R16PS00263_-_Amendment_No._003.pdf

(x)

R16PS00263

x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Sacramento CA 95825-1898 2800 Cottage Way, Room E-1815

R20

Division of Acquisition Services Regional Office Mid-Pacific Region Bureau of Reclamation

04/01/2016003

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

02/29/2016

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

A. TITLE: Folsom UHA Switchgear Replacement

B. PURPOSE: The purpose of this amendment is to incorporate revisions to the solicitation documents and to provide responses to all questions received.

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Matthew T. Byrne

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

Continuation Page For

Solicitation R16PS00263 Amendment 003

Instructions for SF-30

Block 14 (continued)

C. DESCRIPTION: This amendment hereby incorporates the following:

Revised Contract Sections:

Remove Section B and Replace with Section B, Amendment 003.

Remove and replace Specification Section 01 11 00 – Summary of Work, Amendment 003.

Remove and replace Specification Section 01 14 30 – Outages, Amendment 003.

Remove and replace Specification Section 01 33 00 – Submittals, Amendment 003.

Remove and replace Specification Section 02 83 33 – Removal and Disposal of Material Containing Heavy Metals, Amendment 003.

Remove and replace Specification Section 03 11 10 – Concrete Forming, Amendment 003.

Remove and replace Specification Section 03 20 00 – Concrete Reinforcing, Amendment 003.

Remove and replace Specification Section 26 05 04 – Removal of Existing Electrical Equipment and Cable, Amendment 003.

Remove and replace Specification Section 26 13 10 – Medium-Voltage Metal-Clad Switchgear and Fabricated Control Building, Amendment 003.

Remove and replace Specification Section 26 25 10 – Metal Enclosed Bus, Amendment 003.

Remove and replace Specification Section 51 00 05 – Contractor Use Area, Amendment 003.

Remove and replace Specification Section 51 00 22 – Hazardous Materials Assessment, Amendment 003.

Remove and replace Specification Section 52 00 00 – Drawings, Amendment 003.

Remove Section J, Amendment No. 002 and Replace with Section J, Amendment No. 003

Contract Section Added:

Add Section J, Amendment 003, Attachment No. 8, Questions and Answers.

Revised drawings to be removed and replaced:

485-D-50 (Sheet 7)

485-D-353 (Sheet 8)

485-D-60009 (Sheet 16)

485-D-60010 (Sheet 17)

485-D-60011 (Sheet 18)

485-D-60012 (Sheet 19)

485-D-60013 (Sheet 20)

485-D-60015 (Sheet 22)

485-D-60018 (Sheet 15)

Drawings to be removed in entirety:

485-D-E1 (Sheet 42)

485-D-E2 (Sheet 43)

R16PS00263 – Folsom UHA Switchgear Replacement Specifications. No. 20-C0838 Amendment No. 003

Price Schedule

B - 1

CONTINUATION OF

SECTION B – SUPPLIES OR SERVICES AND PRICES/COSTS

Folsom UHA Switchgear Replacement

American River Division – Folsom Unit Central Valley Project, California

B.1 PRICE SCHEDULES

(a) Offers will be considered for award on the following Price Schedule , but no offer will be considered for award on only a part of the Price Schedule.

(b) Offers are subject to the terms and conditions of this solicitation.

(c) Quantities in the Price Schedule are estimated quantities for comparison of offers only.

Except as provided in the contract clause at FAR 52.211-18, Variation in Estimated Quantity, no claim shall be made against the Government for overruns or underruns. The contract clause at FAR 52.211-18, Variation in Estimated Quantity does not apply to lump sum items.

(d) See the contract clause at WBR 1452.232-81, Payment for Mobilization and Preparatory Work, for CLIN 1.

(e) Definitions:

(1) CLIN – Contract Line Item Number.

PRICE SCHEDULE A

Item Section Work or Material Quantity and unit

Unit Price

Amount

WBR

1452.232-81 Mobilization and Preparatory Work For the lump sum of $

01 31 30 Contract Document Management

System For the lump sum of $

01 33 26 Electrical Drawings and Data For the lump sum of $

02 41 07 Removal and Disposal of Existing Features For the lump sum of $

B - 2

PRICE SCHEDULE A

Item Section Work or Material Quantity and unit

Unit Price

02 83 33 Removal and Disposal of Material Containing Heavy Metals For the lump sum of $

03 30 00 Cast-In-Place Concrete For the lump sum of $

03 81 10 Concrete Removal For the lump sum of $

05 50 00 Metal Fabrications For the lump sum of $

26 05 04 Removal of Existing Electrical

Equipment and Cable For the lump sum of $

26 05 13

Medium-Voltage Power Cable - 5kV, Shielded, Insulated, Single Conductor, 750 MCM Power Cable

1,200 lin ft $ $

26 05 13

Medium-Voltage Power Cable - 5kV, Shielded, Insulated, Single Conductor, No. 3/0 AWG Power Cable

800 lin ft $ $

26 05 13 Testing of Existing 5-Kilovolt Power

Cable For the lump sum of $

26 05 33 Electrical Conduit and Raceways For the lump sum of $

26 05 36 Cable Tray System For the lump sum of $

26 13 10

Medium-Voltage Metal-Clad Switchgear and Fabricated Control Building

For the lump sum of $

B - 3

PRICE SCHEDULE A

Item Section Work or Material Quantity and unit

Unit Price

26 13 10

Medium-Voltage Metal-Clad Switchgear and Fabricated Control Building Spare Parts

For the lump sum of $

26 25 10 5-Kilovolt Segregated Phase Bus For the lump sum of $

31 23 11 Earthwork for Structures For the lump sum of $

TOTAL FOR PRICE SCHEDULE A: $_________________

END OF SUPPLIES OR SERVICES AND PRICES/COSTS

B - 4

This page intentionally left blank.

