Sol_140F0620R0002.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040467220

FWS, DIVISION OF CONTRACTING AND GE

LAKE PLAZA NORTH

134 UNION BOULEVARD

Lakewood CO 80228-1807

F06

FWS, DIVISION OF CONTRACTING AND GE

LAKE PLAZA NORTH

134 UNION BOULEVARD

LAKEWOOD, CO 80228-1807

Timothy Officer 303 236-4320

1x 05/05/2020

140F0620R0002

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

REPAIR TRAIL AND REPLACE OBSERVATION DECK AT BOWDOIN NATIONAL WILDLIFE REFUGE, MT

NAICS 237990 - OTHER HEAVY AND CIVIL ENGINEERING CONSTRUCTION

PROJECT MAGNITUDE: BETWEEN $100,000 AND $250,000

TECHNICAL/SPECIFICATIONS:

1. SPECIFICATIONS, 75 PAGES, NOVEMBER 2019

2. DRAWINGS, 8 PAGES, OCTOBER 31, 2019

3. INSTRUCTION TO OFFERORS, 3 PAGES

4. WAGE DETERMINATION, 5 PAGES, DATED JANUARY 3, 2020

5. PROJECT SUBMITTALS LIST, 1 PAGE

6. BID SCHEDULE, 1 PAGE

WORK UNDER THIS CONTRACT:

The contractor shall provide all equipment, labor, and materials to replace the observation deck and repair the trail at the Bowdoin National Wildlife Refuge, MT in accordance with the attached specifications and drawings.

Continued ...

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 100 calendar days and complete it within ________________ ________________ calendar days after receiving

FAR 52.211-10

06/12/2020

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

FWS, DIVISION OF CONTRACTING AND GE

LAKE PLAZA NORTH

134 UNION BOULEVARD

Lakewood CO 80228-1807

F06

Timothy Officer

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 52

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140F0620R0002

LOCATION AND INSPECTION OF THE SITE:

The project location is at the Bowdoin National

Wildlife Refuge, MT. The address is 194 Bowdoin

Auto Tour Road, Malta, MT 59538. Prospective bidders must contact the Project Leader, Neil

Shook, at 406-654-2863 ext. 1 or neil_shook@fws.gov to arrange for a site visit.

Failure of the contractor to ascertain the nature, location, and conditions which affect the work will not relieve the contractor from the responsibility for successfully performing the work without additional expense to the

Government. All questions regarding the subject requirement shall be submitted NLT 1500 MT on May

29, 2020 via email to the Contracting Officer at tim_officer@fws.gov. Please include the solicitation number, company name, address, telephone number, and contact name on any email correspondence.

PROSPECTIVE OFFERORS MUST BE REGISTERED WITH THE

SYSTEM OF AWARD MANAGEMENT AT:

www.sam.gov

Legacy Doc #: FWS

Delivery: 100 Days After Notice to Proceed

Delivery Location Code: 0008350089

FWS BOWDOIN NWR

194 BOWDOIN AUTO TOUR ROAD

MALTA MT 59538-9617 US

Period of Performance: 07/06/2020 to 10/14/2020

00010 REPLACE OBSERVATION DECK

The contractor shall provide all equipment, labor, and materials to replace the observation deck at the Bowdoin National Wildlife Refuge, MT in accordance with the attached specifications and drawings.

Product/Service Code: Y1PZ

Product/Service Description: CONSTRUCTION OF

OTHER NON-BUILDING FACILITIES

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 52

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140F0620R0002

00020 REPAIR TRAIL

The contractor shall provide all equipment, labor, and materials to repair the trail at the

Bowdoin National Wildlife Refuge, MT in accordance with the attached specifications and drawings.

Product/Service Code: Z2PZ

Product/Service Description: REPAIR OR ALTERATION

OF OTHER NON-BUILDING FACILITIES

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Document No.

