SIR 6973GH-22-R-00160.pdf

SOLICITATION, OFFER

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder"

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED BID (RFP)

AC-22-00965

AAQ-731 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ0731-AFN

OKLAHOMA CITY OK 73125

Niamalika Glover 405-954-7831 x 69

PURCHASE REQUEST NO.

6973GH-22-R-00160

10. THE CONTRACT AUTHORITY REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

The Procurement is 100% Set-Aside for competition limited to Small Businesses.

(a) MMAC Site Specific Utility Drawings (NTS)Drawings 8 pages, MMAC Site Drawings

(8-1 /2” X 11” – NTS) 4 pages. See Attachment List for additional documents.

The Estimate Price Range: $500,000.00 and $1,000,000.00

The Line items listed on the SF30 (cover and continuations pages) are for Government use only. Please reference the Section B/Schedule B pricing of this instrument for the contract line items and additional information.

11. The Contractor shall begin performance within

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award notice to proceed. The performance period is mandatory, negotiable. (See ________________________________________________ .)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and is not required.is, B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers must be publicly opened at that time . Sealed envelopes containing offers shall be marked to show the offeror's name and address. The solicitation number, and the date and time offers are due.

D. Offers providing less than

12B. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in item 12B.)

15 365 calendar days and complete it within ________________ ________________ calendar days after receiving

1 1630

AMS Clause 3.2.2.3-71 Alt. I x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Contract Authority acceptance after the date offers are due will not be considered and will _________________ be rejected.

August 12, 2022

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Contract Authority in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13D. Failure to insert any number means the offeror accepts the minimum in item 13D.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (MUST BE FULLY COMPLETED BY OFFEROR)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Contract Authority)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Contract Authority solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE 31B. CONTRACT AUTHORITY 31C. AWARD DATE

BY

2PAGE OF

AAQ-731 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

AAQ731-AFN

OKLAHOMA CITY OK 73125

Niamalika R. Glover

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.)

Continued...

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 69

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

6973GH-22-R-00160

(A) (B) (C) (D) (E) (F)

00001 MMAC Irrigation Plan

WO#21-008412

Electronic & IT: 03

Section B - Supplies or Services/Prices Section B - Schedule

Schedule B

SCHEDULE B

Description Irrigation Area/Sketch Area Sq ft.

(Approx). Amount

CLIN 0001 Design/Build Irrigation System (Ref. SOW, Section 3.1.1) E & F West & South Entrance

Marquee

2500 sq ft. ea.

(5,000 sq ft.

total)

CLIN 0002 Option 1 A ANF1-005 61,100 $______________

CLIN 0003 Option 2 B RTF-025 15,100 $______________

CLIN 0004 Option 3 D REG-029 15,600 $______________

CLIN 0005 Option 4 C, C1, C2 ARB-022 + HQB-001 207,700 $______________

Total Estimated Potential Value $______________

This is a Firm Fixed Price Contract type with Optional Buys. The Optional CLIN's require prior CO approval in writing. The Offeror must provide a quote for all Line Items for the Total Estimated Potential Value, only CLIN 0001 will be obligated at time of award.

The contractor shall furnish all labor, tools, materials, equipment, and supplies necessary to accomplish the construction project;

Design/Build Irrigation System, at the Mike Monroney Aeronautical Center, Oklahoma City, OK set forth below in accordance with the SOW, attached Sketches/drawing, the other terms, conditions, and provisions set forth herein.

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

C.1 Description This will be a Design/Build Construction Contract Project. This includes all architectural/engineering and construction services necessary to provide a complete, water efficient, fully functional and operational irrigation system. The Contractor shall provide all trades, materials, and installation to incorporate all the construction aspects of the project to include furnishing all the labor, equipment, and materials as required.

C.2 Bid vs. Offer References to the terms "bid", "bidder", et. throughout the specification are intended to mean "offer", "offeror", etc.

C.3 Alternate vs. Option References to "alternate" or "alternates" in accordance with Section 01 23 00 Alternates throughout the specification and drawings are intended to mean "option" or "options."

C.4 Specifications and/or Drawings The following specifications and/or drawings are applicable to this acquisition.

