Sol_140L2623R0005.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040607910

BLM ID-STATE OFC HR&ADM SVC (ID953)

1387 S. VINNELL WAY

BOISE ID 83709

LDA

Patricia Fort 2083733910

1x 04/11/2023

140L2623R0005

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

WILSON LAKE SITE IMPROVEMENTS: The Bureau of Land Management (BLM) intends to issue a single, firm fixed-price contract. The Work consists of: Redevelopment of the

Wilson Lake Campground including improvements to campsites, restrooms, kiosks, roadways, parking, and new shade structures.

11. The Contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 210 calendar days and complete it within ________________ ________________ calendar days after receiving

Section F

05/03/2023

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 8/2014)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

BLM ID STATE OFC HR&ADMN (ID953)

1387 S. VINNELL WAY

BOISE ID 83709

LDA

Patricia Fort

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 3304(a)

STANDARD FORM 1442 (REV. 8/2014) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 61

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140L2623R0005

Delivery: 12/29/2023

Delivery Location Code: 0004276369

BLM-ID BURLEY FIELD OFFICE

15 EAST 200 SOUTH

BURLEY ID 83318-9501 US

Period of Performance: 06/01/2023 to 12/29/2023

00010 Wilson Lake Site Improvements

Product/Service Code: Y1PA

Product/Service Description: CONSTRUCTION OF

RECREATION FACILITIES (NON-BUILDING)

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

SOLICITATION NO: 140L2623R0005

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 4

Type of Contract: Construction, Firm-Fixed Price (FFP), Single Award Contract County: Twin Falls County, Idaho Type of Construction: Heavy

Magnitude: Between $250,000 and $500,000 NAICS: 237990 Size Standard: $45.0 Million Set-Aside: Total Small Business

Bureau of Land Management Contracting Officer’s Representative (COR) Contracting Officer

Name: Eddie Sanchez Patricia A. Fort

Email: hsanchez@blm.gov pfort@blm.gov

Site Visit: See Section L.8

Questions Due Date: Wednesday, April 26, 2023, at 10:00 am MT

Proposal Due Date: Wednesday, May 3, 2023, at 10:00 am MT

Award Selection Process: Lowest Price Technically Acceptable mailto:hsanchez@blm.gov mailto:pfort@blm.gov

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 5

TABLE OF CONTENTS

Part I - The Schedule

Section A - Solicitation/Contract Form See Standard Form 1442

Section B - Bid Schedule 6

Section C - Specifications/Drawings 8

Section D - Packaging and Marking 9

Section E - Inspection and Acceptance 10

Section F - Deliveries or Performance 11

Section G - Contract Administration Data 13

Section H - Special Contract Requirements 15

Part II - Contract Clauses

Section I - Contract Clauses 18

Part III - List of Documents, Exhibits, and Other Attachments

Section J - List of Attachments 37

Part IV - Representations and Instructions

Section K - Representations, Certifications, and Other Statements of Offerors 43

Section L - Instructions, Conditions and Notices to Offerors 50

Section M - Evaluation Factors for Award 59

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 6

SECTION B: BID SCHEDULE

Offerors are to complete Blocks 14 - 20 of the SF-1442.