Folsom UHA Switchgear Replacement Specifications No. 20-C0838

Summary of Work

01 11 00 - 1

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.01 LOCATION

A. Work is located at Folsom Western Area Power Administration’s (WAPA) Switchyard on the American River approximately 2 miles north of Folsom, California in Sacramento County.

1.02 PRINCIPAL COMPONENTS OF WORK

A. Remove and replace station service switchgear, UHA, associated protective relay systems, instrumentation transformers, and metering.

1. Location of new switchgear same as existing to maximize use of existing feeders.

2. Furnish walk-in fabricated power control building.

3. Furnish and maintain primary and backup power for critical Government loads.

4. Furnish Contractor required temporary power.

5. Furnish digital multi-function protective relay system and metering.

B. Remove existing canopy structure.

C. Relocate existing sewer vent assembly as needed.

D. Remove and replace existing concrete foundations and slab for fabricated control building.

E. Structural metalwork including:

1. Modifications to existing cable supports.

2. Cable tray beneath existing UHA switchgear location.

3. Flush metal grating cover and floor support system over tunnel located in area between switchgear sections.

F. Furnish guard posts for structure protection.

G. Remove and replace existing 5 kV cables for:

1. KZ4A feeder to UHA-52B (replacement cable routed through new conduits).

2. KV9A feeder to UHA-52A (replacement cable routed through existing conduits).

3. UHA-52-1 (Switchyard station service feeder).

01 11 00 - 2

4. UHA-52-10 (Switchyard station service feeder).

H. Provide Contract Document Management System.

I. Furnish drawings and data.

J. Document as-found equipment and cabling condition prior to removal using video and photographs.

K. Sample existing equipment for heavy metals prior to removal.

L. Document as-built drawing accuracy prior to removal.

M. Provide turn-key interface with existing switchyard and powerplant alarm, protection, control, and SCADA (CVACS) circuits.

N. Provide communication interface with power plant Central Valley Automated Control System (CVACS).

O. Provide as-built manufacturer and Government format interface drawings.

P. Provide new cable tray directly below existing UHA switchgear.

Q. Provide spare parts.

R. Provide substation accessories.

S. Provide training.

T. Site specific provisions, control, devices, and monitoring as shown on drawings.

1.03 SPECIFICATIONS REQUIREMENTS

A. Requirements in Division 1, General Requirements, apply to Divisions 2 through 52.

B. Imperative statements in these specifications are Contractor requirements, unless otherwise stated.

C. Where specifications are written in streamlined form, the words “shall be” are included by inference where a colon (:) is used within the sentence or phrase.

1.04 DEFINITIONS

A. When the specifications use a word or term defined in the Federal Acquisition Regulations (FAR), the definition of the word or term shall be in accordance with FAR sections in effect at the time the solicitation was issued.

01 11 00 - 3

1.05 ACRONYMS

A. The following acronyms apply to specifications Divisions 1 through 52:

1. CE: Construction Engineer.

2. CO: Contracting Officer.

3. COR: Contracting Officer’s Representative.

4. OGR: Onsite Government Representative.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

END OF SECTION

01 11 00 - 4

01 11 00 - 5

Outages

01 14 30 - 1

SECTION 01 14 30

OUTAGES

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include cost in prices offered in Price Schedule A for items of work for which outages are required.

1.02 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 01 14 30-1, Outage Request:

1. Area where work will be done annotated on a site plan drawing showing pertinent features.

2. Show construction outage greater than 2 hours in the construction schedule.

3. Commencement time of work.

4. Duration of work.

5. Number of personnel and their classification.

6. Description of equipment to be used.

7. Information indicating that required materials are on site or data indicating shipping dates of materials not on site.

8. Provide Job Hazard Analyses (JHAs) or written procedure for isolating and removing each hazard source through lockout and tagout procedures for approval.

9. List any impacts to power system operating conditions.

1.03 PROJECT CONDITIONS

A. Schedule and coordinate outages/clearances with the OGR who shall coordinate work and approvals with Operations and other Government entities as necessary.

B. Any outage shall be minimized to the extent possible.

1. Contractor shall have approved Design drawings, Materials and Installation/Demolition Plans prior to approval of the Outage Request, and any work occurring under an outage/clearance.

2. All materials/fabrications for installation shall be approved and readily available prior to the start of the outage/clearance.

01 14 30 - 2

3. Outage duration(s) through the use of Section 01 11 22 - Construction Sequencing should greatly assist in minimizing outages.

4. Temporary use of removed switchgear breakers can be used to service critical loads during the staged construction process.

C. No specific request for an outage/clearance will be considered unless COR has reasonable assurances that materials and equipment required for work will be on site and Contractor will be prepared to perform the work on the start date and during the period of time requested for the specific outage/clearance.

D. An outage/clearance period starts when equipment and systems are de-energized or otherwise affect the normal intended operation of the equipment and system in any way because of the work required under these specifications.

1. The outage/clearance period ends when the Government accepts the work and the equipment/system is restored to normal operation.

2. See FIST 1-1 for outage and clearance requirements.

a. The COR or local Government representative shall be the final authority in interpreting FIST 1-1 and the applicability of any outages/clearances deemed necessary.

E. The Special Work Permit must be issued to the Contractor prior to any work starting under a clearance.

F. Following requirements must be met before beginning onsite work associated with a clearance:

1. Coordinate with OGR to obtain Special Work Permit per HECP requirements from an authorized Bureau of Reclamation representative/Job Supervisor.

a. Special Work Permit will not be issued until the following requirements have been met:

1) Proposed work is described and in compliance with Bureau of Reclamation’s and CCAO Hazardous Energy Control Program (HECP) and Facilities Instructions, Standards, and Techniques (FIST) Volume 1-1, copies of which can be made available to Contractor upon request.

