W52P1J-17-T-3040.pdf

SEE ADDENDUM

(No Collect Calls)

W52P1J-17-T-3040 11-Apr-2017

b. TELEPHONE NUMBER

(309) 782-0703

8. OFFER DUE DATE/LOCAL TIME

03:00 PM 19 Apr 2017

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W52P1J9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

SHEILA K. PETERS

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

W44W9M708701N5

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

ARMY CONTRACTING COMMAND ROCK ISLAND

3055 RODMAN AVENUE

BLDG 60, 3RD FLOOR

SHEILA PETERS

ROCK ISLAND IL 61299-8000

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS AX

13b. RATING

DO-C9

CODE15. DELIVER TO CODE W44W9M 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

MCALESTER ARMY AMMUNITION PLANT

RECEIVING OFFICER

WAREHOUSE 8

1 C TREE ROAD

MCALESTER OK 74501-9002

TEL: FAX:

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

1,500

NAICS:

336510

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF55

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W52P1J-17-T-3040

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Each FSC: 2230 Name: CRANE,RAIL TIE Part Number: TC75E

FFP

Description: CRANE, RAIL TIE INTERIM TIER 4 EMISSION, WATER

COOLED, DIESEL ENGINE DEERE 75G REDUCED TAIL SWING UPPER

STRUCTURE DEERE 75G STANDARD EXCAVATOR BOOM DEERE 75G

EXCAVATOR ARM LOWER PLATFORM AND RAIL WHEEL DRIVE

SYSTEM PRESSURIZED CAB WITH HEATER AND DEFROSTER AND AIR

CONDITIONING MASTER ELECTRIC DISCONNECT 24 VOLT

ELECTRICAL SYSTEM WITH 50 AMP ALTERNATOR HYDRAULIC SHOE

SERVICE BRAKES HYDRAULIC PARK BRAKE/EMERGENCY BRAKE

ASSEMBLY HYDRAULIC DRIVE MOTOR SYSTEM (NO CHAINS) FRONT

AND REAR LIFT AND TIE DOWN HOOKS BRAKE CIRCUIT TO OPERATE

RCE CART BRAKES WORK LIGHT PACKAGE EMERGENCY PUMP BOOM

AND SWING CIRCUITS AUXILIARY HYDRAULIC OIL COOLER SINGLE

TIE G

FOB: Destination

NSN: TC75E:51503

MILSTRIP: W44W9M708701N5

PURCHASE REQUEST NUMBER: W44W9M708701N5

NET AMT

OFFEROR POC INFORMATION

Please complete the following seven fields.

(POINT OF CONTACT - TYPED):

POC NAME: _________________________

POC TITLE: _________________________

POC TELEPHONE: _________________________

POC EMAIL ADDRESS: _________________________

DUNS NUMBER: _________________________ (http://fedgov.dnb.com/webform)

CAGE CODE: _________________________ (http://www.dlis.dla.mil/cage_welcome.asp)

TAXPAYER ID NUMBER: _________________________

(END OF TEXT)

NOTICE FOR LINE ITEM 0001

INSTRUCTIONS FOR SUBMITTALS:

Each Vendor shall provide the following documents for a full evaluation of its offer. Failure to submit the required documents may result in a Vendor's offer not being considered for award:

A. PRICING: Vendor(s) shall insert the proposed unit price and extended price in CLIN 0001. Note: The Government does not recognize digits past the hundredths decimal position (.01) when calculating currency figures.

B. COMPLETE SUBMITTAL: Vendor(s) shall submit a completed, signed and dated copy of their SF1449 solicitation to this ACC-RI office.

C. ALL VENDORS MUST SUBMIT VIA E-MAIL: Proposals/ bids/ quotes shall be submitted electronically by e-mail. The solicitation must be filled out completely and signed by an authorized representative. The completed solicitation shall be scanned, included as an attachment, and e-mailed to the address provided in this solicitation. All e-mailed quotes and attachments must be in Adobe Acrobat (.pdf) format and the solicitation must be submitted in its entirety along with any amendments -- including vendor attachments, drawings, or supporting documents -- by the specified date and time, in order to be considered for award. This instruction takes precedence over any other direction for FBO vendor proposal/bid/quote submittal.

NOTE: Proposals/ bids/ quotes WILL NOT be accepted for this solicitation through the FBO web site.

NOTE: Quotations received after the solicitation closing date and time shall be considered LATE and WILL NOT be considered for award.

