W91151-18-B-0001.pdf

0011135725

A Bid Bond is required (see section 00100, FAR Clause 52.228-1).

Performance and Payment Bonds are required (see section 00700, FAR Clause 52.228-15).

As required by FAR 36.204, the estimated magnatude of this project is betw een $ 250,000-$500,000.

The NAICS for this acquisition is 238220 Plumbing, Heating, and Air Conditioning Contractors (SB size standard $15 Million).

This acquisition is set aside for 100% Women Ow ned Small Businesses (WOSB); no large business quotes w ill be accepted for this procurement.

The aw ardee of this procurement w ill be rquired to provide dedicated supertindent through completion of the project(see section 00700, FAR Clause 52.236-6.

Project Manager, Quality Control, and Superintendent positions are consider key positions. These positions SHALL not be subcontracted below the prime contractor.

Bidders are required to provide a valid CAGE Code (Block 14 CODE), DUNS Code (Block 14 FACILITY), POC and email address w ith their bid.

BID ADDRESS: DPW-Fort Hood Building 4610,Engineer Drive, DPW COR Conference Room, Fort Hood, TX 76544. f Bid Opening is 10 July 2018 at 2:00 pm CDT. Contracators must provide a CD w ith their bids documents on it as w ell as the original bid.

X

JOANNE A. SMONKO 254-287-5676

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

04-Jun-2018

(RFP)

(IFB)

CALL:

Replace HVAC Building 91014

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______30 calendar days and complete it w ithin ________165 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.-211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________0 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________10 Jul 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

MISSION AND INSTALLATION CONTRACTING

MISSION CONTRACTING OFFICE (MCO)

36000 DARNALL LOOP, ROOM 1300B

FORT HOOD TX 76544-5095

W91151

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

AD003154P

8. ADDRESS OFFER TO (If Other Than Item 7)

254-288-3617FAX:TEL: TEL: FAX:

W9115118B0001 47

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Section 00010 - Solicitation Contract Form

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Replace HVAC Building 91014

FFP

Replace HVAC Building 91014 in accordance with the projects scope, plans, drawings and specifications in the contract. The Contractor shall provide all plant, supervision, labor, materials, equipment, supplies and transportation necessary to complete this scope of work. All work shall comply with all State, local and Federal laws and regulations, industry and construction codes and standards, manufacturer’s specifications and recommendations, and all contract special provisions, terms and conditions.Building will be occupied during performance of work under this solicitation.

FOB: Destination

PURCHASE REQUEST NUMBER: 0011135725

PSC CD: Z2AA

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Job Contract Manpower Reporting

FFP

The contractor shall report ALL contractor labor hours (including subcontractor labor hours) required for performance of services provided under this contract for the U.S. Army via a secure data collection site. The contractor is required to completely fill in all required data fields using the following web address:

http://www.ecmra.mil/. Choose Department of the Army CMRA. Reporting inputs will be for the labor executed during the period of performance during each Government fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year, beginning with 2017. Contractors may direct questions to the help desk by clicking on “Send an email” which is located under the Help Resources ribbon on the right side of the login page at:

http://www.ecmra.mil, Choose Department of the Army CMRA.

FOB: Destination

PSC CD: Z2AA

NET AMT

SCOPE OF WORK

PROJECT SYNOPSIS

RPR HVAC

Building 91014 Project Number: AD003154P

DESCRIPTION OF WORK:

The work shall be located at building 91014, located at the intersection of Station Ave and Headquarters Ave, Fort Hood TX. The exact location will be shown by the Contracting Officer. The building will be occupied during the performance of work under this contract.

The purpose of this project is to replace the existing HVAC system (including existing AHU’s and all associated accessories) with new HVAC system and upgrade the control system with new DDC control system in bldg. 91014.

The following drawings are included as part of the Solicitation.

