USCGCMACKINAWDSFY11.doc

HSCG80-09-Q-3FA669 PAGE 1 OF 40

USCGC JUNIPER (WLB-201)

DRYDOCK REPAIRS

NOTICE FOR FILING AGENCY PROTESTS

It is the policy of the Coast Guard to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the General Accounting Office (GAO).

Interested parties are encouraged to seek resolution of their concerns within the Coast Guard as an Alternative Dispute Resolution (ADR) forum, rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the contracting officer or Ombudsman.

Informal forum with the Ombudsman. Interested parties who believe that a Coast Guard procurement is unfair or otherwise defective should first direct their concerns to the cognizant contracting officer. If the contracting officer is unable to satisfy the concerns, the interested party is encouraged to contact the Coast Guard Ombudsman for Agency Protests. Under this informal process, the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, contracting officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the contracting officer through open and frank discussions. If the protester’s concerns are unresolved, an independent review is available by the Ombudsman. The protester may file a formal agency protest to either the contracting officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency’s goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth at FAR 33.103(d)(2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. This will not preclude re-filing of the protest to meet the requirement. To be timely, protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be forwarded to the address below:

Commandant (CG-9131) U.S. Coast Guard Headquarters Procurement Planning & Oversight Division 1900 Half St. SW, JR11-0203 Washington, DC 20593 Telephone: (202) 372-3692

Fax: (202) 475-3904

Surface Forces Logistics Center

CPD/C&P2/IBCT

300 East Main Street, Suite 600

Norfolk, VA 23510

REQUEST FOR QUOTATION

HSCG85-11-Q-P45NA2

USCGC MACKINAW (WLBB 30)

DOCKSIDE REPAIRS

CONTINUATION OF SF 1449 – BLOCKS 17a – 25

(1) Block 17a: Contractor shall include DUNS number.

(2) Block 17b: REMITTANCE ADDRESS: Payment will be made to the Financial Institution listed in Central Contractor Registration (CCR). To receive award Contractor must be registered in Central Contract Registration (CCR) http://www.ccr.gov.

(3) Block 19 through 24: SEE SCHEDULE OF SUPPLIES/SERVICES BELOW.

(4) Block 25: ACCOUNTING AND APPROPRIATION DATA: To be included on contract award document.

DESCRIPTION OF WORK:

(a) The Contractor shall furnish all necessary labor, material, services, equipment, supplies, power, accessories, facilities and such other things as are necessary, except as otherwise specified, to perform dockside repairs to the vessel, in accordance with this solicitation and attached specifications.

(b) Failure to read the specifications in their entirety will not relieve the offeror from the responsibility for properly estimating the difficulty or price of successfully performing the work. Failure to do so will be at the risk of the offeror.

(c) Each offeror shall furnish the information required by the solicitation.

GEOGRAPHICAL RESTRICTION: THE VESSEL HOMEPORT – 627 Coast Guard Drive, Cheboygan, MI

ANTICIPATED AWARD DATE: The contract is expected to be awarded on or about June 29, 2011. Work covered by this solicitation shall be completed within 27 calendar days from the date the vessel becomes available to the Contractor. The availability is scheduled to start on or about September 19, 2011. An arrival conference normally will be held within 48 hours of the scheduled start date.

SCHEDULE OF SUPPLIES/SERVICES: See Schedule of Supplies and Services. Base Contract Line Item Numbers (CLINs) are marked as “D” for Definitive. Optional CLINS are marked “O” for Optional. Insert unit prices in all CLINs listed in the Schedule unless “NSP” is printed in the Unit Price column for any CLIN. “NSP” in the section means “Not Separately Priced.” SEE SEPARATE ATTACHMENT FOR SCHEDULE.

PLEASE NOTE: QUOTES MUST INCLUDE ALL DOCUMENTS REQUESTED IN THIS SOLICITATION (WELDING CERTIFICATES, PAST PERFORMANCE, ETC). QUOTES THAT DO NOT INCLUDE ALL DOCUMENTS REQUESTED MAY BE CONSIDERED INCOMPLETE AND MAY NOT BE CONSIDERED.

