Amendment_0005_with_attachments.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 11. CONTRACT ID CODE I PA~E OF PAGES

I 24

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 15. PROJECT NO. (If applicable)

0005 04/27/2015

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE I Federal Bureau of Prisons, Field Acquisition Offi ce Federal Bureau of Prisons US Armed Forces Reserve Complex FCI Sandstone 346 Marine Forces Drive 2300 County Road 29 Grand Prairie, TX 75051 Sandstone, MN 55072

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION

>-- NO.

IFBP04131500001

9B. DATED (SEE ITEM 11)

01/08/2015

10A. MODIFICATION OF CONTRACT/ORDER NO.

D 10B. DATED (SEE ITEM 13)

CODE j FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

~ The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers D is extended , ~ is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE

PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and th is amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

D D

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

D

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor D is not, D is required to sign this document and return --- - - copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The purpose of Amendment 0005 is to:

1. Establish a receipt of bid deadline of 05/12/2015 by 2:00 P. M. CST,

2. Remove line 2.1F from Part 2-Product, of section 26 12 00 - Electrical from original specifications and Incorporate the attached revised Section 26 12 00 - Electrica l in to the specifications, and

3. Incorporate the most recent version of the construction wage rates, general decision number MN150079, dated 4/17/2015 (attached), is hereby incorporated . All prior versions are removed .

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 1 OA, as heretofore changed , remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

Michelle Morgan, Contract Specialist

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

NSN 7540-01-152-8070

Previous edition unusable

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

(Signature of Contracting Officer) 04/27/2015

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

INSTRUCTIONS

Instructions for items other than those that are self-explanatory, are as follows :

(a) Item 1 (Contract ID Code) . Insert the contract type identification code that appears in the title block of the contract being modified.

(b) Item 3 (Effective date).

(1) For a solicitation amendment, change order, or administrative change, the effective date shall be the issue date of the amendment, change order, or administrative change.

(2) For a supplemental agreement, the effective date shall be the date agreed to by the contracting parties.

(3) For a modification issued as an initial or confirming notice of termination for the convenience of the Government, the effective date and the modification number of the confirming notice shall be the same as the effective date and modification number of the initial notice.

(4) For a modification converting a termination for default to a termination for the convenience of the Government, the effective date shall be the same as the effective date of the termination for default.

(5) For a modification confirming the contacting officer's determination of the amount due in settlement of a contract termination , the effective date shall be the same as the effective date of the initial decision .

(c) Item 6 (Issued By). Insert the name and address of the issuing office. If applicable, insert the appropriate issuing office code in the code block.

(d) Item 8 (Name and Address of Contractor). For modifications to a contract or order, enter the contractor's name, address, and code as shown in the original contract or order, unless changed by this or a previous modification .

(e) Item 9, (Amendment of Solicitation No. - Dated) , and 10, (Modification of Contract/Order No. - Dated). Check the appropriate box and in the corresponding blanks insert the number and date of the original solicitation , contract, or order.

(f) Item 12 (Accounting and Appropriation Data).

When appropriate, indicate the impact of the modification on each affected accounting classification by inserting one of the following entries.

(1) Accounting classification -···············-······-··-··-----··-· Net increase $ ····-··-···-··-··--··-·--··········

(2) Accounting classification Net decrease $ ·-··-··--··-·---··-·-····-·---·--·····-

NOTE: If there are changes to multiple accounting classifications that cannot be placed in block 12, insert an asterisk and the words "See continuation sheet".

(g) Item 13. Check the appropriate box to indicate the type of modification . Insert in the corresponding blank the authority under which the modification is issued. Check whether or not contractor must sign this document. (See FAR 43.103.)

(h) Item 14 (Description of Amendment/Modification) .

(1) Organize amendments or modifications under the appropriate Uniform Contract Format (UCF) section headings from the applicable solicitation or contract. The UCF table of contents , however, shall not be set forth in this document

(2) Indicate the impact of the modification on the overall total contract price by inserting one of the following entries:

(i) Total contract price increased by$ ·-·-··--·····-···-····

(ii) Total contract price decreased by$

(iii) Total contract price unchanged.

(3) State reason for modification .

(4) When removing , reinstating, or adding funds, identify the contract items and accounting classifications.

(5) When the SF 30 is used to reflect a determination by the contracting officer of the amount due in settlement of a contract terminated for the convenience of the Government, the entry in Item 14 of the modification may be limited to --

(i) A reference to the letter determination ; and

(ii) A statement of the net amount determined to be due in settlement of the contract.

(6) Include subject matter or short title of solicitation/contract where feasible.

(i) Item 168. The contracting officer's signature is not required on solicitation amendments. The contracting officer's signature is normally affixed last on supplemental agreements.