G-101 COVER SHEET

C-101 SITE PLAN - UTILITIES

A-101 FIRST FLOOR PLAN

A-102 SECOND FLOOR PLAN

MD-101 MECH. PLAN - DEMOLITION- FIRST FLOOR

MD-102 MECH. PLAN - DEMOLITION- SECOND FLOOR

MD-103 ENLARGED MECH. ROOM - DEMOLITION – FIRST FLOOR

MD-104 ENLARGED MECH. ROOM – DEMOLATION – SECOND FLOOR

M-101 MECHANICAL PLAN - NEW- FIRST FLOOR

M-102 MECHANICAL PLAN – NEW- SECOND FLOOR

M-103 ENLARGED MECH. ROOM – NEW – FIRST FLOOR

M-104 ENLARGED MECH. ROOM – NEW – SECOND FLOOR

M-501 CHILLED WATER PIPING DIAGRAM

M-502 HOT WATER PIPING DIAGRAM

M-503 MECHANICAL DETAILS

M-601 MECHANICAL SCHEDULE

M-701 BOILER / CHILLER CONTROLS

M-702 AIR HANDLING UNIT CONTROLS

M-703 LON BUS CONTROLS

One set of solicitation documents, including plans, specifications, and miscellaneous data, will be furnished to the contractor in Adobe PDF format. After award, one set of Adobe PDF contract drawings and PDF specifications, and one set of MicroStation format drawings (if available) will be furnished to the Contractor on CD. Reference publications will not be furnished. Contractor shall immediately check furnished drawings and notify the Government of any discrepancies.

A project construction sign will not be required for this project. Contractor shall keep all permits and other documents required to be on the job site in a 3-ring binder or posed on a bulletin board within the construction area.

PERFORMANCE PERIOD:

Barring any contingencies that arise during construction, the Government requires that this project be completed within 135 calendar days. Completion is defined as completion of all contractual obligations.

***END OF SCOPE OF WORK***

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Exhibit A Technical Exhibit A

Specifications

3313 20-JAN-2017

Exhibit B Technical Exhibit B Drawings

19 07-JUN-2017

Attachment 1 Attachment 1 Appendix A 120 04-AUG-2016

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS TO OFFERORS

Any bids received in response to this solicitation SHALL carry a 120 day acceptance period before prices need to be verified, extended or re-negotiated.

1. SUBMISSION OF BIDS

The priced bid shall be supported by a draft progress schedule that demonstrates the offeror's understanding of the work requirements, phasing of work between buildings, and estimated time frames for ordering and installing equipment.

Bidders are required to provide a CD copy of their bid documents with their IFB submission.

2. PUBLIC BID OPENINGS

Please refer to Block 13A of the 1442. Anyone wishing to attend the bid opening MUST notify the Contracting Officer (roy.r.cantrell.civ@mail.mil) and Contract Specialist (josephine.a.farthing.civ@mail.mil) by email no later than TBD with a firm commitment to attend.

MAILING ADDRESS

Directorate of Public Works ATTN: Engineering Division (CONTRACTING SECTION) Building 4610 Engineer Drive Fort Hood, TX 76544

PUBLIC BID OPENING

DPW-Fort Hood Bldg 4610 Engineer Drive DPW COR Conference Room Fort Hood, TX 76544

TBD

3. PRE-REQUISITES FOR SPECIALITY TRADE LICENSURE AND

CERTIFICATION

The contractor shall provide documentation to support that it possesses the qualifications to, or can acquire assets to, demonstrate journeyman (or master license) qualifications in the following trades:

・ Electrician Licensing-Master and Journeyman electricians to work in the State of Texas by the Texas Department of Licensing and Regulation

・ Class A Air Conditioning and Refrigeration Contractor’s License as regulated by the Texas by the Texas Department of Licensing and Regulation

In responding to this solicitation, the offeror shall provide copies of certifications/training identified above as a part of the proposal. No substitution of the individual possessing the required pre-qualifications will be authorized without the written approval of the Contracting Officer, and no time will be allowed for the contractor to acquire the required training/certification after the contract is awarded.

4. WORK EXPIERENCE

The prime contractor shall demonstrate that it possesses general construction contract management by providing at least three examples of relevant work experience in an awarded contract similar to the requirements stated in this solicitation. Documentation shall be submitted with the bid and include the contract number, the date of contract award, the customer's name and contact information, the awarded dollar value, the value of the contract at completion, a description of all work elements included in the contract, the number and type of specialty trades needed to complete the contract, the period of time allocated for completion of the work and actual time required to complete the work (include reasons for time extensions). Federal work experience is preferred; however, the Government will accept work experience from both State and institutional and commercial contracts as well. No residential work experience will be considered appropriate for this purpose. Failure to provide this documentation will render the bid/offer non-responsive and no further consideration will be given to that bidder for award of this contract.

5. MANDATORY ATTENDANCE PRE-BID AND PRE-CONSTRUCTION CONFERENCES

The Contracting Officer shall conduct a pre-bid/pre-proposal conference in conjuction with the site visit.

Information on the scheduled Site Visit is located in FAR 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) of this solicitation. When such conference is scheduled, all potential bidders/offerors attending the site visit will be required to attend the pre-bid/pre- proposal conference. Space limitations dictate that no more than two representatives from each company attend. The Contracting Officer will review Bid submission requirements, and other administrative matters critical for successful and timely performance of the work.

