if the subcontractor has a parent company.

(ii) Name of the subcontractor.

(iii) Amount of the subcontract award.

(iv) Date of the subcontract award.

(v) The applicable North American Industry Classification System (NAICS) code.

(vi) Funding agency.

(vii) A description of the products or services (including construction) being provided under the subcontract, including the overall purpose and expected outcomes or results of the subcontract.

(viii) Subcontract number (the contract number assigned by the prime contractor).

(ix) Subcontractor’s physical address including street address, city, state, and country. Also include the nine-digit zip code and congressional district if applicable.

(x) Subcontract primary performance location including street address, city, state, and country. Also include the nine-digit zip code and congressional district if applicable.

(xi) Names and total compensation of each of the subcontractor’s five most highly compensated officers, for the calendar year in which the subcontract is awarded if—

(A) In the subcontractor’s preceding fiscal year, the subcontractor received—

(l) 80 percent or more of its annual gross revenues in Federal contracts (and subcontracts), loans, grants (and subgrants), and cooperative agreements; and

(2) $25,000,000 or more in annual gross revenues from Federal contracts (and subcontracts), loans, grants (and subgrants), and cooperative agreements; and

(B) The public does not have access to information about the compensation of the senior executives through periodic reports filed under section 13(a) or 15(d) of the Securities Exchange Act of 1934 (15 U.S.C. 78m(a), 78o(d)) or section 6104 of the Internal Revenue Code of 1986.

(End of clause)

52.215-2 AUDIT AND RECORDS--NEGOTIATION (MAR 2009) - ALTERNATE I MAR 2009)

(a) As used in this clause, "records" includes books, documents, accounting procedures and practices, and other data, regardless of type and regardless of whether such items are in written form, in the form of computer data, or in any other form.

(b) Examination of costs. If this is a cost-reimbursement, incentive, time-and-materials, labor-hour, or price redeterminable contract, or any combination of these, the Contractor shall maintain and the Contracting Officer, or an authorized representative of the Contracting Officer, shall have the right to examine and audit all records and other evidence sufficient to reflect properly all costs claimed to have been incurred or anticipated to be incurred directly or indirectly in performance of this contract. This right of examination shall include inspection at all reasonable times of the Contractor's plants, or parts of them, engaged in performing the contract. The obligations and rights specified in this paragraph shall extend to the use of, and charges for the use of, the facilities under this contract.

(c) Cost or pricing data. If the Contractor has been required to submit cost or pricing data in connection with any pricing action relating to this contract, the Contracting Officer, or an authorized representative of the Contracting Officer, in order to evaluate the accuracy, completeness, and currency of the cost or pricing data, shall have the right to examine and audit all of the Contractor's records, including computations and projections, related to--

(1) The proposal for the contract, subcontract, or modification;

(2) The discussions conducted on the proposal(s), including those related to negotiating;

(3) Pricing of the contract, subcontract, or modification; or

(4) Performance of the contract, subcontract or modification.

(d) Comptroller General or Inspector General. (1) The Comptroller General of the United States, an appropriate Inspector General appointed under section 3 or 8G of the Inspector General Act of 1978 (5 U.S.C. App.), or an authorized representative of either of the foregoing officials, shall have access to and the right to—

(i) Examine any of the Contractor’s or any subcontractor’s records that pertain to and involve transactions relating to this contract or a subcontract hereunder; and

(ii) Interview any officer or employee regarding such transactions.

(2) This paragraph may not be construed to require the Contractor or subcontractor to create or maintain any record that the Contractor or subcontractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) Reports. If the Contractor is required to furnish cost, funding, or performance reports, the Contracting Officer or an authorized representative of the Contracting Officer shall have the right to examine and audit the supporting records and materials, for the purpose of evaluating (1) the effectiveness of the Contractor's policies and procedures to produce data compatible with the objectives of these reports and (2) the data reported.

(f) Availability. The Contractor shall make available at its office at all reasonable times the records, materials, and other evidence described in paragraphs (a), (b), (c), (d), and (e) of this clause, for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in Subpart 4.7, Contractor Records Retention, of the Federal Acquisition Regulation (FAR), or for any longer period required by statute or by other clauses of this contract. In addition--

(1) If this contract is completely or partially terminated, the Contractor shall make available the records relating to the work terminated until 3 years after any resulting final termination settlement; and

(2) The Contractor shall make available records relating to appeals under the Disputes clause or to litigation or the settlement of claims arising under or relating to this contract until such appeals, litigation, or claims are finally resolved.

