Sol_140L2626R0004.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NO.

5. REQUISITION/PURCHASE REQUEST NO.

CODE

6. PROJECT NO.

8. ADDRESS OFFER TO

4. CONTRACT NO.

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

NEGOTIATED (RFP) REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF

SEALED BID (IFB) INVITATION FOR BID

9. FOR

INFORMATION CALL

PAGES

140L2626R0004

BLM ID-STATE OFC HR&ADM SVC (ID953)

1387 S. VINNELL WAY

BOISE ID 83709

0044044599

LDA

Patricia Fort 2083733910

06/22/2026

07/13/2026

10 60 Section F

Cauldron Linn Recreation Site Improvements

1 52

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Continued...

AMENDMENT

NUMBER

DATE.

BLM ID STATE OFC HR&ADMN (ID953)

1387 S. VINNELL WAY

BOISE ID 83709

LDA

Patricia Fort

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGES

NAME OF OFFEROR OR CONTRACTOR

SUPPLIES/SERVICES

(B)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

OPTIONAL FORM 336 (4-86)

Sponsored by GSA FAR (48 CFR) 53.110

ITEM NO.

(A)

QUANTITY

(C)

NSN 7540-01-152-8067

140L2626R0004

Delivery: 09/30/2026

Delivery Location Code: 0011276391

BLM-ID SHOSHONE FIELD OFFICE (Twin

400 W F ST.

SHOSHONE ID 83352-1522 US

Period of Performance: 07/27/2026 to

09/30/2026

00010 Cauldron Linn Recreation Site Improvements

Product/Service Code: Y1PA

Product/Service Description: CONSTRUCTION OF

RECREATION FACILITIES (NON-BUILDING)

SOLICITATION NO: 140L2626R0004

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 4

Type of Contract: Construction, Firm-Fixed Price (FFP), Single Award Contract County: Twin Falls County, Idaho Type of Construction: Heavy

FAR Magnitude: $250,000 and $500,000 NAICS: 237990 Size Standard: $45.0 Million Set-Aside: Total Small Business

Bureau of Land Management Contracting Officer

Name: Patricia A. Fort

Email: pfort@ios.doi.gov

Proposal Submittal Information:

Site Visit: See Section L.8

Proposal Due Date: July 13, 2026, at 10:00 am MDT

Award Selection Process: Lowest Price Technically Acceptable mailto:pfort@ios.doi.gov

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 5

TABLE OF CONTENTS

Part I - The Schedule

Section A - Solicitation/Contract Form See Standard Form 1442 Section B - Bid Schedule 6 Section C - Specifications/Drawings 7 Section D - Packaging and Marking 7 Section E - Inspection and Acceptance 7 Section F - Deliveries or Performance 7 Section G - Contract Administration Data 8 Section H - Special Contract Requirements 10

Part II - Contract Clauses

Section I - Contract Clauses 13

Part III - List of Documents, Exhibits, and Other Attachments

Section J - List of Attachments 29

Part IV - Representations and Instructions

Section K - Representations, Certifications, and Other Statements of Offerors 36 Section L - Instructions, Conditions and Notices to Offerors 42 Section M - Evaluation Factors for Award 50

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 6

SECTION A - SOLICITATION/CONTRACT FORM

This Request for Proposal is issued on Standard Form (SF) 1442, Solicitation, Offer and Award

SECTION B: BID SCHEDULE

Offerors are to complete Blocks 14 - 20 of the SF-1442.

Cauldron Linn Recreation Site Improvement

Pay Item Pay Description Quantity Unit Unit Cost Total

BID ITEM 1 Mobilization and Construction 1 LS $__________ $___________ Management

BID ITEM 2 Construction Staking 1 LS $__________ $___________

BID ITEM 3 Earth Work 1 LS $__________ $___________

BID ITEM 3 General Excavation 948 CY $__________ $___________

BID ITEM 3 Road Reconditing 1 LS $__________ $___________

BID ITEM 3 Subbase Material 1800 CY $__________ $___________

BID ITEM 3 Base Course 1300 CY $__________ $___________

BID ITEM 3 Surface Course Spread and Compact 1 LS $__________ $___________

BID ITEM 4 Rock Excavation 100 CY $__________ $___________

BID ITEM 5 Boulder Relocation 80 EA $__________ $__________

BID ITEM 9 SIGNS 4 EA $__________ $___________

Period of Performance: 60 Days after receipt of Notice to Proceed

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 7

SECTION C: SPECIFICATIONS/DRAWINGS

See Section J for additional attachments to include project specifications and drawings.