STANDARD FORM 30 (REV. 10-83) BACK

B 4f~~~ri ns ~1'$flU®llPR~LAllEOOilt> 9Q

FACILITIES)?trutle!OM3, 2 14 CONTllACTOR RESPONSIOLE FOR

THE DIMENSIONS, QUANTITIES,

SECTION 26 12 00 - ELECTRICAL AND CONFORMITY WITH THE

CONTRACT DOCUMENTS

PART 1 - GENERAL

APPROVED

D MAKENOTED

CORRECTIONS

1.1 Electrical modifications

CJ NOT APPROVED

RESUBMIT

A.

B.

C.

D.

1.2

A.

The Contractor shall remove and replace exi ting transfor ers US4, T7, 8, , ~1 ,.)) T9 and T 12. PROJECr R ~> ,) J-<J-i•"' it. n. 60 t -i .\ i· The Contractor shall remove, relocate, re lace a S4 approximately 50 feet south of its current location. From inside the Facilities tunnel to outside of food service on the lower compound. Re-feed high voltage wiring approximately 100 feet from the Old Powerhouse High Voltage room to the new US4 transformer.

The Contractor will replace T12 with properly configured transformer to include an above ground high voltage tap .

The Contractor will ensure that all wire sizing and grounding is applicable to each transformer.

REFERENCES

Standards - The design and construction of the facility shall comply with the following :

1. American National Standards Institute

ANSI C57.12.26 Transformers - Pad-mounted, Compartmental Type, Self Cooled, Three-phase Distribution Transformers with High Voltage Bushings, 2500 kVA and Smaller

2. American Society for Testing and Materials

ASTM D 117 Guide for sampling, Test Methods, and Specifications for Oils of Petroleum Origin

ASTM D 92 Test Methods for Flash and Fire Points by Cleveland Open Cup

3. Institute of Electrical and Electronic Engineers

IEEE 386 Separable Insulated Connector Systems for Power Distribu tion Systems above 600 V

IEEE C2 National Electrical Safety Code

SITE IMPROVEMENTS - ELECTRICAL 26 12 00 - 4

Sensitive But Unclassined - SBU

Federal Bureau of Prisons FCI Sandstone, Project 4A9Q

October 28, 2014

IEEE C37.47 Specifications for Distribution Fuse Disconnecting Switch es, Fuse Supports, and Current-Limiting Fuses

IEEE C57.12.00 General Requirements for Liquid-Immersed Distri bution, Power, and Regulating Transformers

IEEE C57.12.80 Terminology for Power and Distribution Transformers

IEEE C57.12.90 Test Code for Liquid-Immersed Distribution, Power, and Regulating Transformers

IEEE C62.11 Metal Oxide Surge Arrestors for AC Power Circuits

IEEE Std 1 General Principles for Temperature Limits in the Rat ing of Electrical Equipment and for the Evaluation of Electrical Insu lation

IEEE Std 4 Standard Techniques for High Voltage Testing

4. lnterNational Electrical Testing Association {NETA)

NETA ATS Electrical Power Distribution Equipment and Systems

1.3 SYSTEMS INTERPRETATION & QUALITY

A. Furnish and install all materials for the electrical system, so as to provide a functioning system in compliance with performance requirements specified.

The omission of express reference to any parts necessary for, or reasonably incidental to, a complete installation shall not be construed as a release from furnishing such parts.

B. No exclusions from, or limitations in, the language used in drawings and/or specifications shall be interpreted as meaning that the appurtenances or accessories necessary to complete any required system or item of equipment are to be omitted.

C. All equipment and materials required for installation under these specifications shall be installed new {less than one year from date of manufacture) and without blemish or defect.

D. All material and equipment shall be listed, labeled or certified by Underwriters' Laboratories, Inc. where such standards have been established. Equipment and material which are not covered by UL Standard will be accepted provided equipment and material is listed, labeled, certified

SITE IMPROVEMENTS - ELECTRICAL 2612 00 -4

Sensitive But Unclassified - SBU

October 28, 2014 or otherwise determined to meet safety requirements of a nationally recognized testing laboratory. Equipment of a class that no nationally recognized testing laboratory accepts, certifies, lists, labels, or determines to be safe will be considered if inspected or tested in accordance with national industrial standards such as NEC, ANSI and IEEE. Evidence of compliance shall include certified test reports and definitive shop drawings.

E. Coordinate the Work of this Section with that of other Sections as required ensuring that the entire work of this Project shall be carried out in an orderly, complete and coordinated fashion. Check proposed equipment against space available, and make sure that proposed equipment can be accommodated. If interferences occur, direct concerns in writing to the Contracting Officer for resolution; or, the Contractor shall at his/her own expense shall provide proper materials, equipment, and labor to correct any damage due to defects in his/her work caused by such interferences.

