N0016721R0017.pdf

1300945961

This RFP

COMPETITION REQUIREMENTS: TOTAL SMALL BUSIINESS SET ASIDES

PROCUREMENT METHOD: CONTRACTING BY NEGOTIATION

SOURCE SELECTIOIN PROCESS: LPTA

TYPE OF CONTRACT: FIRM FIXED PRICE

ESTIMATED COST OF CONSTRUCTION: Betw een $100,000 and $250,000

NAICS CODES: 236220 SIZE STANDARD: 36.5M: FEDERAL SUPPLY CODE: Y1PZ

ALL PREPROPOSAL INQUIRIES (PPI's). MUST BE MADE IN WRITING AND EMAILED TO BROOKS.MCLEAN@NAVY.MIL, NOT LATER THAN 3

CALENDAR DAYS PRIOR TO THE PROPOSAL DUE DATE

RONALD V SMILEY 757-410-0512

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

21-Oct-2021

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______15 calendar days and complete it w ithin ________35 calendar days after receiving aw ard, notice to proceed. This performance period is mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________04 Nov 2021 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

NAVAL SURFACE WARFARE CENTER CARDEROCK

RONALD V. SMILEY

757-410-0512 RONALD.SMILEY3@NAVY.MIL

904 CORPORATE LANE

CHESAPEAKE VA 23320

N00167

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 757-410-0512 TEL: FAX:

N0016721R0017 42

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

N0016721R0017

Section 00 00 00 - Procurement and Contracting Requirements

INSTRUCTIONS TO OFFEROR

GENERAL INFORMATION

A. REQUEST FOR Pre Proposal Inquiries (PPI)

Offerors who determine that the technical and or contractual requirements of this RFP require clarification(s) in order to permit submittal of a responsive proposal shall submit all questions in writing. Additionally, all inquiries shall be submitted using the Pre Proposal Inquiries form attached to this solicitation as (Attachment A).

All inquiries shall be submitted via email to Brooks McLean at brooks.mclean@navy.mil or Crystal Chatmon at crystal.y.chatmon.civ@us.navy.mil no later than 25 October 2021, Monday at 2:00 PM EDT. A response will be published as an amendment to the solicitation.

B. SITE VISIT INFORMATION

1. A site visit shall be coordinated and conducted 3 days from the issue of solicitation with Kelly Mick 757-492-4222 (office) 757-285-4188 (cell) at kelly.mick@navy.mil and Brock Aron at brock.aron@navy.mil, cell

(757) 288-3018, office (757) 492-8794.

Naval Operation Base Norfolk 1052 Pocahontas Dr, Bldg –V-47 Norfolk, VA 23511.

2. The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offeror is urged and expected to inspect the site where the work will be performed.

C. PROPOSAL SUBMISSION REQUIREMENTS

Proposal Due Date: No later than November 4 2021 at 10:00 AM EDT Proposals may be sent via email to brooks.mclean@navy.mil or crystal.y.chatmon.civ@us.navy.mil

D. SOLICITATION SUBMITTAL REQUIREMENTS:

The offeror shall submit one (1) marked Original”, one (1) marked copies, and one (1) electronic copy (CD) of the solicitation submittal requirements identified below. In case of variation, the original hard copy proposal takes precedence over electronic or copies.

• Text pages 8 ½ x 11 format

• 12 point font, Times New Roman

• One complete electronic copy of the entire proposal as a single .pdf searchable file on a CDROM (include with the “Original” submission).

• Include a cover page with Solicitation Number, Solicitation Title, Prime Contractor Name, Address,Phone Number, Fax Number, DUNS, Cage Code, Point of Contact, Title, phone number, and email address.

E. BASIS FOR AWARD

1. The Government reserves the right to eliminate from consideration for award any or all offers at any time prior to award of the contract; to negotiate with offerors in the competitive range; and to award the contract to the offeror submitting the lowest priced, technically acceptable offer.