Three (3) MMAC site drawings showing each area to be irrigated

OVERALL AND ENLARGED DRAWINGS - IRRIGATION AREAS

OVERALL IRRIGATION AREAS A – F

ENLARGED IRRIGATION AREAS A, B, D & F

ENLARGED IRRIGATION AREA C & E

Seven (7) sketches showing MMAC site-specific utilities at each location are a graphical depiction of the irrigation areas. NOTE: These sketches are not-to-scale (NTS) and shall be used for reference only.

UTILITY SKETCHES FOR IRRIGATION AREAS

IRRIG. AREA A - AN1-005 + AREA B RTF-025

IRRIG. AREA C – ARB-022 + HQB-001 OVERALL

IRRIG. AREA C1 – HQB-001 ENLARGED

IRRIG. AREA C2 – ARB-022 ENLARGED

IRRIG. AREA D - REG-029

IRRIG. AREA E - WEST ENTRANCE MARQUEE

IRRIG. AREA F - SOUTH ENTRANCE MARQUEE

Clause List

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

AT THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking Clause List

Not Applicable

Section E - Inspection and Acceptance Clause List

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

3.10.4-11 INSPECTION - DISMANTLING, DEMOLITION, OR REMOVAL OF IMPROVEMENTS

(APR 1996)

Section F - Deliveries or Performance Clause List

F.1 Working Hours Work at the site shall be accomplished between the hours of Normal work hours are between 7:30 a.m. and 4:00 p.m., Monday through Friday. The contractor must coordinate work activities outside these hours with the COR.., Monday through Friday, excluding federally established holidays, except when prior approval has been obtained from the Contracting Officer seven (7) days in advance. Approval for overtime work shall not be construed as an agreement for payment of overtime work.

F.2 Utility Outages and Shutdown Utility outages and shutdown shall be coordinated with the Contracting Officer and Project Manager. Outages affecting FAA operations are required to be accomplished at night, on weekends, or designated government holidays. Complete work requiring a water or electric outages outside of regular business hours. Prior to any outage or shutdown, seven (7) working days notification must be made to coordinate scheduling of any work to be performed during any hours.

F.3 Contractor Use of Premises

(a) General: Limit use of site and premises to allow:

(1) Owner Occupancy

(2) Work by others

(b) Access to Site: Limited to area required for construction.

F.4 Contractor's Construction Schedule and Material Submittals The contractor shall prepare and submit the construction work schedule to the Contracting Officer (CO) for approval within fifteen (15) days of the date established for "Commencement of Work" in accordance with Clause 3.2.2.3-56 which is incorporated by reference.

3.10.1-11 GOVERNMENT DELAY OF WORK (APR 1996)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

Section G - Contract Administration Data Clause List

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within 10 calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

AC1227 RELEASE FORM (JAN 1997)

The contractor will be required to execute Contractor's Release Form DOT F 4220.4 (2-71) prior to final payment under the contract. (Note: A copy of Form DOT F 4220.4 (2-71) is attached hereto for information purposes.)

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL

2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements Clause List

H.1 Permits and Responsibilities The contractor shall secure and pay for all permits, licenses, special inspections, certificates, etc...required by Federal, State, and City/Town officials as necessary to perform the work, prior to starting construction, and in a timely manner to avoid delays in starting the job. The Contractor shall abide by all requirements dictated by the municipality for such permits without any additional cost.

H.2 Submission of Contract Performance and Payment Bonds

(a) Pursuant to AMS Clauses 3.4.1-4, Performance Bond Requirements, and 3.4.1-5, Payment Bond Requirements, incorporated herein by reference, the contractor shall within 15 calendar days after the award of the contract deliver to the Contracting Officer -

(1) A Performance Bond on Standard Form 25 in a penal sum equal to 100 percent of the contract price; and

(2) A Payment Bond on Standard Form 25-A in a penal sum equal to 100 percent of the contract price.

(b) Copies of Standard Form 25 and Standard Form 25-A are attached and listed at Section J.

(c) Each bond shall be accompanied by a Power of Attorney whereby the surety company authorized the execution of the bond by its agent or employee.

(d) Each bond shall remain in full force and effect through the entire term of the contract, including extensions and warranty/guarantee periods, if any.

H.3 Time Extension Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order may also provide an equitable readjustment of liquidated damages under the new completion schedule.