F. The General Contractor shall be responsible for coordination of all equipment, wiring, installation, and testing necessary for a fully functional transformer system, provided by this contract.

1.4 SUBMITTALS

A Inspection and test reports.

B. Provide calculations for determining the kVA rating of transformers provided.

1.5 EXTRA MATERIALS

A Fuses: Provide six of each type and rating used. Include spares for fusible devices. Fuses shall match type installed and be packaged with protective covering for storage and identified with labels describing contents.

PART 2 - PRODUCTS

2.1 EQUIPMENT

A 60 Hertz, 95 KV BIL, liquid immersed and cooled, two winding, insulated, high efficiency, low sound level, low profile type.

SITE IMPROVEMENTS - ELECTRICAL 261200-4

Sensitive But Unclasslfled - SBU

October 28, 2014

8. Coils shall be foil wound or wire wound, without splices, and shall be mineral oil insulated, having average temperature rise of 55/65°C (131/149°F), for continuous operation in ANSI defined usual service conditions of 30°C (86°F) average ambient, and 40°C (104°F) maximum ambient, 900 m (2953') elevation.

C. Windings shall be copper. Aluminum windings shall not be permitted.

D. Provide four taps, 2 - 2 1/2% above and 2 - 2 1/2% below nominal primary voltage.

E. Enclosure shall have the following features:

1. Externally operated tap changer.

2. Liquid level gauge.

3. Dial thermometer.

PART 3 - EXECUTION

3.1 FIELD QUALITY CONTROL

A. All transformers shall be tested and inspected by a qualified testing agency, independent from the installing contractor. Tests and inspections shall be per manufacturer's recommendations and by the lnterNational Electrical Testing Association (NETA), Section 7.2.2.

END OF SECTION 32 30 00

SITE IMPROVEMENTS - ELECTRICAL 2612 00 -4

Sensitive But Unclasalfied - SBU

Page 1of18

General Dec i sion Number : MN150079 04/17/2015 MN79

Superseded General Decision Number : MN20140079

State : Minnesota

Construction Type : Building

Counties : Aitkin , Beltrami , Clearwater , Cook , Hubbard , Itasca , Kanabec , Koochiching , Lake of the Woods , Mahnomen , Pi ne and Wadena Counties in Minnesota .

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories) .

Note : Executive Order (EO) 13658 establishes an hourly minimum wage of $10 . 10 for 2015 that applies to al l contracts subjec t to the Davis - Bacon Act for which the solicitation is issued on or after January 1 , 2015 . If this contract is covered by the EO , the contractor must pay all workers in any classification listed on this wage determination at least $10 .1 0 (or the applicable wage rate listed on this wage determination , if it is higher) for all hours spent performing on the contract . The EO minimum wage rate will be adjusted annually . Addi tiona l information on contractor requirements and worker protections under the EO is availab l e at www . dol . gov/whd/govcontracts .

Modification Number

Publication Date 01/02/2015 03/27/2015 04/17/2015

ASBE0049-001 06/01/2014

ALL COUNTIES EXCEPT MAHNOMEN

Asbestos Workers/Insulator (Includes the application of all insulating materials , protective coverings , coatings & finishes to all

Rates types of mechanical systems) ..... $ 26 . 82

* ASBE0133 - 001 07/01/2014

http: //www.wdol.gov/wdol/scafiles/davisbacon/MN79.dvb?v=2

Fringes

23 . 80

4/27/2015

MAHNOMEN COUNTY

ASBESTOS WORKER/HEAT & FROST

INSULATOR (Includes application of all insulating materials , protective coverings , coatings & finishes to all types of

Rates mechanical systems) . ....... . .... . $ 28 . 62

BOIL0647 - 001 01/01/2013

Rates

BOILERMAKER ...................... $ 32 . 4 0

BRMNOOOl - 022 05/01/2014

AITKIN (Western half)

Rates

BRICKLAYER ....................... $ 32 . 36

BRMN0003-001 05/01/2014

Fringes

14 . 50

Fringes

25 . 37

Fringes

16 . 87

AITKIN (Eastern ha l f , on a line with the northeast boundary line of Mille Lacs County) , COOK , KANABEC & PINE COUNTIES

Rates Fringes

BRICKLAYER ....................... $ 32 . 20 20 . 10

BRMN0015-015 05/01/2014

Page 2of18

BELTRAMI , CLEARWATER , HUBBARD , KOOCHICHING , LAKE OF THE WOODS ,

MAHNOMEN & WADENA

Rates Fringes

BRICKLAYER ...... . ................ $ 31 . 13 16 . 59

BRMN0016 - 001 05/01/2014

ITASCA COUNTY

http://www.wdol.gov/wdo l/scafiles/ davis bacon/MN79 .dvb ?v=2 4/27/2015

Page 3of18

Rates

BRICKLAYER ....................... $ 31 . 75

CARP0322-009 05/01/2009

KANABEC , PINE (Southern 1/3)