SALIENT CHARACTERISTICS

Overall Specifications

Rated Net Power (ISO 9249) shall be no less than 56.9 hp (42.4 kW) The arm force shall be no less than 6,902 lb (30.7 kN) The bucket curl force shall be no less than 10,476 lb (46.6 kN) The Reach shall be no less than 24' from track center Tie crane shall have a minimum lift capacity of 1,200 lbs over the side Optional single tie grapple shall be included Warranty of this equipment is 12 months on all components

Engine

Engine shall be certified to EPA Final Tier 4/EU Stage IV Engine shall have four cylinders and a displacement of no less than 202 cu in (3.3 L) The engine will have a cold start aid such as glow plugs The engine oil and fuel filters will be remotely mounted for ease of access

Cooling

Engine coolant shall protect the machine to temperature of -34°F (-37°C) The radiator and oil cooler will be protected with a trash screen to protect against debris A fan guard inside the engine compartment will help prevent contact with the engine fan blades

Power Train The machine's propel travel motor system shall be hydraulically driven and mounted on the end of each axle A chain drive propel travel motor system shall not be accepted Travel motors shall be actuated by a two direction foot pedal inside operator’s station

Brakes

The machine brake system shall include a spring applied and hydraulically released dry can emergency / parking brake, mounted on the end of each axle

The propel parking brake shall be actuated by a park brake switch mounted in the cab within operators reach

The propel parking brake shall also be actuated by a pilot control circuit leaver mounted in the cab within operators reach

The propel Service Brakes shall Include a hydraulic actuated “shoe brake” assembly mounted on each axle The propel Service Brakes shall be actuated by a foot pedal inside operator’s station Pneumatic actuated propel Service Brakes shall not be accepted

Hydraulics

The hydraulic system shall be open center, load sensing The main pumps shall be three variable-displacement axial-piston pumps with maximum flow of 2 x 19 +

15 gpm Boom and arm shall have reduced drift valves for greater stability and positioning Boom and arm shall be equipped with required hydraulics to operate a rotary tie Grapple Machine shall include a hydraulic emergency pump for boom raise and swing in the event of machine shut down

Electrical

The electrical system shall be 24 volt and alternator rating no less than 50 amp Work lights shall be provided: mounted on the frame and boom One cab entry light shall be provided: one mounted on the cab illuminating the cab access. And will have a switch assessable from the ground The fuse box shall be in the cab, well protected from the elements and opened without tools A safety cover will protect the positive terminal of the battery A TAG-out LOCK-out Battery Disconnect will be provided

Lower structure

The lower undercarriage shall include sufficient key hole style tie down mounts for transportation of this machine by truck

Machine to include structurally sound bumpers, integrated into the frame. The bumpers are to be located fore and aft of the machine and will be required to endure the forces induced by a tow hitch.

The lower undercarriage shall have include Tow hitch points on each end for connecting carts The lower undercarriage shall have include two (2) 4" live axles with 16" rail wheels Each axle will be mounted through spherical pillow block bearings The lower undercarriage shall be equipped with hydraulic service brake connections on each end of the machine to activate hydraulic service disc service brakes on rail carts

The lower undercarriage shall be equipped with hydraulic parking brake connections on each end of the machine to activate hydraulic emergency / park brakes on rail carts

The rail axles shall be set to run on 56.5" Track Gauge Drawbar pull shall be at least 14,661 lbs (6650 kgf) for pulling a minimum cart capacity of 40,000 lbs

Upper structure

Right and left hand exterior mirrors shall be standard Window bars shall be provided to prevent contact with a moving boom Tight tail swing design to prevent cab damage A vandal locks with ignition key will be provided for: cab door; engine hood; fuel cap; and service doors

Swing Mechanism

Swing speed shall be no less than 10.5 rpm Swing torque shall be no less than 12,244 lb ft (16 600 Nm) The machines house Swing brake shall be wet disk, or equivalent, spring applied and hydraulically released

Boom and Arm

The boom shall have a minimum of three bulkheads for durability To extend the life of the pivot joint bushings, they will be powdered metal oil impregnated The end of the arm shall be coated to extend the life of the wear surface with tungsten carbide or equivalent material

Operators Station

The operator’s station shall be mounted on silicon fluid-filled elastic mounts Auto climate control /air conditioner heater and pressurizer will be provided The machine will monitor and display a minimum of the following indicators: engine air filter restriction, alternator voltage, check engine, engine oil pressure, engine coolant temperature and fuel level The monitor shall be capable of showing machine diagnostic information including error messages, fault codes and system operating information.

