Solicitation_22-R-0013 Ballistic Glass.pdf

F8J6CE2144A001

Project Title: 159 FW Ballistic Glass Location: 159 FW 400 Russell Ave, New Orleans, LA 70143 Period of Performance: 120 days Offers are due NLT 13 July 2022 at 10:00CST

1. Set aside: This requirement is 100% set aside for small businesses

2. Small Business size standard: $16.5M

3. NAICS Code:238150 Glass and Glazing Contractors

4. Project Magnitude: Betw een $250,000 and $500,000

5. Prospective Offerers are highly encourage to attend a site visit at 10:00am CST on 22 June 2022

GREGGORY H. PRICE 504-391-8370

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

16-Jun-2022

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______30 calendar days and complete it w ithin ________120 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________13 Jul 2022 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USPFO LA 159 MISSION SUPPORT CONTRACTING

400 RUSSELL AVE BLDG 473 RM 212

NEW ORLEANS LA 70143-5077

W50S7Z

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W50S7Z22R0013 93

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W50S7Z22R0013

Section 00010 - Solicitation Contract Form

SOLICITATION CONTRACT FORM

SECTION 00010

SECTION 00010 Solicitation Contract Form

TABLE OF CONTENTS

SOLICITATION, OFFER, AND AWARD SF 1442 and SF 1442 BACK

SECTION 00010 - PRICING SCHEDULE, NOTES

SECTION 00100 - INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

SECTION 00600 – REPRESENTATIONS & CERTIFICATIONS

SECTION 00700 - CONTRACT CLAUSES

SECTION 00800 – WAGE DETERMINATION

SECTION 01000 – GENERAL REQUIREMENTS

ATTACHMENT 1 – PLANS AND SPECIFICATIONS

EXHIBIT A - Performance Relevancy Questionnaire EXHIBIT C - Reference Questionnaire package

SECTION 00010 NOTES

1. Instructions for the preparation of proposals are located in Sections 00100, 00110 and 00120.

2. Offeror’s attention is invited to the insurance requirement contained in this solicitation (FAR Clause 52.228-5 Insurance – Work on a Government Installation). Certification of the required coverage for the prime contractor shall be furnished prior to beginning work on this contract, and the Contracting Officer may request evidence of the required insurance at any time during the life the contract.

3. Reference DFARS Provision 252.236-7008, Contract Prices – Bidding Schedules. The term “Bidding Schedule” shall also be construed to mean “Offer Schedule” or “Schedule”. The terms “bid” and “offer”, and “bidder” and “offeror” shall be construed as having the same meaning in this solicitation and resulting contract.

4. Reserved

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Building 425 Ballistic Glass

FFP

Building 425 ballistic glass IAW SOW FOB: Destination MFR PART NR: Null

PURCHASE REQUEST NUMBER: F8J6CE2144A001

SIGNAL CODE: A

PSC CD: Y1AA

NET AMT

0002 1 Job Building 489 Ballistic Glass

FFP

Ballistic glass for building 489 IAW SOW FOB: Destination MFR PART NR: Null

PURCHASE REQUEST NUMBER: F8J6CE2144A001

0003 1 Job Building 41 Ballistic Glass

FFP

Ballistic glass for customer service window IAW SOW FOB: Destination MFR PART NR: Null

PURCHASE REQUEST NUMBER: F8J6CE2144A001

0004 1 Job MISC Expenses

FFP

All other costs not directly associated with other CLINS FOB: Destination MFR PART NR: Null

PURCHASE REQUEST NUMBER: F8J6CE2144A001

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government 0004 N/A N/A N/A Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 120 dys. ANP 1 159LGSN

DARREN VICKNAIR

400 RUSSELL AVE, NAS-JRB, HANGAR 5,

ROOM 129

BELLE CHASSE LA 70143

504-391-8076 FOB: Destination

F8J2LG

0002 120 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0003 120 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0004 120 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS

Section 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

1. SCOPE

1.1. You are invited to submit a proposal in response to our Request for Proposal W50S7Z-22-R-0013 Ballistic Glass. As a result of this solicitation, the Government intends to award a single Firm Fixed Price (FFP) contract to the responsible offeror whose proposal represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