CARPENTER (Including Acoustical Ceiling Installation , Drywall Hanging , Form Work & Metal

Rates

Stud Installation) ............... $ 31 . 79

CARP0361-002 07/11/2011

Fringes

26 . 10

Fringes

16 . 10

COOK , PINE (Northern two - thirds , North of State Highway #23 & State Highway #48 , excluding cities of Beroun , Brook Park , Henriette , Pine City , Rock Creek & West Rock) :

CARPENTER (Including Acoustical Ceiling Installation , Drywall Hanging , Form Work & Metal

Rates

Stud Installation) ............... $ 27 . 20

CARP0606-002 05/01/2010

AITKIN , ITASCA , KOOCHICHING , LAKE OF THE WOODS

CARPENTER (Including Acoustical Ceiling Installation , Drywall Hanging , Form Work & Metal

Rates

Stud Installation) . .............. $ 26 . 75

CARP0606-015 06/01/2009

BELTRAMI , CLEARWATER , HUBBARD , MAHNOMEN , WADENA

Rates

CARPENTER (Including http://www. wdo I.gov /wdo l/scafiles/ davis bacon/MN79 .dvb ?v=2

Fringes

14 . 75

Fringes

14 . 65

Fringes

Page 4of18

Acoustical Ce i ling Installation , Drywall Hanging , Form Work & Metal Stud Installation) ............... $ 20 . 57

ELECOll0 - 02 1 05/01/2014

13 . 23

KANABEC (Except Brook , Ford , Krosche , Hil lman , Peace & Pomroy) , PINE (South of Arione , Barry , Clover , Hinckley & Ogema Townships)

Rates Fringes

ELECTRICIAN ...................... $ 37 . 28 25 . 33

ELEC0242 - 017 06/01/2014

AITKIN , COOK , HUBBARD (Except Rockwood , Helga , Farden , Lake Hatt i e , Schoolcraft , Guthr i e , Hart Lake , Lake Alice , Lake George , Hendrickson & Lakeport) ; ITASCA (Southerly 12 Twps .

including Harris , Feely , Blackberry , Spang , Coodland , Sago & Wawina) , KANABEC (Northern part , including Brook , Ford , Krosche , Hillman , Peace & Pomroy) ; PINE (Except southerly townships of Brook Park , Mission Creek , Munch , Crosby , Pokegama , Cross Lake , Chengwatana , Royalton , Rock Creek & Pine City) & WADENA COUNTIES

Rates Fringes

ELECTRICIAN ...................... $ 32 . 54 24 . 07

ELEC0294-005 06/01/2014

BELTRAMI , CLEARWATER , ITASCA AND KOOCHICHING (Western parts bounded on the east by a line extending north and south from the easternmost point of the city limits of Grand Rapids) & LAKE OF THE WOODS (Except NW Angle)

Rates

Electricians :

Projects $3 , 500 , 000 and under ........ . .............. $ 24 . 93 Projects over $3 , 500 , 000 .... $ 33 . 72

ELEC0294 - 013 06/01/2014

Fringes

40 . 5%+9 . 36 73 . 34% http: //www.wdol.gov/wdol/scafiles/davisbacon/MN79.dvb?v=2 4/27/2015

Page 5of18

HUBBARD (North part bounded on the south by a line extending east & west of the south line of Lake Alice & Lake George Townships)

Rates

ELECTRICIAN

Projects $3 , 500 , 000 . 00 and under ....................... $ 24 . 93 Projects over $3 , 500 , 000 . 00 . $ 33 . 72

ELEC1426-017 06/01/2014

MAHNOMEN , LAKE OF THE WOODS (Extreme NW part)

Ra t es

ELECTRICIAN ...................... $ 27 . 59

ELEV0009-004 01 / 01/2015

Rates

ELEVATOR MECHANIC .. . ............. $ 44 . 93

FOOTNOTE :

Fringes

40 . 5 %+9 . 36 73 . 34 %

Fringes

11 . 5 %+8 . 20

Fringes

28 . 385

PAID VACATION : Employer contributes 8% of regular hourly rate as vacation pay credit for employees with more than 5 years of service , and 6% for 6 months to 5 years of service .

PAID HOLIDAYS : New Years Day , Memorial Day , Independence Day , Labor Day , Veterans Day , Thanksgiving Day , Friday after Thanksgiving , and Christmas Day.