2. The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). The Government reserves the right to conduct discussions if the

Contracting Officer later determines them to be necessary. In addition, if the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

3. The LPTA process is selected as appropriate for this acquisition because the best value is expected to result from selection of the technically acceptable proposal with the lowest evaluated price.

4. An overall non-price factors rating must be at least “ACCEPTABLE” in order to be eligible for award.

An “UNACCEPTABLE” rating in any factor results in the overall non-price factors proposal being rated “UNACCEPTABLE” unless corrected through discussions. An overall non-price factors rating of “UNACCEPTABLE” makes a proposal ineligible for award.

F. EVALUATION FACTORS FOR AWARD

1. The Government shall evaluate each offeror on price and the following non-price factor:

Factor 1 – Technical Solution

2. The proposed Task Order will be awarded to the technically acceptable offer with the lowest evaluated price.

PRICE

A. Price Submission:

1. Attachment A PRICE PROPOSAL FORM

Submit cost on the price proposal form provided in solicitation.

B. Basis of Evaluation:

1. The Government will evaluate price based on the total price. Total price consists of the basic requirements and all option items. In accordance with FAR 52.217-5, evaluation of options will not obligate the Government to exercise the option(s). Analysis will be performed by one or more of the following techniques to ensure a fair and reasonable price:

a. Comparison of proposed prices received in response to the RFP.

b. Comparison of proposed prices with the Independent Government Cost Estimate (IGCE).

NON-PRICE FACTORS

A. Solicitation Submittal Requirements:

1. TECHNICAL : Offeror shall submit one (1), marked “Original” with the following characteristics:

• Text 8 ½ x 11 format, Times New Roman, 12 point font

• 11 x 17 for drawings in Factor 1 – Technical Solution.

• Page count excludes cover page and tabs. PAGES THAT EXCEED THE PAGE LIMITATION SHALL

NOT BE EVALUATED.

• Include a cover page with Solicitation Number, Solicitation Title, Prime Contractor Name, Address, Phone Number, Fax Number, DUNS, Cage Code, Point of Contact, Title, phone number, and email address. Cover Page will not be included in the page count.

TECHNICAL FACTOR 1 – TECHNICAL SOLUTION

(a) Solicitation Submittal Requirements:

Provide a narrative describing the technical approach to the project that meets the requirements of the RFP.

Narrative shall not exceed three (3) double-sided pages (or six (6) single-sided pages).

(a) Basis of Evaluation:

The Government will evaluate the narrative considering the extent to which the Offeror demonstrates a clear understanding of the requirements of the project.

STATEMENT OF WORK

PERFORMANCE WORK STATEMENT (PWS)

for Rental of a Temporary Structure

1.0 DESCRIPTION OF SERVICES/INTRODUCTION: An upcoming project is in need of a temporary structure with nominal dimensions of 50-feet wide, 80-feet long and no more than 35-feet high to be located at Naval Station Norfolk within the Vicinity of Bldg V-47. The structure will need to onsite by 1 November 2021.

2.0 BACKGROUND: The project team will be doing testing on a boat and will need dedicated space to store the boat and its prime mover. Due to the project duration and amount of equipment involved with testing (spares, tools, etc) dedicated space is needed to segregate the boat from other ongoing operations at V47.

3.0 OBJECTIVE:

3.1 The contractor shall be responsible for providing any and all services and/or materials required to meet the requirements of this SOW. The contractor shall be responsible for the delivery to NOB Norfolk, VA, Building V-47 of all materials and/or personnel required to meet the requirements of this

SOW.

3.2 The contractor shall deliver and build the structure.

3.3 The contractor shall provide all labor, materials required, ancillary materials required and transportation of materials and equipment necessary to meet the requirements of the structure listed within this statement of work.