2) Clearance request is approved.

3) Mandatory: Minimum one hour HECP familiarization for all Contractor personnel working on site prior to entering areas under outage/clearance. Coordinate with OGR minimum of 3 business days in advance to schedule training.

4) CCAO Operations implements the approved Clearance request via actual lockout - tagout therefore isolating the hazardous energy.

01 14 30 - 3

G. Work not associated with an outage/clearance can be accomplished after the CCAO Permit to Work is issued in accordance with Section 01 14 10 - Use of Site.

H. When work cannot be performed during an approved outage/clearance period, notify the OGR that outage/clearance is not required, and requires rescheduling as applicable.

1. Outage scheduling will depend on Power Plant, Dam, and other critical system operation requirements as determined by the Government.

2. Preferred outage window: October 1 through May 15.

3. Maximum 8 hour outage for connecting backup power source.

a. Maximum 4 hour outage for facilitating power restoration following a forced outage.

4. Outages may be scheduled during off-peak periods, nights, or weekends.

5. Government reserves right to schedule outages for any period during 24-hour day, any day of the week.

6. Contractor’s request for outages, work scheduling, and delivery of materials on site will be governed by available time and outage periods.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

01 14 30 - 4

Submittals

01 33 00 - 1

PPSECTION 01 33 00

SUBMITTALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in Price Schedule A for other items of work.

1.02 REFERENCE STANDARDS

A. American Society of Mechanical Engineers (ASME)

1. ASME Y14.1-12 Decimal Inch Drawing Sheet Size and Format

B. National Institute of Building Sciences (NIBS)

1. NIBS NCS-11 United States National CAD Standards, Version 5

1.03 DEFINITIONS

A. Days: Calendar days.

B. Required Submittal Number (RSN): Identifies items to be submitted together as a complete submittal.

1.04 SUBMITTAL REQUIREMENTS

A. In case of conflict between requirements of this section and requirements included elsewhere in these specifications, requirements included elsewhere take precedence.

B. General:

1. Prepare in English.

2. Label with contract number and title, and RSN.

3. Measurement units: US Customary Units.

C. Drawings:

1. Minimum Identification in Title Block:

a. Contract number and title.

b. Contractor’s or supplier’s title and drawing number.

01 33 00 - 2

c. Date.

2. Provide 3-inch by 3- inch space next to title block for review stamps.

3. Size: D size (22 inches by 34 inches) as defined by ASME Y14.1.

4. Draw to scale using computer drafting or drafting equipment, unless otherwise specified.

a. Computer drafted drawings:

1) In accordance with NIBS NCS.

2) Electronic file format: Compatible with AutoCAD, Version 2007 or later.

b. Drawing prepared with drafting equipment, when allowed: Lettering shall be neat.

5. Drawings Designated as “Government Format” in Specifications:

a. Computer drafted.

b. Government will provide an electronic AutoCAD format template.

c. Title block and sheet format:

1) As shown on standard drawing 40-D-7102.

2) Government will provide specific title block information to be used.

6. Final Drawings:

a. Computer drafted.

b. Government will provide an electronic AutoCAD format template.

c. Show as-built changes, including revision dates, made during installation.

Indicate changes by clouding.

7. Electronic Files: On CD or DVD discs.

D. Product Data:

1. Mark manufacturer’s data for commercial products or equipment, such as catalog cut sheets.

a. Identify manufacturer’s name, type, model, size, and characteristics.

b. Illustrate that product or equipment meets requirements of specifications.

c. Mark items to be furnished in a manner that will photocopy. Do not use highlighter.

d. Strike through items that do not apply.

E. Certifications:

01 33 00 - 3

1. Certifications by a Registered California Professional: Signed and sealed by registered California professional.

2. Manufacturer’s Certifications: Signed by authorized representative of manufacturer.

F. Manuals:

1. Copies:

a. Printed copies: Bound and indexed.

b. Electronic copies: Adobe pdf on CD or DVD discs.

1) Bookmark longer files to assist in navigating file.

2. Contents:

a. Parts identification lists, lists of special tools, and accessories.

b. Schematics and wiring diagrams.

c. Detailed instructions for installing, operating, lubricating, and maintaining equipment.

d. As-built drawings, photographs, and test records or reports if required by the specifications.

1.05 SUBMITTALS PROCEDURES

A. Submit only checked submittals. Submittals without evidence of Contractor’s approval will be returned for resubmission.

B. Submit complete sets of required materials for each RSN as specified in “Submittals Required” column in Table 01 33 00A - List of Submittals. A complete set includes all listed items for RSNs with multiple parts.

C. Submit number of sets specified in “No. of sets to be sent to:” columns in Table 01 33 00A - List of Submittals.

1. Submittals identified with “CDMS” in the “Sets to be sent” column shall be submitted electronically in accordance with Section 01 31 30 - Contract Document Management System (CDMS).

2. Send one hard copy of each submittal to CE.

D. Include the following information in transmittal letters:

1. Contract number and title.

2. RSN for each attached submittal.

3. Responsible code.

4. Number of sets for each RSN.

01 33 00 - 4

5. Identify submittal as initial or resubmittal.

E. Resubmittal of submittals not approved:

1. Mark changes such that they are readily identifiable and show revision date.

2. Describe reasons for significant changes in transmittal letter.

3. Resubmit returned submittals within 21 days after receiving the comments, unless otherwise directed.

4. Requirements for initial submittals apply to resubmittals.

F. More than one RSN may be submitted under a transmittal letter, provided the responsible code is the same.

1.06 REVIEW OF SUBMITTALS

A. Time Required:

1. Submittal review will require 21 days for review of each submittal or resubmittal, unless otherwise specified.

2. Time required for review of each submittal or resubmittal begins when complete sets of materials required for a particular RSN are received and extends through return mailing postmark date.

