Solicitation - N0038326QF053.pdf

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

THIS RFQ IS IS NOT A SMALL BUSINESS SET-ASIDE

15. DATE OF QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

b. TELEPHONE

AREA CODE

NUMBER

STANDARD FORM 18 (REV. 6-95)

Prescribed by GSA-FAR (48 CFR) 53.215-1(a)

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

8. TO:

b. COMPANYa. NAME

c. STREET ADDRESS

d. CITY e. STATE f. ZIP CODE

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

c. CITY

d. STATE e. ZIP CODE

7. DELIVERY

FOB DESTINATION

OTHER

(See Schedule)

10. PLEASE FURNISH QUOTATIONS TO THE

ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS (Date)

IMPORTANT: This is a request for information and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or service. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotation must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations are are not attached.

13. NAME AND ADDRESS OF QUOTER

a. NAME OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NO. 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG. 1

RATING

5a. ISSUED BY 6. DELIVER BY (Date)

5b. FOR INFORMATION CALL (NO COLLECT CALLS)

NAME TELEPHONE NUMBER

AREA CODE NUMBER

FMS Requirement

Section A - Solicitation/Contract Form

N0038325PR0R655- FMS REPAIR

This is a sole source requirement for the repair of the following:

Nomenclature: INERTIAL NAVIGATION

NSN: 7RH 6605 014830602 CB

Part Number: 233A935-1

FMS Case: GR-P-BBK

CRITICAL APPLICATION ITEM (CAI)

QTY: 1

RMC: 3H

NAVUP WSS Philadelphia intends to award this requirement on a sole source basis under an already established BOA.

The Government physically does not have in its possession sufficient, accurate, or legible data to contract with other than the current source. One or more of the items under this acquisition is subject to Free Trade Agreements. (FAR 52.225-3).

One or more of the items under this acquisition are subject to the World Trade Organization Government Procurement Agreement and Free Trade Agreements. (FAR 52.225-5)

These items require Government Source Approval prior to the award. The time required for approval of a new source is normally such that an award cannot be delayed pending approval of a new source. If you are not an approved source, you must submit, together with your proposal, the information detailed in the NAVSUP WSS Source Approval Brochure, which can be obtained on the internet at https://www.navsup.navy.mil/Business-Opportunities/Home/

Offers received which fail to provide all data required by the source approval brochure will not be considered for award under this solicitation.

For information or questions regarding this notice, please contact Mrs. Dana Scott at the email address: dana.l.scott14.civ@us.navy.mil

N0038326QF053

mailto:dana.l.scott14.civ@us.navy.mil

Section B - Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

Evaluation, Labor, Materials and Parts as may be required to restore the following Government owned articles to operating condition.

Nomenclature: INERTIAL NAVIGATION

NSN: 7RH 6605 014830602 CB

Part Number: 233A935-1 FMS Case: GR-P-BBK

CRITICAL APPLICATION ITEM (CAI)

0001AA

Reference CLIN 0001

M/F: PGRPE351430001

SER NR: 500255A

Throughput Constraint: 000/month Induction Exp. Date: TBD / 365 RTAT: TBD days after induction of asset.

Ship to: PGR002 Mark For: PGRP00

SUPPAD: PA2BBK

National Stock Number: 6605014830602 Pricing Arrangement: Firm Fixed Price

1 Each

Additional Regulation or Supplemental Clauses Incorporated by Full Text

WSSTERMBA00 CONTACT INFORMATION (Jan 2021)

When a DCMA office is shown on a Contract/Purchase Order, the Administrative Contracting Officer (ACO) is the primary point of contact and all inquiries shall initially be directed to that office for necessary action.

Inquiries and correspondence directed to the Post Award PCO should be addressed as follows:

Code N732.47 Weapon System LRC: FMS - H60

Telephone: 771-229-0557

E-Mail: DANA.L.SCOTT14.CIV@US.NAVY.MIL

In the event that the listed PCO contact information is no longer valid and a follow-on PCO cannot be identified, contact itimp.wss.

fct@navy.mil.

WSSTERMBZ04 IMPORTANT NOTICE REGARDING HAZARDOUS MATERIAL (Oct 2006)

FAR clause 52.223-3, Hazardous Material Identification and Material Safety Data, is incorporated by reference in Section I in this solicitation and requires offerors to--

(1) identify any hazardous material (defined in FED STD 313 as an item or chemical which is a "health or physical hazard" per OSHA in 29 CFR 1910.1200) that will be delivered under a resultant contract, and

(2) provide a Material Safety Data Sheet meeting OSHA/FED STD 313 requirements for all hazardous material identified.

While not an all-inclusive listing of hazardous material, at a minimum, any item with a four-digit Federal Supply Code (FSC), which correlates to the first four positions of the National Stock Number (NSN), of 6810, 6820, 6830, 6840, 6850, 7930, 8010, N0038326QF053 mailto:itimp.wss.fct@navy.mil mailto:itimp.wss.fct@navy.mil

8030, 8040, 9110, 9135, 9140, 9150, or 9160 is considered hazardous material and requires submission of a Material Safety Data Sheet or an appropriate representation that there is no hazardous material contained in the item.