3.4 The structure shall be capable of being erected on an area that will consist of asphalt mostly with some concrete, grass and dirt with 90 degree, 6 inch variations in height. Visible seams between the variable height of the concrete pad and the bottom surface of the structure walls are acceptable. The structure shall not require any permanent foundation modifications to the NOB Norfolk, Building V-47 concrete pad.

3.5 The structure shall be erected by 1 December 2021.

3.6 The structure shall measure have nominal measurements of 50’wide and 80’ long.

3.7 The overall height of the structure shall not exceed 35 feet.

3.8 The structure shall have overhead lighting that sufficiently illuminates the structure.

3.9 The interior space of the structure shall be a clear span with no internal supports.

3.10 The structure shall have two roll up doors. The doors shall be electrically operated. A roll up door shall be placed on each of the 50-foot wide ends of the structure. The roll up doors shall be 18’ high and 16’wide.

3.11 The structure shall have two personnel entry/exit doors. The width of these doors shall be no less than 3 feet and the height shall be no less than 6 feet, 8 inches. The location of these doors within the structure is optional.

3.12 The structure shall be capable of withstanding sustained 90 mph wind loading.

3.13 The structure must be constructed from fire retardant materials.

3.14 The structure shall not require an inflation system for integrity.

3.15 If the structure is constructed with fabric, heavyweight material shall be used.

3.16 Contractor is responsible for submitting any necessary base access requests.

3.17 The structure shall have an exhaust fan.

4.0 SPECIAL QUALIFICATIONS:

4.1 N/A

5.0 GOVERNMENT FURNISHED EQUIPMENT/PROPERTY/INFORMATION

5.1 N/A

6.0 DELIVERABLES

6.1 Delivery and Installation of a temporary structure.

7.0 SECURITY REQUIREMENTS: N/A

8.0 ECMRA Standard Language – NMCARS April 2018:

The contractor shall report contractor labor hours (including subcontractor labor hours) required for performance of services provided under this contract for NAVSEA NSWCCD via a secure data collection site. Contracted services excluded from reporting are based on Product Service Codes (PSCs). The excluded PSCs are:

(1) W, Lease/Rental of Equipment;

(2) X, Lease/Rental of Facilities;

(3) Y, Construction of Structures and Facilities;

(4) D, Automatic Data Processing and Telecommunications, IT and Telecom- Telecommunications Transmission (D304) and Internet (D322) ONLY;

(5) S, Utilities ONLY;

(6) V, Freight and Shipping ONLY.

The contractor is required to completely fill in all required data fields using the following web address:

https://www.ecmra.mil.

Reporting inputs will be for the labor executed during the period of performance during each Government fiscal year (FY), which runs October 1 through September 30. While inputs may be reported any time during the FY, all data shall be reported no later than October 31 of each calendar year. Contractors may direct questions to the help desk, linked at https://www.ecmra.mil.

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Each

TEMPORARY STRUCTURE

FFP

Temporary structure with nominal dimensions of 50-feet wide, 80-feet long and no more than 35-feet high to be located at Naval Station Norfolk within the Vicinity of Bldg V-47 FOB: Destination

NSN: 5450012627602

VENDOR PART NR: 100001673215-1475

PURCHASE REQUEST NUMBER: 1300945961

PSC CD: 5450

NET AMT

0002 1 Lite

CONSTRUCT STRUCTURE

FFP

THE CONTRACTOR WILL CONSTRUCT THE TEMPORARY STRUCTURED

BY PROVIDING ALL LABOR, MATERIAL AND EQUIPMENT REQUIRED

TO PERFORM THIS TASK.