B. Time in Excess of Specified:

1. The CO may extend the contract completion date to allow additional time for completing work affected by excess review time.

a. The time extension will be to the extent that excess review time caused delay to the contract completion date.

b. The time extension will not exceed the time used in excess of the specified number of days for review of submittals or resubmittals.

c. Concurrent days of excess review time resulting from review of two or more separate submittals or resubmittals will be counted only once in extending the contract completion date.

2. No time extension will be allowed if the Contractor fails to make complete action submittals in sequence and within time periods specified.

3. Adjustment for delay will be made only to the extent that:

a. Approval was required under the contract, and:

b. Requests for approval were properly and timely submitted and were approved.

4. Adjustment will be subject to terms of paragraphs (b) and (c) of the clause at FAR 52.242-14, Suspension of Work; however, no such delay shall be deemed to be a “suspension order” as the term is used in that clause.

01 33 00 - 5

C. Return of Submittals:

1. The transmittal letter for each submittal will be returned as approved, approved subject to identified changes, or not approved.

a. The transmittal letters for RSNs 01 32 20-1, 01 32 20-2, 01 35 20-1, 01 35 20-2, 01 35 30-1, 01 35 30-2, and 01 35 30-3 will be returned accepted, accepted subject to identified changes, or not accepted.

2. Return of submittals will be by CDMS response or hard copy, as applicable.

1.07 TRANSMITTAL

A. Addresses for codes listed in Table 01 33 00A - List of Submittals:

1. Construction Engineer, Bureau of Reclamation, P.O. Box 988, Willows, CA 95988-0988. Street address for express mail delivery: MP Construction Office, 1140 West Wood Street, Willows, CA 95988.

2. Area Office (CCAO), Bureau of Reclamation, Attn: CC-107, 7794 Folsom Dam Road, Folsom, CA 95630-1779.

3. Resident Engineer, MP Construction Office Folsom Dam, 7794 Folsom Dam Road, Folsom, CA 95630-1779.

4. Central Valley Operations (CVO), Bureau of Reclamation, 3310 El Camino Ave., Suite 300, CVO-610, Sacramento, CA 95821.

5. Technical Service Center, Bureau of Reclamation, Attn: 86-68510, P.O. Box 25007, Denver CO 80225-0007; Express Mail: Sixth and Kipling, Building 67, Room 152.

B. Send original transmittal letter with appropriate number of sets to office listed in “Responsible Code” column in Table 01 33 00A - List of Submittals.

1. Responsible codes starting with “86-” are located in the Technical Service Center.

Send these submittals to the TSC address shown above.

C. Send copy of transmittal letter with appropriate number of sets to offices that are not the responsible code, but show “No. of sets to be sent to” in Table 01 33 00A - List of Submittals.

D. When “No. of sets to be sent to” is 0, send a copy of transmittal letter to that office.

E. Submittals required by the specifications, but not listed in Table 01 33 00A - List of Submittals:

1. Submit in accordance with this section.

2. Submit to Construction Engineer and Resident Engineer, unless otherwise specified.

01 33 00 - 6

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

01 33 00 - 7

Table 01 33 00A - List of Submittals

** CE indicates Construction Engineer, AO indicates Area Office, RE indicates Resident Engineer, CVO indicates Central Valley Operations, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Respon-sible code

No. of sets to be sent to: **

CE AO RE CVO TSC

01 11 22-1 Construction Sequencing

Work Sequence Plan

At least 56 days before removal of existing UHA switchgear

86-68430 1 CDMS

01 14 10-1 Use of Site Land Use and Landscape Rehabilitation Plan

At least 28 days before beginning work.

CE 1 CDMS

01 14 30-1 Outages Outage Request At least 20 days before outage

CE 1 CDMS

01 31 30-1 Contract Document Management System

(CDMS)

Approval Data Within 7 days of Award

CE 1 1 1 1 0

01 31 30-2 Contract Document Management System

(CDMS)

Final Data Within 14 days of completion of work

CE 1 1 1 1 1

01 32 20-1 Construction Program

Baseline Schedule:

1. Blackline prints

2. Reports

3. Data on CD-

ROM

Within 21 days after receipt of Notice to Proceed

CE CDMS

01 32 20-2 Construction Program

Updated Monthly or As Requested Schedule:

1. Blackline prints

2. Reports

3. Data on CD-

ROM

With monthly requests for progress payments.

CE 1 CDMS

01 35 10-1 Safety Data Sheets

Complete LHM and

SDS

At least 14 days before jobsite delivery of hazardous material

CE 1 CDMS

01 35 10-2 Safety Data Sheets

Updated LHM and

SDS

At least 14 days before jobsite delivery of hazardous material not previously listed

CE 1 CDMS

01 33 00 - 8

Table 01 33 00A - List of Submittals ** CE indicates Construction Engineer, AO indicates Area Office, RE indicates Resident Engineer, CVO indicates Central Valley Operations, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Respon-sible code