SECTION D: PACKAGING AND MARKING

Packaging and marking of deliverables shall be IAW the Contractor’s standard commercial practices.

SECTION E: INSPECTION AND ACCEPTANCE

E.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.246-12 Inspection of Construction August 1996 52.246-13 Inspection -- Dismantling, Demolition, or Removal of Improvements August 1996

E.2 Final Inspection and Acceptance

Final completion of the punch list items, submission of all required submittals, and final cleanup of the project site shall be completed before the contract’s required completion date. The Contracting Officer or his/her designated representative will perform final inspection. Acceptance of the work will occur only upon written notice of acceptance by the ordering Contracting Officer, or any other Warranted Contracting Officer employed by the Bureau of Land Management (BLM) and performing authorized duties in conjunction with this contract.

The contracts required completion date is 60 calendar days after receipt of the notice to proceed.

SECTION F: DELIVERIES OR PERFORMANCE

F.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.211-13 Time Extensions September 2000 52.236-11 Use and Possession Prior to Completion April 1984 https://www.acquisition.gov/browse/index/far

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 8

F.2 52.211-12 Liquidated Damages--Construction (Apr 1984)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $700 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

F.3 Simultaneous Performance

If a Contractor receives award of more than one contract, simultaneous performance will be required. All work must be completed within the timeframe allowed for each contract.

SECTION G: CONTRACT ADMINISTRATION DATA

G.1 Authorities and Delegations (Sep 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award.

The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor.

Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence.

Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 9

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

G.2 Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (Apr 2013)

Payment requests must be submitted electronically through the U.S. Department of the Treasury's Internet Payment Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor.

To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions- Commercial Items included in commercial item contracts. The IPP website address is https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Invoice date and Government Contract Number

2. Billing period specified with beginning and ending dates. The beginning date must not be later than the completion date or within any previous billing dates.

3. The accounting must follow the approved schedule of values as described in the specification attachment.

4. Total amount due for the billing period

5. Certification of Progress Payment

6. Payrolls (Mail weekly)

7. Substantiation of Subcontractor Payment

8. Certification with final payment request.

9. A Release of Claims (See 1452.204-70) with a request for final payment.

The Contractor must use the IPP website to register, access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

G.3 Local Internet Payment Platform (IPP) Hotline

To check payment status, contact the Payment Hotline at 877-480-9724 or 303-236-2850. You will need to leave a message with the following information:

1. Company Name

2. Contract Number

3. Invoice Number http://www.ipp.gov/ mailto:ippgroup@bos.frb.org

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 10

4. Invoice Amount

5. A brief description of why you are calling

6. Your contact information

If you do not receive a callback from the Payment Hotline within 72 hours, please contact the Contracting Officer with the day and time you contacted the Payment Hotline.

G.4 Government Point of Contact

Patricia A. Fort, Contracting Officer pfort@ios.doi.gov Bureau of Land Management 1387 S. Vinnell Way Boise, ID 83709-1657 Telephone: (208) 373-3910

SECTION H: SPECIAL CONTRACT REQUIREMENTS

H.1 Work Hours

The performance period established for this contract is based upon all work being conducted during regular working hours between 7:00 am and 5:00 pm, Monday through Friday, excluding government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and government holidays, a request must be submitted to the Contracting Officer in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection.