Wilson Lake Site Improvements

Base Bid Items

Estimated Pay Item No. Pay Description Quantity Unit Unit Cost Total

Bid Item 1 Mobilization 1 LS ---- $___________

Bid Item 2 Construction Staking 1 LS ---- $___________

Bid Item 3 Earthwork 1 LS ---- $___________

Bid Item 4 Rock Excavation 120 CY $_________ $___________

Bid Item 5 Boulder Placement 79 EA $_________ $___________

Bid Item 10 Fire Ring Installation 8 EA $_________ $___________

Total Base $___________

Additive 1 Bid Items

Estimated Pay Item No. Pay Description Quantity Unit Unit Cost Total

Bid Item 6 Concrete 12 CY $_________ $___________

Bid Item 7 Pavement Markings 1 LS ---- $___________

Bid Item 8 Vault Toilet 1 LS ---- $___________

Total Additive 1 $___________

Additive 2 Bid Items

Estimated Pay Item No. Pay Description Quantity Unit Unit Cost Total

Bid Item 6 Concrete 12 CY $_________ $___________

Bid Item 7 Pavement Markings 1 LS ---- $___________

Bid Item 11 Kiosk And Signs 1 LS ---- $___________

Total Additive 2 $___________

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 7

Additive 3 Bid Items

Estimated Pay Item No. Pay Description Quantity Unit Unit Cost Total

Bid Item 6 Concrete 19.32 CY $_________ $___________

Bid Item 7 Pavement Markings 1 LS ---- $___________

Bid Item 9 Steel Shelters 2 EA $_________ $___________

Total Additive 3 $___________

Additive 4 Bid Items

Estimated Pay Item No. Pay Description Quantity Unit Unit Cost Total

Bid Item 6 Concrete 13.82 CY $_________ $___________

Bid Item 7 Pavement Markings 1 LS ---- $___________

Bid Item 12 Transport and Install 1 EA ---- $___________ Vault Toilet

Total Additive 4 $___________

Grand Total (Base + Additives) $___________

PERFORMANCE TIME: 210 days Calendar Days from issuance of Notice to Proceed

Award of any additive is dependent upon available funding and all additives are listed in order of priority. If an additive item is unaffordable, the government will consider the next most important additive for award.

Total price will be evaluated for each offeror in consideration of the same combination of base and additive items.

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 8

SECTION C: SPECIFICATIONS/DRAWINGS

See Section J for additional attachments to include project specifications and drawings.

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 9

SECTION D: PACKAGING AND MARKING

Packaging and marking of deliverables shall be IAW the Contractor’s standard commercial practices.

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 10

SECTION E: INSPECTION AND ACCEPTANCE

E.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.246-12 Inspection of Construction August 1996 52.246-13 Inspection -- Dismantling, Demolition, or Removal of Improvements August 1996

E.2 Final Inspection and Acceptance

Final completion of the punch list items, submission of all required submittals, and final cleanup of the project site shall be completed before the contract’s required completion date. The Contracting Officer or his/her designated representative will perform final inspection. Acceptance of the work will occur only upon written notice of acceptance by the ordering Contracting Officer, or any other Warranted Contracting Officer employed by the Bureau of Land Management (BLM) and performing authorized duties in conjunction with this contract. The contracts required completion date is 210 calendar days after receipt of the notice to proceed.

https://www.acquisition.gov/browse/index/far#

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 11

SECTION F: DELIVERIES OR PERFORMANCE

F.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.211-13 Time Extensions September 2000 52.211-18 Variation in Estimated Quantity April 1984 52.236-11 Use and Possession Prior to Completion April 1984

F.2 52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 210 calendar days after receipt of Notice to Proceed. *The time stated for completion shall include final cleanup of the premises.

*The Government recognizes that seasonal climatic conditions may occur that restrict or prohibit normal construction activities. The anticipated length of the seasonal delay for this project is 0 days. This number of days has been included in calculating the stated period of performance. Therefore, the contract period of performance will not be extended due to normal seasonal weather delays.

F.3 52.211-12 Liquidated Damages--Construction (Apr 1984)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $700 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

F.4 52.236-15 Schedules for Construction Contracts (Apr 1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 12

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

F.5 Simultaneous Performance

If a Contractor receives award of more than one contract, simultaneous performance will be required. All work must be completed within the timeframe allowed for each contract.

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 13

SECTION G: CONTRACT ADMINISTRATION DATA

G.1 Authorities and Delegations (Sep 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

G.2 Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (Apr 2013)

Payment requests must be submitted electronically through the U.S. Department of the Treasury's Internet Payment Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions- Commercial Items included in commercial item contracts. The IPP website address is https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Invoice date and Government Contract Number http://www.ipp.gov/

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 14

2. Billing period specified with beginning and ending dates. The beginning date must not be later than the completion date or within any previous billing dates.

3. The accounting must follow the approved schedule of values as described in the specification attachment.

4. Total amount due for the billing period

5. Certification of Progress Payment

6. Payrolls (Mail weekly)

7. Substantiation of Subcontractor Payment

8. 52.223-9 Certification with final payment request.

9. A Release of Claims (See 1452.204-70) with a request for final payment.

The Contractor must use the IPP website to register, access and use IPP for submitting requests for payment.

The Contractor Government Business Point of Contact will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

G.3 Local Internet Payment Platform (IPP) Hotline

To check payment status, contact the Payment Hotline at 877-480-9724 or 303-236-2850. You will need to leave a message with the following information:

1. Company Name

2. Contract Number

3. Invoice Number

4. Invoice Amount

5. A brief description of why you are calling

6. Your contact information

If you do not receive a callback from the Payment Hotline within 72 hours, please contact the Contracting Officer with the day and time you contacted the Payment Hotline.