RFP #140F0620R0002

Document Title

REPAIR TRAIL AND REPLACE OBSERVATION DECK AT

BOWDOIN NWR, MT

5 | P a g e

TABLE OF CONTENTS

A - Solicitation/Contract Form

B - Supplies or Services/Prices

C - Description/Specifications

E - Inspection and Acceptance

F - Deliveries or Performance

G - Contract Administration Data

I - Contract Clauses

J - List of Documents, Exhibits and Other Attachments

K - Representations, Certifications, and Other Statements of Bidders

L - Instructions,Conditions, and Notices to Bidders

M - Evaluation Factors For Award……………………………………………………………………

Document Title

6 | P a g e

A - Solicitation/Contract Form

See the SF 1442

B - Supplies or Services/Prices

The Bidding Schedule is attached (See Section J)

C - Description/Specifications

The Specifications and Drawings are attached (See Section J)

E - Inspection and Acceptance

52.246-12 Inspection of Construction (APR 1996)

(a) Definition.“Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not-

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this- section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

Document Title

7 | P a g e

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may-

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

52.246-21 Warranty of Construction (MAR 1994)

(a) In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph (i) of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

(b) This warranty shall continue for a period of 1 year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of 1 year from the date the Government takes possession.

(c) The Contractor shall remedy at the Contractor’s expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor’s expense any damage to Government-owned or controlled real or personal property, when that damage is the result of-

(1) The Contractor’s failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

(d) The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause.

The Contractor’s warranty with respect to work repaired or replaced will run for 1 year from the date of repair or replacement.

Document Title

8 | P a g e

(e) The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

(f) If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor’s expense.

(g) With respect to all warranties, express or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall-

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

(h) In the event the Contractor’s warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor’s, manufacturer’s, or supplier’s warranty.

(i) Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government-furnished material or design.

(j) This warranty shall not limit the Government’s rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud.

(End of clause)

F - Deliveries or Performance

52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the Notice To Proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 100 calendar days after the date the contractor receives the Notice To Proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 Liquidated Damages – Construction (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $239.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Document Title

9 | P a g e

(End of clause)

52.211-13 -- Time Extensions (SEP 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

G - Contract Administration Data

Prohibition on Text Messaging and Using Electronic Equipment Supplied by the Government while Driving (October 2009)

Executive Order 13513 , Federal Leadership On Reducing Text Messaging While Driving , was signed by President Barack Obama on October 1, 2009 (Ref: http://edocket.access.gpo.gov/2009/pdf/E9-24203.pdf).

This Executive Order introduces a Federal Government-wide prohibition on the use of text messaging while driving on official business or while using Government-supplied equipment. Additional guidance enforcing the ban will be issued at a later date. In the meantime, please adopt and enforce policies that immediately bans text messaging while driving company-owned or rented vehicles, government owned or leased vehicles, or while driving privately owned vehicles while on official government business or when performing any work for or on behalf of the government.

(End of DOI clause)

Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor.

To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is:

https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

A copy of the Invoice must be submitted to the Contracting Officer (CO) and the Contracting Officer’s Representative (COR) for approval, prior to submission into IPP.

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of local clause)

Document Title

10 | P a g e

1452.204-70 Release of Claims—Department of the Interior (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

1452.215-70 Examination of Records by the Department of the Interior (APR 1984)

For purposes of the Examination of Records by the Comptroller General clause of this contract (FAR 52.215–2(d)), the Secretary of the Interior, the Inspector General, and their duly authorized representative(s) from the Department of the Interior shall have the same access and examination rights as the Comptroller General of the United States.

I - Contract Clauses

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (OCT 2018)

52.204-13 System for Award Management Maintenance (OCT 2018)

52.204-16 Commercial and Government Entity Code Reporting (JUL 2016)

52.204-18 Commercial and Government Entity Code Maintenance (JUL 2016)

52.204-22 Alternative Line Item Proposal (JAN 2017)

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment (OCT 2015)

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations (NOV 2015)

52.211-6 Brand Name or Equal (Aug 1999)

52.211-18 Variation in Estimated Quantity (APR 1984)

52.215-1 Instructions to Offerors—Competitive Acquisition (JAN 2017)

52.215-8 Order of Precedence - Uniform Contract Format (OCT 1997)

52.219-8 Utilization of Small Business Concerns (OCT 2018)

52.219-14 Limitations on Subcontracting (JAN 2017)

52.222-3 Convict Labor (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation (MAY 2018)

52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work (MAY 2014)

52.222-6 Construction Wage Rate Requirements (AUG 2018)

52.222-7 Withholding of Funds (MAY 2014)

52.222-8 Payrolls and Basic Records (AUG 2018)

52.222-9 Apprentices and Trainees (JUL 2005)

52.222-10 Compliance with Copeland Act Requirements (FEB 1988)

Document Title

11 | P a g e

52.222-11 Subcontracts (Labor Standards) (MAY 2014)