1.2. This solicitation is 100% set aside for small businesses

2. NOTICE OF PRE-PROPOSAL CONFERENCE

A pre-proposal conference and site visit is scheduled for 22 June 2022 at 10:00am CST. Due to security requirements, all prospective offerers must register 24 hrs prior by emailing the company name and personnel to 159.FW.FAL.MSC.Contracting@us.af.mil

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS

3.1. Submit all questions via email to the contracting office at the address shown below. Do NOT contact the A-E or Engineering personnel directly. Doing so will only delay the response to your question.

Subject Line: Reference No. W50S7Z-22-R-0013 Email: 159.FW.FAL.MSC.Contracting@us.af.mil

INQUIRIES SHALL BE SUBMITTED VIA EMAIL AND INCLUDE THE FOLLOWING INFORMATION:

Date of Proposal Inquiry:

From: ______________________________

Company Name: ___________________________

Phone Number: ____________________________

Email address: _____________________________

Proposal Inquiry: Be specific as to part of solicitation you are questioning.

3.2. Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach offerors before the submission of their offer.

3.3. The Contracting Officer reserves the right to address questions received after the fifth day prior to solicitation closing with those offers deemed compliant and/or in the competitive range after closing. All questions and requests for information (RFI) must be received NOT LATER THAN the fifth working day prior to closing and will be posted not later than two working days prior to closing. OFFERORS ARE STRONGLY ENCOURAGED

TO SUBMIT QUESTIONS EARLY IN THIS PROCESS.

3.4. Any interpretations made will be in the form of an amendment of the solicitation, drawings, specifications, etc., and will be furnished to all prospective offerors via posting to https://www.sam.gov.

3.4.1. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of proposals. Explanations or instructions given in a form other than an amendment to the solicitation shall not be binding. Questions (on a non-attribution basis) and answers shall be furnished to all prospective offerors via the web site.

3.4.2. For security reasons, all technical and engineering data related to this solicitation will be distributed using the https://www.sam.gov. Beta.sam.gov is a web-based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Plans and specifications are uploaded and require Contractors to request explicit access from the Contracting Officer OR export controlled access through DLA.

3.4.2.2. Interested offerors must be registered in the System for Award Management (SAM). To register go to:

www.sam.gov. You will need your DUNS number to register. Instructions for registering are on the web page.

(Please note the registration for access to the secure site takes approximately 15 business days, so plan accordingly.)

4. AMENDMENTS PRIOR TO DATE SET FOR RECEIPT OF PROPOSALS

4.1. The right is reserved, as the interest of the Government may require, to revise or amend, the specifications or drawings or both prior to and/or after the date set for receipt of proposals as necessary. Such amendments, if any, will be announced by an amendment or amendments to this Request for Proposal. All information relating to this RFP, including pertinent changes/amendments and information prior to the date set for receipt of proposals will be posted at https://www.sam.gov.

4.2. Offerors are strongly cautioned to check this site frequently and to “refresh” their web page to ensure they have the lasted information.

5. HAND CARRIED PROPOSALS/INVITATIONS

5.1. A bid repository is provided for hand carried proposals and is located at:

159 MSG/MSC.

NASJRB New Orleans 400 Russell Ave Building 473, Room 212 New Orleans, LA 70143

5.2. Hand carried proposals must be deposited in the repository prior to the time established for receipt of proposals.

5.3. Offerors are cautioned that approval to enter the base must be obtained prior to the closing date for receipt of proposals. Follow the procedures outlined above in paragraph 2.1.2. for entry. Delays are probable at the entry point and should be accounted for. Late receipt of proposals due to base entry delays may not be deemed excusable and the Contracting Officer may declare the proposal late and remove it from consideration.

6. WAGE DETERMINATION

6.1. The Construction Wage Rate Requirements formerly known as Davis Bacon Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are LA20220052 dated 24 Feb 2022 for Plaquemines Parish, LA.