PRICE TOTALS:

Insert individual prices in Schedule of Supplies/Services above and insert totals of extended prices as indicated below:

Total Definitive Item CLINs:

Total Optional Item CLINs:

Excluding Composite Labor

TRAVEL AND PER DIEM $__________________

Composite Labor:

TOTAL:

CONTRACT CLAUSES:

FAR 52.212-4 CONTRACT TERMS AND CONDITIONS – COMMERCIAL ITEMS (JUN 2010) ADDENDUM

FAR 52.217-7 OPTION FOR INCREASED QUANTITY – SEPARATELY PRICED LINE ITEM (MAR 1989) - VARIATION The Government may require the performance of the numbered line items, identified in the Schedule as option items, at the unit prices stated in the Schedule. The option quantities shown in the Schedule are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract performance period. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or both. When time is of the essence, initial notification will be provided verbally followed within 24 hours by a facsimile of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at any phase during the contract performance period as stated herein, or any extension of the performance period. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, not later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option item shall be commenced as soon as proper sequencing permits. The exercise of any option item listed in the Schedule will not normally extend the contract performance period. However, the Contracting Officer may consider a request by the Contractor for contract extension if an option is exercised after 50% of the contract performance period has expired.

(End of Clause)

FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html

FAR 52.215-5

FAR 52.222-20

Facsimile Proposals (OCT 1997) Walsh-Healy Public Contracts Act (OCT 2010)

Alternate I (JUL 1995)

FAR 52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of the Chief, SFLC/CPD/ C&P2, and shall not be binding until so approved.

FAR 52.209-7 - INFORMATION REGARDING RESPONSIBILITY MATTERS (JAN 2011)

(a) Definitions. As used in this provision—

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the Central Contractor Registration database at http://www.ccr.gov (see 52.204-7).

(End of provision)

FAR 52.209-9 – UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS (JAN 2011)

(a) The Contractor shall update the information in the Federal Awardee Performance and Integrity Information System (FAPIIS) on a semi-annual basis, throughout the life of the contract, by posting the required information in the Central Contractor Registration database at http://www.ccr.gov .

(b)

(1) The Contractor will receive notification when the Government posts new information to the Contractor’s record.

(2) The Contractor will have an opportunity to post comments regarding information that has been posted by the Government. The comments will be retained as long as the associated information is retained, i.e., for a total period of 6 years. Contractor comments will remain a part of the record unless the Contractor revises them.

(3)

(i) Public requests for system information posted prior to April 15, 2011, will be handled under Freedom of Information Act procedures, including, where appropriate, procedures promulgated under E.O. 12600.

(ii) As required by section 3010 of Public Law 111-212, all information posted in FAPIIS on or after April 15, 2011, except past performance reviews, will be publicly available.

(End of clause)

FAR CLAUSE 52.217-8 – OPTION TO EXTEND SERVICES (NOV 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the contractor any time prior to contract expiration.

(END OF CLAUSE)

VOLATILE ORGANIC COMPOUNDS (VOC) REGULATIONS:

(a) Contractors are required to comply with federal, state and local VOC compliance laws and regulations. Among other requirements, certain Contractors may also be required to operate pursuant to a Title V permit. The need for such a permit will depend on the provisions of the applicable state’s “State Implementation Plan” (SIP) and the type/quantity of the Contractor’s regulated emissions, including VOCs. Certain SIPs may also mandate certain Contractors to operate under the terms of a compliance plan intended to reduce VOC emissions.

(b) Contractors, therefore, must submit the following to the designated NESU Port Engineer not later than two weeks after contract award:

1) Copies of any federal, state or local permits required and applicable to the use or application of VOCs at Contractor’s facility or offsite work places;

2) Copies of any compliance plans required and applicable to the use or application of VOCs at Contractor’s facility or offsite work places.