No. of sets to be sent to: **

CE AO RE CVO TSC

01 35 20-1 Safety and Health

Safety Program Submitted and approved prior to mobilization

CE 1 CDMS

01 35 20-2 Safety and Health

Monthly Accident Summary Report

First day of each month

CE 1 CDMS

01 35 30-1 Contractor‘s Onsite Safety Personnel

Resumes and Qualifications

Prior to employment CE 1 CDMS

01 35 30-2 Contractor’s Onsite Safety Personnel

Safety Inspections, Incidents, Accident, and Emergency Reports

At least once each week

CE 1 CDMS

01 35 50-1 Site Security Security Program At least 28 days before beginning work

CE 1 CDMS

01 35 50-2 Site Security List of Onsite Employees and Vehicles

At least 7 days before employee reports to site and updated at least monthly

CE 1 CDMS

01 46 20-1 Testing Agency Services

Testing Agency Services Plan

At least 35 days before start of onsite construction work

CE 1 CDMS

01 46 20-2 Testing Agency Services

Contractor Quality Testing Results

Within 14 days of testing completion

CE 1 CDMS

01 55 20-1 Traffic Control Traffic Control Plan At least 35 days before affecting public traffic

CE 1 CDMS

01 57 20-1 Environmental Controls

Air Quality Plan At least 35 days before start of onsite construction work

CE 1 CDMS

01 57 20-2 Environmental Controls

Initial Equipment Inventory and Emissions Projections

At least 35 days before start of onsite construction work

CE 1 CDMS

01 57 20-3 Environmental Controls

Monthly Equipment Inventory and Emissions Records

With monthly requests for progress payments

CE 1 CDMS

01 57 30-1 Water Pollution Control

Spill Prevention, Control, and Countermeasure (SPCC) Plan

At least 28 days before delivery or storage of oil

CE 1 CDMS

01 74 00-1 Cleaning and Waste Management

Waste Production and Disposal Plan

At least 21 days before beginning work

01 33 00 - 9

Table 01 33 00A - List of Submittals ** CE indicates Construction Engineer, AO indicates Area Office, RE indicates Resident Engineer, CVO indicates Central Valley Operations, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Respon-sible code

No. of sets to be sent to: **

CE AO RE CVO TSC

01 74 00-2 Cleaning and Waste Management

Waste Production and Disposal Records

Within 7 days of hazardous waste disposal

CE 1 CDMS

01 74 00-3 Cleaning and Waste Management

Environmental Consultant Resume

At least 35 days before beginning environmental assessment

CE 1 CDMS

01 74 00-4 Cleaning and Waste Management

Post-Construction Environmental Site Assessment

Within 14 days of completion of work

CE 1 CDMS

01 78 30-1 Project Record Documents

Final As-built Drawings

Within 14 days of completion of work

CE 2 0 0 0 0

02 83 33-1 Removal and Disposal of Material Containing Heavy Metals

Resumes, Certificates, and Qualifications

At least 28 days before beginning onsite work

CE 1 CDMS

02 83 33-2 Removal and Disposal of Material Containing Heavy Metals

Written Compliance Program for Worker Protection from Coatings Containing Hazardous Materials

At least 28 days before beginning onsite work

CE 1 CDMS

02 83 33-3 Removal and Disposal of Material Containing Heavy Metals

Emissions and Exposure Monitoring Plan for Coating Removal Debris and Dust

At least 28 days before beginning onsite work

CE 1 CDMS

02 83 33-4 Removal and Disposal of Material Containing Heavy Metals

Exposure Certifications and Test Results

Within 7 days after completion of testing

02 83 33-5 Removal and Disposal of Material Containing Heavy Metals

Preconstruction Test Results

02 83 33-6 Removal and Disposal of Material Containing Heavy Metals

Test Results During Work Activities

01 33 00 - 10

Table 01 33 00A - List of Submittals ** CE indicates Construction Engineer, AO indicates Area Office, RE indicates Resident Engineer, CVO indicates Central Valley Operations, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Respon-sible code

No. of sets to be sent to: **

CE AO RE CVO TSC

02 83 33-7 Removal and Disposal of Material Containing Heavy Metals

Post-Construction Test Results

02 83 33-8 Removal and Disposal of Material Containing Heavy Metals

Waste Characterization, Handling, and Disposal Plan

At least 28 days before beginning onsite work

CE 1 CDMS

02 83 33-9 Removal and Disposal of Material Containing Heavy Metals

Certificate of Disposal

Within 14 days after

03 11 10-1 Concrete Forming

Formwork Design and Drawings

At least 28 days before beginning concrete placement

CE 1 CDMS

03 20 00-1 Concrete Reinforcing

Reinforcement Diagrams and Lists

At least 28 days before beginning concrete placement

CE 1 CDMS

03 30 00-1 Cast-In-Place Concrete

Mix Design At least 28 days before beginning concrete placement

CE 1 CDMS

03 62 20-1 Nonshrink Grout for Equipment and Metalwork

Packaged Nonshrink Grout Data

At least 28 days before beginning nonshrink grout.

CE 1 CDMS

03 81 10-1 Concrete Removal

Concrete Removal Plan

At least 28 days before beginning concrete removal

CE 1 CDMS

Deleted 26 05 04-1 Removal of

Existing Electrical Equipment and Cable

Electrical Equipment Removal Request

At least 56 days before removal of existing UHA switchgear

86-68430 1 CDMS

26 05 10-1 Conductors and Cables

Approval Data At least 56 days before procurement

86-68430 1 CDMS

26 05 10-2 Conductors and Cables

Field Test Reports Within 14 days after tests are completed

86-68430 1 CDMS

26 05 10-3 Conductors and Cables

Final Drawings Within 28 days after installation

86-68430 1 CDMS

01 33 00 - 11

Table 01 33 00A - List of Submittals ** CE indicates Construction Engineer, AO indicates Area Office, RE indicates Resident Engineer, CVO indicates Central Valley Operations, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Respon-sible code

