Plummer Park Community Center Project.pdf
PDF 163 KB Posted
- Attached to
- Plummer Park Community Center Project
- Solicitation number
- FFS - 0025
- Issued by
- Los Angeles County, California
About this file
This is a bid opportunity document from the City of West Hollywood's Public Works Department for the Plummer Park Community Center Project (Invitation #FFS-0025). The project scope includes removing the existing reception desk, temporary wall, and doors; constructing new partitions; removing and installing an entry double door; and renovating the courtyard, along with associated civil, landscaping, electrical, mechanical, and structural works. The City posted the bid on October 12, 2026, with a bid due date of November 24, 2026, at 1:00 PM (PDT). A mandatory onsite pre-bid meeting is scheduled for October 27, 2026, at 10:00 AM (PDT) at 7377 Santa Monica Blvd, West Hollywood, CA 90069, with attendance required. An online question and answer period is available with a deadline of November 10, 2026, at 10:00 AM (PDT). The project duration is 180 calendar days, and the City will accept electronic bids through the PlanetBids Vendor Portal.
The estimated bid value for this lump sum contract is $1,500,000. Contractors must possess either an A or B license and are required to furnish all labor, incidental trade-related materials, tools, equipment, transportation, mobilization, vehicle expenses, fuel, relevant expenses, taxes, insurances, bonding, traffic control, permits, and public noticing. A bid bond of 10 percent is required at the time of submission, along with a 100 percent performance bond and 100 percent payment bond. Liquidated damages are set at $1,700 per calendar day. Bids should be submitted to the City's owner's agent, Phillip Ticun, at pticun@weho.org. The project location is 8300 Santa Monica Blvd, West Hollywood, California 90069, in Los Angeles County.
View the file
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
City of West Hollywood
Opportunity Detail
Bid Bond
Plummer Park Community Center Project FFS - 0025
Title Plummer Park Community Center Project Invitation # FFS - 0025
Posting Date 10/12/2026 12:10 AM (PDT) Project Stage Bidding Bid Due Date 11/24/2026 1:00 PM (PDT)
Response Format Electronic
Type Bid Response Types Line Items
Bid Bond Type of Award Lump Sum
Categories 90638 - General Construction - Architectural 90900 - Building Construction Services, New (Incl. Maintenance And Repair Services) 90922 - Building Construction, Non-Residential (Office Bldg., Etc.)
91000 - Building Maintenance, Installation And Repair Services 91200 - Construction Services, General (Incl. Maintenance And Repair
Services) License Requirements A and/or B
Department Public Works Address 8300 Santa Monica Blvd
West Hollywood, California 90069
County Los Angeles
Offer Valid Liquidated Damages $1,700 per Calendar Day Estimated Bid Value $1,500,000 Start/Delivery Date
Project Duration 180 Calendar Days
Bid Bond 10.00%
10/21/26, 11:59 AM PlanetBids Vendor Portal https://vendors.planetbids.com/portal/22761/bo/bo-detail/147170#bidInformation 1/3
Pre-Bid Meeting Information
Online Q&A
Contact Information
Description
Payment Bond 100.00% Performance Bond 100.00%
Pre-Bid Meeting Yes Meeting Type Onsite
Date & Time 10/27/2026 10:00 AM (PDT) Address 7377 Santa Monica Blvd, West Hollywood, CA 90069
Attendance Required Yes Additional Details Contractors to meet staff at the entrance to the Community Center.
Online Q&A Yes Q&A Deadline 11/10/2026 10:00 AM (PDT)
Contact Info Phillip Ticun pticun@weho.org
Bids to Owner's Agent
Scope of Services The City seeks to award a construction contract to complete the PLUMMER PARK COMMUNITY CENTER PROJECT - FFS 0025 in the City of West Hollywood. The project scope of work includes removing the existing reception desk, temporary wall, and doors; constructing new partitions; removing and installing the entry double door; and renovating the courtyard, along with associated civil, landscaping, electrical, mechanical, and structural works. Contractors shall furnish all labor, incidental trade-related materials, tools, equipment, transportation/ mobilization/ vehicle expenses/ fuel, relevant expenses, taxes, insurances, bonding, traffic control, permits, and public noticing, as required, to accomplish the work in accordance with the City’s contract requirements/specifications.
Other Details
Notes Special Notices
Local Programs & Policies
10/21/26, 11:59 AM PlanetBids Vendor Portal https://vendors.planetbids.com/portal/22761/bo/bo-detail/147170#bidInformation 2/3
Search & Bid on Thousands of Contracts www.vendorline.com
10/21/26, 11:59 AM PlanetBids Vendor Portal https://vendors.planetbids.com/portal/22761/bo/bo-detail/147170#bidInformation 3/3 https://vendor.planetbids.com/
File details come from the government source that posted it. Updated .