In the event the current prevailing Wage Determination is changed by the Department of Labor prior to the closing date of the solicitation, the most current wage determination is in effect. Should the wage rate change after closing, but prior to award, the updated Wage Determination will be incorporated by amendment and issued to all offerors that have not been eliminated from the competition. If applicable, these offerors/contractors will be given a reasonable opportunity to provide revised proposals solely to amend proposals due to Wage Determination changes.

If the wage determination modification does not change any affected wage rates, then the provisions of FAR 22.404- 5(c)(4) will apply.

6.2. Applicable wage rates can be found at SAM.gov.

7. PROPOSAL EXPENSES AND PRE-CONTRACT COSTS

This RFP does not commit the Government to pay costs incurred in preparation and submission of initial and subsequent proposals or for other costs incurred prior to award of a formal contract.

8. REMOVAL OF SECTIONS AT TIME OF AWARD

Sections 00100, 00110, 00120, 00600 and all exhibits will be physically removed as a result of an award, but will be deemed to be incorporated by reference in that award.

9. DISPOSITION OF UNSUCCESSFUL PROPOSALS

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful proposals. The Government will destroy extra copies of unsuccessful proposals. No destruction certificate will be provided.

10. INFORMATION REGARDING AVAILABILITY OF UTILITY SERVICES

It has been determined that all reasonable amounts of power where/if physically available, used in connection with this project will be furnished to contractor without cost. The offerors will take this into consideration when computing its offer. (FAR Clause 52.236-14, Availability and Use of Utility Services)

11. BID BONDS

An Original Bid bond is required with submission of the proposal

12. EXCEPTIONS

If the offeror takes exception to any of the requirements specified in this solicitation, the offeror shall clearly identify each such exception and include a complete explanation of why the exception was taken and what benefit accrues to the Government. All exceptions to the solicitation requirements (Sections 00010 through 00800) and supporting rationale shall be included in an addendum to the proposal and clearly labeled "Exceptions". An addendum is only required if the offeror takes exception to any requirement in the solicitation. (The Addendum does not have a page limitation, but shall only include information relevant to exceptions taken to the solicitation requirements.) The Government will assume an offeror takes no exceptions to any solicitation requirement if the offeror does not submit an Addendum identifying exceptions. Offerors are advised that solicitation requirements are not necessarily negotiable and such exceptions may render an offeror's proposal unacceptable and ineligible for award.

13. CLAUSES

12.1. Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

12.2. Clauses and provisions in this document may not appear in consecutive order.

14. BRAND NAME REQUIREMENTS

Reserved

End of Section 00100

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management OCT 2018 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.215-1 Instructions to Offerors--Competitive Acquisition NOV 2021 52.219-2 Equal Low Bids OCT 1995 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.225-10 Notice of Buy American Requirement--Construction Materials

MAY 2014

52.236-28 Preparation of Proposals--Construction OCT 1997 52.252-3 Alterations in Solicitation APR 1984 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements MAR 2022 252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.236-7008 Contract Prices-Bidding Schedules DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firm fixed contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

50% 25%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract

Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is [Contracting Officer shall insert description of the geographical areas where the contract is to be performed, giving the State, county, and city].

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $ 3M, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

159 MSC

400 Russell Ave, Building 473 Room 212 New Orleans, LA 70143

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visit will be 22 June at 1000am CST. Submit attendee name and company at least 24 hrs prior to site visit.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

www.acquisition.gov

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (NOV 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

252.211-7002 AVAILABILITY FOR EXAMINATION OF SPECIFICATIONS, STANDARDS, PLANS,

DRAWINGS, DATA ITEM DESCRIPTIONS, AND OTHER PERTINENT DOCUMENTS (DEC. 1991)

The specifications, standards, plans, drawings, data item descriptions, and other pertinent documents cited in this solicitation are not available for distribution but may be examined at the following location:

400 Russell Ave Building 473 Room 212, New Orleans, LA 70143

PROPOSAL PREP

SECTION 00110 SUBMISSION REQUIREMENTS AND INSTRUCTIONS

1. PROPOSAL PREPARATION INSTRUCTIONS

1.1. These instructions prescribe the format of proposals, and describe the approach for the development and presentation of the proposal data. They are designed to ensure the submission of necessary information to provide for the understanding and comprehensive evaluation of proposals. Carefully review this section prior to commencing proposal preparation. All solicitation amendments must be acknowledged in accordance with Section 00100, FAR Provision 52.215-1, Instruction to Offerors – Competitive Acquisition.