In addition to any holidays declared by Executive Orders, the following Federal Legal Holidays are observed:

New Year’s Day, Martin Luther King Jr. Day, President’s Day, Memorial Day, Juneteenth, Independence Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day, Christmas Day

H.2 Communications

“Time” for communications received after 3:00 pm, after 12:00 pm locally on Fridays, or after 12:00 pm locally prior to a holiday will not start until the next business day. All times are local Mountain time.

H.3 Fire Danger Season

If the Contracting Officer Representative (COR) allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

H.4 Drawings

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

mailto:pfort@ios.doi.gov

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 11

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full- size drawings may contact the Contracting Officer identified in the solicitation.

H.5 Preservation of Historical and Archeological Data

(a) The Historic and Archeological Data Preservation Act of 1974 provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings.

No objects of cultural resource value may be removed.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The Contractor will be responsible for protecting the cultural resources within the effected area from damage. In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting Officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

(e) The Contractor agrees to insert this paragraph in all subcontracts that involve the performance of work on the terrain of the site.

H.6 Safety and Quality Control Plan

Following contract award, the contractor must provide effective quality assurance and safety plans for acceptance by the Government.

H.7 Limitations on Subcontracting Reporting

In accordance with 52.219-14 Limitations on Subcontracting, the prime contractor must perform at least 15% of the cost of the contract, excluding the cost of materials with its own employees and employees of a similarly situated subcontractor. A similarly situated subcontractor is a small business concern subcontractor that is a participant of the same SBA program that qualified the prime contractor as an eligible offeror and awardee of the contract. The contractor is responsible for ensuring compliance with the Limitation on Subcontracting.

At the conclusion of the period of performance and prior to final payment, the contractor shall submit a Limitation on Subcontracting Report directly to the Contracting Officer. The following information is required as part of the report: 1) the total amount paid to the Prime during the performance period broken out by labor and materials 2) list of Similarly Situated Subcontractors and the amounts paid to each during the performance period broken out by labor and materials 3) list of any other subcontractors and the amounts paid to each during the performance period broken out by labor and materials.

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 12

If the Contracting Officer review of the report finds that the contractor is not in compliance for the period of performance, the contractor will be notified in writing. Penalties for failure to comply are described in 13 CFR 125.6(h) which states: Whoever violates the requirements set forth in paragraph (a) of this section shall be subject to the penalties prescribed in 15 U.S.C. 645(d), except that the fine shall be treated as the greater of $500,000 or the dollar amount spent, in excess of permitted levels, by the entity on subcontractors.

A party's failure to comply with the spirit and intent of a subcontract with a similarly situated entity may be considered a basis for debarment on the grounds, including but not limited to, that the parties have violated the terms of a Government contract or subcontract pursuant to FAR 9.406-2(b)(1)(i) (48 CFR 9.406-2(b)(1)(i)).

H.8 Environmental Impact

All waste materials generated by any work under the contract performed on a Government installation shall at all times be handled, transported, stored, and disposed of by the contractor and by his subcontractors in accordance with all applicable Federal, state, and local laws, ordinances, regulations, court orders, and other types of rulings having the effect of the law, including, but not limited to Executive Order 12088, 13 October 1978, Federal Compliance with Pollution Control Standards; the Federal Water Pollution Control Act, as amended (33 U.S.C.

1251 ET SEQ); the Clean Air Act as amended (42 U.S.C. Sec 7401 ET SEQ); the Endangered Species Act, as amended (16 U.S.C. Sec 1531, ET SEQ); the Toxic Substances Control Act, as amended (15 U.S.C. Sec 2601, ET SEQ); the National Historic Preservation Act, as amended (16 U.S.C. Sec 470, ET SEQ); the Solid Waste Disposal Act, as amended (42 U.S.C. 6901 ET SEQ); and the Archaeological and Historic Preservation Act, as amended (16 U.S.C. Sec 469, ET SEQ). Should the United States Government be held liable for any neglect or improper actions by the contractor or any subcontractor regarding removal or disposal of any hazardous waste, the contractor shall reimburse the Government for all such liability.