G.4 Government Point of Contact

Patricia A. Fort, Contracting Officer pfort@blm.gov Bureau of Land Management 1387 S. Vinnell Way Boise, ID 83709-1657 Telephone: (208) 373-3910 mailto:ippgroup@bos.frb.org mailto:pfort@blm.gov

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 15

SECTION H: SPECIAL CONTRACT REQUIREMENTS

H.1 Work Hours

The performance period established for this contract is based upon all work being conducted during regular working hours between 7:00 am and 5:00 pm, Monday through Friday, excluding government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and government holidays, a request must be submitted to the Contracting Officer in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection.

In addition to any holidays declared by Executive Orders, the following Federal Legal Holidays are observed:

New Year’s Day, Martin Luther King Jr. Day, President’s Day, Memorial Day, Juneteenth, Independence Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day, Christmas Day

H.2 Communications

“Time” for communications received after 3:00 pm, after 12:00 pm locally on Fridays, or after 12:00 pm locally prior to a holiday will not start until the next business day. All times are local Mountain time.

H.3 Fire Danger Season

If the Contracting Officer Representative (COR) allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

H.4 Drawings

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full-size drawings may contact the Contracting Officer identified in the solicitation.

H.5 Preservation of Historical and Archeological Data

(a) The Historic and Archeological Data Preservation Act of 1974 provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings. No objects of cultural resource value may be removed.

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 16

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The Contractor will be responsible for protecting the cultural resources within the effected area from damage.

In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting Officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

(e) The Contractor agrees to insert this paragraph in all subcontracts that involve the performance of work on the terrain of the site.

H.6 Safety and Quality Control Plan

Following contract award, the contractor must provide effective quality assurance and safety plans for acceptance by the Government.

H.7 Limitations on Subcontracting Reporting

In accordance with 52.219-14 Limitations on Subcontracting, the prime contractor must perform at least 15% of the cost of the contract, excluding the cost of materials with its own employees and employees of a similarly situated subcontractor. A similarly situated subcontractor is a small business concern subcontractor that is a participant of the same SBA program that qualified the prime contractor as an eligible offeror and awardee of the contract. The contractor is responsible for ensuring compliance with the Limitation on Subcontracting.

At the conclusion of the period of performance and prior to final payment, the contractor shall submit a Limitation on Subcontracting Report directly to the Contracting Officer. The following information is required as part of the report:

1) the total amount paid to the Prime during the performance period broken out by labor and materials 2) list of Similarly Situated Subcontractors and the amounts paid to each during the performance period broken out by labor and materials 3) list of any other subcontractors and the amounts paid to each during the performance period broken out by labor and materials.

If the Contracting Officer review of the report finds that the contractor is not in compliance for the period of performance, the contractor will be notified in writing. Penalties for failure to comply are described in 13 CFR 125.6(h) which states: Whoever violates the requirements set forth in paragraph (a) of this section shall be subject to the penalties prescribed in 15 U.S.C. 645(d), except that the fine shall be treated as the greater of $500,000 or the dollar amount spent, in excess of permitted levels, by the entity on subcontractors. A party's failure to comply with the spirit and intent of a subcontract with a similarly situated entity may be considered a basis for debarment on the grounds, including but not limited to, that the parties have violated the terms of a Government contract or subcontract pursuant to FAR 9.406-2(b)(1)(i) (48 CFR 9.406-2(b)(1)(i)).

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 17

H.8 Environmental Impact

All waste materials generated by any work under the contract performed on a Government installation shall at all times be handled, transported, stored, and disposed of by the contractor and by his subcontractors in accordance with all applicable Federal, state, and local laws, ordinances, regulations, court orders, and other types of rulings having the effect of the law, including, but not limited to Executive Order 12088, 13 October 1978, Federal Compliance with Pollution Control Standards; the Federal Water Pollution Control Act, as amended (33 U.S.C. 1251 ET SEQ); the Clean Air Act as amended (42 U.S.C. Sec 7401 ET SEQ); the Endangered Species Act, as amended (16 U.S.C. Sec 1531, ET SEQ); the Toxic Substances Control Act, as amended (15 U.S.C. Sec 2601, ET SEQ); the National Historic Preservation Act, as amended (16 U.S.C. Sec 470, ET SEQ); the Solid Waste Disposal Act, as amended (42 U.S.C.

6901 ET SEQ); and the Archaeological and Historic Preservation Act, as amended (16 U.S.C. Sec 469, ET SEQ).

Should the United States Government be held liable for any neglect or improper actions by the contractor or any subcontractor regarding removal or disposal of any hazardous waste, the contractor shall reimburse the Government for all such liability.