No. of sets to be sent to: **

CE AO RE CVO TSC

26 05 13-1 Medium Voltage Power Cable System

Approval Drawings and Data

At least 56 days before procurement

86-68430 1 CDMS

26 05 13-2 Medium Voltage Power Cable System

Existing 5 kV Cables Inspection Report and Field Test

Within 14 days after tests are completed

86-68430 1 CDMS

26 05 13-3 Medium Voltage Power Cable System

New 5 kV Cable Field Test Plan

At least 56 days before procurement

86-68430 1 CDMS

26 05 13-4 Medium Voltage Power Cable System

Factory Production Test Certifications

At least 28 days prior to shipment

26 05 13-5

Medium Voltage Power Cable System

Field Test Reports Within 30 days after tests are completed

86-68430 1 CDMS

26 05 33-1 Electrical Conduit and Raceways

Approval Drawings and Data

At least 56 days before procurement

86-68430 1 CDMS

26 05 33-2 Electrical Conduit and Raceways

Final Drawings Within 28 days after installation of conduit

86-68430 CDMS

1 1 1 1 1

26 05 36-1 Cable Tray System

Manufacturer’s Approval Data and Design Data

At least 42 days before procurement

86-68430 1 CDMS

26 05 36-2 Cable Tray System

Approval Layout Drawings and Bill of Materials (Manufacturer’s Format)

At least 42 days before procurement

86-68430 1 CDMS

26 05 90-1 Wiring Checkout and Tests

Test Notification and Plan

Within 14 days prior to checkout and test

86-68430 1 CDMS

26 05 90-2 Wiring Checkout and Tests

Test Reports Within 30 days after tests are completed

01 33 00 - 12

Table 01 33 00A - List of Submittals ** CE indicates Construction Engineer, AO indicates Area Office, RE indicates Resident Engineer, CVO indicates Central Valley Operations, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Respon-sible code

No. of sets to be sent to: **

CE AO RE CVO TSC

26 13 10-1 Medium - Voltage Metal- Clad Switchgear and Fabricated Control Building

Pre-Assembled or Assembled On-Site Walk-In Equipment Structure, Civil Approval Drawings and Data

At least 84 days before fabrication or procurement

86-68430 1 CDMS

26 13 10-2 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Pre-Assembled or Assembled On-Site Walk-In Equipment Structure, Civil Final Drawings and Data

At least 28 days before fabrication or procurement

86-68430 1 CDMS

26 13 10-3 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Pre-Assembled or Assembled On-Site Walk-In Equipment Structure, Mechanical Systems Approval Drawings and Data

At least 56 days before fabrication or procurement

86-68430 1 CDMS

26 13 10-4 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Pre-Assembled or Assembled On-Site Walk-In Equipment Structure, Electrical Systems Approval Drawings and Data

At least 84 days before fabrication or procurement

86-68430 1 CDMS

26 13 10-5 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Metal-Clad Switchgear Approval Drawings and Data

At least 56 days before fabrication or procurement

86-68430 1 CDMS

26 13 10-6 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Erection Plans and Manual

At least 28 days before delivery

86-68430 CDMS

1 1 1 1 1

01 33 00 - 13

Table 01 33 00A - List of Submittals ** CE indicates Construction Engineer, AO indicates Area Office, RE indicates Resident Engineer, CVO indicates Central Valley Operations, and TSC indicates Technical Service Center. CDMS indicates Contract Document Management System.

RSN

Clause or

Section Title

Submittals required

Due date or delivery time

Respon-sible code

No. of sets to be sent to: **

CE AO RE CVO TSC

26 13 10-7 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Factory Test Notification

At least 14 days before testing

86-68430 1 CDMS

26 13 10-8 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Factory Test Reports

Within 14 days after tests are completed

86-68430 1 CDMS

26 13 10-9 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Field Test Reports Within 14 days after tests are completed

86-68430 1 CDMS

26 13 10-10 Medium- Voltage Metal- Clad Switchgear and Fabricated Control Building

Metal-Clad Switchgear Final Documentation

At time of shipment 86-68430 1 CDMS

26 25 10-1 Metal Enclosed Bus

Approval Drawings and Data

At least 56 days before procurement

86-68430 1 CDMS

26 25 10-2 Metal Enclosed Bus

Factory Test Report Within 30 days after tests are completed

86-68430 1 CDMS

26 25 10-3 Metal Enclosed Bus

Field Test Reports Within 30 days after tests are completed

86-68430 1 CDMS

31 23 02-1 Compacting Earth Materials

Test Results Within 24 hours after completing individual tests

01 33 00 - 14

Removal and Disposal of Material Containing Heavy Metals

02 83 33 - 1

SECTION 02 83 33

REMOVAL AND DISPOSAL OF MATERIAL CONTAINING HEAVY METALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Removal and Disposal Materials Containing Heavy Metals:

1. Payment: Lump sum price offered in Price Schedule A.

1.02 REFERENCE STANDARDS

A. ASTM International (ASTM)

1. ASTM E1728-10 Collection of Settled Dust Samples Using Wipe Sampling Methods for Subsequent Lead Determination

B. Bureau of Reclamation (USBR)

1. RSHS-2009 Reclamation Safety and Health Standards, including revisions posted at http://www.usbr.gov/ssle/safety/RSHS/rshs.

html

C. Code of Federal Regulations (CFR)

1. 29 CFR 1910.1000 Air Contaminants

2. 29 CFR 1910.1025 Lead

3. 29 CFR 1926.55 Gases, Vapors, Fumes, Dusts, and Mists

4. 29 CFR 1926.62 Lead

5. 29 CFR 1926.1118 Arsenic

6. 29 CFR 1926.1127 Cadmium

7. 40 CFR 61, Subpart A National Emission Standards for Hazardous Air Pollutants, General Provisions