H.9 Hazardous Materials

Any material suspected of being hazardous that is encountered during performance of a project shall immediately be brought to the attention of the Contracting Officer, at which time a determination will be made as to whether hazardous material testing shall be performed. If the Contracting Officer directs the contractor to perform tests, and/ or the material is found to be of a hazardous nature requiring additional protective measures, a contract modification may be required, subject to equitable adjustment under the terms of the contract. The contractor is advised that friable and/or non-friable asbestos-containing material may be encountered in project areas.

Friable asbestos-containing material is any material that contains more than one percent asbestos by weight, and that hand pressure can crumble, pulverize or reduce to powder when dry. Non-friable asbestos containing materials are materials in which asbestos fibers are bound by a matrix material, saturation, impregnation or coating.

Non-friable asbestos-containing materials do not normally release airborne asbestos fiber during routine handling and end-use. However, excessive fiber concentrations may be produced during uncontrolled abrading, sanding, drilling, cutting, machining, removal, demolition, or other similar activities. 29 CFR 1910.1001 shall be referenced in the event asbestos-containing materials are encountered. Friable asbestos-containing materials are not authorized for use in new construction or maintenance projects.

H.10 Unauthorized Personnel

The contractor shall inform all personnel working under his jurisdiction (including subcontractor and visiting supplier personnel) that access to areas outside of the immediate work area; excluding direct haul and access routes, contracting and Civil Engineering offices and points of supply and storage; is prohibited. Circulation of said personnel will be limited to official business only. Persons in violation of the above will be apprehended and appropriately disciplined.

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 13

PART II - CONTRACT CLAUSES

SECTION I: CONTRACT CLAUSES

I.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.202-1 Definitions June 2020 52.203-3 Gratuities April 1984 52.203-5 Covenant Against Contingent Fees May 2014 52.203-6 Restrictions on Subcontractor Sales to the Government June 2020 52.203-7 Anti-Kickback Procedures June 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity May 2014

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity May 2014 52.203-12 Limitation on Payments to Influence Certain Federal Transactions June 2020 52.203-17 Contractor Employee Whistleblower Rights Nov 2023 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements January 2017

52.204-9 Personal Verification Contractor Personnel January 2011 52.204-10 Reporting Executive Compensation and First-Tier Subcontract

Awards November 2025

52.204-91 Contractor Identification November 2025 52.204-13 System for Award Management - Maintenance November 2025 52.204-19 Incorporation by Reference of Representations and Certifications December 2014 52.209-6 Protecting the Government's Interest when Subcontracting with

Contractors Debarred, Suspended, Proposed for Debarment or Voluntarily Excluded

November 2025

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations November 2025 52.215-2 Audit and Records-Negotiated November 2025 52.215-8 Order of Precedence-Uniform Contract Format November 2025 52.219-6 Notice of Total Small Business Set Aside November 2025 52.219-8 Utilization of Small Business Concerns November 2025 52.219-14 Limitations on Subcontracting (Deviation) (October 2025) November 2025 52.219-28 Postaward Small Business Program Rerepresentation November 2025 52.222-1 Notice to the Government of Labor Disputes November 2025 52.222-3 Convict Labor November 2025 52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation November 2025

52.222-6 Construction Wage Rate Requirements (Aug 2018) November 2025 52.222-9 Apprentices and Trainees (July 2005) (Deviation) November 2025 52.222-10 Compliance with Copeland Act Requirements November 2025 52.222-11 Subcontracts (Labor Standards) (May 2014) November 2025 52.222-12 Contract Termination-Debarment (May 2014) February 2025

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 14

52.222-13 Compliance with Davis-Bacon and Related Act Regulations. February 1988 52.222-14 Disputes Concerning Labor Standards November 2025 52.222-15 Certification of Eligibility February 1988 52.222-35 Equal Opportunity for Veterans July 2014 52.222-36 Equal Opportunity for Workers with Disabilities November 2025 52.222-37 Employment Reports on Veterans November 2025 52.222-40 Notification of Employee Rights under the National Labor Relations