52.222-12 Contract Termination - Debarment (MAY 2014)

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations (MAY 2014)

52.222-14 Disputes Concerning Labor Standards (FEB 1988)

52.222-15 Certification of Eligibility (MAY 2014)

52.222-21 Prohibition of Segregated Facilities (APR 2015)

52.222-22 Previous Contracts and Compliance Reports (FEB 1999)

52.222-26 Equal Opportunity (SEP 2016)

52.222-27 Affirmative Action Compliance Requirements for Construction (APR 2015)

52.222-36 Equal Opportunity for Workers with Disabilities (JUL 2014)

52.222-50 Combating Trafficking in Persons (MAR 2019)

52.222-55 Minimum Wages under Executive Order 13658 (DEC 2015)

52.222-62 Paid Sick Leave Under Executive Order 13706 (JAN 2017)

52.223-1 Biobased Product Certification (MAY 2012)

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

(SEP 2013)

52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997)

52.223-5 Pollution Prevention and Right-to-Know Information (MAY 2011)

52.223-6 Drug-Free Workplace (MAY 2001)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011)

52.224-1 Privacy Act Notification (APR 1984)

52.224-2 Privacy Act (APR 1984)

52.225-13 Restrictions on Certain Foreign Purchases (JUN 2008)

52.227-1 Authorization and Consent (Dec 2007)

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (Dec 2007)

52.227-4 Patent Indemnity—Construction Contracts (Dec 2007)

52.228-2 Additional Bond Security (OCT 1997)

52.228-5 Insurance - Work on a Government Installation (JAN 1997)

52.228-11 Pledges of Assets (AUG 2018)

Document Title

12 | P a g e

52.228-12 Prospective Subcontractor Requests for Bonds (MAY 2014)

52.229-3 Federal, State, and Local Taxes (FEB 2013)

52.232-17 Interest (MAY 2014)

52.232-23 Assignment of Claims (MAY 2014)

52.232-27 Prompt Payment for Construction Contracts (JAN 2017)

52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors (DEC 2013)

52.233-1 Disputes (MAY 2014)

52.233-3 Protest after Award (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim (OCT 2004)

52.242-13 Bankruptcy (JUL 1995)

52.242-14 Suspension of Work (APR 1984)

52.243-5 Changes and Changed Conditions (APR 1984)

52.248-3 Value Engineering - Construction (OCT 2015)

52.249-2 Termination for Convenience of the Government (Fixed-Price) (APR 2012) - Alternate I

(SEP 1996)

52.249-10 Default (Fixed-Price Construction). (APR 1984)

52.252-5 Authorized Deviations in Provisions (APR 1984)

52.253-1 Computer Generated Forms (JAN 1991)

52.219-28 Post-Award Small Business Program Re-representation (JUL 2013)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

Document Title

13 | P a g e

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall re-represent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall re-represent its size status in accordance with the size standard in effect at the time of this re-representation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following re-representation and submit it to the contracting office, along with the contract number and the date on which the re-representation was completed:

The Contractor represents that it ___ is, ___ is not a small business concern under NAICS Code [insert NAICS Code] assigned to contract number [insert contract number]. (Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

52.225-9 Buy American - Construction Materials (MAY 2014)

(a) Definitions. As used in this clause-

Commercially available off-the-shelf (COTS) item- (1) Means any item of supply (including construction material) that is-

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

Document Title

14 | P a g e

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means-

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means-

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if-

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which non-availability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference. (1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)).

The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

Document Title

15 | P a g e

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute or Balance of Payments Program.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Document Title

16 | P a g e

Foreign and Domestic Construction Materials Price Comparison

Construction Material Description

Unit of Measure Quantity Price

(Dollars)*

Item 1:

Foreign construction material ________ ________ ________

Domestic construction material ________ ________ ________

Item 2:

Foreign construction material ________ ________ ________

Domestic construction material ________ ________ ________

* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

(End of clause)

52.228-14 Irrevocable Letter of Credit (NOV 2014)

(a) “Irrevocable letter of credit” (ILC), as used in this clause, means a written commitment by a federally insured financial institution to pay all or part of a stated amount of money, until the expiration date of the letter, upon presentation by the Government (the beneficiary) of a written demand therefor. Neither the financial institution nor the offeror/Contractor can revoke or condition the letter of credit.

(b) If the offeror intends to use an ILC in lieu of a bid bond, or to secure other types of bonds such as performance and payment bonds, the letter of credit and letter of confirmation formats in paragraphs (e) and (f) of this clause shall be used.