(g) )(1) Except as provided in paragraph (g)(2) of this clause, the Contractor shall insert a clause containing all the terms of this clause, including this paragraph (g), in all subcontracts under this contract. The clause may be altered only as necessary to identify properly the contracting parties and the Contracting Officer under the Government prime contract.

(2) The authority of the Inspector General under paragraph (d)(1)(ii) of this clause does not flow down to subcontracts.

The clause may be altered only as necessary to identify properly the contracting parties and the Contracting Officer under the Government prime contract.

(End of clause)

Section 00800 - Special Contract Requirements

ACCOUNTING AND APPROPRIATION DATA

AA: 96 NA X 3123.0000 H5 X 08 2425 050600 96301 3230 0JGD1D NA 1K5D0C

AMOUNT: $237,730.00

CIN W81EU6921069300001: $50,520.00

CIN W81EU6921069300005: $40,530.00

CIN W81EU6921069300006: $59,830.00

CIN W81EU6921069300007: $86,850.00

AB: 96 NA 2009 3135.0000 H5 2009 08 2425 050600 96301 3230 0JGD1D NA LF8521

AMOUNT: $749,992.00

CIN W81EU6921069300002: $215,000.00

CIN W81EU6921069300003: $120,400.00

CIN W81EU6921069300004: $86,000.00

CIN W81EU6921069300008: $328,592.00

CLAUSES INCORPORATED BY FULL TEXT

52.203-15 Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (MAR 2009)

(a) The Contractor shall post notice of employees rights and remedies for whistleblower protections provided under section 1553 of the American Recovery and Reinvestment Act of 2009 (Pub. L. 111-5).

(b) The Contractor shall include the substance of this clause including this paragraph (b) in all subcontracts.

(End of clause)

52.225-21 Required Use of American Iron, Steel, and Other Manufactured Goods—Buy American Act—Construction Materials (MAR 2009)

(a) Definitions. As used in this clause—

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Domestic construction material means—

(1) An unmanufactured construction material mined or produced in the United States; or

(2) A construction material manufactured in the United States.

Foreign construction material means a construction material other than a domestic construction material.

Manufactured construction material means any construction material that is not unmanufactured construction material.

Steel means an alloy that includes at least 50 percent iron, between .02 and 2 percent carbon, and may include other elements.

United States means the 50 States, the District of Columbia, and outlying areas.

Unmanufactured construction material means raw material brought to the construction site for incorporation into the building or work that has not been—

(1) Processed into a specific form and shape; or

(2) Combined with other raw material to create a material that has different properties than the properties of the individual raw materials.

(b) Domestic preference.

(1) This clause implements—

(i) Section 1605 of the American Recovery and Reinvestment Act of 2009 (Recovery Act) (Pub. L. 111-5), by requiring, unless an exception applies, that all iron, steel, and other manufactured goods used as construction material in the project are produced in the United States; and

(ii) The Buy American Act (41 U.S.C. 10a - 10d) by providing a preference for unmanufactured domestic construction material.

(2) The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraph (b)(3) and (b)(4) of this clause.

(3) This requirement does not apply to the construction material or components listed by the Government as follows:

(Contracting Officer to list applicable excepted materials or indicate “none”)

(4) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(3) of this clause if the Government determines that—

(i) The cost of domestic construction material would be unreasonable.

(A) The cost of domestic iron, steel, or other manufactured goods used as construction material is unreasonable when the cumulative cost of such material will increase the cost of the contract by more than 25 percent;

(B) The cost of unmanufactured construction material is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available quantities and of a satisfactory quality; or

(iii) The application of the restriction of section 1605 of the Recovery Act or the Buy American Act to a particular construction material would be inconsistent with the public interest.

(c) Request for determination of inapplicability of Section 1605 of the Recovery Act or the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(4) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Cost;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(4) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed cost comparison table in the format in paragraph (d) of this clause.

(iii) The cost of construction material shall include all delivery costs to the construction site and any applicable duty.