Act November 2025

52.222-50 Combating Trafficking in Persons November 2025 52.222-54 Employment Eligibility Verification November 2025 52.222-62 Paid Sick Leave under Executive Order 13706 November 2025 52.222-90 Addressing DEI Discrimination by Federal Contractors March 2026 52.223-2 Reporting of Biobased Products under Service and Construction

Contracts (DEVIATION Feb 2025) November 2025

52.223-3 Hazardous Material Identification and Material Safety Data - Alternate I

July 1995

52.226-7 Drug-Free Workplace May 2024 52.227-1 Authorization and Consent December 2007 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement June 2020 52.227-4 Patent Indemnity - Construction Contracts December 2007 52.228-11 Individual Surety--Pledge of Assets February 2021 52.228-12 Prospective Subcontractor Requests for Bonds December 2022 52.229-3 Federal, State and Local Taxes July 2025 52.232-5 Payments under Fixed-Price Construction Contracts September 2002 52.232-16 Progress Payments - Alternate I November 2021 52.232-17 Interest May 2014 52.232-23 Assignment of Claims May 2014 52.232-27 Prompt Payment for Construction Contracts January 2017 52.232-39 Unenforceability of Unauthorized Obligations June 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors March 2023 52.233-1 Disputes - Alternate I November 2025 52.233-3 Protest After Award November 2025 52.233-4 Applicable Law for Breach of Contract Claim November 2025 52.236-5 Material and Workmanship November 2025 52.236-6 Superintendence by the Contractor July 2025 52.236-8 Other Contracts July 2025 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements July 2025

52.236-10 Operations and Storage Areas July 2025 52.236-11 Use and Possession Prior to Completion July 2025 52.236-12 Cleaning Up July 2025 52.236-13 Accident Prevention July 2025 52.236-14 Availability and Use of Utility Services July 2025 52.236-17 Layout of Work July 2025 52.240-91 Security Prohibition and Exclusions November 2025 52.240-92 Security Requirements. November 2025 52.240-93 Basic Safeguarding of Covered Contractor Information Systems November 2025 52.242-13 Bankruptcy July 1995

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 15

52.242-14 Suspension of Work April 1984 52.243-4 Changes June 2025 52.244-6 Subcontracts for Commercial Products and Commercial Services

(January 2025) (Deviation) April 2026

52.248-3 Value Engineering-Construction - Alternate I April 1984 52.249-2 Alt I Termination for Convenience of the Government (Fixed-Price) -

Alternate I April 2012

52.249-3 Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements)

April 2012

52.249-10 Default (Fixed-Price Construction) April 1984

I.2 52.222-7 Withholding of Funds (Nov 2025)

The Contracting Officer must, upon his or her own action or upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the Contractor under this contract or any other Federal contract with the same Prime Contractor, or any other federally assisted contract subject to prevailing wage requirements, which is held by the same Prime Contractor, so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and helpers, employed by the Contractor or any subcontractor the full amount of wages required by the contract. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee, or helper, employed or working on the site of the work, all or part of the wages required by the contract, the Contracting Officer may, after written notice to the Contractor, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased.

I.3 52.222-8 Payrolls and Basic Records (Nov 2025)

(a) Payrolls and basic records relating thereto must be maintained by the Contractor during the course of the work and preserved for a period of 3 years thereafter for all laborers and mechanics working at the site of the work.

Such records must contain the name, address, and social security number of each such worker, his or her correct classification, hourly rates of wages paid (including rates of contributions or costs anticipated for bona fide fringe benefits or cash equivalents thereof of the types described in 40 U.S.C. 3141(2)(B) (Construction Wage Rate Requirement statute)), daily and weekly number of hours worked, deductions made, and actual wages paid.

Whenever the Secretary of Labor has found, under paragraph (d) of the clause entitled Construction Wage Rate Requirements, that the wages of any laborer or mechanic include the amount of any costs reasonably anticipated in providing benefits under a plan or program described in 40 U.S.C. 3141(2)(B), the Contractor must maintain records which show that the commitment to provide such benefits is enforceable, that the plan or program is financially responsible, and that the plan or program has been communicated in writing to the laborers or mechanics affected, and records which show the costs anticipated or the actual cost incurred in providing such benefits. Contractors employing apprentices or trainees under approved programs must maintain written evidence of the registration of apprenticeship programs and certification of trainee programs, the registration of the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs.