1.2. Offerors are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete proposal. Failure to furnish a complete proposal, at the time of proposal submission, may result in the proposal being unacceptable to the Government and eliminated from consideration for award.

2. PROPOSAL CONTENT

2.1. Prospective offerors shall submit the following volumes in two separate packages:

2.1.1. Submit Volume 1, Price proposal, pro forma documents, in original in accordance with instructions contained herein.

Volume 2, Part 1 – Technical Capability Proposal, in original

Subfactor 1 – Experience and Capability (limit resumes to 2 pages each) Subfactor 2 – Construction Schedule (schedule no page limit; narrative – no more than 5 pages) Subfactor 3 – Quality Control

Volume 2, Part 2 – Past/Present Performance Information

Subfactor 1 – Quality Control Subfactor 2 - Timely Performance Subfactor 3 – Compliance with Safety Standards Subfactor 4 – Management Effectiveness Subfactor 5 – Compliance with Federal laws and regulations

Exhibit A - Performance Relevancy Questionnaire should provide questionnaire responses to the Contracting Officer not later than the closing date.

Exhibit C – Reference Questionaire

2.3. After compiling all required information, submit original documents to the following:

159.FW.FAL.MSC.Contracting@us.af.mil or hand deliver to 400 Russell Ave. Building 473 Room 212, New Orleans, LA 70143 Mark the front of the envelope/box with the following: “PROPOSAL No. W50S7Z-22-R-0013, DO NOT OPEN--- Competitive Acquisition”.

2.4. PROPOSAL FORMAT

2.4.1. Purpose: These instructions prescribe the format of proposals, and describe the approach for the development and presentation of the proposed data. The proposal shall include all of the information requested in the specific instructions. Failure to include all information requested may adversely affect the evaluation.

2.4.2. A proposal that merely reiterates or promises to accomplish the requirements of the RFP will be considered unacceptable. A proposal that is orderly and sufficiently documented will be easy for the Government to understand and will enable the Government to perform a thorough and fair evaluation.

2.4.3. Offerors are cautioned to submit enough information to enable the evaluation committee to fully ascertain each offeror’s capability to perform all of the requirements contemplated by this solicitation. All commitments made in the proposal may become a part of the resultant contract. The data submitted with each proposal should be complete and concise, but not overly elaborate. Excessive reliance on promotional brochures is discouraged.

2.4.4. Written proposals shall be prepared on standard 8.5 x 11 inch paper (charts may be landscaped but must be on 8.5 x 11 inch paper) and shall be in a legible font size (10 min.). All pages of each proposal shall be appropriately numbered, and identified with the RFP number. For ease of reference, consecutive page numbering with tabs is required. Type size for graphics, charts, diagrams and tables shall be of an appropriate font and size for the application, and must be clearly readable without magnification assistance to the normal eye. Text lines will be no less than single-space. To the maximum extent practicable, proposal submission shall be double sided. Where page limits exist a page is defined as one single side of a page. Double sided pages count as 2 pages. Unless otherwise stated, tabs, indexes and dividers do not count in the page count.

2.4.5. Binding: Elaborate format and binding are neither necessary nor desirable. All binders will be capable of lying flat when opened. Three ring binders are preferred. The cover and spine of each binder will clearly identify the offeror’s name, Project number, RFP number, RFP title and copy number, (e.g. copy 2 of 3). The original for each volume will be clearly identified on the cover and the spine. All binders will allow for easy removal and replacement of pages.

2.4.6. Indexing: Each binder will contain a “Table of Contents” for that volume. The “Table of Contents” will identify major areas, paragraphs and subparagraphs by number and title, as well as by page number and volume locations. Tab indexing will be used to identify Sections as appropriate.