Failure to provide the required information and documentation may render you ineligible for award. If you have questions about whether a solicited item is classified as hazardous, contact the NAVICP HAZMAT point of contact, NAVSUP WSS Code N26 Director Jeff Whitman, at (564) 230-3019 or .jeff.w.whitman.civ@us.navy.mil

N0038326QF053

Section C - Description/Specifications/Statement of Work

CLIN: 0001

NIIN: 014830602

ITEM NAME: INERTIAL NAVIGATION

1. SCOPE

1.1 This contract/purchase order contains the requirements for repair and the contract quality requirements for the

.INERTIAL NAVIGATION

2. APPLICABLE DOCUMENTS

2.1 Applicable Documents - The document(s) listed below form a part of this contract/purchase order including modifications or exclusions.

2.1.1 "Document References" listed below must be obtained by the Contractor. Ordering information is included as an attachment to this contract/purchase order.

3. REQUIREMENTS

3.1 Cage Code/Reference Number Items - The repaired under this contract/purchase order INERTIAL NAVIGATION shall meet the operational and functional requirements as represented by the Cage Code(s) and reference number(s) listed below.

All repair work shall be performed in accordance with the contractor's repair/overhaul standard practices, manuals and directives including but not limited to drawings, technical orders, manufacturing operations, tooling instructions, approved repair standards and any other contractor or government approved documents developed to provide technical repair procedures.

03640 REF NO. 233A935-1

3.2 Marking - PACKAGING AND MARKING SHALL BE IN ACCORDANCE WITH BEST STANDARD

COMMERCIAL PACKAGING FOR OVERSEAS SHIPMENT.

3.3 Changes in Design, Material Servicing, or Part Number - Except for a Code 1 change, which shall be processed as provided in the code statement shown below, no substitution of items shall be made until the NAVSUP-WSS- MECH Contracting Officer has notified and approval has been given by issuance of a written change order. When any change in design, material, servicing or part number is made to replace or substitute any item to be furnished on this contract/purchase order, the Contractor shall furnish, for the substituting/replacement item, a drawing and an explanation of the reason for the change, explaining the reason therefor. If finished detail drawings are not available, shop drawings in the form used by the manufacturer will be acceptable for Government evaluation. When notifying the Procurement Contracting Officer of the reasons for making substitutions, the type of change shall be indicated by code number in accordance with one of the following statements:

Code 1: PART NUMBER CHANGE ONLY - If the Manufacturer's Part Number indicated thereon has changed, but the parts are identical in all respects, supply the item and advise NAVSUP-WSS-MECH immediately of the new part number.

Code 2: Assembly (or set or kit) not furnished - Used following detail parts.

Code 3: Part not furnished separately - Use assembly.

Code 4: Part redesigned - Old and new parts are completely interchangeable. Code 5: Part redesigned - New part replaces old.

Old part cannot replace new. Code 6: Part redesigned - Parts not interchangeable.

Requirements

Case: GR-P-BBK

NSN: 6605014830602

Nomenclature: INERTIAL NAVIGATION UNIT

PN: 233A935-1

CAI

Additional Regulation or Supplemental Clauses Incorporated by Full Text

WSSTERMCZ01 CONFIGURATION MANAGEMENT AND CONTROLS (Dec 2023)

Prescription: Required in all Navy Aviation (Phil only) solicitations/contracts

1.0 Configuration Management

1.1 The cognizant Naval Air Systems Command (NAVAIR) Program Manager will maintain configuration control and change authority for all items in this contract.

1.2 In accordance with the configuration management provisions of this contract, the Contractor must maintain the total Equipment baseline configuration of the parts on this contract including, but not limited to, hardware, software and firmware.

NOTE: The latest revisions of the DOD Forms referenced in this term can be found at https://www.esd.whs.mil/dd. The latest revisions of the DIDs referenced in this term can be found at https://quicksearch.dla.mil/.

2.0 Engineering Changes

2.1 The Government will not be responsible for any contract delay or disruption or any increased costs of performance of the Contractor due to a misclassification of an Engineering Change Proposal (ECP) by the Contractor, including those costs associated with replacement of delivered items resulting from such a misclassification. ECP's are classified as Class I (Major) or Class II (Minor).

For detailed classification criteria refer to the DD Form 1692 instructions sheet. ECPs must be prepared in accordance with DI-SESS- 80639E, Engineering Change Proposal (ECP).

NOTE: Any ECP or notification of an ECP submitted to the PCO in accordance with this paragraph must also be copied to the NAVSUP WSS CM Team at usn.philadelphia.navsupwssphil.mbx.configuration-management@us.navy.mil.

2.1.1 Class I (Major) Changes: The Contractor must coordinate with the cognizant NAVAIR Program Office prior to any Class I ECP submission. The Contractor must submit all Class I changes, via the Defense Contract Management Agency (DCMA) Contract Management Office (CMO) and the Procurement Contracting Officer (PCO), to the cognizant NAVAIR Program Office for approval

The Contractor must notify the PCO of any pending or approved Class I engineering changes with another or disapproval.

Government activity that the Contractor proposes to incorporate under this contract. The cognizant NAVAIR Program Office will approve or disapprove of all Class I changes. Any approved Class I change may necessitate contract changes by the contracting officer, which changes may be handled under the Changes clause of this contract, FAR 52.243-1. The Contractor must not implement a Class I change on this contract until a contract modification is issued by the PCO.

2.1.2 Any Class II change involving a Critical Safety Item (CSI) must be submitted to the PCO for Class II (Minor) Changes:

NAVAIR Program Office approval unless NAVAIR has delegated approval authority to the cognizant DCMA CMO. For Class II changes to items without a criticality determination, the items will be considered CSI for the purposes of processing in accordance with this paragraph. Class II changes related to non-CSI's must be submitted to the cognizant DCMA CMO for concurrence in classification and may be implemented only upon receiving DCMA concurrence. Class II changes must be made at no additional cost to the Government.