(b) (1) The Contractor must submit weekly for each week in which any contract work is performed a copy of all payrolls to the Contracting Officer. The payrolls submitted must set out accurately and completely all of the information required to be maintained under paragraph (a) of this clause, except that full social security numbers and home addresses must not be included on weekly transmittals.

Instead the payrolls must only need to include an individually identifying number for each employee (e.g., the last four digits of the employee’s social security number).

The required weekly payroll information may be submitted in any form desired. Optional Form WH-347 is available for this purpose and may be obtained from the U.S. Department of Labor Wage and Hour Division website at https://www.dol.gov/agencies/whd/forms.

http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title40-section3141(2)(B)&num=0&edition=prelim http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title40-section3141(2)(B)&num=0&edition=prelim https://www.dol.gov/whd/forms/wh347.pdf https://www.dol.gov/agencies/whd/forms

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 16

The Prime Contractor is responsible for the submission of copies of payrolls by all subcontractors.

Contractors and subcontractors must maintain the full social security number and current address of each covered worker, and must provide them upon request to the Contracting Officer, the Contractor, or the Wage and Hour Division of the Department of Labor for purposes of an investigation or audit of compliance with prevailing wage requirements. It is not a violation of this section for a Prime Contractor to require a subcontractor to provide addresses and social security numbers to the Prime Contractor for its own records, without weekly submission to the Contracting Officer.

(2) Each payroll submitted must be accompanied by a "Statement of Compliance," signed by the Contractor or subcontractor or his or her agent who pays or supervises the payment of the persons employed under the contract and must certify-

(i) That the payroll for the payroll period contains the information required to be maintained under paragraph (a) of this clause and that such information is correct and complete;

(ii) That each laborer or mechanic (including each helper, apprentice, and trainee) employed on the contract during the payroll period has been paid the full weekly wages earned, without rebate, either directly or indirectly, and that no deductions have been made either directly or indirectly from the full wages earned, other than permissible deductions as set forth in the Regulations, 29 CFR Part 3; and

(iii) That each laborer or mechanic has been paid not less than the applicable wage rates and fringe benefits or cash equivalents for the classification of work performed, as specified in the applicable wage determination incorporated into the contract.

(3) The weekly submission of a properly executed certification set forth on the reverse side of Optional Form WH-347 must satisfy the requirement for submission of the "Statement of Compliance" required by subparagraph (b)(2) of this clause.

(4) The falsification of any of the certifications in this clause may subject the Contractor or subcontractor to civil or criminal prosecution under Section 1001 of Title 18 and Section 3729 of Title 31 of the United States Code.

(c) The Contractor or subcontractor must make the records required under paragraph (a) of this clause available for inspection, copying, or transcription by the Contracting Officer or authorized representatives of the Contracting Officer or the Department of Labor. The Contractor or subcontractor must permit the Contracting Officer or representatives of the Contracting Officer or the Department of Labor to interview employees during working hours on the job. If the Contractor or subcontractor fails to submit required records or to make them available, the Contracting Officer may, after written notice to the Contractor, take such action as may be necessary to cause the suspension of any further payment. Furthermore, failure to submit the required records upon request or to make such records available may be grounds for debarment action pursuant to 29 CFR 5.12.

I.4 52.222-55 Minimum Wages for Contractor Workers under Executive Order 14026 (DEVIATION) (Oct 2023)

(a) Definitions. As used in this clause— United States means the 50 states, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, and the outer Continental Shelf as defined in the Outer Continental Shelf Lands Act (43 U.S.C. 1331, et seq.).