FOB: Destination

VENDOR PART NR: 100001673215-1475

PSC CD: E1GZ

0003 1 Lite

SHIPPING

FFP

COST OF SHIPPING

FOB: Destination

VENDOR PART NR: 100001673215-1475

PSC CD: E1GZ

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 04-OCT-2021 1 N/A

FOB: Destination

0002 POP 12-JUL-2021 TO

30-SEP-2022

N/A N/A

0003 POP 12-JUL-2021 TO

30-SEP-2022

N/A N/A

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions JUN 2020 52.203-2 Certificate Of Independent Price Determination APR 1985 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

JUN 2020

52.203-13 Contractor Code of Business Ethics and Conduct JUN 2020 52.203-14 Display of Hotline Poster(s) JUN 2020 52.203-15 Whistleblower Protections Under the American Recovery and

Reinvestment Act of 2009

JUN 2010

52.203-16 Preventing Personal Conflicts of Interest JUN 2020 52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

JUN 2020

52.203-18 Prohibition on Contracting With Entities That Require Certain Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements

JAN 2017

52.204-1 Approval of Contract DEC 1989 52.204-2 Security Requirements MAR 2021 52.204-2 Alt II Security Requirements (MAR 2021) - Alternate II APR 1984 52.204-3 Taxpayer Identification OCT 1998 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-5 Women-Owned Business (Other Than Small Business) OCT 2014 52.204-6 Unique Entity Identifier OCT 2016 52.204-7 System for Award Management OCT 2018 52.204-8 Annual Representations and Certifications SEP 2021 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

JUN 2020

52.204-12 Unique Entity Identifier Maintenance OCT 2016 52.204-13 System for Award Management Maintenance OCT 2018 52.204-14 Service Contract Reporting Requirements OCT 2016 52.204-15 Service Contract Reporting Requirements for Indefinite-

Delivery Contracts

OCT 2016

52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-17 Ownership or Control of Offeror AUG 2020 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-20 Predecessor of Offeror AUG 2020 52.204-21 Basic Safeguarding of Covered Contractor Information

Systems

JUN 2016

52.204-22 Alternative Line Item Proposal JAN 2017 52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

JUL 2018

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

OCT 2020

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

AUG 2020

52.207-1 Notice Of Standard Competition MAY 2006 52.207-2 Notice Of Streamlined Competition MAY 2006 52.207-3 Right of First Refusal of Employment MAY 2006 52.207-4 Economic Purchase Quantity-Supplies AUG 1987 52.207-5 Option To Purchase Equipment FEB 1995 52.207-6 Solicitation of Offers from Small Business Concerns and

Small Business Teaming Arrangements or Joint Ventures (Multiple-Award Contracts)

OCT 2016

52.208-4 Vehicle Lease Payments APR 1984 52.208-5 Condition of Leased Vehicles APR 1984 52.208-6 Marking of Leased Vehicles APR 1984 52.208-7 Tagging of Leased Vehicles MAY 1986 52.208-8 Required Sources for Helium and Helium Usage Data AUG 2018 52.209-1 Qualification Requirements FEB 1995 52.209-2 Prohibition on Contracting with Inverted Domestic

Corporations--Representation

NOV 2015

52.209-5 Certification Regarding Responsibility Matters AUG 2020 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

JUN 2020

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

OCT 2018

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law

FEB 2016

52.211-1 Availability of Specifications Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29

AUG 1998

52.211-2 Availability of Specifications, Standards, and Data Item Descriptions Listed in the Acquisition Streamlining and Standardization Information System (ASSIST)

JUL 2021

52.211-3 Availability of Specifications Not Listed in the GSA Index of Federal Specifications, Standards, and Commercial Item Descriptions

JUN 1988

52.211-8 Time of Delivery JUN 1997 52.211-10 Commencement, Prosecution, and Completion of Work APR 1984 52.211-12 Liquidated Damages--Construction SEP 2000 52.211-13 Time Extensions SEP 2000 52.211-13 Time Extensions SEP 2000 52.211-14 Notice Of Priority Rating For National Defense, Emergency