2.4.7. Electronic Submission: The preferred method of submission of proposal documents is email to 159.FW.FAL.MSC.Contracting@us.af.mil or via DOD SAFE if file size is too large.

2.4.10. The offeror shall be held responsible for the validity of all information supplied in his/her proposal, including that provided by potential subcontractors. Should subsequent investigation disclose that the facts and conditions were not as stated, the proposal may be rejected.

2.5. PROPOSAL VOLUME CONTENTS: Each offeror’s proposal shall be submitted as set forth below and all information shall be confined to the appropriate part to facilitate independent evaluation. Proposals, which do not include the requested minimum information, may be eliminated from further consideration for award.

2.5.1. VOLUME 1, PRICE/COST INFORMATION AND PRO FORMA DOCUMENTS

2.5.1.1. Offerors shall provide all price/cost information necessary to provide a meaningful basis for Government's analysis and evaluation of price/cost for the project set forth in Section 00120 of this solicitation. The Government is not, and does not intend on, requesting certified cost or pricing data.

2.5.1.2. Provide an introductory page to include Cage Code,Unique Entity Identifier (UEI), points of contact, authorized negotiators, contact phone, and email addresses. Also, include your business socioeconomic status, e.g.

small business, woman-owned small business, HUBZone small business, etc.

2.5.1.3. Offer and Section 00010 – Complete in its entirety the “Offeror” portion of the Standard Form (SF) 1442.

An official having the authority to contractually bind your company must sign the SF 1442 in accordance with FAR

4.102. One copy of the SF 1442 is required to have an original signature.

2.5.1.4. Section 00010 – Insert the price/cost associated with the project in the line items. All line items (CLINs) must be priced to be considered.

2.5.1.5. Representations and Certifications- Section 00600- insert the required certifications and representations and return only those shown in section 00600. Return the entire Section 00600 with your proposal. All other required representations and certifications are to be completed on line in the System for Award Management (SAM) at www.sam.gov.

2.5.1.6. All potential offerors are required to register in the System for Award Management. See FAR Provision 52.204-7 System for Award Management.

2.5.1.8. Joint Venture Requirements - Parties wishing to propose as a joint venture must submit, with the Pro Forma documents, an executed copy of the joint venture agreement. The joint venture agreement shall be executed in accordance with FAR 4.102(d). Each joint venture partner shall submit evidence satisfactory to the Contracting Officer that its Board of Directors has approved its participation in the joint venture or by an instrument of similarly binding character in the case of an unincorporated entity. Offerors are reminded that to obtain an award the awardee, to include a joint venture, must be registered in the System for Award Management (SAM) database. Applicable to set-aside solicitations: Joint Ventures must meet applicable size standards (See FAR Subpart 19.1). Submit with the proposal any size determination for the Joint Venture entity received from the Small Business Administration. A Joint Venture where-in one party is not a small business may be referred to the Small Business Administration ( IAW FAR 19.302 (b)) to determine eligibility. All questions regarding Joint Ventures must be directed to the Small Business Administration (SBA) and not the Contracting Officer.

2.5.2. VOLUME 2, PART 1, OFFEROR TECHNICAL CAPABILITY PROPOSAL

2.5.2.1. Volume 2 Part 1 is comprised of three (3) subfactors: Subfactor 1, Experience and Capability; Subfactor 2, Construction Schedule; and Subfactor 3, Quality Control.

2.5.2.1.1. Government acknowledges that the technical proposal will involve discussion of some of the same projects/contracts discussed in the Past Performance volume. While Past Performance examines how an offeror performed in the past, so as to determine the probability of success on future projects, this subfactor examines the offeror’s experience with complex multidiscipline project management and execution and how the offeror demonstrates an understanding of the contract’s requirements taking this experience into consideration. The Government intends to use Exhibit A Part 1 information in the evaluation of experience for Subfactor 1. A reiteration of the information provided in Exhibit A is neither required nor desired. Offeror should reference this information by providing a short summation of their relevant experience to meet the submission requirements of this subfactor.

2.5.2.2. Subfactor 1: Experience and Capability. The Experience and Capability Proposal is limited to 10 single pages, excluding tabs, indexes and resumes as noted below. Pages in excess of the limit will not be evaluated.

