W9098S-17-T-0067.pdf

SEE ADDENDUM

(No Collect Calls)

W9098S-17-T-0067 06-Mar-2017

b. TELEPHONE NUMBER

309-782-5149

8. OFFER DUE DATE/LOCAL TIME

03:00 AM 06 Apr 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W9098S9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

JOHN E. JACOBSEN

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

ROCK ISLAND ARSENAL (ACC-RI)

JOINT MANUFACTURING & TECHNOLOGY CENTER

BLDG 211 RODMAN AVENUE

1 ROCK ISLAND ARSENAL

ROCK ISLAND IL 61299-5000

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS AX 13b. RATING

DO-C9

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

332322

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF59

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT 41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W9098S-17-T-0067

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES MAX

QUANTITY

UNIT UNIT PRICE MAX AMOUNT

0001 3,000 Each

DUCT ASSEMBLY, TOP FRONT

FFP

Duct Assembly, Top Front - Includes: DUCT, drawing 12561749, Initial revision and DUCT drawing 13015211, Initial revision: Nylon 6, Heat-Stabilized, Black.

Purchase IAW 13015205, Initial Revision

***PRICES MUST BE FILLED OUT ON THE PRICE MATRIX***

Certificate of Conformance (COC) required per FAR 52.246-15.

Certified Test Report (CTR) required:

Contractor SHALL ship both the COC and CTR in with each shipment.

For RIA Internal Use Only:

Project Code: D17

QA#:

PR #:

FOB: Destination

MAX

NET AMT

UNIT UNIT PRICE MAX AMOUNT

0002 3,000 Each

AIR DUCT ASSEMBLY, VERTICAL

FFP

Air Duct Assembly, Vertical - Includes: DUCT, 13015064, Initial revision, , and 3-PLATE 12340961, Revsion C. DO NOT include the Insulation 12563646.

Purchase IAW 13015069, Intial Revision

***PRICES MUST BE FILLED OUT ON THE PRICE MATRIX***

Certificate of Conformance (COC) required per FAR 52.246-15.

Certified Test Report (CTR) required:

Contractor SHALL ship both the COC and CTR in with each shipment.

For RIA Internal Use Only:

Project Code: D17

QA#:

UNIT UNIT PRICE MAX AMOUNT

0003 3,000 Each

DUCT ASSEMBLY, AIR, REAR

FFP

Duct Assembly, Air, Rear - Includes: DUCT 13015208, Initial Revision: PANEL 13015070, Initial revision: 2-BAFFLE, 13015212 Initial revision; , 2-Baffle 13015213, Initial Revision; 2-BAFFLE 13015216 Initial Revision; 8-LOUVER 13015204 Initial Revision. Purchase IAW 12561750, Initial Revision

***PRICES MUST BE FILLED OUT ON THE PRICE MATRIX***

Certificate of Conformance (COC) required per FAR 52.246-15.

Certified Test Report (CTR) required:

Contractor SHALL ship both the COC and CTR in with each shipment.

For RIA Internal Use Only:

Project Code: D17

QA#:

PROCUREMENT OVERVIEW

Addendum to FAR 52.212-1 Instructions to Offerors – Commercial Items (JAN 2017):

1. The Army Contracting Command – Rock Island (ACC-RI) hereby issues solicitation W9098S-17-T-0067 for the procurement of various duct assemblies in support of the Ambulance program at the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC). This solicitation is issued in accordance with FAR Part 12 (Acquisition of Commercial Items) and FAR Part 13.5 (Simplified Procedures for Certain Commercial Items). The result of this solicitation will be a Firm Fixed Price (FFP), 5-year Indefinite Delivery/Indefinite Quantity (IDIQ) contract with the following ordering periods:

Ordering Period 1 – date of award to 365 days Ordering Period 2 – 366 days to 731 days Ordering Period 3 – 732 days to 1,096 days Ordering Period 4 – 1,097 days – 1,461 days Ordering Period 5 – 1,462 days – 1,826 days