2.2 The Contractor is not entitled to any equitable adjustment to the contract price or terms based on the Government's disapproval of a Class I or Class II ECP.

3.0 Variances

3.1 The Contractor must not deliver any item for acceptance by the Government that incorporates a known departure from product definition information unless a Request for Variance (RFV) has been approved. Authorized variances are a temporary departure from the requirements only and do not authorize a change to the item's approved configuration. RFV's are classified as Critical, Major, or Minor. For detailed classification criteria refer to the DD Form 1694 instructions sheet. Any variance requests to CSI's must be classified as major, at a minimum. For variances to items without a criticality determination, the items will be considered CSI for the purposes of processing and classified as a major, at a minimum. Variance requests shall be prepared in accordance with DI-SESS- 80640E - Request for Variance (RFV).

NOTE: Any RFV submitted to the PCO in accordance with this paragraph must also be submitted to the NAVSUP WSS RFV Review Team at usn.philadelphia.navsupwssphil.mbx.rfv-review-team@us.navy.mil.

NOTE: Should a variance be discovered after product delivery, the Contractor must notify the PCO and NAVSUP WSS Quality (NOE_N22@us.navy.mil).

3.1.1 Critical/Major Variances: The Contractor must submit all critical/major variance requests, via the DCMA CMO and the PCO, to the cognizant NAVAIR Program Office for approval or disapproval. All approved critical/major variances require a contract modification by the PCO prior to final inspection and acceptance of the items.

3.1.2 Minor Variances: For minor RFVs, delivery and/or shipment of such items under this contract is not permitted until approved by the cognizant DCMA CMO.

3.2 The Contractor is not entitled to any equitable adjustment to the contract price or terms based on the Government's disapproval of a critical, major, or minor variance.

Section D - Packaging and Marking

NIIN: 014830602

ITEM NAME: INERTIAL NAVIGATION

5. PACKAGING

5.1 Preservation, Packaging, Packing and Marking - Preservation, Packaging, Packing and Marking shall be in accordance with the Contract/Purchase Order Schedule and as specified below.

Marking - PACKAGING AND MARKING SHALL BE IN ACCORDANCE WITH BEST STANDARD COMMERCIAL

PACKAGING FOR OVERSEAS SHIPMENT.

Additional Regulation or Supplemental Clauses Incorporated by Full Text

WSSTERMDZ03 PRESERVATION, PACKAGING, PACKING AND MARKING (Nov 2024)

PRESERVATION, PACKAGING, PACKING AND MARKING

The contractor shall preserve, package, pack and mark all items as cited below. Where specifications or standards are cited herein the latest revision of that specification or standard shall apply.

1. PRESERVATION REQUIREMENTS

a. SYSTEM STOCK SHIPMENTS - The contractor shall preserve all items intended to in enter the military distribution system for stock accordance with the MIL-STD-2073-1, "Standard Practice for Military Packaging", Packaging Requirements Code specified in the Schedule.

When a Specialized Preservation Code/Method of Preservation (MOP) (Table J-Ia) is specified, and one or more of the following packaging fields (WM, CUD, CT, UC) value is a 00 (numeric), the Specialized Preservation/MOP procedure and materials takes precedence. Contractors should disregard the LP field and third digit of the PACK field and use the Unit Container Level (UCL) to identify the level of packing protection the unit container meets for packing requirements. When HM = D, the item is regulated in accordance with Title 49 Code of Federal

; when HM = N the item is not regulated for transportation.Regulations (CFR)

1) When a specified packaging material has an associated Qualified Products List (QPL), the contractor shall use only packaging materials produced by a manufacturer listed on the applicable QPL. Barrier materials that have QPLs are MIL-PRF-131, MIL-PRF-81705, MIL-PRF- 22191, MIL-PRF-3420 and MIL-PRF-22019. Sources for QPL material can be obtained from the Qualified Products Database at http://qpldocs.dla.mil/.

b. IMMEDIATE USE/INSTALLATION AND PART NUMBER BUY SHIPMENTS - Government PCO or ACO approval is required to use the packaging standards outlined in this paragraph. Any national stock numbered (NSN) item required for immediate use (used or consumed within or part numbered item (authority granted to ship without NSN) shall be preserved and packed in 7 days of receipt) or direct installation, accordance with ASTM D3951, "Standard Practice for Commercial Packaging", for all shipments to a Continental United States (CONUS) government activity or contractor-owned facility. All material destined for overseas shipment (OCONUS) shall be preserved in accordance with

MIL-STD-2073-1.

c. GOVERNMENT-OWNED MATERIAL - In the event that the contract expires, is terminated, or completed, and Government-owned material is to be returned to the supply system, the contractor shall preserve and package this material in accordance with the requirements of paragraph 1.a.

2. PROTECTION FROM DEGRADATION DUE TO ELECTROSTATIC (ES)/ELECTROMAGNETIC (EM) FORCES

a. When ASTM D3951 is authorized for packaging and the item is considered Electrostatic Discharge Sensitive (ESDS), protection shall be in accordance with ANSI/ESD S20.20-2021, "For the Development of an ESD Control Program for - Protection of Electrical and Electronic Parts, Assemblies and Equipment (Excluding Electrically Initiated Explosive Devices)."

b. When MIL-STD-2073-1 is specified and the preservation method code (PMT) in the solicitation does not specify ESD/EM protection (PMT = GX) and the contractor's proposed item of supply is subject to degradation from ES/EM forces, contractors shall provide recommended packaging data with their proposals/quotes.