2.5.2.2.1 Demonstrate offerors technical experience and capability to perform a project of this magnitude and complexity. Discuss and provide experience of key construction personnel including, but not limited to, Project Manager, Site Superintendent(s), Quality Control Manager (on site) and Safety Manager. Discuss any previous projects that are similar to this project in terms of scope, size and complexity. Specifically discuss past projects for painting aircraft or static displays. If no experience so state and indicate in detail how you plan to overcome this lack of experience. The onus is solely on the offeror to indicate in detail how the offeror plans to overcome this lack of experience. (Resumes or experience cut sheets are limited to 2 pages each and are not part of the page count.) In the event the intended person is not part of the offeror’s organization at the time the proposal is submitted then a completed Exhibit B, “Subcontractor/Team/Key Personnel Information and Consent Form” is also required or the information will not be considered. The Exhibit D Consent form or Letter of Intent is required for the Subcontractor to be considered.

2.5.2.3. Subfactor 2: Construction Schedule. The construction schedule and commissioning approach/timeline is obtained for the purposes of evaluating an offerors understanding of the requirements of the schedule and commissioning. The Schedule itself is not subject to page limits; however any narrative accompanying the schedule submission is limited to 5 pages, excluding tabs and indexes.

2.5.2.3.1. Provide Construction Schedule in a Gantt chart that shows the complete project schedule from Notice to Proceed date of 30 May 2022 (estimated) to include all construction activities as well as concurrent activities, and outline the critical path activities that will show successful execution of the construction project within the period of performance requirements per FAR 52.211-10. Also, include a narrative discussing the scheduling processes and resource allocation that ensure completion and control of schedule progress from beginning to the end of the project.

2.5.2.4. Subfactor 3: Quality Control. The proposal narrative demonstrates that the quality control staff, with lines of authority, is adequate to meet the contract’s requirements. The proposed Quality Control answers should provide a detailed explanation of how quality issues are dealt with on various types of construction projects and as a minimum, meetings, inspections, submittal reviews, correction of non-compliant work and how you intend to ensure non-reoccurrence and reporting of quality problems to Government officials. (Note: A Quality Control Plan is not required with this proposal).

2.5.3. VOLUME 2, PART 2 OFFEROR PAST/PRESENT PERFORMANCE INFORMATION

2.5.3.1. Volume 2 Part 2 is obtained for the purpose of evaluating Past/Present Performance. Past/Present Performance includes current/on-going performance that is complete to 70% or greater. Volume 2 includes the offeror’s Performance Relevancy Questionnaire, Exhibit A Parts 1 and 2; and any discussion and or additional information, awards, letters, etc. concerning past/present performance the offeror includes. Offerors are cautioned to complete all the questions on the Exhibit A Parts 1 and Part 2. Detailed instructions are included in Exhibit A.

2.5.3.2. Offerors shall use the Reference Package, Exhibit C, to obtain references from past and present clients.

2.5.3.3. Past/Present Performance, which includes current on-going (present) performance that is complete to 70% or greater will be evaluated using the evaluation criteria set forth in Section 00120 of the solicitation. If the offeror represents the combining of two or more companies, joint venture or formal teaming agreement, for the purpose of this RFP, each company shall complete Exhibit As and obtain Exhibit C references. The Government may contact these references and may consider this information as well as information obtained from any other sources when evaluating the offeror's past/present performance.

2.5.3.4. Offerors shall discuss their performance using the Performance Relevancy Questionnaire format, Exhibit A, Part 1. Prepare not more than (3) of these documents. Contractors should select their projects carefully because the quality of the contractor’s relevant performance is more important than the quantity of projects submitted.

2.5.3.5. Use the Exhibit A format to provide information that demonstrates a history of performance on contracts that are similar in scope, complexity, and cost magnitude to this project’s plans and specifications. Explain what aspects of the contract you find relevant to the proposed effort and identify how each contract ranks, in terms of relevancy, with respect to the other contracts addressed in proposal.