(c) If no federal, state or local permits or compliance plans are required and applicable to the use or application of VOCs at Contractor’s facility or offsite workplaces, the Contractor shall submit to the designated NESU Port Engineer a letter, notarized under oath, that such documents are not required.

(d) Contractors will submit the following to the designated NESU Port Engineer not later than two weeks after contract award: Data Sheets (MSDS) documents, certificates, specifications or any other manufacturing data verifying the VOC ratings of paints to be applied to the Cutter in accordance with MLCA Standard Spec 63000N, Section 5.3.1.

REQUIRED INSURANCE:

The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including:

1. Ship Repairer's Liability - $500,000 per occurrence.

2. Comprehensive General Liability - $500,000 per occurrence.

3. Full insurance coverage in accordance with the United States’ Longshoremen's and Harbor Worker's Act.

4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract.

The insurance certificate must provide the name of the US Coast Guard vessel and the contract number as specifically insured.

INSPECTIONS:

Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms to contract quality requirements.

Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract.

The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation.

GROWTH WORK:

(a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre-priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair. In this situation, FAR 52.212-4, Alternate I will be incorporated.

(b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any proposal submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted on an MLCA 002 proposal form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change/modification whether such work was deleted, added or changed. Any amount claimed for subcontracts shall be supported by a separate, similar price breakdown. If the proposal includes a request for a time extension, justification shall be furnished with the proposal.

(c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation. The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC.

COMPOSITE LABOR RATE:

The composite labor rate offered shall be the sole labor hour rate used to price the prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the prime Contractor's direct labor associated with such changes under this contract.

(a) The composite labor hour rate shall represent total compensation for the following:

(1) direct labor wages and salaries;

(2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits;

(3) other direct costs associated with transit time, delay, disruption, expendable supplies, and equipment;

(4) all indirect costs such as overhead and general and administrative expense;

(5) any port or association fees, rents, or other levies;

(6) profit (fee); and

(7) all direct and indirect costs and profit associated with the following support functions:

Supervision and Management Planning and Estimating

Material Handling Housekeeping

Engineering Transportation/Drivers

Quality Assurance Contract Administration

Security Testing

(b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated.

(c) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government’s best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised.

MAINTAINING, REPORTING, AND DISPOSING OF GOVERNMENT PROPERTY IN THE PERFORMANCE OF A SHIP REPAIR CONTRACT:

1. The Government Property Clause incorporated by reference delineates the Contractor's overall responsibility when taking possession of Government property in performance of a contract. In performance of this contract the Contractor will be required to properly identify, track and control property within its possession. This includes, a) property furnished by the Government (GFP) to the Contractor in conjunction with specific CLIN Items. These items and their values are listed in the specification, b) property that is pre-existing in a location that during the course of performance will be replaced or renewed.

2. The items listed in the specification, as Government furnished property will be provided in the quantities designated. Government furnished property may be provided in person by an official Coast Guard employee, shipment via commercial carrier, etc. The Contractor shall sign for all Government furnished property using either a DD Form 1149, entitled, “Requisition and Invoice/Shipping Document” or a DD Form 1348, entitled, “Issue Release/Receipt Document”. A copy of the DD 1149 or DD 1348 must be sent within 48 hours of receipt of property, to the designated Government Property Administrator. The name of the individual assigned as Property Administrator will be furnished to the Contractor at time of award. The Contractor shall not take receipt of property that is not listed in the specification, has not been previously identified as becoming part of the contract (via contract modification) or which otherwise cannot be identified. Such irregularities shall be immediately reported to the Property Administrator.

3. The Contractor shall complete the report provided herein, entitled, “Government Property Report”. This report is intended as a living document whereby relevant fields shall be filled in, maintained and kept current at all times. All property described in paragraph 1(a and b) above shall be reported on the report. At contract completion the Contractor and the Property Administrator shall ensure that all fields are appropriately completed. A signature block is provided at the end of the report for both parties to attest to the report's accuracy and completeness. The Government Property Report shall clearly delineate the complete track that all Government property took over the course of the contract. This completed report must accompany the Contractor's final invoice. Final payment may be delayed, without penalty of interest, until such time as the report is received. A separate copy of the completed report and any final DD 1149s or DD 1348s executed, as a result of carrying out disposition instructions shall be provided to the Property Administrator.