Preparedness, and Energy Program Use

APR 2008

52.211-15 Defense Priority And Allocation Requirements APR 2008 52.211-18 Variation in Estimated Quantity APR 1984 52.214-18 Preparation of Bids-Construction APR 1984 52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2017 52.215-2 Audit and Records--Negotiation JUN 2020 52.215-10 Price Reduction for Defective Certified Cost or Pricing Data AUG 2011 52.215-11 Price Reduction for Defective Certified Cost or Pricing Data--

Modifications

JUN 2020

52.215-12 Subcontractor Certified Cost or Pricing Data JUN 2020 52.215-13 Subcontractor Certified Cost or Pricing Data--Modifications JUN 2020 52.215-15 Pension Adjustments and Asset Reversions OCT 2010 52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits

(PRB) Other than Pensions

JUL 2005

52.215-19 Notification of Ownership Changes OCT 1997 52.215-20 Requirements for Certified Cost or Pricing Data or

Information Other Than Certified Cost or Pricing Data

OCT 2010

52.216-27 Single or Multiple Awards OCT 1995 52.217-5 Evaluation Of Options JUL 1990 52.219-8 Utilization of Small Business Concerns OCT 2018 52.219-11 Special 8(a) Contract Conditions JAN 2017 52.219-12 Special 8(a) Subcontract Conditions OCT 2019 52.219-14 Limitations On Subcontracting SEP 2021 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work

MAY 2014

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-30 Construction Wage Rate Requirements--Price Adjustment (None or Separately Specified Method)

AUG 2018

52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-36 Equal Opportunity for Workers with Disabilities JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons OCT 2020 52.222-54 Employment Eligibility Verification OCT 2015 52.222-55 Minimum Wages Under Executive Order 13658 NOV 2020 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data FEB 2021 52.223-6 Drug-Free Workplace MAY 2001 52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration

Equipment and Air Conditioners.

JUN 2016

52.223-15 Energy Efficiency in Energy-Consuming Products MAY 2020 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

AUG 2018

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

JUN 2020

52.227-1 Authorization and Consent JUN 2020 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-1 Bid Guarantee SEP 1996 52.228-2 Additional Bond Security OCT 1997 52.228-11 Individual Surety--Pledge of Assets FEB 2021 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.229-4 Federal, State, And Local Taxes (State and Local

Adjustments)

FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-17 Interest MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-37 Multiple Payment Arrangements MAY 1999 52.233-1 Disputes MAY 2014 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.234-4 Earned Value Management System NOV 2016 52.236-1 Performance of Work by the Contractor APR 1984 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-28 Preparation of Proposals--Construction OCT 1997 52.237-2 Protection Of Government Buildings, Equipment, And

Vegetation

APR 1984

52.237-4 Payment by Government to Contractor APR 1984 52.241-2 Order of Precedence - Utilities FEB 1995 52.241-3 Scope and Duration of Contract FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.243-1 Changes--Fixed Price AUG 1987 52.243-1 Alt III Changes--Fixed Price (Aug 1987) - Alternate III APR 1984 52.243-4 Changes JUN 2007 52.243-5 Changes and Changed Conditions APR 1984 52.244-2 Subcontracts JUN 2020 52.244-6 Subcontracts for Commercial Items JUL 2021 52.245-1 Government Property SEP 2021 52.245-2 Government Property Installation Operation Services APR 2012 52.246-2 Inspection Of Supplies--Fixed Price AUG 1996 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-1 Value Engineering JUN 2020 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984 52.249-14 Excusable Delays APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7003 Agency Office of the Inspector General AUG 2019 252.203-7004 Display of Hotline Posters AUG 2019 252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019 252.204-7006 Billing Instructions OCT 2005 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.211-7007 Reporting of Government-Furnished Property AUG 2012 252.215-7006 Use of Employees or Individual Subcontractors Who Are

Members of the Selected Reserve

OCT 2008

252.222-7004 Compliance With Spanish Social Security Laws and Regulations

JUN 1997

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements DEC 2010

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.225-7030 Restriction On Acquisition Of Carbon, Alloy, And Armor