(c) The letter of credit shall be irrevocable, shall require presentation of no document other than a written demand and the ILC (including confirming letter, if any), shall be issued/confirmed by an acceptable federally insured financial institution as provided in paragraph (d) of this clause, and—

(1) If used as a bid guarantee, the ILC shall expire no earlier than 60 days after the close of the bid acceptance period;

(2) If used as an alternative to corporate or individual sureties as security for a performance or payment bond, the offeror/Contractor may submit an ILC with an initial expiration date estimated to cover the entire period for which financial security is required or may submit an ILC with an initial expiration date that is a minimum period of one year from the date of issuance. The ILC shall provide that, unless the issuer provides the beneficiary written notice of non-renewal at least 60 days in advance of the current expiration date, the ILC is automatically extended without amendment for one year from the expiration date, or any future expiration date, until the period of required coverage is completed and the Contracting Officer

Document Title

17 | P a g e provides the financial institution with a written statement waiving the right to payment. The period of required coverage shall be:

(i) For contracts subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of—

(A) One year following the expected date of final payment;

(B) For performance bonds only, until completion of any warranty period; or

(C) For payment bonds only, until resolution of all claims filed against the payment bond during the one-year period following final payment.

(ii) For contracts not subject to 40 U.S.C. chapter 31, subchapter III, Bonds, the later of—

(A) 90 days following final payment; or

(B) For performance bonds only, until completion of any warranty period.

(d)(1) Only federally insured financial institutions rated investment grade by a commercial rating service shall issue or confirm the ILC.

(2) Unless the financial institution issuing the ILC had letter of credit business of at least $25 million in the past year, ILCs over $5 million must be confirmed by another acceptable financial institution that had letter of credit business of at least $25 million in the past year.

(3) The Offeror/Contractor shall provide the Contracting Officer a credit rating that indicates the financial institutions have the required credit rating as of the date of issuance of the ILC.

(4) The current rating for a financial institution is available through any of the following rating services registered with the U.S. Securities and Exchange Commission (SEC) as a Nationally Recognized Statistical Rating Organization (NRSRO). NRSRO’s can be located at the website http://www.sec.gov/answers/nrsro.htm maintained by the SEC.

(e) The following format shall be used by the issuing financial institution to create an ILC:

[Issuing Financial Institution’s Letterhead or Name and Address]

Issue Date __________

Irrevocable Letter of Credit No. _______________________

Account party’s name _______________________________

Account party’s address ______________________________

For Solicitation No. _________________ (for reference only) http://uscode.house.gov/ http://uscode.house.gov/ http://www.sec.gov/answers/nrsro.htm

Document Title

18 | P a g e

To: [U.S. Government agency]

[U.S. Government agency’s address]

1. We hereby establish this irrevocable and transferable Letter of Credit in your favor for one or more drawings up to United States $______. This Letter of Credit is payable at [issuing financial institution’s and, if any, confirming financial institution’s] office at [issuing financial institution’s address and, if any, confirming financial institution’s address] and expires with our close of business on ___________, or any automatically extended expiration date.

2. We hereby undertake to honor your or the transferee’s sight draft(s) drawn on the issuing or, if any, the confirming financial institution, for all or any part of this credit if presented with this Letter of Credit and confirmation, if any, at the office specified in paragraph 1 of this Letter of Credit on or before the expiration date or any automatically extended expiration date.

3. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this Letter of Credit that it is deemed to be automatically extended without amendment for one year from the expiration date hereof, or any future expiration date, unless at least 60 days prior to any expiration date, we notify you or the transferee by registered mail, or other receipted means of delivery, that we elect not to consider this Letter of Credit renewed for any such additional period. At the time we notify you, we also agree to notify the account party (and confirming financial institution, if any) by the same means of delivery.

4. This Letter of Credit is transferable. Transfers and assignments of proceeds are to be effected without charge to either the beneficiary or the transferee/assignee of proceeds. Such transfer or assignment shall be only at the written direction of the Government (the beneficiary) in a form satisfactory to the issuing financial institution and the confirming financial institution, if any.

5. This Letter of Credit is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, International Chamber of Commerce Publication No. _____________________ (Insert version in effect at the time of ILC issuance, e.g., “Publication 600, 2006 edition”) and to the extent not inconsistent therewith, to the laws of _____________________ [State of confirming financial institution, if any, otherwise State of issuing financial institution].