Goods shall be delivered to:

TRANSPORTATION OFFICER, W52H1C

BLDG 299, BECK AND GILESPIE

EAST END, RECG DOOR 16A

ROCK ISLAND IL 61299-5000

2. The actual dates will be clarified at the time of award. The total minimum and maximum quantities for each CLIN are listed in the table below. These guaranteed minimum quantities are the only guaranteed quantities to be awarded under this solicitation. The Government is under no further obligation to order additional quantities on any CLIN. Except for the minimum guaranteed quantity, all quantities are estimates and do not bind the Government in any way.

GUARANTEED

CLIN DESCRIPTION MINIMUM QTY MAXIMUM QTY

0001 Duct Assembly, Top Front 150 each 3,000 each 0002 Air Duct Assembly, Vertical 192 each 3,000 each 0003 Duct Assembly, Air, Rear 150 each 3,000 each

3. QUALITY INPSECTION REQUIREMENTS (COC & CTR)

3.1 Definitions

COC – Certificate of Conformance – IAW FAR 52.246-15 CTR – Certified Test Report

3.2 COC & CTR required for all CLIN’s. COCs and CTRs shall accompany the material when received at the Rock Island Arsenal.

3.3 Material received without COCs and CTRs may be rejected and not processed until the correct paperwork has been received. This will delay inspection and acceptance of the material as well as delay payment.

3.4 Contractors shall be responsible for all freight charges for material if it is rejected. Material must have adequate weather protection to prevent rusting during transit. Material must meet the Buy American Act. See DFARS clauses 252.225-7000 and 252.225-7001.

4. Each delivery order will state the delivery schedule required. Deliveries will begin as early as 30 days after delivery order issuance and may include an incremental monthly delivery schedule of up to 60 each per month unless otherwise specified in the delivery order. Please note that there may be instances where a delivery order is issued several months in advance of the required delivery schedule. Please keep in mind that future delivery orders may have a shorter lead-time (no less than 30 days) as indicated above. Firm delivery dates will be expressed on the delivery order(s).

5. On time delivery is very critical. Therefore, the contractor must adhere to the delivery requirements indicated in the award. Failure to comply with the contractual delivery schedule after award may result in termination of the order or require consideration if the Government elects to extend the delivery. The Government is not required to extend your delivery schedule if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflicts, etc. are not acceptable excuses for failing to meet the delivery schedules. Early delivery is authorized, but must be approved and coordinated in advance of due date with the Contract Specialist and/or Contracting Officer designated in this contract. If there is going to be a delay in delivery, the vendor is required to notify the Contract Specialist and Contracting Officer designated in this contract.

6. Please note that your performance under this contract (including timeliness of deliveries and the quality of the supplies delivered) will be monitored and recorded by this contracting office. This information may be used to determine a record of past performance for future contract awards. Contractors/Offerors that are concerned about their record of past performance may contact this office if they wish to view and discuss their records.

The monitoring of the vendor’s performance will be accomplished through the Contractor Performance Assessment Reporting System (CPARS).

7. The contractor shall submit tracking information with the contract number on all deliveries to the Rock Island Arsenal. The Tracking information shall be sent via email to the Contract Specialist listed on page 1 of the delivery order.

8. Prices shall be submitted on an F.O.B. Destination (52.247-34) basis. Ship to location is Rock Island IL 61299-5000. The price applicable to an individual delivery order is the price for the contract year and quantity range in which the delivery is issued. The delivery date does not determine the ordering period. All delivery orders will be issued unilaterally by the Government. Upon award, Delivery Order 0001 will be placed for at least the guaranteed minimum quantity.