Steel Plate

DEC 2006

252.225-7031 Secondary Arab Boycott Of Israel JUN 2005 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

APR 2019

252.227-7013 Rights in Technical Data--Noncommercial Items FEB 2014 252.227-7016 Rights in Bid or Proposal Information JAN 2011 252.227-7022 Government Rights (Unlimited) MAR 1979 252.227-7023 Drawings and Other Data to become Property of Government MAR 1979 252.227-7025 Limitations on the Use or Disclosure of Government-

Furnished Information Marked with Restrictive Legends

MAY 2013

252.227-7033 Rights in Shop Drawings APR 1966 252.227-7037 Validation of Restrictive Markings on Technical Data SEP 2016 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7002 Obstruction of Navigable Waterways DEC 1991 252.236-7004 Payment for Mobilization and Demobilization DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.245-7001 Tagging, Labeling, and Marking of Government-Furnished

Property

APR 2012

252.245-7002 Reporting Loss of Government Property JAN 2021 252.245-7003 Contractor Property Management System Administration APR 2012 252.245-7004 Reporting, Reutilization, and Disposal DEC 2017 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (SEP 2021)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 236220.

(2) The small business size standard is $39,500,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA- Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.209-12 CERTIFICATION REGARDING TAX MATTERS (OCT 2020)

(a) This provision implements section 523 of Division B of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts.

(b) If the Offeror is proposing a total contract price that will exceed $5.5 million (including options), the Offeror shall certify that, to the best of its knowledge and belief, it--

(1) Has [ ] filed all Federal tax returns required during the three years preceding the certification;

(2) Has not [ ] been convicted of a criminal offense under the Internal Revenue Code of 1986; and

(3) Has not [ ], more than 90 days prior to certification, been notified of any unpaid Federal tax assessment for which the liability remains unsatisfied, unless the assessment is the subject of an installment agreement or offer in compromise that has been approved by the Internal Revenue Service and is not in default, or the assessment is the subject of a non-frivolous administrative or judicial proceeding.

52.211-1 AVAILABILITY OF SPECIFICATIONS LISTED IN THE GSA INDEX OF FEDERAL

SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS, FPMR PART 101-29 (AUG 1998)

(a) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service, Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(b) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (a) of this provision.

Additional copies will be issued for a fee.

52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL

SPECIFICATIONS, STANDARDS AND COMMERCIAL ITEM DESCRIPTIONS (JUN 1988)

The specifications cited in this solicitation may be obtained from:

(Activity) ____________________________________ (Complete address) _____________________________ (Telephone number) _____________________________ (Person to be contacted) _______________________

The request should identify the solicitation number and the specification requested by date, title, and number, as cited in the solicitation.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a contract resulting from this solicitation.

52.216-9 FIXED FEE--CONSTRUCTION (JUN 2011)

(a) The Government shall pay to the Contractor for performing this contract the fixed fee specified in the Schedule.

(b) Payment of the fixed fee shall be made in installments based upon the percentage of completion of the work as determined from estimates submitted to and approved by the Contracting Officer, but subject to the withholding provisions of paragraph (c) below.

(c) The Contracting Officer shall withhold a reserve not to exceed 15 percent of the total fixed fee or $100,000, whichever is less, to protect the Government's interest. The Contracting Officer shall release 75 percent of all fee withholds under this contract after receipt of an adequate certified final indirect cost rate proposal covering the year of physical completion of this contract, provided the Contractor has satisfied all other contract terms and conditions, including the submission of the final patent and royalty reports, and is not delinquent in submitting final vouchers on prior years' settlements. The Contracting Officer may release up to 90 percent of the fee withholds under this contract based on the Contractor's past performance related to the submission and settlement of final indirect cost rate proposals.

52.216-22 INDEFINITE QUANTITY. (OCT 1995)

(a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract.

(b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum". The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum".

(c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations.

(d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time…