H.4 Accident and Fire Reporting

(a) The Contractor shall report to the Contracting Officer any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment; or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the Contracting Officer or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email or facsimile transmission shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

H.5 Construction Safety Program

(a) The Mike Monroney Aeronautical Center (MMAC) Construction Safety program has been developed to protect MMAC employees, contractors, visitors, and students from workplace incidents related to construction activities. Chapter 33 Construction Safety (Section J) establishes work requirements, procedures, and standards that construction contractors and related providers must comply with while working on the MMAC campus.

(b) This chapter applies to all personnel working on and near construction projects or whose responsibilities impact construction activities on the MMAC campus.

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

3.2.5-7 DISCLOSURE REGARDING PAYMENTS TO INFLUENCE CERTAIN FEDERAL

TRANSACTIONS (JAN 2022)

(a) Definitions.

(1) "The Act," as used in this clause, means section 1352, title 31, United States Code.

(2) "Agency," as used in this clause, means executive agency, within the meaning of 5 U.S.C. 101, 102, and 104(I), and any wholly owned Government corporation within the meaning of 31 U.S.C. 9101.

(3) "Covered Federal action," as used in this clause, means any of the following Federal actions:

(i) The awarding of any Federal contract.

(ii) The making of any Federal grant.

(iii) The making of any Federal loan.

(iv) The entering into of any cooperative agreement.

(v) The extension, continuation, renewal, amendment, or modification of any Federal contract, grant, loan, or cooperative agreement.

(4) "Indian tribe" and "tribal organization," as used in this clause, have the meaning provided in section 4 of the Indian Self-Determination and Education Assistance Act (25 U.S.C. 5304) and include Alaskan Natives.

(5) "Influencing or attempting to influence," as used in this clause, means making, with the intent to influence, any communication to or appearance before an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with any covered Federal action.

(6) "Local government," as used in this clause, means a unit of government in a State and, if chartered, established, or otherwise recognized by a State for the performance of a governmental duty, including a local public authority, a special district, an intrastate district, a council of governments, a sponsor group representative organization, and any other instrumentality of a local government.

(7) "Officer or employee of an agency," as used in this clause, includes the following individuals who are employed by an agency:

(i) An individual who is appointed to a position in the Government under title 5, United States Code, including a position under a temporary appointment.

(ii) A member of the uniformed services, as defined in subsection 101(3), title 37, United States Code.

(iii) A special Government employee, as defined in section 202, title 18, United States Code.

(iv) An individual who is a member of a Federal advisory committee, as defined by the Federal Advisory Committee Act, title 5, United States Code, appendix 2.

(8) 'Person,' as used in this clause, means an individual, corporation, company, association, authority, firm, partnership, society, State, and local government, regardless of whether such entity is operated for profit, or not for profit. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(9) 'Reasonable compensation,' as used in this clause, means, with respect to a regularly employed officer or employee of any person, compensation that is consistent with the normal compensation for such officer or employee for work that is not furnished to, not funded by, or not furnished in cooperation with the Federal Government.

(10) 'Reasonable payment,' as used in this clause, means, with respect to professional and other technical services, a payment in an amount that is consistent with the amount normally paid for such services in the private sector.

(11) 'Recipient,' as used in this clause, includes the Contractor and all subcontractors. This term excludes an Indian tribe, tribal organization, or any other Indian organization with respect to expenditures specifically permitted by other Federal law.

(12) 'Regularly employed,' as used in this clause, means, with respect to an officer or employee of a person requesting or receiving a Federal contract, an officer or employee who is employed by such person for at least 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person for receipt of such contract. An officer or employee who is employed by such person for less than 130 working days within 1 year immediately preceding the date of the submission that initiates agency consideration of such person must be considered to be regularly employed as soon as he or she is employed by such person for 130 working days.

(13) 'State,' as used in this clause, means a State of the United States, the District of Columbia, the Commonwealth of Puerto Rico, a territory or possession of the United States, an agency or instrumentality of a State, and multi- State, regional, or interstate entity having governmental duties and powers.

(b) Prohibitions. The offeror, by signing its offer, hereby certifies to the best of his or her knowledge and belief that:

(1) No Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the awarding of any Federal contract, the making of any Federal grant, the making of any Federal loan, the entering into of any cooperative agreement, and the extension, continuation, renewal, amendment or modification of any Federal contract, grant, loan, or cooperative agreement;

(2) If any funds other than Federal appropriated funds (including profit or fee received under a covered Federal action) have been paid, or will be paid, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the screening information request (SIR), the offeror must complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to the Contracting Officer; and

(3) He or she will include the language of this clause in all subcontract awards at any tier and require that all recipients of subcontract awards in excess of $150,000 must disclose accordingly.