H.9 Hazardous Materials

Any material suspected of being hazardous that is encountered during performance of a project shall immediately be brought to the attention of the Contracting Officer, at which time a determination will be made as to whether hazardous material testing shall be performed. If the Contracting Officer directs the contractor to perform tests, and/ or the material is found to be of a hazardous nature requiring additional protective measures, a contract modification may be required, subject to equitable adjustment under the terms of the contract. The contractor is advised that friable and/or non-friable asbestos-containing material may be encountered in project areas.

Friable asbestos-containing material is any material that contains more than one percent asbestos by weight, and that hand pressure can crumble, pulverize or reduce to powder when dry. Non-friable asbestos containing materials are materials in which asbestos fibers are bound by a matrix material, saturation, impregnation or coating.

Non-friable asbestos-containing materials do not normally release airborne asbestos fiber during routine handling and end-use. However, excessive fiber concentrations may be produced during uncontrolled abrading, sanding, drilling, cutting, machining, removal, demolition, or other similar activities. 29 CFR 1910.1001 shall be referenced in the event asbestos-containing materials are encountered. Friable asbestos-containing materials are not authorized for use in new construction or maintenance projects.

H.10 Unauthorized Personnel

The contractor shall inform all personnel working under his jurisdiction (including subcontractor and visiting supplier personnel) that access to areas outside of the immediate work area; excluding direct haul and access routes, contracting and Civil Engineering offices and points of supply and storage; is prohibited. Circulation of said personnel will be limited to official business only. Persons in violation of the above will be apprehended and appropriately disciplined.

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 18

PART II - CONTRACT CLAUSES

SECTION I: CONTRACT CLAUSES

I.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.202-1 Definitions June 2020 52.203-3 Gratuities April 1984 52.203-5 Covenant Against Contingent Fees May 2014 52.203-6 Restrictions on Subcontractor Sales to the Government June 2020 52.203-7 Anti-Kickback Procedures June 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity May 2014

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity May 2014 52.203-12 Limitation on Payments to Influence Certain Federal Transactions June 2020 52.203-17 Contractor Employee Whistleblower Rights and Requirement to

Inform Employees of Whistleblower Rights June 2020

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

January 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

May 2011

52-204.9 Personal Verification Contractor Personnel January 2011 52.204-10 Reporting Executive Compensation and First-Tier Subcontract

Awards June 2020

52.204-13 System for Award Management Maintenance October 2018 52.204-14 Service Contract Reporting Requirements October 2016 52.204-18 Commercial and Government Entity Code Maintenance August 2020 52.204-19 Incorporation by Reference of Representations and Certifications December 2014 52.204-23 Prohibition on Contracting for Hardware, Software, and Services

Developed or Provided by Kaspersky Lab and Other Covered Entities November 2021

52.209-6 Protecting the Government's Interest when Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment

November 2021

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations November 2015 52.215-2 Audit and Records-Negotiated June 2020 52.215-8 Order of Precedence-Uniform Contract Format October 1997 52.219-6 Notice of Total Small Business Set Aside November 2020 52.219-8 Utilization of Small Business Concerns November 2016 52.219-14 Limitations on Subcontracting October 2022 52.219-28 Post-Award Small Business Program Rerepresentation October 2022 52.222-1 Notice to the Government of Labor Disputes March 2020 52.222-3 Convict Labor June 2003 52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation May 2018

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 19

52.222-9 Apprentices and Trainees July 2005 52.222-10 Compliance with Copeland Act Requirements February 1988 52.222-11 Subcontracts (Labor Standards) July 2005 52.222-12 Contract Termination-Debarment February 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations. February 1988 52.222-14 Disputes Concerning Labor Standards February 1988 52.222-15 Certification of Eligibility February 1988 52.222-26 Equal Opportunity September 2016 52.222-27 Affirmative Action Compliance Requirements for Construction April 2015 52.222-40 Notification of Employee Rights under the National Labor Relations

Act December 2010

52.222-50 Combating Trafficking in Persons October 2020 52.222-54 Employment Eligibility Verification May 2022 52.222-55 Minimum Wages For Contractor Workers Under Executive Order

14026 January 2022

52.222-62 Paid Sick Leave under Executive Order 13706 January 2022 52.223-3 Alt I Hazardous Material Identification and Material Safety Data -