3. PACKING REQUIREMENTS - The contractor shall pack as follows:

Domestic Shipments (CONUS): Level B

Overseas Shipments (OCONUS) (including Navy ships at sea):

Via air, FPO, APO Level B

Via freight forwarder Level B

Via surface Level A

Exterior shipping containers for Packing Levels A and B are listed in MIL-STD-2073-1, Appendix C, Table C.II. Long-life reusable containers and wood containers are shipping containers which do not require overpacking for shipment.

4. MARKING REQUIREMENTS - All unit, intermediate and shipping containers shall be marked in accordance with MIL-STD-129. In addition, the following specific requirements apply:

a. ADDITIONAL MARKING FOR SPARES ONLY Each MIL-STD-129 label shall also include the following:-

1) Procurement Instrument Identifier (PIID) - the 13-digit contract order number,

2) Contract Line Item Number (CLIN) - the 4-digit individual line item number (e.g. 0001, 0002, etc.), and

3) SubCLIN - the 6-digit sub line item number (e.g. 0001AA, 0001AB, 0002AA, 0002AB, etc.).

b. DEPOT LEVEL REPAIRABLE (DLR) LABELS

1) Items identified with a Cognizance (COG) Code of either "7" or an even number preceding the NSN, excluding 6A, 6H and 6X COGs (e.

g. 7RH 5826-014289999), are defined as Depot Level Repairable (DLR) items. DLR items require that a DLR label be placed on the outside of the unit, intermediate and shipping containers as close to the bar code label as possible.

2) Labels are available via the Naval Forms Online website: . The website will advise the https://forms.documentservices.dla.mil/order/ procedures for ordering and establishing an account.

3) NAVSUP WSS authorizes contractors to create and print their own DLR labels.

Labels shall follow the standard size and font options listed in below chart. Text shall be in all upper case letters of the same style font. The label used shall be sized proportionate to the size of the container. Labels shall be horizontally printed and consist of yellow "DLR" text font on a solid blue background. Labels shall meet requirements of MIL-STD-129 section 4.2.2. Labels shall be of a water-resistant grade of paper, film, or plastic, coated on one side with water-insoluble, permanent type adhesive. The adhesive shall adhere to metal, plastic, aluminum or fiberboard surfaces under high and low temperatures. Labels shall have a finish suitable for printing and writing on with ink without feathering or spreading, be capable of withstanding normal handling and storage conditions, and remain securely in position. Application specific performance criteria and durability requirements to ensure functionality in various climatic environments should be tailored, if required, using MIL-PRF-61002. MIL-PRF-61002 can be used as an acquisition tool when labels presently being used are not performing satisfactorily or when new conditions or applications require special label stock for those particular situations.

NSN DESCRIPTION

QUANTITY

PER UNIT PACKAGE

APPLICATION FORM NUMBER

0108LF5055300

DLR Label

2 in. x 3 in.

Unit

Container

NAVSUP 1397-1

0108LF5055000

DLR Label

3 in. x 5 in.

Intermediate / Shipping

Container

NAVSUP 1397

c. SPECIAL MATERIAL IDENTIFICATION CODE (SMIC) FOR NAVSUP WSS MARITIME REQUIREMENTS ONLY

1) Certain program related items are identified by a two-position SMIC, which appears as a suffix to the NSN (e.g. 1H 4730 009001317 L1), and require special markings. Containers shall be marked or labeled with letters, maximum two inches high on two (2) sides and two

(2) ends as follows:

N0038326QF053

https://forms.documentservices.dla.mil/order/%20

SMIC MARKINGS COLOR TYPE CONTAINER

L1 LEVEL 1 RED Unit, intermediate and shipping (size permitting)

S1

SURFACE

LEVEL 1

RED Unit, intermediate and shipping (size permitting)

D4/D5/D7 DSS-SOC RED Unit, intermediate and shipping (size permitting)

C1 *

LEVEL 1 SPECIAL

CLEAN O2-N2

GREEN Unit, intermediate and shipping

CP/VG *

SPECIAL CLEAN

O2-N2 GREEN Unit, intermediate and shipping

D0/D6/D8 * DSS-SOC SPECIAL CLEAN O2-N2 GREEN Unit, intermediate and shipping

VU FBW SFCC VU BLUE Unit, intermediate and shipping (size permitting)

SW FBW SFCC SW BLUE Unit, intermediate and shipping (size permitting)

Q3/Q5 Q3 or Q5 RED Unit, intermediate and shipping

* denotes Oxygen Clean requirements in accordance with MIL-STD-1330 "Precision Cleaning and Testing of Shipboard Oxygen, Helium, Helium- Oxygen, Nitrogen, and Hydrogen Systems."

5. PALLETIZATION. Palletization of shipments shall be accomplished in accordance with MIL-STD-147 "DOD Standard Practice: Palletized Unit Loads." Failure to meet these palletization/packaging requirements and measures, without a written waiver from the PCO or ACO, may result in charges back to the contractor for repalletization and/or repackaging of items. Pallets shall conform to the requirements of American National Standards Institute, Material Handling-MH1-2016, Pallets, Slip Sheets, and Other Bases for Unit Loads. MH1-2016 may be obtained at the following website: http://www.mhi.org

a. General Purpose Unit Loads - When shipping directly to a Navy afloat unit, pallets meeting MH1-2016, Part No. MH1/9-02SW4048 or MH1 /9-10BW4048 for unit loads under 1,500 pounds and MH1/9-03SW4048 for unit loads over 1,500 pounds shall be used.

b. Hazardous Material Unit Loads - Unless otherwise specified in the contract or purchase order hazardous material containers, except cylinders and 55 gallon drums, shall be palletized utilizing MH1-2016 Part No. MH1/9-07SW4848 pallets.

c. Use of nonstandard commercial pallets is prohibited.