2.5.3.6. Offerors should consider the currency and relevancy of the past/present performance information to be considered, the performance must have been completed during the past five (5) years. The period begins five (5) years prior to the solicitation release date and includes current performance. Performance that is more current may have greater impact than older performance.

2.5.3.7. In determining relevancy to the solicitation requirement, offerors should consider the similarity of construction methods employed, size, scope, cost magnitude, location, client type (e.g. federal government) and complexity of work performed to those required for the proposed effort. Location should also be considered.

2.5.3.8. Offerors are encouraged to include with their proposal information any problems encountered on the identified contracts and the offeror's correction actions.

2.5.3.9. Offerors lacking relevant present/past performance experience may submit information regarding predecessor companies, key personnel who have relevant experience or subcontractors that will perform major or critical aspects of the requirement if such information is relevant to this acquisition. Such information shall, as a minimum, include:

Name(s) of Predecessor Company/Subcontractor and/or Key Personnel Complete Address Telephone, Fax Number and email address Brief synopsis of the experience- A resume may be submitted for "Key Personnel" Describe relevancy to this project

2.5.3.10 Provide three (3) references, for each Predecessor Company, Subcontractor or Key Personnel. Clearly identify the contractor/individual for whom the reference information concerns.

2.5.3.11. Past Performance References – REQUIRED – A “Final” Performance Evaluation (Construction) (also referred to as CCASS Evaluation) issued for a project may be included in lieu of sending out reference package for the project. OR Offerors shall prepare and submit to prior client(s) of all the projects listed on your Exhibit A submission a Reference Package (Exhibit C) (Detailed instructions are included in Exhibit C Package). This includes correspondence explaining the requirement to obtain an independent evaluation of prior contract performance, and the Past Performance Questionnaire for use in evaluating Past Performance. Inform references that completed Performance Questionnaire should be returned to the Contracting Officer via email at: 159.FW.FAL.MSC.Contracting@us.af.mil to arrive later than the closing date for receipt of proposals.

Offeror must not review the Past Performance Questionnaire prior to submission. They are to be submitted by the client/evaluator directly to the Contracting Officer. Offeror's should follow-up and encourage references to get the questionnaires to the Contracting Officer in a timely manner.

2.5.3.12. In assessing past performance, the Government may also consider the past/present performance of the offeror’s key personnel, Project Manager, Quality Control Manager and Site Superintendent, as it relates to previous projects. In the event the intended key personnel for this solicitation’s project do not have demonstrated past performance in the project(s) submitted in the Exhibit A’s, the Government reserves to obtain reference information additional information is required.

2.5.3.12.1. Each key person without prior past performance history demonstrated on the submitted Exhibit A shall provide a summary of experience or a resume. In the event the intended person is not part of the offeror’s organization at the time the proposal is submitted then a completed Exhibit B, “Subcontractor/Team/Key Personnel Information and Consent Form (Exhibit D)” or Letter of Intent, is also required or the information will not be considered. The Government may seek additional references and reserves the right to use the information provided to obtain additional references.

2.5.3.13. Offerors are advised that the Government may use all data provided by the offeror in this volume and data obtained from any other sources, to include, but not limited to, data independently obtained from other Government or commercial sources; from any other sources available to the Government, to include, but not limited to, the Federal Awardee Performance and Integrity Information System (FAPIIS), Electronic Subcontract Reporting System (eSRS), or other databases; interviews with Program/Project Managers, Contracting Officers or rely upon personal business experience with the offeror. The Government reserves the rights to obtain and evaluate past performance information from any source it deems appropriate. While the Government may elect to consider data obtained from other sources, the burden of providing current accurate and complete past/present performance information rests with the offeror.