ENGI0049-056 05/01/2014

AITKIN , COOK , HUBBARD , ITASCA , KANABEC , KOOCHICHING , PINE ,

WADENA

Rates Fringes

OPERATOR : Power Equipment

GROUP 1 ..................... $ 36 . 94 16 . 45

GROUP 2 ..................... $ 36 . 60 16 . 45

GROUP 3 ..................... $ 35 . 19 16 . 45

GROUP 4 .............. . ...... $ 34 . 85 16 . 45

GROUP 5 ..................... $ 34 . 68 16 . 45

GROUP 6 ............... . . . ... $ 33 . 17 16 . 45

Page 6of18

GROUP 7 ..................... $ 32 . 05

GROUP 8 ..................... $ 30 . 0 4

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

16 . 45 16 . 45

GROUP 1 : Truck & Crawler Crane with 200 ' of Boom & Over , including Jib ($ . 50 premium with 300 ' of Boom & over , including jib) ; & Tower Crane 250 ' & Over .

GROUP 2 : Truck & Crawler Crane with 150 ' of Boom, up to but not including 200 ' of Boom , including Jib ; & Tower Crane 200 ' & Over .

GROUP 3 : Traveling Tower Crane ; Truck & Crawl er Crane , u p to but not including 150 ' of Boom, including Jib ; Tower Crane (Stationary) up to 200 '; All - Terrain Vehicle Crane , Dragline .

GROUP 4 : Backhoe/Track/Trackhoe , Hoist (3 drums or more) ;

Overhead Crane (inside building perimeter) .

GROUP 5 : Asphalt Spreader , Bulldozer , Forklift , Compressor 450 CFM or over (2 or more mach i nes) ; Boom Truck up to 100 ft , Loader over 1 cu yd , Hoist (1 or 2 drums) ; Roller , Scraper , Tractor over 02 .

GROUP 6 : Loader up to 1 cu . yd ., Tractor 02 or similar size .

GROUP 7 : Crane Oiler .

GROUP 8 : Oiler , Greaser (Tractor/Truck) .

ENGI0049 - 057 05/01/2014

BELTRAMI , CLEARWATER , LAKE OF THE WOODS , MAHNOMEN

OPERATOR :

GROUP

GROUP

GROUP

GROUP

GROUP

GROUP

GROUP

GROUP

Power Equipment 1 ..................... $ 2 ..................... $ 3 ..................... $ 4 ..................... $ 5 ..................... $ 6 ..................... $ 7 ..................... $ 8 .............. . ...... $

Rates

35 . 05 34 . 73 33 . 40 33 . 08 32 . 92 31 . 50 30 . 44 28 . 55

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

http://www.wdol.gov/wdol/scafiles/davisbacon/MN79.dvb?v=2

Fr i nge s

16 . 45 16 . 45 16 . 45 16 . 45 16 . 45 16 . 45 16 . 45 16 . 45

Page 7of18

GROUP 1 : Truck & Crawler Crane with 200 ' of Boom & Over , including Jib ($ . 50 premium with 300 ' of Boom & over , including jib) ; & Tower Crane 250 ' & Over .

GROUP 2 : Truck & Crawler Crane with 150 ' of Boom, up to but not including 200 ' of Boom, including Jib ; & Tower Crane 200 ' & Over .

GROUP 3 : Traveling Tower Crane ; Truck & Crawler Crane , up to but not including 150 ' of Boom, including Jib ; Tower Crane (Stationary) up to 200 '; All - Terrain Vehicle Crane , Dragline .

GROUP 4 : Backhoe/Track/Trackhoe , Hoist (3 drums or more) ;

Overhead Crane (inside building perimeter) .

GROUP 5 : Asphalt Spreader , Bulldozer , Forklift , Compressor 450 CFM or over (2 or more machines) ; Boom Truck up to 100 ft , Loader over 1 cu yd , Hoist (1 or 2 drums) ; Roller , Scraper , Tractor over D2 .

GROUP 6 : Loader up to 1 cu . yd ., Tractor D2 or similar size .

GROUP 7 : Crane Oiler .

GROUP 8 : Oiler , Greaser (Tractor/Truck) .

IRON0512 - 017 06/09/2013

AITKIN , BELTRAMI , CLEARWATER , COOK , HUBBARD , KOOCHICHING , LAKE

OF THE WOODS , MAHNOMEN , PINE

Rates Fringes

IRONWORKER , ORNAMENTAL ,

REINFORCING , AND STRUCTURAL ...... $ 29 . 34 22 . 05

LAB00132-033 05/01/2012

PINE

Rates Fringes

LABORER

Common or General ........... $ 28 . 46 15 . 82 Mason Tender (Brick) , Pipelayer ................... $ 28 . 96 15 . 82 http://www.wdol.gov/wdol/scafiles/davisbacon/MN79.dvb?v=2 4/27/2015

LAB00132 - 034 01/01/2012

PINE COUNTY

LABORER (ASBESTOS ABATEMENT)

Removal from Floors , Walls

Rates

& Ceilings .................. $ 27 . 33

LAB00132-038 05/01/2012

PINE COUNTY

Rates

LABORER (LANDSCAPE) .............. $ 17 . 49

LAB00563-020 05/01/2012

AITKIN , HUBBARD , KANABEC , WADENA

Laborers :

(1) Common or General Laborer , Mason Tender

Rates

(Brick , Cement/Concrete) .... $ 21 . 81

(2) Pipelayer ............... $ 22 . 56

Fringes

14 . 94

Fringes

12 . 10

Fringes

14 . 97 14 . 97

PROJECTS OVER $950 , 000 : $1 . 75 additional per hour .