4. Pursuant to the Government Property Clause the authority to render disposition instructions of Government property associated with this contract is delegated to the Property Administrator. The Contractor shall comply with all instructions in the contract for the return of Government property to the Coast Guard. This includes Government property taken off the vessel (shafts, propellers, etc.), Government property returned to the vessel (special tools, etc.) or surplus Government property not used during performance of the contract.

CONTRACTING OFFICER’S AUTHORITY:

No oral or written statement of any person other than the Contracting Officer will in any manner or degree modify or otherwise affect the terms of this contract. The Contracting Officer is the only person authorized to approve changes in any of the requirements under this contract, and, notwithstanding any provisions contained elsewhere in this contract, said authority remains solely with the Contracting Officer. In the event the Contractor effects any such change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in cost incurred as a result thereof.

CONTRACTOR PERFORMANCE ASSESSMENT REPORT (CPAR) :

(a) GENERAL: The U.S. Coast Guard Surface Forces Logistic Center (SFLC) will monitor and evaluate the successful offeror’s past performance of this contract and prepare a Contractor Performance Assessment Report (CPAR) in accordance with FAR Part 42.15. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the government for future source selections and in accordance with FAR 15.304, when past performance is an evaluation factor for award.

(b) NOTIFICATION: Upon completion of the contract, the contractor will be notified of the assessment. The contractor will be allowed 30 days to respond to the SLFC’s assessment of its performance entered into CPARS. The contractor’s response, if any, will be made part of the CPAR system at https://www.cpars.disa.mil.

(c) INFORMATION: Information included in the CPAR may include, but is not limited to, the contractor’s record of conforming to contract requirements and to standards of good workmanship; the contractor’s record of forecasting and controlling costs; the contractor’s adherence to contract schedules, including the administrative aspects of performance; the contractor’s history of reasonable and cooperative behavior and commitment to customer satisfaction; the contractor’s record of integrity and business ethics, and generally, the contractor’s business-like concern for the interest of the customer.

(d) RELEASE OF DATA: CPARS information is considered business sensitive and will not be released except: (1) to other Federal procurement activities which request it; (2) when SFLC must release pursuant to a Freedom of Information Act (FOIA) request; or (3) when prior written consent is requested and obtained from the contractor.

METHOD OF PAYMENT AND INVOICING INSTRUCTIONS FOR SHIP REPAIR:

The Government will make payment under this contract based on a percentage or stage of completion. The Contractor may invoice each contract line item (CLIN) as work progresses. The amount invoiced shall be calculated based on those prices stipulated in the contract Schedule of Supplies/Services as follows:

A CLIN may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that CLIN have no limitation as to the percentage of completion required before invoicing. (The minimum percentage of completion (25%) to be reached prior to billing each CLIN may be waived by the Contracting Officer on a case by case basis for large dollar CLINS.)

Invoices submitted by the Contractor which are deemed not proper, in accordance with FAR clause, 52.212-4 will be returned. Invoices shall include (see the clause for a full summation of invoice requirements):

Name and Address of the Contractor;

Invoice date

Contract Number/Modification No.

Description, quantity, unit of measure, unit price and extended price;

Shipping and Payment Terms;

Name and Address of Contractor official to whom payment is to be sent;

Name, title, phone number, and mailing address of person to be notified in the event of a defective invoice.

The invoice must include:

a) The percentage of completion for each CLIN identified;

b) Name of the Contracting Officer;

c) Vessel name; and,

d) The overall percentage and dollar amount previously billed, currently billed and unbilled;

e) The Data Universal Numbering System (DUNS) number.