8. 40 CFR 117 Determination of Reportable Quantities for Hazardous Substances

9. 40 CFR 261 Identification and Listing of Hazardous Waste

10. 40 CFR 262, Subpart B Standards Applicable to Generators of Hazardous Waste

11. 40 CFR 263 Transporters of Hazardous Waste

02 83 33 - 2

12. 40 CFR 264 Owners and Operators of Hazardous Waste Treatment, Storage, Disposal Facilities

13. 40 CFR 268 Land Disposal Restrictions

14. 40 CFR 302 Designation, Reportable Quantities, and Notification

15. 49 CFR 107 Hazardous Materials Program Procedures

16. 49 CFR Chapter 1 Research and Special Programs Administration, Department of Transportation, Hazardous Materials Regulations

17. 49 CFR 171 General Information, Regulations, and Definitions

18. 49 CFR 172 Hazardous Materials Table; Special Provisions, Hazardous Communications, Emergency Response Information, and Training Requirements

19. 49 CFR 173 Shippers- General Requirements for Shipments and Packagings

20. 49 CFR 178 Specifications for Packagings

D. California Code of Regulations (CCR), Title 22, Department of Toxic Substance Control

1. 22 CCR Division 4.5 Environmental Health Standards for the Management of Hazardous Wastes

2. 22 CCR 66262.20–66262.23 General Requirements, Manifest

3. 22 CCR 66262.12 Identification Numbers for the Generator

1.03 DEFINITIONS

A. Competent Person:

1. For lead hazards: As defined in 29 CFR 1926.62.

2. For designing and implementing technical controls to limit employee exposure to airborne contaminants: As defined in 29 CFR 1926.55.

B. Coatings Containing Heavy Metals:

1. Coating containing lead, heavy metals, and other contaminants which may be present in such quantities that solid waste generated from coating removal operations will exhibit the toxicity characteristic when tested in accordance with 40 CFR 261.24 and/or which present airborne hazards during disturbance and removal operations.

02 83 33 - 3

2. The following metals and compounds may be present in aging paint and coating systems, unless otherwise noted:

a. Arsenic: See 29 CFR 1926.1118.

b. Beryllium.

c. Cadmium: See 29 CFR 1926.1127.

d. Chromium.

e. Lead: See 29 CFR 1926.62.

f. Silver.

g. Vanadium.

h. Zinc

C. COR: Contracting Officer’s Representative.

D. CIH: Certified Industrial Hygienist.

E. DTSC: California Department of Toxic Substance Control

F. ELAP: Environmental Laboratory Accreditation Program recognized as the accrediting authority for California under the National Environmental Laboratory Accreditation Program (NELAP).

G. EPA: United States Environmental Protection Agency.

H. Handling: Includes containment, collection, storage, and transportation.

I. NELAP: National Emissions Standards for Hazardous Air Pollutants.

J. OSHA: Occupational Safety and Health Administration, an agency of the United States Department of Labor.

K. RCRA: Resource Conservation and Recovery Act. The principal federal law that governs the disposal of solid waste and hazardous waste.

L. Regulated Area:

1. Areas on project site where Action Levels are exceeded for hazardous materials, including but not limited to heavy metals.

2. Areas where coating removal operations are performed and isolated by physical boundaries for the prevention of uncontrolled release of hazardous materials.

1.04 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 - Submittals.

B. RSN 02 83 33-1, Resumes, Certificates, and Qualifications:

02 83 33 - 4

1. Qualifications of Onsite Competent Person.

2. CIH:

1) Copy of current valid ABIH certificate.

2) Include address and telephone number.

3. Independent testing laboratory:

1) EPA NELAP laboratory accreditation number for heavy metals.

2) Name, address, and telephone number.

4. First Aid and CPR certificates for persons designated to provide first aid during hazard abatement.

5. Certificates of Employee Training:

a. Has received training in proper handling of hazardous materials in accordance with Federal OSHA.

b. Understands health implications and risks involved, including illnesses possible from exposure to airborne contaminants.

c. Understands use and limits of respiratory equipment to be used.

d. Understands results of monitoring of airborne quantities of contaminants.

e. Document dates of training, training entity, names of instructors, and qualification of instructors.

6. Transporter Qualifications:

a. Written evidence that the transporter to be used is approved for hazardous waste transport in accordance with local, state, and federal regulations.

7. Disposal Facility Qualifications:

a. Written evidence that the facility to be used is approved for hazardous waste disposal in accordance with local, state, and federal regulations.

C. RSN 02 83 33-2, Written Compliance Program for Worker Protection from Coatings Containing Hazardous Materials:

1. Program, for approval, which details engineering controls, administrative controls and personal protective equipment to be implemented for worker protection during coating removal activities and deconstruction and demolition of buildings and equipment.

2. Respirator Usage: Record of diagnostic test and examination by a Board Eligible or Certified Occupational Medicine Physician.

3. Respirator program as required by 29 CFR 1926.1101, 29 CFR 1926.103, and 29 CFR 1926.62 (e)(2).

4. Describe procedures, equipment and training of employees on hazards involved during handling and disposal of coatings.

02 83 33 - 5

5. Program shall be prepared by Certified Industrial Hygienist (CIH).

6. Include plans for decontamination procedures to be used during coating removal activities if required. Describe procedures, equipment and facilities to be used at the site for deconstruction and demolition.

D. RSN 02 83 33-3, Emissions and Exposure Monitoring Plan for Coating Deconstruction and Demolition Generated Debris and Dust:

1. Detailed monitoring plan, designed by a CIH. Include the following:

a. Detailed surface contamination and air monitoring plan for deconstruction and demolition operations.

