A02_-_CSS_Attachment_3_-_QASP_Ballistic_BPA_11-18-13.pdf

Attachment 3 Solicitation: W911QY-17-R-0035

QUALITY ASSURANCE SURVEILLANCE PLAN

1. Objective. This Quality Assurance Surveillance Plan (QASP) serves as the principal basis for assessing overall performance quality. This document will be used by the Government to assess the effectiveness of the Contractor’s technical services. This QASP provides the methodology by which the Contractor's performance will be monitored to determine compliance with established performance objectives and to establish performance benchmarks that ensure a quantifiable basis for measuring effectiveness. The plan is designed so that surveillance is limited to that which is necessary to verify the Contractor is performing technical services satisfactorily and relates directly to performance objectives delineated in the SOW.

2. Government Surveillance. The Contracting Officer will appoint a Contracting Officer’s Representative (COR) and may appoint a Technical Monitor to function as the technical representative for the Contracting Officer on this contract; and her/his authority will be limited to administering specific technical aspects of the contract. The COR and/or Technical Monitor will not provide direction that is outside the scope of responsibilities delineated under this contract and will defer any conditional interpretations to the Contracting Officer. The COR/Technical Monitor will:

• Maintain a detailed knowledge of the technical requirements of the contract;

• Document Contractor performance in accordance with the QASP;

• Identify and immediately forward notifications of deficient, or non-compliant performance to the Contracting Officer;

• Approve priorities of support, resources, and associated schedules.

3. Surveillance Methods. Surveillance of Contractor performance is the method used by the Government to determine whether the contractor is effectively and efficiently complying with all terms and conditions of the contract. The functional expertise of the COR/Technical Monitor plays a critical role in adequately evaluating contractor performance.

4. Performance Objectives. This performance-based service contract incorporates the following performance objectives: (1) delivery of high-quality ballistic testing; (2) GFE control and accountability; (3) adherence to contract schedule, milestone, and delivery requirements, and (4) efficient and effective cost control.

It is the contractor’s responsibility to employ the necessary resources to ensure accomplishment of these objectives. The Government’s assessment of the contractor’s performance in achieving these objectives will utilize the standards, acceptable quality levels, and surveillance methods described in the Performance Requirements Summary matrix set forth below.

The contractor will be notified, in writing, of the Government’s determination of its performance level for each performance objective, including all instances where the contractor failed to meet the acceptable quality level.

Attachment 3 Solicitation: W911QY-17-R-0035

PERFORMANCE OBJECTIVES SUMMARY MATRIX

TASK/

DELIVERABLE

PERFORMANCE

STANDARD

PERFORMANCE

INDICATOR/ACCEPT

ABLE LEVEL OF

PERFORMANCE

(ALP)

METHOD OF

SURVEILLANCE

PERFORMANCE RATING

Technical Performance

High Quality Ballistic Testing and Evaluation

Contract requirements met with few minor and no significant problems encountered.

Performance meets all technical and functional requirements, and is highly responsive to any changes in technical focus of the project.

Personnel qualifications, assessments, evaluations, analyses, recommendations, and related input are thorough, reliable, highly relevant to contract requirements, and consist of substantial depth and breadth of subject matter expertise.

Contractor technical performance meets all contract requirements.

Problems that are encountered are minor and resolved in a satisfactory manner.

Routine Assessment of Workforce Qualifications and Availability of Resources

Test reports document all testing and evaluation of various products.

Acceptance Sampling

Assignment of performance rating for QUALITY criteria:

Excellent Performance meets all and exceeds standard compliance of many CONTRACT requirements.

Performance delivered with no required re-performance/rework at least 99% of time. Problems that are encountered are minor and resolved in a highly effective manner.

Acceptable Performance and deliverables meet all contract requirements. Performance delivered with no re-performance/rework at least 90% of time. Problems that are encountered are minor and resolved in a satisfactory manner.

Unacceptable Many contract requirements not met.

Numerous re-performance/reworks required. Substantial problems were encountered and were resolved in a less than satisfactory manner.

Adherence to Milestone Schedule

Contract milestones, periods of performance, and/or data submission dates are met or exceeded;

highly qualified Key Personnel are available as required.

Contractor meets Contract milestone requirements at least 90% of the time, or satisfactorily describes the reason for failure (excluding government- caused delays).

Frequent discussion of progress to date

Assignment of performance rating for SCHEDULE criteria:

Excellent Contract milestones/ performance dates met or exceeded at least 95% of time (excluding government caused delays)

Acceptable Contract milestones/ performance dates met or exceeded at least 85- 95% of time (excluding government caused delays)

Unacceptable Contract milestones/ performance dates met less than 85% of time (excluding government caused delays)

PERFORMANCE OBJECTIVES SUMMARY MATRIX