The Data Universal Numbering System (DUNS) number is the primary identifier in Central Contractor Registration (CCR), (see FAR 52.232-33, Payment by Electronic Funds Transfer – Central Contractor Registration (OCT 2003)). Contractors are located and identified in CCR by their DUNS number. Therefore, to facilitate payment, the DUNS number shall be recorded on every invoice submitted to the U.S. Coast Guard.

All payments for partial performance rendered by the Government under this contract are based on the assumption that the Contractor will, in good faith, execute and honor all payment terms entered into between it, the prime Contractor, and any subcontractor thereof in the performance of this contract. The Contractor hereby acknowledges the Government’s right to reduce or suspend progress payments based on non-payment in accordance with any payment terms of the subcontract agreement.

All items of work invoiced under this contract will be verified by the designated billing office and confirmed by the Contracting Officer’s Technical Representative (COTR) as accurate and complete.

Any amount deemed not payable will be deducted from the Contractor’s invoice. Deducted amounts may be resubmitted on the next invoice for reconsideration.

Additional work verbally agreed to by the parties that has not yet been incorporated into the contract by modification shall not be included in an invoice. Payments will not be made for any work to which a modification has not been properly executed. Invoices submitted for payment that includes such a request will be reduced by the unmodified amount.

Upon signature of the COTR, the invoice may be submitted for payment in one of the following methods:

1. Fax to (757) 628-4676 – Attn: Sandra Martinez, Contracting Officer

2. E-mail to sandra.a.martinez@uscg.mil

3. Mail to:

U. S. Coast Guard Surface Forces Logistics Center Attn: SANDRA MARTINEZ, CPD/C&P2/IBCT 300 East Main Street, Suite 600 Norfolk, VA 23510-9102

The Contractor’s final invoice submitted under the contract must be marked as follows:

“THIS INVOICE CONSTITUTES THE FINAL INVOICE – UPON PAYMENT OF THIS INVOICE NO OTHER MONIES ARE DUE UNDER CONTRACT NUMBER (to be assigned upon contract award)”

NOTE: 10% OF THE TOTAL CONTRACT PRICE WILL BE WITHHELD UNTIL ALL DELIVERABLES, REQUIRED BY THE CONTRACT, ARE RECEIVED AND ACCEPTED.

CONTRACT DEFICIENCY REPORT:

The Contracting Officer or Contracting Officer’s Technical Representative (COTR) may issue a Contract Deficiency Report (CDR), MLCA Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COTR. The COTR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor, IBCT Technical Representative, the NESU and Program Manager. The Contracting Officer will render a final determination and provide it to the Contractor and COTR in writing.

(End of FAR 52.212-4 Addendum)

FAR 52.212-5 -- Contract Terms and Conditions Required to Implement Statutes or Executive Orders -- Commercial Items (MAR 2011)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)).

____ Alternate I (AUG 2007) of 52.222-50 (22 U.S.C. 7104(g)).

(2) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.] √ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 253g and 10 U.S.C. 2402).

___ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)).

___ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009).

√ (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Jul 2010) (Pub. L. 109-282) (31 U.S.C. 6101 note).

___ (5) 52.204-11, American Recovery and Reinvestment Act—Reporting Requirements (Jul 2010) (Pub. L. 111-5).

√ (6) 52.209-6, Protecting the Government’ Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Dec 2010) (31 U.S.C. 6101 note). (Applies to contracts over $30,000). (Not applicable to subcontracts for the acquisition of commercially available off-the-shelf items).

_XX__ (7) 52.219-3, Notice of Total HUBZone Set-Aside or Sole-Source Award (Jan 2011) (15 U.S.C. 657a).

___ (8) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Jan 2011) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a).

___ (9) [Reserved]

____ (10) (i) 52.219-6, Notice of Total Small Business Aside (June 2003) (15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-6.

___ (iii) Alternate II (Mar 2004) of 52.219-6.

___ (11) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

___ (ii) Alternate I (Oct 1995) of 52.219-7.

___ (iii) Alternate II (Mar 2004) of 52.219-7.

√ (12) 52.219-8, Utilization of Small Business Concerns (Jan 2011) (15 U.S.C. 637(d)(2) and (3)).