Worker –

(1) (i) Means any person engaged in performing work on, or in connection with, a contract covered by Executive Order 14026, and–

(A) Whose wages under such contract are governed by the Fair Labor Standards Act (29 U.S.C. chapter 8), the Service Contract Labor Standards statute (41 U.S.C. chapter 67), or the Wage Rate Requirements (Construction) statute (40 U.S.C. chapter 31, subchapter

IV);

https://www.dol.gov/whd/forms/wh347.pdf

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 17

(B) Other than individuals employed in a bona fide executive, administrative, or professional capacity, as those terms are defined in 29 CFR part 541; and

(C) Regardless of the contractual relationship alleged to exist between the individual and the employer.

(ii) Includes workers performing on, or in connection with, the contract whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c).

(iii) Also includes any person working on, or in connection with, the contract and individually registered in a bona fide apprenticeship or training program registered with the Department of Labor’s Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship.

(2) (i) A worker performs on a contract if the worker directly performs the specific services called for by the contract; and

(ii) A worker performs in connection with a contract if the worker's work activities are necessary to the performance of a contract but are not the specific services called for by the contract.

(b) Executive Order Minimum wage rate.

(1) The Contractor shall pay to workers, while performing in the United States, and performing on, or in connection with, this contract, a minimum hourly wage rate of $15.00 per hour beginning January 30, 2022.

(2) The Contractor shall adjust the minimum wage paid, if necessary, beginning January 1, 2023, and annually thereafter, to meet the applicable annual E.O. minimum wage. The Administrator of the Department of Labor’s Wage and Hour Division (the Administrator) will publish annual determinations in the Federal Register no later than 90 days before the effective date of the new E.O. minimum wage rate.

The Administrator will also publish the applicable E.O. minimum wage on https://www.sam.gov (or any successor website), and a general notice on all wage determinations issued under the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, that will provide information on the E.O. minimum wage and how to obtain annual updates. The applicable published E.O. minimum wage is incorporated by reference into this contract.

(3) (i) The Contractor may request a price adjustment only after the effective date of the new annual E.O. minimum wage determination. Prices will be adjusted only for increased labor costs (including subcontractor labor costs) as a result of an increase in the annual E.O. minimum wage, and for associated labor costs (including those for subcontractors).

Associated labor costs shall include increases or decreases that result from changes in social security and unemployment taxes and workers’ compensation insurance, but will not otherwise include any amount for general and administrative costs, overhead, or profit.

(ii) Subcontractors may be entitled to adjustments due to the new minimum wage, pursuant to paragraph (b)(2). Contractors shall consider any subcontractor requests for such price adjustment.

(iii) The Contracting Officer will not adjust the contract price under this clause for any costs other than those identified in paragraph (b)(3)(i) of this clause, and will not provide duplicate price adjustments with any price adjustment under clauses implementing the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute.

(4) The Contractor warrants that the prices in this contract do not include allowance for any contingency to cover increased costs for which adjustment is provided under this clause.

(5) A pay period under this clause may not be longer than semi-monthly, but may be shorter to comply with any applicable law or other requirement under this contract establishing a shorter pay period. Workers shall be paid no later than one pay period following the end of the regular pay period in which such wages were earned or accrued.

(6) The Contractor shall pay, unconditionally to each worker, all wages due free and clear without subsequent rebate or kickback.

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 18

The Contractor may make deductions that reduce a worker’s wages below the E.O. minimum wage rate only if done in accordance with 29 CFR 23.230, Deductions.

(7) The Contractor shall not discharge any part of its minimum wage obligation under this clause by furnishing fringe benefits or, with respect to workers whose wages are governed by the Service Contract Labor Standards statute, the cash equivalent thereof.

(8) Nothing in this clause shall excuse the Contractor from compliance with any applicable Federal or State prevailing wage law or any applicable law or municipal ordinance or any applicable contract establishing a minimum wage higher than the E.O. 14026 minimum wage. However, wage increases under such other laws or municipal ordinances are not subject to price adjustment under this subpart.

(9) The Contractor shall pay the E.O. minimum wage rate whenever it is higher than any applicable collective bargaining agreement(s) wage rate.