LAB00563-035 05/01/2012

AITKIN , HUBBARD , KANABEC , AND WADENA COUNTIES

Rates

LABORER (LANDSCAPE) .............. $ 17 . 49

LAB00563-043 01/01/2012

AITKIN , HUBBARD , KANABEC , AND WADENA COUNTIES

LABORER (ASBESTOS ABATEMENT)

Removal from Floors , Walls

Rates

& Ceilings .................. $ 27 . 33 http://www.wdol.gov/wdol/scafiles/davisbacon/MN79.dvb?v=2

Fringes

12 . 10

Fringes

14 . 94

Page 8of18

Page 9of18

LAB01091 - 019 05/01/2012

COOK COUNTY

Rates Fringes

LABORER (LANDSCAPE) .............. $ 17 . 49 12 . 10

LAB01097-009 05/01/2012

BELTRAMI , CLEARWATER , ITASCA , KOOCHICHING , LAKE OF WOODS , AND

MAHNOMEN COUNTIES

Rates

LABORER (LANDSCAPE) .............. $ 17 . 49

LAB01097-016 05/01/2012

BELTRAMI , CLEARWATER , LAKE OF THE WOODS , MAHNOMEN

LABORER (Projects $760 , 000 & over : )

(1) Common or General , Rates

Mason Tender (B rick) ........ $ 17 . 29

(2) Pipelayer ............... $ 17 . 69

LABORER (Projects under $760 , 000 : )

(1) Common or General , Mason Tender (Brick) ........ $ 14 . 70

(2) Pipelayer ............... $ 15 . 04

LAB01097-018 05/01/2012

ITASCA , KOOCHICHING

Rates

LABORER

Common or General , Mas on Tender (Brick) .............. $ 20 . 62 Pipelayer ................... $ 21 . 02

PAIN0061-002 05/01/2014

Fringes

12 . 10

Fringes

14 . 84 14 . 84

14.84 14 . 84

Fringes

16 . 25 16 . 25

PINE (Southern half , on a line east and west through Hinckley)

Rates

Drywall Finisher/Taper .............. $ 32 . 18 Sander ...................... $ 24 . 14

PAINTER

Brush , Roller , Paperhanger .. $ 33 . 17 Spray ....................... $ 33 . 17

PA I N0106 - 016 05/01/20 1 4

Fringes

18 . 0 1 18 . 01

18 . 17 18 . 17

COOK , HUBBARD , ITASCA , KOOCHICHING , PINE (Northern part including Hinckley and Sandstone)

Rates

PAINTER

New :

Brush , Roller , Paperhanger . $ 28 . 81 Spray , Drywall Finisher/Taper ............. $ 29 . 41

Repaint/Remodel :

Brush , Roller , Paperhanger . $ 27 . 3 1 Spray , Drywall Finisher/Taper ............. $ 27 . 91

PAIN0386 - 004 05/01/2014

KANABEC

Rates

Drywall Finisher/Taper .............. $ 30 . 46 Sander ........ . ............. $ 22 . 85

PAIN0386 - 015 05/01/2014

KANABEC

Rates

PAINTER

Brush , Roller , Paperhanger .. $ 32 . 88 Spray ....................... $ 32 . 88

PAIN0884-018 06/01/2010

http://www.wdol.gov/wdol/scafiles/ davis bacon/MN79 .dvb ?v=2

Fringes

15 . 27

15 . 27

15 . 27

15 . 27

Fringes

19 . 73 19 . 73

Fringes

18 . 46 18 . 46

Page 10of18

Page 11of18

AITKIN , BELTRAMI , HUBBARD , LAKE OF THE WOODS , MAHNOMEN , WADENA

Rates Fringes

PAINTER

Brush , Roller , Paperhanger .. $ 24 . 16 13 . 31

PROJECTS UNDER $8 , 000 : Receive 80 % of basic hourly rate .

PAINTER ' S PREMIUM : $0 . 75 per hour additional for the following work : Spray , Two Component Paints , Epoxies , Sandblasting & Rigging , Work done on Swing Scaffolding , Safety harness , Window Jacks , Boatswain ' s Chair , Coverings & erection of scaffolding for same , Work on erected Structural Steel , Abrasive Blasting .