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to section 1605 of the Recovery Act or the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable cost of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(4)(i) of this clause.

(3) Unless the Government determines that an exception to section 1605 of the Recovery Act or the Buy American Act applies, use of foreign construction material is noncompliant with section 1605 of the American Recovery and Reinvestment Act or the Buy American Act.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Cost Comparison

Construction Material

Unit of Quantity Cost (Dollars)*

Description

Measure

Item 1:

Foreign construction material _______

Domestic construction material_______

Item 2:

Foreign construction material _______

Domestic construction material_______

(List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.)

(Include other applicable supporting information.)

(* Include all delivery costs to the construction site.])

(End of clause)

52.225-22 Notice of Required Use of American Iron, Steel, and Other Manufactured Goods—Buy American Act—Construction Materials (MAR 2009)

(a) Definitions. “Construction material,” “domestic construction material,” “foreign construction material,” “manufactured construction material,” “steel,” and “unmanufactured construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Required Use of Iron, Steel, and Other Manufactured Goods—Buy American Act—Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-21).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of section 1605 of the American Recovery and Reinvestment Act of 2009 (Pub. L. 111-5) (Recovery Act) or the Buy American Act should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-21 in the request. If an offeror has not requested a determination regarding the inapplicability of 1605 of the Recovery Act or the Buy American Act before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) If the Government determines that an exception based on unreasonable cost of domestic construction material applies, the Government will evaluate an offer requesting exception to the requirements of section 1605 of the Recovery Act or the Buy American Act by adding to the offered price of the contract—

(i) 25 percent of the offered price of the contract, if foreign iron, steel, or other manufactured goods are used as construction material based on unreasonable cost of comparable manufactured domestic construction material; and

(ii) 6 percent of the cost of foreign unmanufactured construction material included in the offer based on unreasonable cost of comparable domestic unmanufactured construction material.

(2) If two or more offers are equal in price, the Contracting Officer will give preference to an offer that does not include foreign construction material excepted at the request of the offeror on the basis of unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-21, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer and a separate cost comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-21 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-21 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

PERFORMANCE AND PAYMENT BONDS

Performance and Payment Bonds are required within 10 calendar days after award.

00800 SPECIALCON REQUIREMENTS

TABLE OF CONTENTS

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

CLAUSE NUMBER

CLAUSE TITLE

52.211-12

LIQUIDATED DAMAGES – CONSTRUCTION (SEP 2000)

52.231-5000 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE

SCHEDULE (MAR 1995) – EFAR

52.236-4

PHYSICAL DATA (APR 1984)

52.236-16

QUANTITY SURVEYS (APR 1984)

252.236-7000

MODIFICATION PROPOSALS – PRICE BREAKDOWN (DEC 1991)

252.236-7001

CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

252.236-7002

OBSTRUCTION OF NAVIGABLE WATERWAYS (DEC 1991)

252.236-7004

PAYMENT FOR MOBILIZATION AND DEMOBILIZATION

(DEC 1991)

LOCAL CLAUSES:

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 89) ER 415-1-15

CERF IMPLEMENTATION (1983 JUN OCE)

CONTINUITY OF WORK (1965 APR OCE)

LAYOUT OF WORK (1965 APR OCE)

REAL ESTATE

REPORT OF DREDGING OPERATIONS

SHOALING

VARIATIONS IN ESTIMATED QUANTITIES—DREDGING

WITHDRAWAL OF CONTRACTOR'S PLANT FROM CONTRACT WORK

CONTRACTOR PERFORMANCE EVALUATIONS

SECTION 00800

SPECIAL CONTRACT REQUIREMENTS

52.211-12

LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract the Contractor shall pay liquidated damages to the Government in the amount of $ 925.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.231-5000

EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (MAR 1995) - EFAR

(a) This clause does not apply to terminations. See 52.249-5000, Basis for Settlement of Proposals and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition owned or controlled and furnished by a Contractor or subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the Contractor’s accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the Contractor’s accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, “Construction Equipment Ownership and Operating Expense Schedule,” Region II. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the Contracting Officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d)(ii) and FAR 31.205-36. Rates for equipment rented from an organization under common control, lease-purchase arrangements will be determined using the schedule except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the small purchase threshold, the Contracting Officer shall request the Contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, “Contract Pricing Proposal Cover Sheet.”

