B.08.03 W911KB20B0004-0004.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to add an option for construction of a Wing Wall Baling Deck to be located adjacent to the River Baling Deck. The Wing Wall Baling Deck is a pile-supported structure about 92-feet by 45-feet w ide. See summary of changes.

BIDDERS ARE REQUIRED TO ACKNOWLEDGE RECEIPT OF THIS AMENDMENT ON THE REVERSE SIDE OF THE SF1442.

1. CONTRACT ID CODE PAGE OF PAGES

1 8

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 25-Feb-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W911KB20B0004

X 9B. DATED (SEE ITEM 11)

03-Feb-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

25-Feb-2020

CODE

U.S. ARMY ENGINEER DISTRICT, AK

CEPOA-CT (W911KB)

PO BOX 6898

JBER AK 99506-0898

W911KB 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W911KB20B0004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 11 00 - STANDARD FORM (SF) 1442

The following have been added by full text:

AM #0004 SUMMARY OF CHANGES

AMENDMENT #0004

The following drawings are substituted for the superseded drawings:

River Baling Deck drawings: Sheet C-002

The following revised documents are substituted for the superseded documents. The identifier “AM#04” appears before and after new and/or revised material and replacement pages are provided, except as noted:

- Table of Contents

- Bid Schedule

- Section 01 50 00-2.2.3 – replacement page 2 is provided

- Section 31 41 16-3.3.3 and 3.3.6 – replacement page 10 provided (replaces former pages 10 and 11)

The following documents/drawings are deleted:

NONE

The following documents are added:

Wing Wall Baling Deck drawings (31 sheets plus exhibit drawings)

Section 01 33 00: Wing Wall Baling Deck submittal Register

Wing Wall Baling Deck specifications:

Division 03 - Concrete

03 30 53 Miscellaneous Cast-In-Place Concrete 03 45 33 Precast Structural Concrete 03 62 16 Non-Shrink Grouting

Division 05 - Metals

05 12 00 Structural Steel

Division 31 - Earthwork

31 00 00 Earthwork 31 62 16.16 Pipe Piles

Division 32 - Exterior Improvements

32 15 00 Aggregates 32 32 34 Mechanically Stabilized Earth Retaining Wall

The following revisions are incorporated:

NONE

Other:

The following have been modified:

TABLE OF CONTENTS

AM#04

RIVER BALING DECK (CHL020)

and

WING WALL BALING DECK (CHL022)

CHENA RIVER LAKES FLOOD CONTROL

PROJECT

NORTH POLE, ALASKA

PROJECT TABLE OF CONTENTS

DIVISION 00 – PROCUREMENT AND CONTRACTING REQUIREMENTS (Apply to Entire Contract)

00 11 00 STANDARD FORM 1442

CAUTION TO BIDDERS

BID SCHEDULE

00 21 00 INSTRUCTIONS TO BIDDERS

00 45 00 REPRESENTATIONS AND CERTIFICATIONS

00 72 00 CONTRACT CLAUSES

00 73 00.00 29 SPECIAL CONTRACT REQUIREMENTS

00 73 46 WAGE DETERMINATION

DIVISION 01 – GENERAL REQUIREMENTS (Apply to Entire Contract)

01 19 40.00 29 SPECIAL ITEMS (CIVIL WORKS)

01 22 00.00 10 MEASUREMENT AND PAYMENT

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENT SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.15.10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 45 04.00 29 CONTRACTOR QUALITY CONTROL

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 20.01 29 ENVIRONMENTAL PROTECTION

01 78 00 CLOSEOUT SUBMITTALS

CHL020 RIVER BALING DECK TECHNICAL SPECIFICATIONS

DIVISION 31 – EARTHWORK

31 00 00 EARTHWORK

31 41 16 SHEET METAL PILING

AM#04

AM#04

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 11 23 AGGREGATE BASE COURSE

CHL022 WING WALL BALING DECK TECHNICAL SPECIFICATIONS

DIVISION 03 - CONCRETE

03 30 53 MISCELLANEOUS CAST-IN-PLACE CONCRETE

03 45 33 PRECAST STRUCTURAL CONCRETE

03 62 16 NON-SHRINK GROUTING

DIVISION 05 - METALS

05 12 00 STRUCTURAL STEEL

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 62 16.16 PIPE PILES

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 15 00 AGGREGATES

32 32 34 MECHANICALLY STABILIZED EARTH RETAINING WALL

-- END OF PROJECT TABLE OF CONTENTS—

SECTION 00 11 01 - CLIN SCHEDULE

The following have been modified:

CLIN SCHEDULE

AM#04

BID SCHEDULE

CHL020 River Baling Deck and

CHL022 Wing Wall Baling Deck Chena River Lakes Flood Control Project

North Pole, Alaska

Item No. Description Qty Unit Unit Price Total Amount

BASE ITEMS

0001 Construct CHL020 River Baling Deck, complete. 1 Job $___________ $___________

Total of Base Items: $___________

OPTION ITEMS

0002 Construct CHL022 Wing Wall Baling

Deck, complete. 1 Job $___________ $___________

Total of Option Items: $___________

Total of Base and Option Items: $___________

EVALUATION OF BIDS:

1. AWARD: Award will be made to the low, responsive, responsible bidder.

2. INCOMPLETE BIDS: Failure to submit a bid on all items in the schedule will result in an incomplete bid and the bid will be rejected. Job or unit prices must be shown for each item within the schedule.

3. MISTAKES IN BIDS: Apparent clerical mistakes and arithmetic discrepancies will be addressed in accordance with FAR Part 14.407, MISTAKES IN BIDS.

4. OPTIONS: Options will be evaluated in accordance with Solicitation Provision 52.217-5. The Contracting Officer may exercise the options by written notice to the Contractor in accordance with Contract Clause 52.217-

7. Exercised items shall be completed within the contract completion period stated in FAR 52.211-10.

-- END OF PROPOSAL SCHEDULE –

SECTION 00 21 00 - INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

The following have been added by full text:

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

SECTION 00 72 00 - CONTRACT CLAUSES

The following have been added by full text:

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within 30 Days of Award. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

(End of clause)

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 30 November 2020 The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 15 April 2020. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

(End of Summary of Changes)