6. WOOD PACKAGING MATERIAL (WPM). All shipments destined to the DOD must be treated and marked in accordance with the International Standards for Phytosanitary Measures Guidelines for Regulating Wood Packaging Material in International Trade ( ) for ISPM 15 OCONUS shipments.

a. For all WPM furnished under this contract the contractor shall ensure the American Lumber Standards Committee (ALSC) approved mark is applied to every shipment regardless of destination.

b. Failure to comply with the requirements of ISPM 15 may result in refusal of the shipment, destruction or corrective treatment of WPM at the point of receipt and the associated costs charged back to the contractor.

7. NAVY SHELF-LIFE PROGRAM. Navy shelf-life requirements are listed under the item description in a 3-digit alpha/numeric code. Position one (1) is the DOD shelf-life code, defining the type of shelf-life for an item (Type I, non-extendible or Type II, extendible), and the number of months an item can remain ready for issue in a Navy specified package. Positions two (2) and three (3) combined form the Navy-unique shelf-life action codes used by storage activities, and do not impose any requirements on the contractor. The contractor shall use the applicable shelf-life paragraphs and table in MIL-STD-129 to apply either Type I or Type II shelf-life markings to an item's unit, intermediate and shipping containers. Contractors will ensure that at least eighty-five percent (85%) of the Navy shelf-life requirement is remaining when received by the first government activity.

8. REUSABLE NSN CONTAINERS. An item that has an NSN assigned in the "Container NSN" field (e.g. 8145 012622982) requires shipment in a reusable shipping and storage container.

a. REUSABLE CONTAINERS FOR NAVSUP WSS, MARITIME REQUIREMENTS - Reusable NSN containers for maritime material (designated by a COG Code of "7E", "7G" and "7H") shall be provided as contractor-furnished material (CFM).

b. REUSABLE CONTAINERS FOR NAVSUP WSS, AVIATION REQUIREMENTS - Reusable NSN containers (excluding fiberboard and most wood) for aviation material (designated by a COG Code of "7R", "6K" or "0R") shall be provided as government-furnished material (GFM).

Fast pack containers will not be provided as GFM. To obtain GFM reusable containers, the contractor must request via email usn.philadelphia.

navsupwssphil.mbx.navsupcrf@us.navy.mil at least 90 days prior to the anticipated shipping date, 30 days prior for repair contracts. If the Navy's Container Management Area (CMA) informs the contractor that containers are unavailable, the following alternate packaging requirements apply. The unavailability of reusable containers shall not be an excusable delivery delay.

ALTERNATE PACKAGING REQUIREMENTS FOR ITEMS ASSIGNED THE FOLLOWING CONTAINERS

Container NSN Container Part Number (80132) Alternate Packaging Code

IAW MIL-STD-2073-1

8145 002609548 P069-2

N 001 000 GX 1 00 K3 LT B ED

UCL = B

SPMK = 39

PACK = QFF

8145 002609556 P069-1

8145 002609559 P069-3

8145 002609562 P069-4

8145 010124088 P069-6

N0038326QF053

https://www.ippc.int/en/publications/640/

8145 010140440 P069-5

8145 011644073 P069-7

8145 012622982 15450-1

If MOP/PMT = GX

N 001 000 GX 1 00 K3 GH Z ED

Z= use 1.5" of "GH" cushioning between barrier bag and Unit Container

UCL = B

SPMK = 39

PACK = QFF

For all other MOPs/PMTs

N 001 000 51 1 00 EA GH F ED

UCL = B

SPMK = 03

PACK = QFF

8145 012622983 15450-2

8145 012622984 15450-3

8145 012622985 15450-4

8145 012622986 15450-5

8145 012622987 15450-6

8145 012622988 15450-7

c. All excess empty reusable shipping and storage containers shall be turned-in to the nearest Container Reuse and Refurbishment Center (CRRC). CRRC locations/points of contact: Program Manager - 215-697-2063

Norfolk, VA - 757-445-9099 ext. 124 Yokosuka, JAPAN - 011-81-46-816-6304

Cherry Point, NC - 252-466-2331 Lemoore, CA - 559-998-0220

Jacksonville, FL - 904-542-1014 Okinawa, JAPAN - 011-81-46-816-6304

San Diego, CA - 619-545-8360 Iwakuni, JAPAN - 011-81-46-816-6304

Puget Sound, WA - 360-476-9777 Bahrain - 011-318-439-9553

d. The stock-numbered, long-life, reusable containers identified herein as GFM are property of the U.S. Navy and only shall be used to fulfill orders from the Navy and U.S. Marine Corps; these containers shall not be used to fulfill orders from the U.S. Army, U.S. Air Force, any other agency of the U.S. Government or Foreign Military Sales (FMS) customer.