9. Payments – Payment will be made by DFAS, via Wide Area Work Flow.

10. Only ACC-RI (CCRC-IJ) is authorized to issue delivery orders under this IDIQ contract.

11. Proposed prices must remain valid for 60 days.

12. The Offeror shall enter firm fixed unit prices for each CLIN and Quantity Ranges, for all Ordering Periods, on the Ambulance Duct Assemblies Price Matrix.

The proposed unit prices shall be the prices used by the Government to calculate the Total Evaluated Price.

Offerors must propose unit prices for all quantity ranges in all ordering periods (five one-year ordering periods) and for all CLINs identified in the pricing matrix.

Each area that requires the offeror’s input has been highlighted in Blue. Failure to complete the Price Matrix may deem the offeror ineligible for award.

Proposed prices are limited to two decimal places and shall be in current U.S. Dollars. All proposed pricing will be binding.

No other information is to be added to the Price Matrix, nor shall any changes be made to the Price Matrix.

The Government reserves the right to require the submission of any data (i.e. cost or pricing data) necessary to validate the reasonableness of an offer.

13. Army Contracting Command Government Point of Contact (POC) Attachment.

Title Name Phone # Email Contract John Jacobsen 309-782-5149 john.e.jacobsen16.civ@mail.mil Specialist

Procuring Lukas Darland 309-782-0085 lukas.k.darland.civ@mail.mil Contracting Officer

Branch Rachel Phelps 309-782-0281 rachel.m.phelps2.civ@mail.mil Chief

Division Mary Donovan 309-782-7946 mary.j.donovan4.civ@mail.mil Chief

Deputy Mark Mower 309-782-1169 mark.e.mower.civ@mail.mil

Executive Director

Executive Jay T. Carr 309-782-1999 jay.t.carr.civ@mail.mil Director

**NOTE: Communication with the Government should start at the lowest possible level.

14. Effective Immediately: Rock Island Arsenal (RIA) Visitor Access Passes are issued to individuals, not companies. All visitors, to include transportation and freight services, official and unofficial, are highly suggested to pre-register at least three (3) business days in advance. Pre-registering visitors allows for the NCIC-III background check to be conducted before the individual visits RIA, reducing the wait time necessary to complete the check.

All visitors must complete a Visitor Access Request Form. Access Request Forms should be emailed or faxed prior to the delivery. The Visitor Access Request Form can be found at http://www.usagria.army.mil/AccessRequests.

Follow the instructions on How to Obtain a Visitor Pass. All first time visitors must process through the Moline Gate Visitor Center.

TRUCKS MUST ENTER THROUGH MOLINE, IL GATE, OFF OF RIVER DRIVE IN MOLINE I-74.

Transportation Service Providers are required to send drivers with proper identification who meet all the installation access requirements. Transportation Service Providers are required to send United States Citizens and drivers that will pass applicable background checks failure to do so can result in warnings or Non-use. Real-ID access implementation is active at Rock Island Arsenal, IL. Individuals using a driver's license from the states of Illinois, Minnesota, Missouri, New Mexico or Washington will have to use a secondary form of Identification to enter U.S.

military installations. Additional forms of identification that may be used in conjunction with a state driver's license are Vehicle Registration with name and address, Veterans Health Identification Card, PIV Card, PIV-1 Card, DHS "Trusted Traveler" Card, U.S. Certificate of Naturalization or Certificate of Citizenship (Form N-550), and State of Illinois Firearm Owners Identification (FOID) card.

The prime vendor needs to ensure this information is passed on to any subcontractors and/or transportation providers they may utilize during performance of their contract. DRIVERS WHO DO NOT MEET THE INSTALLATION

ACCESS REQUIREMENTS, THEY WILL NOT BE ALLOWED ON THE INSTALLATION AND WILL BE

TURNED AWAY.