___ (13) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2011) (15 U.S.C. 637 (d)(4).)

___ (ii) Alternate I (Oct 2001) of 52.219-9.

___ (iii) Alternate II (Oct 2001) of 52.219-9.

___ (iv) Alternate III (July 2010) of 52.219-9.

√ (14) 52.219-14, Limitations on Subcontracting (Dec 1996) (15 U.S.C. 637(a)(14)).

___ (15) 52.219-16, Liquidated Damages—Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

___ (16) (i) 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns (Oct 2008) (10 U.S.C. 2323) (if the offeror elects to waive the adjustment, it shall so indicate in its offer).

___ (ii) Alternate I (June 2003) of 52.219-23.

___ (17) 52.219-25, Small Disadvantaged Business Participation Program—Disadvantaged Status and Reporting (Dec 2010) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323).

___ (18) 52.219-26, Small Disadvantaged Business Participation Program—Incentive Subcontracting (Oct 2000) (Pub. L. 103-355, section 7102, and 10 U.S.C. 2323).

____ (19) 52.219-27, Notice of Total Service-Disabled Veteran-Owned Small Business Set-Aside (May 2004) (15 U.S.C. 657 f).

√ (20) 52.219-28, Post Award Small Business Program Re-representation (Apr 2009) (15 U.S.C. 632(a)(2)).

_ (21) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

√ (22) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jul 2010) (E.O. 13126).

√ (23) 52.222-21, Prohibition of Segregated Facilities (Feb 1999).

√ (24) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246).

√ (25) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212).

√ (26) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793).

√ (27) 52.222-37, Employment Reports on Veterans (Sep 2010) (38 U.S.C. 4212).

√ (28) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

___ (29) 52.222-54, Employment Eligibility Verification (Jan 2009). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

___ (30) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

___ (31) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

___ (32) (i) 52.223-16, IEEE 1680 Standard for the Environmental Assessment of Personal Computer Products (Dec 2007) (E.O. 13423).

___ (ii) Alternate I (Dec 2007) of 52.223-16.

√ (33) 52.223-18, Contractor Policy to Ban Text Messaging while Driving (Sep 2010) (E.O. 13513).

___ (34) 52.225-1, Buy American Act--Supplies (Feb 2009) (41 U.S.C. 10a-10d).

___ (35) (i) 52.225-3, Buy American Act –Free Trade Agreements – Israeli Trade Act (Jun 2009) (41 U.S.C. 10a-10d, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, Pub. L. 108-77, 108-78, 108-286, 108-301, 109-53, 109-169, 109-283, and 110-138).

___ (ii) Alternate I (Jan 2004) of 52.225-3.

___ (iii) Alternate II (Jan 2004) of 52.225-3.

___ (36) 52.225-5, Trade Agreements (Aug 2009) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

√ (37) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

___ (38) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

___ (39) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

___ (40) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)).

___ (41) 52.232.30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)).

√ (42) 52.232-33, Payment by Electronic Funds Transfer—Central Contractor Registration (Oct. 2003) (31 U.S.C. 3332).

___ (43) 52.232-34, Payment by Electronic Funds Transfer—Other Than Central Contractor Registration (May 1999) (31 U.S.C. 3332).

___ (44) 52.232-36, Payment by Third Party (Feb 2010) (31 U.S.C. 3332).

___ (45) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

___ (46) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631).

___ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

___ (1) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.).

____ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 1989) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.).

____ (3) 52.222-43, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Multiple Year and Option Contracts) (Sep 2009) (29 U.S.C.206 and 41 U.S.C. 351, et seq.).

___ (4) 52.222-44, Fair Labor Standards Act and Service Contract Act -- Price Adjustment (Sep 2009) (29 U.S.C. 206 and 41 U.S.C. 351, et seq.).