9. REUSABLE NSN CONTAINERS FOR FOREIGN MILITARY SALES (FMS), JOINT PROGRAM OFFICE (JPO) OR OTHER

FOREIGN FORCES ACQUISITION

a. Reusable shipping and storage containers shall be provided as CONTRACTOR-FURNISHED MATERIAL (CFM), unless otherwise specified.

b. Contractors may tender offers including alternate, non-reusable, packaging methods and be considered responsive.

10. HAZARDOUS MATERIALS. This section applies when items to be delivered under this contract are considered hazardous materials as defined by 49 CFR, FED-STD-313, or by the Government's technical representative.

a. Packaging and marking for hazardous materials shall comply with applicable requirements for Performance Oriented Packaging (POP) contained in 49 CFR and the international modal regulations. All performance test requirements shall be supported by test certificates and reports attesting to the date and the results obtained from performance oriented packaging testing. The contractor shall be responsible for assuring that sources providing performance testing services are registered with the U.S. Department of Transportation (DOT). The contractor's signed certification that the packaged configuration meets the applicable modal regulation shall be incorporated on the Wide Area Workflow Receiving Report (WAWF RR), DD Form 250, Material Inspection and Receiving Report, or other related acceptance documents if a WAWF RR, DD Form 250 is not used. The Shipper's Declaration for Dangerous Goods (SDDG) must be included for all air shipments. All test certificates, reports and training records shall be available for inspection by authorized Government representatives for a period of three years.

b. When a contract/order for hazardous material requires shipment to a military aerial port or through a military container consolidation point including DODAACs SW3225, SW3123, SW3142, N45627, FB4427, FB9150, FB4497, FY8910, FY9125, FB4418, FY4462, FB4484, FB4479, those shipments shall comply with NAVSUP PUB 505/AFMAN 24-204, Preparing Hazardous Materials for Military Air Shipment.

11. SAFETY DATA SHEETS. As required by clauses FAR 52.223-3 "Hazardous Material Identification and Material Safety Data" and DFARS 252.223-7001 "Hazard Warning Labels" the contractor/offeror is required to list any hazardous material to be delivered under the resultant contract by the submission of Safety Data Sheets (SDSs) and Globally Harmonized System (GHS) compliant product label, when applicable, to the NAVSUP WSS or DLA Contracting Officer prior to award. An electronic copy in PDF format of the SDS and GHS product label must also be emailed to NAVSUP WSS Code N242 at Please include the NSN, CAGE, Part Number, quantity of NAVSUPWSSMECH.HAZMAT@US.NAVY.MIL.

hazardous material, contract number, and point of contact for hazardous material questions in the body of the email.

12. REPACKAGING TO CORRECT PACKAGING DEFICIENCIES

a. Notwithstanding inspection and acceptance by the Government of items furnished under this contract, or any condition of this contract concerning the conclusiveness thereof, the contractor guarantees that the preservation, packaging, packing and marking (PPP&M), and the preparation of, and method of shipment of such items will conform to the requirements of this contract.

b. Items that do not conform to the PPP&M requirements of this contract may have a Supply Discrepancy Report (SDR, SF-364) written against the contractor at the time of receipt.

N0038326QF053

mailto:NAVSUPWSSMECH.HAZMAT@US.NAVY.MIL

c. The Government may at the option of the PCO or ACO, correct PPP&M deficiencies, without prior contractor notification, and require an equitable adjustment in the contract price to cover labor and material when corrective actions are warranted, or return the non-conforming material to the contractor for repackaging at the contractor's expense.

Section E - Inspection and Acceptance

NIIN: 014830602

ITEM NAME: INERTIAL NAVIGATION

4. QUALITY ASSURANCE PROVISIONS

4.1 Responsibility for Inspection - Unless otherwise specified in the contract/purchase order, the Contractor is responsible for the performance of all inspection requirements as specified herein. Except as otherwise specified in the contract/purchase order, the Contractor may use his own or any other facilities suitable for the performance of the inspection requirements specified herein, unless disapproved by the Government. The Government reserves the right to perform any of the inspections set forth in the specification where such inspections are deemed necessary to assure supplies and services conform to prescribed requirements.

4.2 Responsibility for Compliance - All items must meet all requirements of this contract/purchase order. The inspection set forth in this specification shall become a part of the Contractor's overall inspection system or quality program. The absence of any inspection requirements shall not relieve the Contractor of the responsibility of assuring that all products or supplies submitted to the Government for acceptance comply with all requirements of the contract/purchase order. Sampling in quality conformance does not authorize submission of known defective material, either indicated or actual, nor does it commit the Government to acceptance of defective material.

4.3 Records - Records of all inspection work by the Contractor shall be kept complete and available to the Government during the performance of contract/purchase order and for a period of 365 calendar days after final delivery of supplies.

4.4 Inspection/Testing Repaired Items - The Contractor shall perform all inspection and testing requirements as specified in the original manufacturer's specifications and drawings.

FAR Clauses Incorporated by Full Text

52.246-2 Inspection of Supplies-Fixed-Price. (Aug 1996)

INSPECTION OF SUPPLIES-FIXED-PRICE (AUG 1996)

(a) "Supplies," as used in this clause, includes but is not limited to raw materials, components, intermediate assemblies, end products, Definition.

and lots of supplies.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering supplies under this contract and shall tender to the Government for acceptance only supplies that have been inspected in accordance with the inspection system and have been found by the Contractor to be in conformity with contract requirements. As part of the system, the Contractor shall prepare records evidencing all inspections made under the system and the outcome. These records shall be kept complete and made available to the Government during contract performance and for as long afterwards as the contract requires. The Government may perform reviews and evaluations as reasonably necessary to ascertain compliance with this paragraph. These reviews and evaluations shall be conducted in a manner that will not unduly delay the contract work. The right of review, whether exercised or not, does not relieve the Contractor of the obligations under the contract.