(4) This certification and disclosure is a prerequisite for making or entering into this contract imposed by the Act.

Any person who makes a prohibited expenditure or fails to file or amend a disclosure form, must be subject to a civil penalty of not less than $10,000 and not more than $100,000, for each such failure.

(c) The prohibitions of the Act do not apply under the following conditions:

(1) Agency and legislative liaison by its own employees.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of a payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action if the payment is for agency and legislative liaison activities not directly related to a covered Federal action.

(ii) For purposes of subdivision (c)(1)(i) of this clause, providing any information specifically requested by an agency or Congress is permitted at any time.

(iii) The following agency and legislative liaison activities are permitted at any time where they are not related to a specific solicitation for any covered Federal action:

(A) Discussing with an agency the qualities and characteristics (including individual demonstrations) of the person's products or services, conditions or terms of sale, and service capabilities.

(B) Technical discussions and other activities regarding the application or adaptation of the person's products or services for an agency's use.

(iv) The following agency and legislative liaison activities are permitted where they are prior to Screening Information Request (SIR) of any covered Federal action:

(A) Providing any information not specifically requested but necessary for an agency to make an informed decision about initiation of a covered Federal action;

(B) Technical discussions regarding the preparation of an unsolicited proposal prior to its official submission; and

(C) Capability presentations by persons seeking awards from an agency pursuant to the provisions of a law authorizing such actions;

(v) Only those services expressly authorized by subdivision (c)(1)(i) of this clause are permitted under this clause.

(2) Professional and technical services.

(i) The prohibition on the use of appropriated funds, in subparagraph (b)(1) of this clause, does not apply in the case of:

(A) A payment of reasonable compensation made to an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action, if payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action.

(B) Any reasonable payment to a person, other than an officer or employee of a person requesting or receiving a covered Federal action or an extension, continuation, renewal, amendment, or modification of a covered Federal action if the payment is for professional or technical services rendered directly in the preparation, submission, or negotiation of any submittal/offer or application for that Federal action or for meeting requirements imposed by or pursuant to law as a condition for receiving that Federal action. Persons other than officers or employees of a person requesting or receiving a covered Federal action include consultants and trade associations.

(ii) For purposes of subdivision (c)(2)(i) of this clause, 'professional and technical services' must be limited to advice and analysis directly applying any professional or technical discipline. For example, drafting of a legal document accompanying a submittal/offer by a lawyer is allowable. Similarly, technical advice provided by an engineer on the performance or operational capability of a piece of equipment rendered directly in the negotiation of a contract is allowable. However, communications with the intent to influence made by a professional (such as a licensed lawyer) or a technical person (such as a licensed accountant) are not allowable under this section unless they provide advice and analysis directly applying their professional or technical expertise and unless the advice or analysis is rendered directly and solely in the preparation, submission or negotiation of a covered Federal action. Thus, for example, communications with the intent to influence made by a lawyer that do not provide legal advice or analysis directly and solely related to the legal aspects of his or her client's submittal/offer, but generally advocate one proposal over another are not allowable under this section because the lawyer is not providing professional legal services.

Similarly, communications with the intent to influence made by an engineer providing an engineering analysis prior to the preparation or submission of a submittal/offer are not allowable under this section since the engineer is providing technical services but not directly in the preparation, submission or negotiation of a covered Federal action.

(iii) Requirements imposed by or pursuant to law as a condition for receiving a covered Federal award include those required by law or regulation and any other requirements in the actual award documents.

(iv) Only those services expressly authorized by subdivisions (c)(2)(i) and (ii) of this clause are permitted under this clause.

(v) The reporting requirements herein must not apply with respect to payments of reasonable compensation made to regularly employed officers or employees of a person.

(d) Disclosure.

(1) If the Contractor, who requests or receives from an agency a Federal contract, has made or has agreed to make any payment using non-appropriated funds (to include profits from any Covered Federal action), to any person for the purpose of influencing or attempting to influence an officer or employee of any Agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with a Covered Federal action, the Contractor must file with that agency a disclosure form, OMB Standard Form LLL, Disclosure of Lobbying Activities..