PA I N0884 - 019 08/01/2011

AITKIN

Rates Fringes

DRYWALL FINISHER/TAPER ........... $ 24 . 56 14 . 05

PROJECTS UNDER $8 , 000 : Rate is 80 % of basic hourly rate .

PAIN0884 - 020 08/01/2011

BELTRAMI, CLEARWATER , LAKE OF THE WOODS , MAHNOMEN , WADENA

Rates Fringes

DRYWALL FINISHER/TAPER ........... $ 22 . 86 13 . 53

PROJECTS UNDER $8 , 000 : Rate is 80% of basic hourly rate .

PLAS0633-002 05/01/2012

PINE (South of the northern boundaries of Dell Grove , Sandstone & Danforth Townships)

Rates Fringes

CEMENT MASON/CONCRETE FINISHER .. . $ 32 . 39 16 . 60

PLAS0633 - 010 05/01/2012

AITKIN , COOK & PINE (North of T 24N) http://www.wdol.gov/wdol/scafiles/davisbacon/MN79.dvb?v=2 · 4/27/2015

Page 12of18

Rates Fringes

CEMENT MASON/CONCRETE FINISHER ... $ 29 . 69 16 . 30

PLAS0633 - 060 05/01/2012

KANABEC

Rates Fringes

CEMENT MASON/CONCRETE FINISHER ... $ 32 . 39 1 6 . 60

PLAS0633 - 061 05/11/2012

WADENA

Rates Fringes

CEMENT MASON/CONCRETE FINISHER ... $ 26 . 71 14 . 64

PLAS0633-062 05/11/2012

BELTRAMI , HUBBARD , ITASCA & KOOCHICHING

Rates Fringes

CEMENT MASON/CONCRETE FINISHER ... $ 26 . 71 14 . 64

PLAS0633 - 063 05/01/2012

CLEARWATER , LAKE OF THE WOODS , MAHNOMEN

Rates Fringes

CEMENT MASON/CONCRETE FINISHER ... $ 28 . 31 13 . 19

PLUMOOll - 004 05/12/2014

KANABEC , PINE

Rates Fringes

PLUMBER/PIPEFITTER ............... $ 37 . 27 14 . 03

PLUMOOll - 020 05/01/2012

AITKIN , BELTRAMI , CLEARWATER , COOK (a strip 20 mi l es i nland along the shores of Lake Superior) , HUBBARD , LAKE OF THE WOODS , MAHNOMEN , WADENA

Page 13of18

Rates Fringes

PLUMBER/PIPEFITTER ............... $ 30 . 15 13 . 33

PLUM0589-008 05/01/2014

COOK (Except a strip 20 miles inland along the shores of Lake Superior) , ITASCA , KOOCHICHING

Rates

PLUMBER/PIPEFITTER

Contracts $90 , 000 . 00 and under ....................... $ 39 . 4 6 Contracts over $90 , 000 . 00 ... $ 39 . 46

ROOF0096-012 05/01/2014

ITASCA , KOOCHICHING

Rates

ROOFER ........................... $ 28 . 64

ROOF0096 - 013 05/01/2014

BELTRAMI , CLEARWATER , LAKE OF THE WOODS , MAHNOMEN

Rates

ROOFER ........................... $ 25 . 83

ROOF0096 - 031 07/01/2012

AITKIN , HUBBARD , WADENA

Rates

ROOFER ........................... $ 2 9 . 4 6

ROOF0096 - 033 06/01/2014

KANABEC

Fringes

17 . 01 17 . 01

Fringes

10 . 57

Fringes

10 . 58

Fringes

11. 25

Rates Fringes

ROOFER ........................... $ 30 . 14 15 . 26

ROOF0096 - 046 07/05/2013

COOK , PINE

Rates

ROOFER ........................... $ 31 . 15

SHEEOOl0-011 06/01/2008

BELTRAMI , CLEARWATER , LAKE OF THE WOODS

SHEET METAL WORKER (Including HVAC Duct and System

Rates

Installation) .................... $ 27 . 00

SHEEOOl0 - 046 05/01/2008

ITASCA, KOOCHICHING

SHEET METAL WORKER (Including HVAC Duct and System

Rates

Installation) .................... $ 29 . 99

SHEEOOl0 - 073 06/01/2010

HOBARD , WADENA

SHEET METAL WORKER (Including HVAC Duct and System

Rates

Installation) .................... $ 30 . 07

SHEEOOl0-075 05/01/2009

AITKIN , COOK

SHEET METAL WORKER (Including HVAC Duct and System

Rates

Installation) .................... $ 31 . 61

SHEEOOl0-079 05/01/2009 http://www.wdol.gov/wdol/scafiles/davisbacon/MN79.dvb?v=2