END OF SECTION 00110

PROPOSAL EVAL

SECTION 00120 PROPOSAL EVALUATION AND BASIS FOR AWARD

1. GENERAL INFORMATION

1.1. This solicitation is for a Firm Fixed Price Contract. The Government intends to award a single contract to a qualified Small Business Offeror deemed responsible in accordance with the Federal Acquisition Regulation (FAR), whose proposal conforms to all the RFP’s requirements and is judged to represent the Best Value to the Government in accordance with the evaluation scheme set out in this solicitation. The award will be made based on the best overall (i.e. best value) proposal that is determined to be the most be the most beneficial to the Government, with appropriate consideration given to the three (3) evaluation factors: Technical, Price, and Past Performance. To arrive at a Best Value decision, the Source Selection Authority will integrate the evaluation of Past/Present Performance, Technical and Price as set out in the solicitation. In terms of the relative importance of the factors, the Technical factor is approximately equal to the Present/ Past Performance and when combined, the non-cost factors are approximately equal to the Price Factor. The firm that represents the best value to the Government will be selected for award in accordance with FAR 15.1 Source Selection Processes and Techniques.

1.2. To arrive at a Best Value decision this acquisition will utilize the FAR Part 15.101-1 tradeoff process unless the lowest priced offeror (with a price deemed reasonable and realistic) is also deemed to be the highest rated in terms of non-price evaluation criteria. If the lowest priced offeror is also the highest rated in terms of non-Price Factors, no tradeoff is necessary. Further, there is no tradeoff necessary between any offer that is lower priced and higher rated in terms of non-Price Factors with respect to any other offers that are higher priced and lower rated for the non-Price Factors. While the Government and the Source Selection Authority will strive for maximum objectivity, the evaluation process, by its nature, is subjective and therefore, professional judgment is implicit throughout the entire evaluation process.

1.3. The source selection process will be conducted in accordance with FAR Subpart 15.3, Source Selection procedures. Offers will be evaluated using the criteria listed in “Evaluation Factors for Award.” Noncompliance with the RFP requirements may raise serious questions regarding an offeror’s technical ability, past performance and/or pricing and may be grounds to eliminate the proposal from consideration for contract award. Failure to include all information requested may adversely affect the evaluation. A proposal that merely reiterates or promises to accomplish the requirements of the RFP will be considered unacceptable. A proposal that is orderly and sufficiently documented will be easy for the Government to understand and will enable the Government to perform a thorough and fair evaluation.

1.4. The Contracting Officer will begin the evaluation process by conducting a proposal compliance review for all timely-received proposals for determination of basic proposal adequacy prior to providing the proposals to the evaluators. Failure to provide a complete proposal may result in the proposal being removed from further consideration for award. Failure to address any factor Technical, Past Performance and Price or any technical subfactor shall be grounds for elimination from evaluation and consideration for award.

1.5. Offerors must ensure that no pricing information is displayed in Volume 2, Technical and Past Performance Proposal.

1.6. Although the assessment of Past Performance as a specific evaluation factor is separate and distinct from the Determination of Responsibility required by FAR Part 9, Past Performance information obtained herein will be used during the Government’s responsibility determination. The Government also reserves the right to obtain additional information solely for the purpose of making a responsibility determination from all offerors after receipt of proposals. Requests for responsibility information do not constitute discussions.

1.7 The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). The Government reserves the right to conduct discussions if the Contracting Officer, in his/her sole discretion, later determines them to be necessary or appropriate. Further, the Government reserves the right to create or not to create a competitive range.

1.8. ENFORCEABILITY OF PROPOSAL: The proposal must set forth full, accurate and complete information as required by this solicitation. By submission of the offer, the Offeror agrees that all items proposed (if applicable e.g., key personnel, subcontractors, etc.) will be utilized for the duration of the contract and any substitutions shall require prior Contracting Officer's approval.

2. EVALUATION FACTORS FOR AWARD

2.1. The evaluation factors are (1) Technical, (2) Past/Present Performance and (3) Price. To arrive at a Best Value decision, the Source Selection Authority will integrate the evaluation of Past/Present Performance, Technical and Price as set out in the solicitation. In terms of the relative importance of the factors, the Technical factor is approximately equal to the Present/ Past Performance and when combined, the non-cost factors are approximately equal to the Price Factor. The firm that represents the best value to the Government will be selected for award in accordance with FAR 15.1 Source Selection Processes and Techniques.

2.1.1. Factor 1: The Technical factor is further divided into the following subfactors:

1. Experience and…