___ (5) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.).

___ (6) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.).

___ (7) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247).

___ (8) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note)).

(ii) 52.219-8, Utilization of Small Business Concerns (Dec 2010) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iii) [Reserved]

(iv) 52.222-26, Equal Opportunity (Mar 2007) (E.O. 11246).

(v) 52.222-35, Equal Opportunity for Veterans (Sep 2010) (38 U.S.C. 4212).

(vi) 52.222-36, Affirmative Action for Workers with Disabilities (Oct 2010) (29 U.S.C. 793).

(vii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(viii) 52.222-41, Service Contract Act of 1965, (Nov 2007), (41 U.S.C. 351, et seq.)

(ix) 52.222-50, Combating Trafficking in Persons (Feb 2009) (22 U.S.C. 7104(g)).

___ Alternate I (Aug 2007) of 52.222-50 (22 U.S.C. 7104(g)).

(x) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.)

(xi) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (Feb 2009) (41 U.S.C. 351, et seq.)

(xii) 52.222-54, Employment Eligibility Verification (Jan 2009).

(xiii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Mar 2009) (Pub. L. 110-247). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xiv) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of Clause)

GOVERNMENT PROPERTY REPORT

The Contractor shall complete each column throughout the contract performance period with the assistance of the Government Property Administrator, as needed.

Contractor point of contact:

telephone number:

Contractor’s address:

The chart below is for use during the performance of the above listed contract. The Contractor shall complete each column of the chart with the assistance of the Government Property Administrator, as needed.

Type of property received (include name, description , nsn and serial #) value of property

consumed Use this block to record :

1. current location of property in the possession of the Contractor for use during the availability or otherwise being temporarily held until being returned to/reinstalled on cutter.

2. disposition instructionsfor unused, serviceable, salvage or scrap property. state which apply.

date disposition carried out

* Definitions (all property defined below will require disposition instructions):

Serviceable - defined as property that was pre-existing in a location that was, during the course of performance, replaced and which will be turned in by the Coast Guard for future use.

Salvage – defined as property that has no serviceable value, but that has some value in excess of its scrap value.

Scrap – defined as property having no value except for it basic material content.

The undersigned hereby certify that all property provided under referenced contract has been accounted for. That is property has either been consumed in the performance of the contract or disposition instructions, as listed above, have been provided.

PROPERTY ADMINISTRATOR DATE

(Sign at time disposition instructions are given)

CONTRACTOR SIGNATURE DATE

(sign after execution of disposition instructions)

NOTE: The Contractor must carry out all disposition instructions as instructed above. This report must accompany the Contractor’s final invoice. (07/02)

FAR 52.212-1 Instructions to Offerors—Commercial Items (Jun 2008) (ADDENDUM)

FAR 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at: http://www.arnet.gov/index.html.

FAR 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS AND STANDARDS AND COMMERCIAL ITEMS DESCRIPTIONS (JUN 1988)

a. Orders for U.S. Coast Guard specification reference drawings must be placed within 10 days of the solicitation issue date. To request drawings, contact sandra.a.martinez@uscg.mil. All requests should identify the solicitation number. U.S. Coast Guard specification reference drawings are available in CD-ROM format and are provided free of charge. The CD-ROM(s) contain WINDOWS compliant raster/vector formats (e.g. *.TIF, *.TIF (group4), *.DWG, and *.DWF, etc.).

Drawing measurements should be verified by the Contractor prior to ordering materials.

FAR 52.211-14 -- NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PREPAREDNESS, AND ENERGY PROGRAM USE (APR 2008)

Any contract awarded as a result of this solicitation will be [ ] DX rated order; [X] DO rated order certified for national defense, emergency preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR 700), and the Contractor will be required to follow all of the requirements of this regulation. (End of Provision)

FAR 52.215-5 FACSIMILE PROPOSALS (OCT 1997)

(a) Definition. Facsimile proposal, as used in this provision, means a proposal, revision or modification of a proposal, or withdrawal of a proposal that is transmitted to and received by the Government via…