1) The plan shall include but not be limited to equipment specifications, analytical contaminant list sampling and analysis methods, equipment calibration information, name of person conducting sampling, type and location of sampling (personal or area), collection media specifications, flow rates and duration of samples.

2) The plan shall include laboratory information including name, address and phone number of lab.

3) The plan shall include area monitoring and personal monitoring to show no PEL is exceeded.

4) The plan shall include specification and placement of Critical barrier placement to ensure no migration of dust into facility.

E. RSN 02 83 33-4, Exposure Certifications and Test Results:

1. Air monitoring results and documentation.

2. Describe analytical data delivery package including quality control and quality assurance.

3. Include map indicating location of each sample.

4. Blood Tests for Heavy Metals:

a. Blood lead and zinc protoporphyrin level (ZPP).

F. RSN 02 83 33-5, Preconstruction Test Results:

1. Background Results:

a. Wipe sampling in coating removal work area for heavy metals (including lead).

2. Include map indicating location of each sample.

3. Provide appropriate quality control information to supplement analytical data.

Include from blanks, laboratory control samples with percent recovery, duplicates, matrix spike samples with percent recovery, and other appropriate quality control measures.

02 83 33 - 6

G. RSN 02 83 33-6, Test Results During Work Activities:

1. Test Results During Work Activities:

a. Personal and area air monitoring results for lead concentrations during coating deconstruction and demolition activities. Air samples for total lead are to be analyzed by EPA Method 6010B and EPA Air Method

TO-13A.

2. Include map indicating location of each sample.

3. Provide appropriate quality control information to supplement analytical data.

Include blanks, laboratory control samples with percent recovery, duplicates, matrix spike samples from project with percent recovery, and other appropriate quality control measures.

H. RSN 02 83 33-7, Post-Construction Test Results:

1. Post construction test results for:

a. Area ambient air monitoring results by EPA 6010B and TO-13A for total lead and coal tar components.

b. Wipe sampling in coating deconstruction and demolition work area for heavy metals (including lead).

2. Compare with preconstruction test results for increased contaminant levels.

3. Include map indicating location of each sample.

4. Provide appropriate quality control information to supplement analytical data.

Include from blanks, laboratory control samples with percent recovery, duplicates, matrix spike samples from project with percent recovery, and other appropriate quality control measures.

I. RSN 02 83 33-8, Waste Characterization, Handling, and Disposal Plan:

1. Include:

a. Plan for sampling, testing, characterization of all segregated waste streams:

1) Include required method detection limits.

2) Describe analytical data delivery package including quality control and quality assurance.

3) Plan for collecting samples from waste and analytical test methods that will be used to characterize the waste.

4) Test results of waste for heavy metals.

b. Plan for handling, storage, transporting, and disposal of project-generated waste and cleaning of reusable items.

02 83 33 - 7

c. Plan for testing and disposal of wastewater: Include name, location, and address of proposed treatment facility and contact person at proposed treatment facility.

d. Name, address and qualifications of testing laboratory.

e. Name, address and qualifications of transporter.

f. Name, address and qualifications of disposal facility.

g. Written notice from owner or operator of disposal facility documenting permits and agreement to accept waste generated under this contract.

J. RSN 02 83 33-9, Certificate of Disposal:

1. Certification that all hazardous materials and wastes have been treated and disposed of, including items disposed of using a waste exemption statement.

2. Submit one copy of the completed hazardous waste manifest, signed and dated by the initial transporter in accordance with 40 CFR 262 and signed by the accepting disposal facility.

K. Provide turn-in documents or weight tickets for non-hazardous waste disposal.

1.05 QUALIFICATIONS

A. Certified Industrial Hygienists (CIH): Certified by American Board of Industrial Hygiene (ABIH).

B. Laboratory Qualifications: Certified analytical laboratory meeting requirements of EPA NELAP and California ELAP for heavy metals.

C. Disposal Facility Qualifications for Hazardous Waste: RCRA permitted facility as appropriate.

D. Competent Person:

1. For lead, defined in 29 CFR 1926.62.

2. Experienced in administration and supervision of coating removal containment and ventilation projects under OSHA and EPA regulations.

E. Onsite Supervisor:

1. Competent Person:

a. Capable of identifying existing asbestos and other hazards and selecting appropriate control strategy.

b. Has the authority to take prompt corrective measures to eliminate them.

2. On jobsite during all hazardous waste related activities.

3. Duties include:

02 83 33 - 8

a. Control entry to and from any regulated area;

b. Supervise employee exposure monitoring required by Federal OSHA.

c. Ensure employees wear appropriate PPE, are trained in the use of appropriate methods for exposure control, use proper hygiene methods and decontamination procedures;

d. Ensure engineering controls in use are in proper operating condition and are functioning properly.

e. Responsible for compliance with applicable Federal, State of California, and local requirements.

f. Have input to and sign the Regulated Area Plans.

F. Certified Industrial Hygienists (CIH):

1. Certified by American Board of Industrial Hygiene (ABIH).

2. Completely independent from the contractor according to federal, state or local regulations.

3. Duties:

a. Have input to, review, and sign the Regulated Area Plans.

b. Prepare and perform training.

c. Direct air monitoring.

d. Assist Onsite Supervisor in implementing safety and health requirements during the performance of the required work.

e. Visit the site at least once per week for the duration of hazardous materials activities.

f. Be available for emergencies.

G. On-site Containment and Coating Removal Workers: On-site workers involved with containment and ventilation system, handling of coatings, equipment, and materials that may be contaminated with hazardous materials (including lead).

1. Instructed on dangers of hazardous material (including lead exposure), on respirator use, decontamination, and applicable EPA and OSHA regulations.

H. First Aid and CPR Trained Persons:

1…