(10) The Contractor shall follow the policies and procedures in 29 CFR 23.240(b) and 23.280 for treatment of workers engaged in an occupation in which they customarily and regularly receive more than $30 a month in tips.

(c) (1) This clause applies to workers as defined in paragraph (a). As provided in that definition–

(i) Workers are covered regardless of the contractual relationship alleged to exist between the contractor or subcontractor and the worker;

(ii) Workers with disabilities whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(c) are covered; and

(iii) Workers who are registered in a bona fide apprenticeship program or training program registered with the Department of Labor’s Employment and Training Administration, Office of Apprenticeship, or with a State Apprenticeship Agency recognized by the Office of Apprenticeship, are covered.

(2) This clause does not apply to–

(i) Contracts or subcontracts to which the States of Texas, Louisiana, or Mississippi, including their agencies, are a party;

(ii) Fair Labor Standards Act (FLSA)-covered individuals performing in connection with contracts covered by the E.O., i.e. those individuals who perform duties necessary to the performance of the contract, but who are not directly engaged in performing the specific work called for by the contract, and who spend less than 20 percent of their hours worked in a particular workweek performing in connection with such contracts;

(iii) Individuals exempted from the minimum wage requirements of the FLSA under 29 U.S.C.

213(a) and 214(a) and (b), unless otherwise covered by the Service Contract Labor Standards statute, or the Wage Rate Requirements (Construction) statute. These individuals include but are not limited to-

(A) Learners, apprentices, or messengers whose wages are calculated pursuant to special certificates issued under 29 U.S.C. 214(a);

(B) Students whose wages are calculated pursuant to special certificates issued under 29 U.S.C.

214(b); and

(C) Those employed in a bona fide executive, administrative, or professional capacity (29 U.S.C.

213(a)(1) and 29 CFR part 541).

(d) Notice. The Contractor shall notify all workers performing work on, or in connection with, this contract of the applicable E.O. minimum wage rate under this clause. With respect to workers covered by the Service Contract Labor Standards statute or the Wage Rate Requirements (Construction) statute, the Contractor may meet this requirement by posting, in a prominent and accessible place at the worksite, the applicable wage determination under those statutes. With respect to workers whose wages are governed by the FLSA, the Contractor shall post notice, utilizing the poster provided by the Administrator, which can be obtained at www.dol.gov/agencies/whd/government-contracts, in a prominent and accessible place at the worksite.

PROJECT DESCRIPTION: Cauldron Linn Recreation Site Improvements Page 19

Contractors that customarily post notices to workers electronically may post the notice electronically provided the electronic posting is displayed prominently on any Web site that is maintained by the contractor, whether external or internal, and customarily used for notices to workers about terms and conditions of employment.

(e) Payroll Records.

(1) The Contractor shall make and maintain records, for three years after completion of the work, containing the following information for each worker:

(i) Name, address, and social security number;

(ii) The worker’s occupation(s) or classification(s);

(iii) The rate or rates of wages paid;

(iv) The number of daily and weekly hours worked by each worker; (v) Any deductions made;

and

(vi) Total wages paid.

(2) The Contractor shall make records pursuant to paragraph (e)(1) of this clause available for inspection and transcription by authorized representatives of the Administrator. The Contractor shall also make such records available upon request of the Contracting Officer.

(3) The Contractor shall make a copy of the contract available, as applicable, for inspection or transcription by authorized representatives of the Administrator.

(4) Failure to comply with this paragraph (e) shall be a violation of 29 CFR 23.260 and this contract.

Upon direction of the Administrator or upon the Contracting Officer's own action, payment shall be withheld until such time as the noncompliance is corrected.

(5) Nothing in this clause limits or otherwise modifies the Contractor’s payroll and recordkeeping obligations, if any, under the Service Contract Labor Standards statute, the Wage Rate Requirements (Construction) statute, the Fair Labor Standards Act, or any other applicable law.

(f) Access. The Contractor shall permit authorized representatives of the Administrator to conduct investigations, including interviewing workers at…