(End of Clause)

52.236-4

PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor’s information. The Government shall not be responsible for any interpretation of, or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys and soundings.

(b) Weather Conditions. See clause entitled “TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER” of this Section.

(c) Transportation Facilities. The location is served by railroads and major highways. The Contractor shall investigate and obtain the necessary information and data regarding the availability and use of access roads, dock facilities, highways and railroad facilities to the site of the work. The Contractor shall, without additional expense to the Government, be responsible for obtaining any necessary permits to operate on or cross public highways and roads and railroads in connection with the prosecution of the contract work. See the Contract Clause (Section 00700) entitled “Permits and Responsibilities”.

(d) Project Condition Soundings. Government sounding drawings from the previous year are included as reference drawings and are listed in the paragraph entitled "Contract Drawings, Maps and Specifications" of this section.

(e) Lake Levels. Data and forecasts are available through the publication, "Monthly Bulletin of Lake Levels" by the Department of the Army, Detroit District, Corps of Engineers, ATTN: CELRE-EP-HW, P.O. Box 1027, Detroit, MI 48231-1027.

52.236-16

QUANTITY SURVEYS (APR 1984)

(a) Quantity surveys shall be conducted, and the data derived from these surveys shall be used in computing the quantities of work performed and the actual construction completed and in place.

(b) The Government shall conduct the original and final surveys and make the computations based on them. The Contractor shall conduct the surveys for any periods for which progress payments are requested and shall make the computations based on these surveys. All surveys conducted by the Contractor shall be conducted under the direction of a representative of the Contracting Officer, unless the Contracting Officer waives this requirement in a specific instance.

(c) Promptly upon completing a survey, the Contractor shall furnish the originals of all field notes and all other records relating to the survey or to the layout of the work to the Contracting Officer, who shall use them as necessary to determine the amount of progress payments. The Contractor shall retain copies of all such material furnished to the Contracting Officer.

(End of clause)

252.236-7000

MODIFICATION PROPOSALS – PRICE BREAKDOWN (DEC 1991)

(a) The Contractor shall furnish a price breakdown, itemized as required and within the time specified by the Contracting Officer, with any proposal for a contract modification.

(b) The price breakdown –

(1) must include sufficient detail to permit an analysis of profit, and of all costs for –

(i) material;

(ii) labor;

(iii) equipment;

(iv) subcontracts; and

(v) overhead

(2) must cover all work involved in the modification, whether the work was deleted, added, or changed.

(c) The Contractor shall provide similar price breakdowns to support any amounts claimed for subcontracts.

(d) The Contractor’s proposal shall include a justification for any time extension proposed.

(End of clause)

252.236-7001

CONTRACT DRAWINGS, MAPS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from drawings or specifications or the misdescription of details of work that area manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the correct drawings identified on the following index of drawings:

Title

File

Drawing No.

CONTRACT DRAWINGS:

Dunkirk Harbor

1/1

C-101

Dunkirk, New York

Maintenance Dredging FY 2009

General Plan

REFERENCE DRAWINGS:

08S-DUK-1/1

VH-101

1/2 Project Condition Soundings – May, July 2008

08S-DUK-1/2

VH-102

2/2 Project Condition Soundings – May, July 2008

(End of Clause) 252.236-7002

OBSTRUCTION OF NAVIGABLE WATERWAYS (DEC 1991)

(a) The Contractor shall—

(1) Promptly recover and remove any material, plant, machinery, or appliance which the Contractor loses, dumps, throws overboard, sinks, or misplaces, and which, in the opinion of the Contracting Officer, may be dangerous to or obstruct navigation;

(2) Give immediate notice, with description and locations of any such obstructions, to the Contracting Officer; and

(3) When required by the Contracting Officer, mark or buoy such obstructions until the same are removed.

(b) The Contracting Officer may—

(1) Remove the obstructions by contract or otherwise should the Contractor refuse, neglect, or delay compliance with paragraph (a) of this clause; and

(2) Deduct the cost of removal from any monies due or to become due to the Contractor; or

(3) Recover the cost of removal under the Contractor’s bond.

(c) The Contractor’s liability for the removal of a vessel wrecked or sunk without fault or negligence is limited to that provided in sections 15, 19, and 20 of the River and Harbor Act of March 3, 1899 (33 U.S.C. 410 et seq.).