(c) The Government has the right to inspect and test all supplies called for by the contract, to the extent practicable, at all places and times, including the period of manufacture, and in any event before acceptance. The Government shall perform inspections and tests in a manner that will not unduly delay the work. The Government assumes no contractual obligation to perform any inspection and test for the benefit of the Contractor unless specifically set forth elsewhere in this contract.

(d) If the Government performs inspection or test on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties. Except as otherwise provided in the contract, the Government shall bear the expense of Government inspections or tests made at other than the Contractor's or subcontractor's premises; provided, that in case of rejection, the Government shall not be liable for any reduction in the value of inspection or test samples.

(e)

When supplies are not ready at the time specified by the Contractor for inspection or test, the Contracting Officer may charge to the Contractor (1) the additional cost of inspection or test.

(2) The Contracting Officer may also charge the Contractor for any additional cost of inspection or test when prior rejection makes reinspection or retest necessary.

(f) The Government has the right either to reject or to require correction of nonconforming supplies. Supplies are nonconforming when they are defective in material or workmanship or are otherwise not in conformity with contract requirements. The Government may reject nonconforming supplies with or without disposition instructions.

(g) The Contractor shall remove supplies rejected or required to be corrected. However, the Contracting Officer may require or permit correction in place, promptly after notice, by and at the expense of the Contractor. The Contractor shall not tender for acceptance corrected or rejected supplies without disclosing the former rejection or requirement for correction, and, when required, shall disclose the corrective action taken.

(h) If the Contractor fails to promptly remove, replace, or correct rejected supplies that are required to be removed or to be replaced or corrected, the Government may either (1)by contract or otherwise, remove, replace, or correct the supplies and charge the cost to the Contractor or (2) terminate the contract for default. Unless the Contractor corrects or replaces the supplies within the delivery schedule, the Contracting Officer may require their delivery and make an equitable price reduction. Failure to agree to a price reduction shall be a dispute.

(i)

If this contract provides for the performance of Government quality assurance at source, and if requested by the Government, the Contractor shall (1) furnish advance notification of the time-

(i) When Contractor inspection or tests will be performed in accordance with the terms and conditions of the contract; and

(ii) When the supplies will be ready for Government inspection.

(2) The Government's request shall specify the period and method of the advance notification and the Government representative to whom it shall be furnished. Requests shall not require more than 2 workdays of advance notification if the Government representative is in residence in the Contractor's plant, nor more than 7 workdays in other instances.

(j) The Government shall accept or reject supplies as promptly as practicable after delivery, unless otherwise provided in the contract. Government failure to inspect and accept or reject the supplies shall not relieve the Contractor from responsibility, nor impose liability on the Government, for nonconforming supplies.

(k) Inspections and tests by the Government do not relieve the Contractor of responsibility for defects or other failures to meet contract requirements discovered before acceptance. Acceptance shall be conclusive, except for latent defects, fraud, gross mistakes amounting to fraud, or as otherwise provided in the contract.

(l) If acceptance is not conclusive for any of the reasons in paragraph (k) hereof, the Government, in addition to any other rights and remedies provided by law, or under other provisions of this contract, shall have the right to require the Contractor (1)at no increase in contract price, to correct or replace the defective or nonconforming supplies at the original point of delivery or at the Contractor's plant at the Contracting Officer's election, and in accordance with a reasonable delivery schedule as may be agreed upon between the Contractor and the Contracting Officer; provided, that the Contracting Officer may require a reduction in contract price if the Contractor fails to meet such delivery schedule, or (2) within a reasonable time after receipt by the Contractor of notice of defects or nonconformance, to repay such portion of the contract as is equitable under the circumstances if the Contracting Officer elects not to require correction or replacement. When supplies are returned to the Contractor, the Contractor shall bear the transportation cost from the original point of delivery to the Contractor's plant and return to the original point when that point is not the Contractor's plant. If the Contractor fails to perform or act as required in paragraph (l)(1) or (l)(2) of this clause and does not cure such failure within a period of 10 days (or such longer period as the Contracting Officer may authorize in writing) after receipt of notice from the Contracting Officer specifying such failure, the Government shall have the right by contract or otherwise to replace or correct such supplies and charge to the Contractor the cost occasioned the Government thereby.

(End of clause)

52.246-11 Higher-Level Contract Quality Requirement. (Dec 2014)

Higher-Level Contract Quality Requirement (Dec 2014)

(a) The Contractor shall comply with the higher-level quality standard(s) listed below.

__ISO 9001 Quality Management Systems - Requirements or Higher __[Contracting Officer insert the title, number (if any), date, and tailoring (if any) of the higher-level quality standards.]

(b) The Contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph (a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts, in-

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require-

(i) Control of such things as design, work operations, in-process control, testing, and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

52.246-15 Certificate of Conformance. (Apr 1984)

CERTIFICATE OF CONFORMANCE (APR 1984)

(a) When authorized in writing by the cognizant Contract Administration Office (CAO), the Contractor shall ship with a Certificate of Conformance any supplies for which the contract would otherwise require inspection at source. In no case shall the Government's right to inspect supplies under the inspection provisions of this contract be prejudiced. Shipments of such supplies will not be made under this contract until use of the Certificate of Conformance has been authorized in writing by the CAO, or inspection and acceptance have occurred.