The Contractor shall attend a Government coordinated pre-construction conference within 10 calendar days of contract award. As a minimum, the conference shall be attended by the contractor’s appointed project manager, the superintendent, the QCM, and administrative personnel responsible for preparation of contract documents, certified payroll records and invoices. The contractor shall deliver letter appointments of its key personnel that include each individual’s duties, roles and responsibilities.

6. SUBCONTRACTOR LIST

Offeror shall submit a list of proposed subcontractors as an attachment to their BID. If offeror does not intend on utilizing subcontractors (self-perform), offeror shall state so in their bid.

7. AMENDMENTS TO SOLICITATION

(a) If this solicitation is amended, then all terms and conditions which are not modified remain unchanged.

(b) Offerors shall acknowledge receipt of any amendment to this solicitation (1) by signing and returning the amendment, or (2) by identifying the amendment number and date in the space provided for this purpose on the form for submitting a quote. The Government must receive the acknowledgment by the date and time specified for receipt of proposals indicated in block 10 of the

SF1442.

8. FALSE STATEMENTS IN BIDS

Offerors must provide full, accurate, and complete information as required by this solicitation and its attachments. The penalty for making false statements in proposals is prescribed in 18 U.S.C. 1001.

9. EXPLANATION TO PROSPECTIVE OFFERORS

Any prospective offeror desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing by the date and time specified in FAR Clause 52.236-27.

Oral explanations or instructions given before the award of a contract will not be binding. Any information given a prospective offeror concerning a solicitation will be furnished promptly to all other prospective offerors as an amendment to the solicitation, if that information is necessary in submitting bids or if the lack of it would be prejudicial to other prospective offerors.

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2016 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.215-7008 Only One Offer OCT 2013

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of afirm fixed contract resulting from this solicitation.

(End of provision)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

16.9% 6.4%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Fort Hood, Texas; Bell County

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% (percent) of the bid price or $1M, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

Mission and Installation Contracting Command - Fort Hood Contracting Division, Construction Team ATTN: Roy R. Cantrell, Contracting Officer 36000 Darnall Loop, Room 1300B Fort Hood, TX 76544-5095

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for 19 June 2018, 9:00 am

(c) Participants will meet at

DPW – Fort Hood Building 4610, Engineer Drive COR Conference Room Fort Hood, Texas 76544

Contractors interested in attending the scheduled pre-bid conference and site visit MUST notify the Contracting Officer of record in this solicitation to be announced with a firm commitment to attend. Due to heightened security requirements within Department of Defense and Fort Hood, no contractor will be allowed entry to the building without having provided this notification. The notification must include the names and position titles of representatives attending the pre-bid conference; due to space constraints, each contractor is allowed to name two representatives in the notification.

From the Main Gate Entrance, proceed to the Santa Fe Avenue Overpass. At the second light, turn left onto Santa Fe Avenue. Continue along Santa Fe Avenue to Engineer Drive. Turn left at Engineer Drive and park in the DPW East Parking lot. Enter Building 4610 and have a seat in the waiting area to the left.

The Contract Specialist will escort you to the conference room. Fort Hood is a closed access installation.

All visitors must obtain a visitors’ pass at the Main Gate Visitors’ Center before being allowed on post.

Consequently, participants should allow at least one hour prior to the site visit for obtaining this pass.

All questions resulting from the site visit must be submitted electronically to the email below prior to closing of bids.

Josephine.a.farthing.civ@mail.mil roy.r.cantrell2.civ@mail.mil

Remarks and explanations made by the government representative during the course of the site visit shall not change or qualify any of the terms or conditions of the solicitation. The solicitation can only be changed by a written amendment issued by a warranted contracting officer. All Requests For Information ( RFIs) and clarifications considered as a result of inquiries from contractors at the site visit will be incorporated in one or more amendments to the solicitation, all of which will be provided to the contractor in sufficient time to allow the contractors to finalize bids/proposals prior to submission.

RFIs are due 26 June 2018 2:30pm CDT to Josephine A. Farthing (josephine.a.farthing.civ@mail.mil)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

None

Section 00600 - Representations & Certifications

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Section 00700 - Contract Clauses

SPECIAL INSTRUCTIONS

INSTRUCTIONS TO OFFERORS

MANDATORY ATTENDANCE – PRE-CONSTRUCTION CONFERENCES

The Contractor is required to attend a Government coordinated preconstruction conference upon contract award. As a minimum, the conference shall be attended by the contractor’s appointed project manager, the superintendent, theQuality Control Manager, and administrative personnel responsible for preparation of contract documents, certifiedpayroll records and invoices. The contractor will deliver letter appointments of its key personnel that include each individual’s duties, roles and responsibilities.