Page 14of18

Fringes

14 . 08

Fringes

11 . 67

Fringes

16 . 08

Fringes

16 . 67

Fringes

16 . 52

KANABEC , PINE

SHEET METAL WORKER (Including HVAC Duct and System

Rates

Installation) .................... $ 38 . 46

FOOTNOTE : Paid Holiday : Labor Day

SHEEOOl0 - 080 05/01/2010

MAHNOMEN

SHEET METAL WORKER (Including HVAC Duct and System

Rates

Installation) .................... $ 32 . 10

SUMN2009- 033 07/27/2009

Rates

GLAZIER .......................... $ 19 . 75

LABORER : Roof Tearoff ........... $ 10 . 42

OPERATOR : Bobcat/Skid Steer/Skid Loader ................ $ 20 . 75

OPERATOR : Excavator ............. $ 17 . 64

OPERATOR : Mechanic .............. $ 19 . 74

TRUCK DRIVER : Dump Truck ........ $ 13 . 92

Fringes

18 . 34

Fringes

17 . 15

Fringes

5 . 53

2 . 08

0 . 00

2 . 97

4 . 47

1. 08

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental .

Page 15of18

Unlisted classifications needed for work not included within the scope of the c l ass i fications listed may be added after award only as provided in the labor standards contract clauses ( 2 9CFR 5 . 5 (a) ( 1) (ii) ) .

Page 16of18

The body of each wage determination lists the classif i cation and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination . The classifications are listed in alphabetical order of " identifiers " that indicate whether the particular rate is a union rate (current union negotiated rate for local) , a survey rate (weighted average rate) or a union average rate (weighted union average rate) .

Union Rate Identifiers

A four l etter classification abbrev i ation identif i er enc l osed in dotted lines beginning with characters other than " SU " or " UAVG " denotes that the union class i fication and rate were prevailing for that classification in the survey . Example :

PLUM0198 - 005 07/01/2014 . PLUM is an abbreviation i dentif i er of the union which prevailed in the survey for this classification , which in this example would be Plumbers . 0198 indicates the local union number or district council number where applicable , i . e ., Plumbers Local 0198 . The next number , 005 in the example , is an internal number used in processing the wage determination . 07/01/2014 is the effective date of the most current negotiated rate , which in this example is July 1 , 2014 .

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate .

Survey Rate Identifiers

Classifications listed under the " SU " identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classif i cation . As t h is weighted average rate includes all rates reported in the survey , it may include both union and non - union rates . Example : SULA2012 - 007 5/13/2014 . SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates . LA indicates the State of Louisiana . 2012 is the year of survey on which these classifications and rates are based . The next number , 007 in the example , is an internal number used in producing the wage determination . 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier .

http://www. wdo I.gov /wdo l/scafiles/ davis bacon/MN79 .dvb ?v=2 4/27/2015

Page 17of18

Survey wage rates are not updated and remain in effect until a new survey is conducted .

Union Average Rate Identifiers

Classification(s) l isted under the UAVG ident i fier indicate that no single majority rate prevailed for those classifications ; however , 100 % of the data reported for the classifications was union data . EXAMPLE : UAVG- OH - 0010 08/29/2014 . UAVG indicates that the rate is a weighted union average rate . OH indicates the state . The next number , 0010 in the example , is an internal number used in producing the wage determination . 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier .

A UAVG rate will be updated once a year , usually in January of each year , to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based .

WAGE DETERMINAT I ON APPEALS PROCESS

1 . ) Has there been an initial decision in the matter? This can be :

an existing published wage determination a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters , initial contact , including requests for summaries of surveys , should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility f or the Davis - Bacon survey program . If the response from this initial contact is not satisfactory , then the process described in 2 . ) and 3 . ) should be followed .

With regard to any other matter not yet ripe for the forma l process described here , initial contact should be with the Branch of Construction Wage Determinations . Write to :

Branch of Construction Wage Determinations Wage and Hour Division U. S . Department of Labor

Page 18of18

200 Constitution Avenue , N. W.

Washington , DC 20210

2 . ) If the answer to the question in 1 . ) is yes , then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1 . 8 and 29 CFR Part 7) . Write to :

Wage and Hour Administrator U. S . Department of Labor 200 Constitution Avenue , N.W .

Washington , DC 20210

The request should be accompanied by a full statement of the interested party ' s position and by any information (wage payment data , project description , area practice material , etc . ) that the requestor considers relevant to the issue .

3 . ) If the decision of the Administrator is not favorable , an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board) . Write to :

Administrative Review Board U. S . Department of Labor 200 Constitution Avenue , N. W.

Washington , DC 20210

4 . ) All decisions by the Administrative Review Board are final .

END OF GENERAL DECISION

http://www. wdo I.gov /wdo 1/ scafiles/ davis bacon/MN79 .dvb ?v=2 4/27/2015