(End of clause)

252.236-7004

PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (DEC 1991)

(a) The Government will pay all costs for the mobilization and demobilization of all of the Contractor’s plant and equipment at the contract lump sum price for this item.

(1) Sixty (60%) percent of the lump sum price upon completion of the Contractor’s mobilization at the work site.

(2) The remaining forty (40%) percent upon completion of demobilization.

(b) The Contracting Officer may require the Contractor to furnish cost data to justify this portion of the bid if the Contracting Officer believes that the percentages in paragraphs (a)(1) and (2) of this clause do not bear a reasonable relation to the cost of the work in this contract.

(1) Failure to justify such price to the satisfaction of the Contracting Officer will result in payment, as determined by the Contracting Officer, of—

(i) Actual mobilization costs at completion of mobilization;

(ii) Actual demobilization costs at completion of demobilization; and

(iii) The remainder of this item in the final payment under this contract.

(2) The Contracting Officer’s determination of the actual costs in paragraph (b)(1)of this clause is not subject to appeal.

(End of clause)

LOCAL CLAUSES:

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 89) ER 415-1-15

(1) This provision specifies the procedures for determination of time extensions for unusually severe weather in accordance with the contract clause entitled “Default: (Fixed Price Construction)”. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(a) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe that the adverse weather anticipated for the project location during any given month.

(b) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(2) The following schedule of monthly anticipated adverse weather delays is based upon National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor’s progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED UPON (7) DAY WORK WEEK

(3) Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and the resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 % or more of the Contractor’s scheduled work day.

The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph 2, above, the Contracting Officer will convert and qualifying delays to calendar days, giving full consideration for equivalent fair weather days, and issue a modification in accordance with the contract clause entitled “Default (Fixed Price Construction)”.

(End of Clause)

CERF IMPLEMENTATION (1983 JUN OCE)

If the work specified in this contract is performed by a hopper dredge(s), the owner must have an active Basic Ordering Agreement (BOA) for the hopper dredge(s) on file with the Corps. The Contractor shall be obligated to make the hopper dredge(s) available to serve in the Corps of Engineers Reserve Fleet (CERF) at any time that the hopper dredge(s) is performing work under this contract. When the Contracting Officer is notified of the decision to activate this dredge(s) into the CERF, he shall take appropriate action to release the dredge(s). He may then extend or terminate the contract to implement whichever action is in the best interest of the Government. The CERF Contractor shall also be subject to the following conditions:

(a) The Director of Civil Works may require the Contractor to perform emergency dredging at another CONUS (48 contiguous states) site for a period of time equal to the remaining time under this contract at the date of notification plus up to ninety (90) days at the previously negotiated rate which appears on the schedule of prices in the BOA.

(b) The Chief of Engineers may require the Contractor to perform emergency dredging at an OCONUS (Outside CONUS which includes Alaska, Hawaii, Puerto Rico, the Virgin Islands, or U.S. Trust Territories) site for a period of time equal to the time remaining under this contract at the date of notification plus up to one hundred eighty (180) days at the negotiated rate which appears on the schedule of prices in the BOA.

(c) The CERF shall be activated by the Chief of Engineers or the Director of Civil Works; then the Ordering Contracting Officer will notify the Contractor. From the time of notification, the selected hopper dredge(s) must depart for the emergency assignment within seventy-two (72) hours for CONUS or ten (10) days for OCONUS assignments.

(d) A confirming delivery order will be issued pursuant to the Basic Ordering Agreement (BOA) by the Ordering Contracting Officer. Such delivery order shall utilize the schedule of rates in the BOA for the specific hopper dredge(s).

(e) If during the time period specified in a, b, or c, above, a CERF vessel(s) is still required, the contract performance may be continued for additional time by mutual agreement.

(EFARS 52.2/9112)

CONTINUITY OF WORK (1965 APR OCE)

No payment will be made for work done in any area designated by the Contracting Officer until the full depth required under the contract is secured in the whole of such area, unless prevented by ledge rock, nor will payment be made for excavation in any area not adjacent to and in prolongation of areas where full depth has been secured except by decision of the Contracting Officer. Should any such nonadjacent area be excavated to full depth during the operations carried on under the contract, payment for all work therein may be deferred until the required depth has been made in the area intervening. The Contractor may be required to suspend dredging at any time when for any reason the gages or ranges cannot be seen or properly followed.