6. If this credit expires during an interruption of business of this financial institution as described in Article 17 of the UCP, the financial institution specifically agrees to effect payment if this credit is drawn against within 30 days after the resumption of our business.

Sincerely, [Issuing financial institution]

(f) The following format shall be used by the financial institution to confirm an ILC:

[Confirming Financial Institution’s Letterhead or Name and Address]

(Date) __________________

Document Title

19 | P a g e

Our Letter of Credit Advice Number ____________________

Beneficiary: _________________ [U.S. Government agency]

Issuing Financial Institution: __________________________

Issuing Financial Institution’s LC No.: __________________

Gentlemen:

1. We hereby confirm the above indicated Letter of Credit, the original of which is attached, issued by __________ [name of issuing financial institution] for drawings of up to United States dollars ___________/U.S. $_______ and expiring with our close of business on _____________ [the expiration date], or any automatically extended expiration date.

2. Draft(s) drawn under the Letter of Credit and this Confirmation are payable at our office located at

3. We hereby undertake to honor sight draft(s) drawn under and presented with the Letter of Credit and this Confirmation at our offices as specified herein.

4. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this confirmation that it be deemed automatically extended without amendment for one year from the expiration date hereof, or any automatically extended expiration date, unless:

(a) At least 60 days prior to any such expiration date, we shall notify the Contracting Officer, or the transferee and the issuing financial institution, by registered mail or other receipted means of delivery, that we elect not to consider this confirmation extended for any such additional period; or

(b) The issuing financial institution shall have exercised its right to notify you or the transferee, the account party, and ourselves, of its election not to extend the expiration date of the Letter of Credit.

5. This confirmation is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, International Chamber of Commerce Publication No. _____________________ (Insert version in effect at the time of ILC issuance, e.g., “Publication 600, 2006 edition”) and to the extent not inconsistent therewith, to the laws of _____________________ [State of confirming financial institution].

6. If this confirmation expires during an interruption of business of this financial institution as described in Article 17 of the UCP, we specifically agree to effect payment if this credit is drawn against within 30 days after the resumption of our business.

Sincerely, [Confirming financial institution]

(g) The following format shall be used by the Contracting Officer for a sight draft to draw on the Letter of Credit:

Sight Draft

Document Title

20 | P a g e

[City, State]

(Date) _____________________________ [Name and address of financial institution]

Pay to the order of ______________ [Beneficiary Agency] ___________ the sum of United States $____________. This draft is drawn under Irrevocable Letter of Credit No. _______________________.

[Beneficiary Agency] [By]

(End of clause)

52.228-15 Performance and Payment Bonds - Construction (OCT 2010)

(a) Definitions. As used in this clause -

"Original contract price" means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.

(b) Amount of required bonds. Unless the resulting contract price is $150,000 or less, the successful offeror shall furnish performance and payment bonds to the Contracting Officer as follows:

(1) Performance bonds (Standard Form 25). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bonds (Standard Form 25-A). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(3) Additional bond protection. (i) The Government may require additional performance and payment bond protection if the contract price is increased. The increase in protection generally will equal 100 percent of the increase in contract price.

(ii) The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(c) Furnishing executed bonds. The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within the time period specified in the Bid Guarantee provision of the solicitation, or otherwise specified by the Contracting Officer, but in any event, before starting work.

(d) Surety or other security for bonds. The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register or may be obtained from the U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6F01, Hyattsville, MD 20782. Or via the internet at http://www.fms.treas.gov/c570/.

(e) Notice of subcontractor waiver of protection (40 U.S.C. 3133(c)). Any waiver of the right to sue on the payment bond is void unless it is in writing, signed by the person whose right is waived, and executed after such person has first furnished labor or material for use in the performance of the contract.

Document Title

21 | P a g e

52.232-5 Payments Under Fixed-Price Construction Contracts (MAY 2014)

(a) Payment of price. The Government shall pay the Contractor the contract price as provided in this contract.

(b) Progress payments. The Government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the Contracting Officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the Contracting Officer.

(1) The Contractor's request for progress payments shall include the following substantiation:

(i) An itemization of the amounts requested, related to the various elements of work required by the contract covered by the payment requested.

(ii) A listing of the amount included for work performed by each subcontractor under the contract.

(iii) A listing of the total amount of each subcontract under the contract.

(iv) A listing…