An interior light shall be standard The windshield wiper shall have intermittent speeds and built in washer with fluid Cab front windows - top and bottom shall be capable of opening A pilot control shut-off lever will shut off hydraulic pilot pressure to all pilot control valves and will lock machine travel The seat shall be adjustable for: height; fore-aft; backrest; and headrest height The engine shall perform self-diagnostic check at start up

GOVERNMENT POCS

Army Contracting Command - Rock Island Government Points of Contact (POC)

Title Name Phone E-mail

Contract Specialist Sheila Peters 309-782-0703 sheila.k.peters2.civ@mail.mil Procuring Contracting Elvia Jaggers 309-782-3271 elvia.jaggers.civ@mail.mil Officer (PCO) Branch Chief Valiant DuHart 309-782-8517 valiant.m.duhart.civ@mail.mil Division Chief Mary Donovan 309-782-7946 mary.j.donovan4.civ@mail.mil Jeremy Miller 309-782-5213 jeremy.h.miller.civ@mail.mil Deputy Executive Director Mark E. Mower 309-782-1169 mark.e.mower.civ@mail.mil Executive Director Jay T. Carr 309-782-1999 jay.t.carr.civ@mail.mil

Note: Communication with the Government should start at the lowest possible level.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 31-JUL-2017 1 MCALESTER ARMY AMMUNITION

PLANT

RECEIVING OFFICER

WAREHOUSE 8

1 C TREE ROAD

MCALESTER OK 74501-9002

FOB: Destination

W44W9M

CLAUSES INCORPORATED BY REFERENCE

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-18 Prohibition on Contracting With Entities That Require Certain Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreeements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-8 Annual Representations and Certifications JAN 2017 52.209-5 Certification Regarding Responsibility Matters OCT 2015 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under and Federal Law

FEB 2016

52.211-15 Defense Priority And Allocation Requirements APR 2008 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.232-17 Interest MAY 2014 52.246-2 Inspection Of Supplies--Fixed Price AUG 1996 52.247-34 F.O.B. Destination NOV 1991 52.253-1 Computer Generated Forms JAN 1991 252.203-7003 Agency Office of the Inspector General DEC 2012 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.211-7008 Use of Government-Assigned Serial Numbers SEP 2010 252.225-7002 Qualifying Country Sources As Subcontractors DEC 2016 252.225-7013 Duty-Free Entry--Basic (May 2016) MAY 2016 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.246-7000 Material Inspection And Receiving Report MAR 2008 252.247-7022 Representation Of Extent Of Transportation Of Supplies By

Sea

AUG 1992

CLAUSES INCORPORATED BY FULL TEXT

52.0000-4000 02 NON-RELEASE OF CONTRACT INFORMATION (MAR 2000)

1. Any proprietary, confidential commercial, trade secret or similar type of information in the contract resulting from this solicitation may not be released to anyone outside the Government.

2. Do not release proprietary, confidential commercial, trade secret or similar type of information from this contract to anyone inside the Government that does not have a legitimate need to know the information.

3. If in doubt about what information in the contract may be released, contact the Contracting Officer.

4. Criminal penalties are provided by 18 U.S.C. for the improper release of proprietary and/or confidential commercial information. (End of notice)

52.0000-4001 CLAUSES/SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

(FAR 52.252-1/52.252-2)

This solicitation incorporates one or more clauses and/or solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available.

The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at these addresses:

http://farsite.hill.af.mil/; http://www.arnet.gov/far/; http://akss.dau.mil/jsp/default.jsp;

(End of clause/provision)

52.0000-4002 SHIPPING/DELIVERY INSTRUCTIONS AND INFORMATION (FEB 2004)

1. THE COMPLETE 13-DIGIT PURCHASE ORDER, DELIVERY ORDER, OR CONTRACT NUMBER (The Number that starts with W52P1J----) MUST BE ON THE OUTSIDE OF THE SHIPPING CONTAINER. This number must also appear on all packing slips, invoices, bills, or any communications regarding this order.

2. A Packing List must be included with each shipment.

3. Any excess quantity delivered, that is not covered by a Variation in Quantity clause, is subject to rejection.

4. SHIPMENT OR DELIVERY TO ANY ADDRESS OTHER THAN THE ₃ SHIP TO₄ ADDRESS

DESIGNATED IN THE PURCHASE ORDER/DELIVERY ORDER/CONTRACT (Block 14 of the DD1155, Block 15 of the SF1449, or Block 11 of the SF 26) MAY RESULT IN A DELAY IN PAYMENT.