(2) The Contractor must file a disclosure form at the end of each calendar quarter in which there occurs any event that materially affects the accuracy of the information contained in any disclosure form previously filed by such person under subparagraph (d)(1) of this clause. An event that materially affects the accuracy of the information reported includes:

(i) A cumulative increase of $25,000 or more in the amount paid or expected to be paid for influencing or attempting to influence a covered Federal action; or

(ii) A change in the person(s) or individual(s) influencing or attempting to influence a covered Federal action; or

(iii) A change in the officer(s), employee(s), or Member(s) contacted to influence or attempt to influence a covered Federal action.

(3) The Contractor must require the certification, and if required, a disclosure form by any person who requests or receives any subcontractor exceeding $150,000 under the Federal contract.

(4) All subcontractor disclosure forms must be forwarded from tier to tier until received by the prime Contractor.

The prime Contractor must submit all disclosures to the Contracting Officer at the end of the calendar quarter in which the disclosure form is submitted by the subcontractor.

(e) Agreement. The Contractor agrees not to make any payment prohibited by this clause.

(f) Penalties.

(1) Any person who makes an expenditure prohibited under paragraph (b) of this clause or fails to file or amend the disclosure form to be filed or amended by paragraph (b) must be subject to civil penalties as provided for by 31 U.S.C. 1352. An imposition of a civil penalty does not prevent the Government from seeking any other remedy that may be applicable.

(2) Contractors may rely without liability on the representations made by their subcontractors in the certification and in the disclosure form.

(g) Cost allowability. Nothing in this clause makes allowable or reasonable any costs which would otherwise be unallowable or unreasonable. Conversely, costs made specifically unallowable by the requirements in this clause will not be made allowable under any other provision.

(End of clause)

3.8.2-17 KEY PERSONNEL AND FACILITIES (JUL 2019)

(a) The personnel and/or facilities as specified below are considered essential to the work being performed hereunder and may, with the consent of the contracting parties, be changed from time to time during the course of the contract.

(b) Prior to removing, replacing, or diverting any of the specified personnel and/or facilities, the Contractor must notify in writing, and receive consent from, the Contracting Officer reasonably in advance of the action and must submit justification (including proposed substitutions) in sufficient detail to permit evaluation of the impact on this contract.

(c) No diversion will be made by the Contractor without the written consent of the Contracting Officer.

(d) The key personnel and/or facilities under this contract are:

Landscape Architect [ ]

(List key personnel and/or facilities)

(End of clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC1231 NOTIFICATION REQUIREMENTS WHEN FRIABLE ASBESTOS MATERIAL IS

REMOVED/DISTURBED (JAN 1997)

(a) Prior to any planned and/or scheduled disturbance of friable asbestos material, mainly CAFCO ceilings, the contractor shall present a written plan to the Contracting Officer. The plan shall include, but not be limited to, location, type facility, size of area to be disturbed or removed, method of containment to be used, disposal procedures, clean-up procedures, number of employees involved, protective clothing/equipment to be used, the date and time removal/disturbance is planned and any other information requested by the Contracting Officer. The contractor shall not proceed with any removal or disturbance of friable asbestos material without written approval from the Contracting Officer.

(b) If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (MAY 2019)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer's Representative (COR).

FAA ORDERS/DIRECTIVES

*Contractor & Industrial Security Program FAA Order 1600.72A https://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Note: All contractors with access to government computer systems are required to take annual Security Awareness Virtual Initiative (SAVI) training. Information on how to accomplish this training is located at:

https://my.faa.gov/org/linebusiness/ash/programs/savi.html

*Accountability Board FAA Order 1110.125B https://www.faa.gov/documentLibrary/media/Order/FAA_Order_1110.125B.pdf

*FAA Occupational Safety & Health Policy FAA Order 3900.19C https://www.faa.gov/documentLibrary/media/Order/FAA_Order_3900.19C.pdf

*FAA Information Security and Privacy Program and Policy FAA Order 1370.121 https://employees.faa.gov/documentLibrary/media/Order/1370.121.pdf

*Ground Vehicle Operations to include Taxiing, or Towing Aircraft on Airports

Advisory Circular AC 150/5210-20A https://www.faa.gov/airports/resources/advisory_circulars/index.cfm/go/document.information/documentID/102808

*Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

*Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the…