(EFARS 52.2/9110(c))

LAYOUT OF WORK (1965 APR OCE)

(a) The Government has established bench marks and horizontal control points at the site of the work. These are described and indicated on contract drawings.

(b) From these control points the Contractor shall lay out the work by establishing all lines and grades at the site necessary to control the work and shall be responsible for all measurements that may be required for the execution of the work to the location and limit marks prescribed in the specifications or on the contract drawings. The Contractor shall establish and maintain at the site of the work the following horizontal and vertical controls:

See Section 01 35 13, “SPECIAL PROJECT PROCEDURES,” Paragraph “Datum and Benchmarks”.

See Section 35 20 23, "MAINTENANCE DREDGING," Paragraph “Layout of Work”.

The above are minimum requirements and the Contractor shall place and establish such additional stakes and markers as may be necessary for control and guidance of his construction operations. All survey data shall be recorded in accordance with standard and approved methods. All field notes, sketches, recordings and computations made by the Contractor in establishing above horizontal and vertical control points shall be available at all times during the progress of the work for ready examination by the contracting officer or his duly authorized representative.

(c) The Contractor shall furnish, at his own expense, all such stakes, spikes, steel pins, templates, platforms, equipment, tools and material and all labor as may be required in laying out any part of the work from the control points established by the Government. It shall be the responsibility of the Contractor to maintain and preserve all stakes and other markers established by him until authorized to remove them. If any of the control points established at the site by the Government are destroyed by or through the negligence of the Contractor prior to their authorized removal, they may be replaced by the Contracting Officer, and the expense of replacement will be deducted from any amount due or which may become due the Contractor. The Contracting Officer may require that work be suspended at any time when horizontal and vertical control points established at the site by the Contractor are not reasonably adequate to permit checking the work. Such suspension will be withdrawn upon proper replacement of the control points.

(EFARS 52.2/9108(a)(b))

REAL ESTATE

No real estate rights have been obtained by the Government for this project. If any real estate rights are desired by the Contractor in addition to that already available to the Government for access to the disposal facility and/or project area, they shall be obtained by the Contractor at his own expense. Copies of any such agreements shall be furnished to the Contracting Officer for approval before entering thereon. Such agreements shall clearly relieve the Government of any responsibility for damages resulting from the use of such grounds.

REPORT OF DREDGING OPERATIONS

As set forth in Section 00700, “Contract Clauses”, paragraph entitled “Inspection of Construction,” which requires the maintenance of inspection records, either ENG Form 4267 (Report of Operations – Pipeline, Dipper or Bucket Dredges) or ENG Form 27 (Report of Operations – Hopper Dredges), as appropriate to the type of work being performed, shall be completed daily. The Contractor shall furnish the completed forms, to the Contracting Officer. Blank copies of both forms are located, as Attachments, within Section 00100, “BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS INDEX” at the end of this Solicitation. An adequate supply will be provided to the Contractor by the Contracting Officer. If the Contractor proposes to use any other form, it shall be approved by the Contracting Officer prior to use.

SHOALING (1965 APR OCE)

If, before the contract is completed, shoaling occurs in any section previously accepted, including shoaling in the finished channel, because of the natural lowering of the side slopes, redredging at contract price, within the limit of available funds, may be done if agreeable to both the Contractor and the Contracting Officer.

(EFARS 52.2/9110(f))

VARIATIONS IN ESTIMATED QUANTITIES--DREDGING (1985 JAN HQ USACE)

Where the quantity of a pay item in this contract is an estimated quantity and where the actual quantity of material within the required dredging prism varies more than fifteen percent (15%) above or below the stated estimated quantity within the required dredging prism, an equitable adjustment in the contract unit price will be made upon demand of either party. The equitable adjustment will be based upon any increase or decrease in costs due solely to the variations above one-hundred fifteen percent (115%) or below eighty-five percent (85%) of the estimated quantity within the required dredging prism.

Any equitable adjustment in the contract unit price will also apply to that part of the actual quantity of allowable overdepth material above one-hundred fifteen percent (115%) or below…