SUBMISSION OF PROPOSALS

The Offeror will submit a proposal that provides a complete line item breakout of tasks, quantities, and unit prices, by building, that reflects the complete work effort required by the contract. The cost of project management, superintendence, quality control and fee will be provided separately from the pricing provided for the various task areas. The priced proposal will be supported by a draft progress schedule that demonstrates the offeror's understanding of the work requirements, phasing of work between buildings, and estimated time frames for ordering and installing equipment.

AMENDMENTS TO SOLICITATION

(a) If this solicitation is amended, then all terms and conditions which are not modified remain unchanged.

Offerors will acknowledge receipt of any amendment to this solicitation

(1) by signing and returning the amendment, or

(2) by identifying the amendment number and date in the space provided for this purpose on the form for submitting a quote. The Government must receive the acknowledgment by the date and time specified for receipt of proposals indicated in block 10 of the SF1442.

FALSE STATEMENTS IN PROPOSAL

Offerors must provide full, accurate, and complete information as required by this solicitation and its attachments. The penalty for making false statements in quotes is prescribed in 18 U.S.C. 1001.

WORK EXPERIENCE

Please provide customer's name and contact information, the awarded dollar value, a description of all work elements included in the contract, the number and type of specialty trades needed to complete the contract, and the period of time allocated for completion of the work. Federal work experience is preferred; however, the Government will accept work experience from both, State and Institutional and Commercial contracts as well. No residential work experience will be considered appropriate for this purpose.

SUBCONTRACTOR LIST

Offerors will submit a list of proposed subcontractors as an attachment to their quote/offer. Failure to provide this listing will render the quote nonresponsive and eliminate the offer from further consideration for award.

(End of Special Requirements)

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-1 Approval of Contract DEC 1989 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000 52.219-8 Utilization of Small Business Concerns NOV 2016 52.219-14 Limitations On Subcontracting JAN 2017 52.219-30 Notice of Set-Aside for, or Sole Source Award to, Women-

Owned Small Business Concerns Eligible Under the Women- Owned Small Business Program

DEC 2015

52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards- Overtime

Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-37 Employment Reports on Veterans FEB 2016 52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2017 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.223-20 Aerosols JUN 2016 52.223-21 Foams JUN 2016 52.223-21 Foams JUN 2016 52.225-9 Buy American--Construction Materials MAY 2014 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-1 Bid Guarantee SEP 1996 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-13 Alternative Payment Protections JUL 2000 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-2 Service Of Protest SEP 2006 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-13 Alt I Accident Prevention (Nov 1991) - Alternate I NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.236-27 Alt I Site Visit (Construction) (Feb 1995) - Alternate I FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.243-6 Change Order Accounting APR 1984 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.252-1 Solicitation Provisions Incorporated By Reference FEB 1998 52.252-2 Clauses Incorporated By Reference FEB 1998 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.223-7001 Hazard Warning Labels DEC 1991 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.227-7033 Rights in Shop Drawings APR 1966 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JUN 2013

52.000-4132 AMC-LEVEL PROTEST PROGRAM (NOV 2008)

If you have complaints about this procurement, it is preferable that you first attempt to resolve those concerns with the responsible contracting officer. However, you can also protest to Headquarters, AMC. The HQ, AMC- Level Protest Program is intended to encourage interested parties to seek resolution of their concerns within AMC as an Alternative Dispute Resolution forum, rather than filing a protest with the Government Accountability Office or other external forum. Contract award or performance is suspended during the protest to the same extent, and within the same time periods, as if filed at the GAO. The AMC protest decision goal is to resolve protests within 20 working days from filing. To be timely, protests must be filed within the periods specified in FAR 33.10. If you want to file a protest under the AMC- Level Protest Program, the protest must request resolution under that program and be sent to the address below. All other agency-level protests should be sent to the contracting officer for resolution.

HQ Army Material Command Office of Command Counsel 9301 Chapek Rd, Room 2-1SE3401 Ft. Belvoir, VA 22060-5527 Facsimile number (703) 806-8866 or 8875

Packages sent by FedEx or UPS should be addressed to:

HQ Army Material Command Office of Command Counsel Room 2-1SE3401 1412 Jackson Loop Ft. Belvoir, VA 22060-5527

The AMC-Level Protest procedures are found at:

http://www.amc.army.mil/pa/COMMANDCOUNSEL.asp.

If internet access is not available, contact the contracting officer or HQ, AMC to obtain the AMC-Level Protest Procedures.

(End of Provision)

52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of the contracting officer and shall not be binding until so approved.

(End of clause)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 30 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120 days The time stated for completion shall include final cleanup of the premises.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $975.43 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the…