5. ANY CHANGE IN THE ₃ SHIP TO₄ ADDRESS MUST BE APPROVED BY A WRITTEN CONTRACT

MODIFICATION FROM THE CONTRACTING OFFICER.

6. Information from FAR clause 52.232-25, Prompt Payment (FEB 2002), Paragraph (a)(5)(i): For the sole purpose of computing an interest penalty that might be due the Contractor, Government acceptance is deemed to occur constructively on the 7th day (unless otherwise specified in this contract) after the Contractor delivers the supplies or performs the services in accordance with the terms and conditions of the contract, unless there is a disagreement over quantity, quality, or Contractor compliance with a contract provision. If actual acceptance occurs within the constructive acceptance period, the Government will base the determination of an interest penalty on the actual date of acceptance. The constructive acceptance requirement does not, however, compel Government officials to accept supplies or services, perform contract administration functions, or make payment prior to fulfilling their responsibilities.

(End of Provision)

52.0000-4003 DISCLOSURE OF UNIT PRICE INFORMATION (JUN 2005)

This constitutes notification pursuant to Executive Order 12600, Pre-Disclosure Notification Procedures for Confidential Commercial Information (June 23,1987), of our intention to release unit prices of the awardee in response to any request under the Freedom of Information Act, 5 USC 552. Unit price is defined as the contract price per unit or item purchased. We consider any objection to be waived unless the Contracting Officer is notified of your objection to such release prior to submission of initial proposals.

(End of clause)

RECEIVING OFFICE REQUIREMENT – MCAAP (OCT 2007)

52.0011-4000 MC

At the McAlester Army Ammunition Plant truck shipments are accepted at Warehouse 8, Receiving Office, Monday through Thursday (except holidays) from 6:30 A.M. until 3:00 P.M. only. All shipments must be at main gate (truck gate) on or before 3:00 P.M. No shipments will be accepted after 3:00 P.M. unless prior arrangements have been made.

No shipments will be accepted on government holidays.

(End of Notice)

CONFORMANCE WITH ENVIRONMENTAL MANAGEMENT SYSTEM – FOR WORK PERFORMED AT

MCALESTER ARMY AMMUNITION PLANT (OCT 2008)

52.0023-4000 MC

The Contractor shall perform work under this contract consistent with all applicable federal, state, local requirements and with the relevant policy and objectives identified in McAlester Army Ammunition Plant’s (MCAAP’s) environmental management system (EMS) located to http:www.mcaap.army.mil. The Contractor shall perform work in a manner that conforms to all applicable Environmental Management Programs and Operational Controls identified by the MCAAP EMS, and provide monitoring and measurement information as necessary for the organization to address environmental performance relative to MCAAP’s EMS objectives and goals. In the event an environmental nonconformance or noncompliance associated with the contracted services is identified, the Contractor shall take corrective and/or preventative actions. In the case of a noncompliance, the Contractor shall respond and take corrective action immediately. In violations caused by Contractor negligence, the Contractor shall reimburse the Government for the amount of that fine and all associated costs. The Contractor shall also provide cleanup of any spills, including oil, that result from the Contractor’s operations and report spills to MCAAP’s Environmental Management Office. In the case of a nonconformance, the Contractor shall respond and take corrective action based on the time schedule established by the Environmental Management Office and approved by the Contracting Officer. In addition, the Contractor shall ensure that their employees are aware of the roles and responsibilities identified by the EMS and how these requirements affect their work performed under this contract.

Prior to commencing work, all on-site Contractors shall provide documentation to the Contracting Officer that any required EPA sponsored environmental training specified for the type of work conducted has been obtained. Upon contract award, and during performance of the contract, the Contracting Officer’s Representative will provide or arrange EMS training for appropriate Contractor staff.

(End of Clause)

PROHIBITED WITHIN GENERAL CONFINES OF INSTALLATION (FEB 2004)

52.0045-4001 MC

The following are prohibited within the general confines of the McAlester Army Ammunition Plant at any time:

(a) Firearms/dangerous weapons

(b) Drugs/intoxicants

(c) Binoculars, cameras, camera equipment, cell phones and PDAs with camera capability (unless authorized by the Security Officer)

(d) Matches, lighters or other fire flame or spark producing devices in designated areas

(e) Gas cans/flammable material storage containers (unless approved by MCAAP Fire Department)

(f) Fireworks without the Commander's approval

(g) Smoking in all buildings, when handling flammable and hazardous materials, in railroad cars, trucks and vans, on warehouse docks and platforms, in open storage containing combustibles, within 50 feet of a gasoline refueling storage or drainage area, where posted signs prohibit smoking.