POC for this Policy are:

Rock Island Arsenal Visitor Center

(309) 782-0485 -phone

(309) 782-5029 -fax usarmy.ria.imcom.mbx.usag-access-request@mail.mil

END OF ADDENDUM TO 52.212-1, INSTRUCTIONS TO OFFERORS - COMMERCIAL

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 N/A N/A N/A N/A

0002 N/A N/A N/A N/A

0003 N/A N/A N/A N/A

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities APR 1984 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7003 Agency Office of the Inspector General DEC 2012 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7008 Compliance With Safeguarding Covered Defense Information Controls

OCT 2016

252.204-7011 Alternative Line Item Structure SEP 2011 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.215-7007 Notice of Intent to Resolicit JUN 2012 252.215-7008 Only One Offer OCT 2013 252.222-7007 Representation Regarding Combating Trafficking in Persons JAN 2015 252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic

(Dec 2016)

DEC 2016

252.225-7012 Preference For Certain Domestic Commodities DEC 2016

252.225-7021 Trade Agreements--Basic DEC 2016 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

SEP 2004

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

JUN 2012

252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014

CLAUSES INCORPORATED BY FULL TEXT

52.0000-4173 EVALUATION OF OFFERS - ALL OR NONE AWARD (MAR 1988)

An offeror must quote on all items in this solicitation to be eligible for award. All items will be awarded only as a unit. (PADDS MS7100/IOC 52.215-4507) (End of provision)

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

(End of provision)

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (OCT 2016)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF

1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions or commercial items for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers.

Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision.

Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

ADDENDUM TO 52.212-1, INSTRUCTIONS TO OFFERORS - COMMERCIAL

PROVISIONS INCORPORATED BY REFERENCE

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain

Federal Transactions

SEP 2007

52.204-7 System for Award Management OCT 2016 52.203-18 Prohibition on Contracting with Entities that Require Certain Internal

Confidentiality Agreements of Statements- Representation

JAN 2017

52.215-20 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data

OCT 2010

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

252.225-7013 Duty Free Entry MAY 2016

PROVISIONS INCORPORATED BY FULL TEXT

52.209-7 – Information Regarding Responsibility Matters. (Jul 2013)

(a) Definitions. As used in this provision— “Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from lukas.k.darland.civ@mail.mil.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of Provision)

252.211-7001 Availability of Specifications, Standards, and Data Item Descriptions Not Listed in the Acquisition Streamlining and Standardization Information System (ASSIST), and Plans, Drawings, and Other Pertinent Documents. (MAY 2006)

Offerors may obtain the specifications, standards, plans, drawings, data item descriptions, and other pertinent documents cited in this solicitation by following the instructions below:

The TDP for this solicitation resides within the FedBizOpps notice(https://www.fbo.gov), associated with this solicitation number.

a. Log on to the FBO web site under Vendor Login.

b. Search and find this solicitation.

c. Click on packages tab or find the drawings link on the left hand side of the screen.

d. Click “request explicit access” button or if prompted enter your Marketing Partner Identification Number (MPIN), select “Verify MPIN.”

(1) TDPs that have an Export Control Warning Notice are subject to the Arms Export Control Act (Title 22, U.S.C., Sec 2751, et.seq.) or the Export Administration Act of 1979, as amended, Title 50, U.S.C, App. 2401 et. seq..

(2) Further dissemination must be in accordance with provisions of DoD Directive 5230.25. This also applies to distribution of the TDP to all SUBCONTRACTORS at every level.

(3) To obtain these TDPs, vendors and contractors must have a current DD 2345, Militarily Critical Technical Data Agreement on file with Defense Logistics Information Service (DLIS). If you are currently certified, your MPIN will be verified and you may proceed to the next step. To obtain certification, go to http://www.dlis.dla.mil/jcp/ click on documents and follow instructions provided. Processing time is estimated at six (6) to ten (10) weeks after receipt. FBO will allow you to access export controlled TDPs once certification is confirmed.