(b) The Contractor's signed certificate shall be attached to or included on the top copy of the inspection or receiving report distributed to the payment office or attached to the CAO copy when contract administration (Block10 of the DDForm250) is performed by the Defense Contract Administration Services. In addition, a copy of the signed certificate shall also be attached to or entered on copies of the inspection or receiving report accompanying the shipment.

(c) The Government has the right to reject defective supplies or services within a reasonable time after delivery by written notification to the Contractor. The Contractor shall in such event promptly replace, correct, or repair the rejected supplies or services at the Contractor's expense.

(d) The certificate shall read as follows:

I certify that on [ ], the [ ] furnished the supplies or services called for by Contract No. via [____ insert date ____ insert Contractor's name ____ ____ ] on [ ] in accordance with all applicable requirements. I further certify that the supplies or Carrier ____ identify the bill of lading or shipping document services are of the quality specified and conform in all respects with the contract requirements, including specifications, drawings, preservation, packaging, packing, marking requirements, and physical item identification (part number), and are in the quantity shown on this or on the attached acceptance document.

Date of Execution: Signature: Title: ____ ____ ____

(End of clause)

52.246-16 Responsibility for Supplies. (Apr 1984)

RESPONSIBILITY FOR SUPPLIES (APR 1984)

(a) Titleto supplies furnished under this contract shall pass to the Government upon formal acceptance, regardless of when or where the Government takes physical possession, unless the contract specifically provides for earlier passage of title.

(b) Unless the contract specifically provides otherwise, risk of loss of or damage to supplies shall remain with the Contractor until, and shall pass to the Government upon-

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Acceptance by the Government or delivery of the supplies to the Government at the destination specified in the contract, whichever is later, if transportation is f.o.b. destination.

(c) Paragraph (b) of this clause shall not apply to supplies that so fail to conform to contract requirements as to give a right of rejection. The risk of loss of or damage to such nonconforming supplies remains with the Contractor until cure or acceptance. After cure or acceptance, paragraph (b) of this clause shall apply.

(d) Under paragraph (b) of this clause, the Contractor shall not be liable for loss of or damage to supplies caused by the negligence of officers, agents, or employees of the Government acting within the scope of their employment.

(End of clause)

Additional Regulation or Supplemental Clauses Incorporated by Full Text

WSSTERMEZ03 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (Dec 2014)

(a)

ISO 9001 Quality Management Systems - Requirements

NOTE: When the "OTHER" block is selected, please identify the industry, military, or international Quality Management System that you intend to use. Your proposed system will be reviewed and assessed for suitability and equivalency.

(b) Measuring and Test Equipment

ISO 10012 Requirements for Measurement Processes and Measuring Equipment

NOTE: When the "OTHER" block is selected, please identify the industry, military, or international Calibration Standard that you intend to use. Your proposed standard will be reviewed and assessed for suitability and equivalency.

(c) The contractor shall use and be compliant with the revision of the applicable Quality Management System and Calibration Standard in effect at time of the offeror's latest proposal submission.

Enclosure (1)

WSSTERMEZ04 INSPECTION AND ACCEPTANCE – SHORT VERSION (Jun 2022)

Supplies furnished hereunder shall be inspected at Contractor’s and/or subcontractor's plant. Acceptance shall be at Contractor's and/or subcontractor's plant .

Manufacturing Site:

Address:

If supplies will be packaged at a location different from the offeror address indicated on the solicitation, the offeror shall provide the name and street address of the packaging location:

Packaging House:

Address:

Section F - Deliveries or Performance

Overall Contract Delivery Period

Government Origin (Shipping Point)

Line Item Delivery Schedule Quantity Address and POC Special Handling/Notes

0001AA

Delivery Schedule From date of lead time event to delivery 365 Calendar Days

DATE OF INDUCTION

Period of Performance From 05 Jan 2026 To 06 Apr 2026

1 Each Ship To

MAPAC: PGR002

CountryCode: USA

M WERB EMAIL DTD 11-26-2019

NAVSUP WSS

CAVALIER LOGISTICS, 45085 OLD OX

ROAD

DULLES, VA 20166

UNITED STATES

JUSTIN MARRERO, TRANSPORTATION

SPECIALIST

Email: FMS@CAVLOG.COM Telephone: 703-733-4010

FoB Details Government Origin (Shipping Point)

FAR Clauses Incorporated by Full Text

52.211-17 Delivery of Excess Quantities. (Sep 1989)

DELIVERY OF EXCESS QUANTITIES (SEPT 1989)

The Contractor is responsible for the delivery of each item quantity within allowable variations, if any. If the Contractor delivers and the Government receives quantities of any item in excess of the quantity called for (after considering any allowable variation in quantity), such excess quantities will be treated as being delivered for the convenience of the Contractor. The Government may retain such excess quantities up to $250 in value without compensating the Contractor therefor, and the Contractor waives all right, title, or interests therein. Quantities in excess of $250 will, at the option of the Government, either be returned at the Contractor's expense or retained and paid for by the Government at the contract unit price.

(End of clause)

52.242-17 Government Delay of Work. (Apr 1984)

GOVERNMENT DELAY OF WORK (APR 1984)

(a) If the performance of all or any part of the work of this contract is delayed or interrupted (1)by an act of the Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or (2)by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an adjustment is provided or excluded under any other term or condition of this contract.

(b) A claim under this clause shall not be allowed-

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved; and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract.

(End of clause)

52.247-29 F.o.b.