Alternate I July 1995

52.223-6 Drug Free Workplace May 2001 52.225-13 Restrictions on Certain Foreign Purchases February 2021 52.227-1 Authorization and Consent December 2007 52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement June 2020 52.227-4 Patent Indemnity - Construction Contracts December 2007 52.228-11 Individual Surety--Pledge of Assets February 2021 52.228-12 Prospective Subcontractor Requests for Bonds December 2022 52.228-14 Irrevocable Letter of Credit November 2014 52.229-3 Federal, State and Local Taxes April 2003 52.232-5 Payments under Fixed-Price Construction Contracts September 2002 52.232-16 Alt I Progress Payments - Alternate I November 2021 52.232-17 Interest May 2014 52.232-23 Assignment of Claims May 2014 52.232-27 Prompt Payment for Construction Contracts January 2017 52.232-39 Unenforceability of Unauthorized Obligations June 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors March 2023 52.233-1 Alt I Disputes - Alternate I December 1991 52.233-3 Protest After Award August 1996 52.233-4 Applicable Law for Breach of Contract Claim October 2004 52.236-5 Material and Workmanship April 1984 52.236-6 Superintendence by the Contractor April 1984 52.236-8 Other Contracts April 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements April 1984

52.236-10 Operations and Storage Areas April 1984 52.236-11 Use and Possession Prior to Completion April 1984 52.236-12 Cleaning Up April 1984 52.236-13 Accident Prevention November 1991 52.236-14 Availability and Use of Utility Services April 1984 52.236-17 Layout of Work April 1984

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 20

52.242-13 Bankruptcy July 1995 52.243-4 Changes June 2007 52.244-6 Subcontracts for Commercial Products and Commercial Services March 2023 52.245-1 Government Property September 2021 52.245-9 Use and Charges August 2010 52.248-3 Value Engineering-Construction - Alternate I April 1984 52.246-21 Warranty of Construction March 1994 52.249-2 Alt I Termination for Convenience of the Government (Fixed-Price) -

Alternate I April 2012

52.249-3 Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements)

April 2012

52.249-10 Default (Fixed-Price Construction) April 1984 DIAR 1452.236-70 Prohibition Against Use of Lead-Based Paint - Department of the

Interior July 1996

DIAR 1452.237-70 Information Collection - Department of the Interior July 1996

I.2 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021)

(a) Definitions. As used in this clause— Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet). Covered foreign country means The People’s Republic of China. Covered telecommunications equipment or services means–

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or (4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means–

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 21

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph

(c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub.

L.115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement. (1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause https://dibnet.dod.mil/

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 22

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial products or commercial services.

I.3 52.222-6 Construction Wage Rate Requirements (Aug 2018)

(a) Definition.—“Site of the work”— (1) Means—

(i) The primary site of the work. The physical place or places where the construction called for in the contract will remain when work on it is completed; and

(ii) The secondary site of the work, if any. Any other site where a significant portion of the building or work is constructed, provided that such site is—

(A) Located in the United States; and

(B) Established specifically for the performance of the contract or project;

(2) Except as provided in paragraph (3) of this definition, includes any fabrication plants, mobile factories, batch plants, borrow pits, job headquarters, tool yards, etc., provided—

(i) They are dedicated exclusively, or nearly so, to performance of the contract or project; and

(ii) They are adjacent or virtually adjacent to the “primary site of the work” as defined in paragraph (a)(1)(i), or the “secondary site of the work” as defined in paragraph (a)(1)(ii) of this definition;

(3) Does not include permanent home offices, branch plant establishments, fabrication plants, or tool yards of a Contractor or subcontractor whose locations and continuance in operation are determined wholly without regard to a particular Federal contract or project. In addition, fabrication plants, batch plants, borrow pits, job headquarters, yards, etc., of a commercial or material supplier which are established by a supplier of materials for the project before opening of bids and not on the Project site, are not included in the “site of the work.” Such permanent, previously established facilities are not a part of the “site of the work” even if the operations for a period of time may be dedicated exclusively or nearly so, to the performance of a contract.

(b)(1) All laborers and mechanics employed or working upon the site of the work will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, or as may be incorporated for a secondary site of the work, regardless of any contractual relationship which may be alleged to exist between the Contractor and such laborers and mechanics. Any wage determination incorporated for a secondary site of the work shall be effective from the first day on which work under the contract was performed at that site and shall be incorporated without any adjustment in contract price or estimated cost. Laborers employed by the construction Contractor or construction subcontractor that are transporting portions of the building or work between the secondary site of the work and the primary site of the work shall be paid in accordance with the wage determination applicable to the primary site of the work.

PROJECT DESCRIPTION: Wilson Lake Site Improvements Page 23

(2) Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Construction Wage Rate Requirements statute on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (e) of this clause; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such period.

(3) Such laborers and mechanics shall be paid not less than the appropriate wage rate and fringe benefits in the wage determination for the classification of work actually performed, without regard to skill, except as provided in the clause entitled Apprentices and Trainees.