(4) Upon completion of the purposes for which Government Technical Data has been provided, the Contractor is required to destroy all documents, including all reproductions, duplications, or copies thereof as may have been further distributed by the Contractor. Destruction of this technical data shall be accomplished by: shredding, pulping, burning, or melting any physical copies of the TDP and/or deletion or removal of downloaded TDP files from computer drives and electronic devices, and any copies of those files.

e. If prompted to select “Request Explicit Access.” This will generate an email to the Contract Specialist listed on the first page of the contract notifying them to review your request. FBO will subsequently automatically generate an email stating when you have permission to view or download TDP items. Allow 2 – 3 working days to complete this FBO-TDP access/approval process through the FBO system.

f. If multiple individuals in your company need access to the Technical Data Package (TDP) for a solicitation and an explicit access request is required, each individual MUST submit an explicit access request to be granted approval to view the TDP. Those same individuals MUST be registered in Federal Business Opportunities (FBO).

Any individuals no longer with the company should be deleted. Questions related to registration in FBO should be directed to https://www.fbo.gov/index The FBO helpdesk phone number is (866) 606-8220. Vendors are responsible for placing correct information in FBO.

g. It is strongly suggested that you submit the explicit access request and provide the buyer with the completed “Use and Non-Disclosure Agreement” at the same time if the solicitation requires both to gain access to view the

TDP.

h. A user guide for FBO can be found at https://www.fbo.gov - on the right is User Guides - click on “Vendor”.

END OF PROVISION

52.223-22 – Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. (Dec 2016)

(a) This representation shall be completed if the Offeror received $7.5 million or more in Federal contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year.

(b) Representation. [Offeror is to check applicable blocks in paragraphs (b)(1) and (2).]

(1) The Offeror (itself or through its immediate owner or highest-level owner) [ ] does, [ ] does not publicly disclose greenhouse gas emissions, i.e., make available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard.

(2) The Offeror (itself or through its immediate owner or highest-level owner) [ ] does, [ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly available Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage.

(3) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program.

(c) If the Offeror checked “does” in paragraphs (b)(1) or (b)(2) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported:_____.

(End of provision)

52.211-14 NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PREPAREDNESS, AND ENERGY PROGRAM USE (APR 2008)

Any contract awarded as a result of this solicitation will be [] DX rated order; [x] DO rated order certified for national defense, emergency preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR 700), and the Contractor will be required to follow all of the requirements of this regulation.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil (End of provision)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Acquisition Regulations System, Department of Defense (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

52.0000-4173 EVALUATION OF OFFERS - ALL OR NONE AWARD (MAR 1988)

An offeror must quote on all items in this solicitation to be eligible for award. All items will be awarded only as a unit. (PADDS MS7100/IOC 52.215-4507) (End of provision)

END OF ADDENDUM TO 52.212-1, INSTRUCTIONS TO OFFERORS - COMMERCIAL

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

PRICE ONLY.

For each CLIN, the Government will calculate a Weighted Evaluation Price by multiplying the proposed unit prices for each quantity range and each Ordering Period by their respective weight and maximum quantity, and summing their totals. The weight associated with each range represents the likelihood that an order, if placed, would be placed within that range. The Evaluated CLIN Price is the sum of the weighted prices for all ordering periods.

The Total Evaluated Price will be calculated by adding each of the Evaluated CLIN Prices for all CLINs.

The Total Evaluated Price will be evaluated, but will not be assigned a rating.

The Total Evaluated Price will be evaluated utilizing the proposal analysis techniques IAW FAR 13.106.

Unbalanced Pricing: As part of the evaluation, proposals may be reviewed to identify any significant unbalanced pricing found between Ordering Periods, quantity ranges, contract line items or sub-line items as applicable. In accordance with FAR 15.404-1(g), i.e., Unbalanced Pricing, a proposal may be rejected if the Contracting Officer determines the lack of balance poses an unacceptable risk to the Government.

(b) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (DEC 2016)

ALTERNATE I (OCT 2014)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal . If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (t) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a…