SECURITY REQUIREMENTS – BADGING

52.0045-4002 MC

(a) Any foreign nationals without a green card will not be allowed entrance to the installation. Those individuals with a green card must be escorted within the restricted area at all times

(b) Contractors by virtue of contract award will be given access privileges to McAlester AAP. Contractors/Sub- Contractors are required to provide security at McAlester AAP a letter of introduction for company personnel by providing the following: 1) Name; 2) Physical Address (including city and state); 3) Date of Birth; 4) Place of Birth; and 5) Whether or not they are a U.S. Citizen on company letterhead. Information shall be provided to McAlester AAP, Security Division, Attn: Ms. Traci Howard, McAlester, OK 74501 or faxed to 918-420- .

(Applies to contracts that require access to restricted areas)

(c) Each member of the Contractor's work force shall be individually badged at the Security Office in Building 31.

The badge shall be retained and worn by the Contractor's employees throughout the contract period. (Applies to contracts that require access to restricted areas)

(d) Contractor is responsible for the turn-in of all security badges, including sub-contractors badges, daily and upon completion of the contract or termination of individual employees. (Applies to contracts that require access to restricted areas)

(e) Report lost badges to the Security Office and the KO as soon as the loss is discovered. (Applies to contracts that require access to restricted areas)

(f) Be prepared to produce security badges each time entering a security area. Temporary badges for any individual who may have forgotten his/her badge can be obtained from the Security Office. (Applies to contracts that require access in restricted areas).

Security Requirements – Vehicles

52.0045-4003 MC

(1) TRAFFIC ENFORCEMENT: (a) McAlester AAP traffic laws are enforced by the Law Enforcement and Security Division using Oklahoma state codes. All roads/streets have speed limit signs posted; (b) Traffic violations are adjudicated by the U.S. Magistrate located at McAlester AAP. Court appearances may be requested or mandatory; and (c) Radar is used to enforce traffic speed limits.

(2) INSURANCE: All vehicles entering the installation must possess the minimum insurance as required by the State of Oklahoma.

(3) VEHICLES: (a) Vehicles entering McAlester AAP, whether Contractor-owned or privately owned, shall undergo inspections and may be issued a pass if entering a restricted area. Vehicle permits for restricted areas will be issued for up to 45 days maximum. Each vehicle will be required to carry a fire extinguisher at all times; (b) Company or privately-owned vehicles, when parked, must have ignition keys removed. After duty hours, vehicles left on the installation will be parked outside restricted areas unless otherwise stipulated in the contract. Vehicles or equipment remaining inside restricted areas will be properly secured or immobilized; and (c) Contractor is solely responsible for the removal of incapacitated vehicles or equipment from restricted areas. (d) All vehicles shall be parked at least 20 meters from all buildings unless unloading or loading; and (e) The contractor can expect to be inspected at one or all of the two manned gates. The contractor should expect five to ten minute delays at each gate.

In addition, to get to some of the remote areas, the contractor should expect at least a 15-minute delay both in and out to allow security to open necessary gates.

(4) RESTRICTED AREAS: Any contractor personnel granted access into restricted areas will be subject to vehicle search upon entering or leaving these areas possibility resulting in some delay. Any non-US contractor personnel granted access into restricted areas w ill at all times be escorted by US contractor personnel who have been properly badged and granted access. (Applies to contracts that require work in restricted areas)

HOURS OF OPERATION – MCAAP

52.0047-4001 MC

Normal work hours are Monday through Thursday 6:30 A.M. until 5 P.M. Contractors will not be permitted to work on Fridays, Saturdays, Sundays, or legal holidays for any reason, unless otherwise approved by the Contracting Officer. The following legal holidays will be observed:

January 1st 3rd Monday of January 3rd Monday of February Last Monday of May July 4th 1st Monday of September 2nd Monday of October November 11th 4th Thursday of November December 25th

When one of the designated holidays falls on a Friday or Saturday, holiday will be observed on Thursday. If the holiday falls on a Sunday, holiday will be observed on the following Monday.

(End of Notice)

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (JAN 2017)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation.

Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers.

Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision.

Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

Award will be based on the lowest priced, responsive, responsible vendor whose offer conforms to the solicitation requirements.

(End of provision)

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision --

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means—

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) Concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

"Forced or indentured child labor" means all work or service-

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except--

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased…