hialeah SHIP_Program_Niurka_Ortiz.pdf

For more information, please visit our online supplier portal, located at https://procurement.opengov.com/portal/cityofhialeahfl

INVITATION FOR BID (“IFB”)

SHIP Program Niurka Ortiz

2025-26-046

ADDITIONAL INFORMATION & CLARIFICATION DEADLINE

Tuesday, September 22, 2026

RESPONSE SUBMISSION DATE AND TIME

Tuesday, September 29, 2026

Each Response must be submitted electronically to the City’s e-procurement Portal located at https://procurement.opengov.com/portal/cityofhialeahfl no later than the date and time specified below. Response received after said date and time or in any other format will not be considered and no time extensions will be granted.

Invitation For Bid #2025-26-046 Title: SHIP Program Niurka Ortiz

Table Of Contents

1. ADVERTISEMENT & INVITATION

2. GENERAL TERMS AND CONDITIONS

3. SPECIAL CONDITIONS

4. SCOPE OF SERVICES

5. RESPONSE

6. PRICING PROPOSAL

7. ATTACHMENTS

Attachments:

A - Sample Contract SHIP Bid

1. ADVERTISEMENT & INVITATION

The City of Hialeah, Florida, will receive electronic (sealed) response for the project entitled: SHIP Program

Niurka Ortiz until Tuesday, September 29, 2026 via the City's e-Procurement Portal located at https://procurement.opengov.com/portal/cityofhialeahfl. The responses must be submitted electronically in the manner specified below in the electronic submittal method described below and in no other manner. Bids submitted in any other manner will not be considered.

SHIP Program Niurka Ortiz

2025-26-046

Contract documents, including drawings, technical specifications, addendums, and proposal forms may be obtained on the City's e-Procurement Portal located at https://procurement.opengov.com/portal/cityofhialeahfl.

This project involves rehabilitation and updated of an existing single-family home, including roof replacement, new gutters, and replacement of windows and doors. HVAC systems will be upgraded, including relocation of the air handling unit, duct cleaning, and addition of new air vents.

Interior work includes kitchen remodeling with new appliances, lighting installation, closet modifications, removal of popcorn ceilings, and full interior and exterior painting. Plumbing and electrical systems will be inspected and repaired as needed, including grounding improvements and water line verification.

Exterior improvements include a new metal fence, replacement of the driveway, and installation of a new patio cover.

The contractor shall has solid experience in residential rehabilitation projects, including structural, mechanical, electrical, and plumbing upgrades, and capable of delivering quality work in compliance with applicable codes and standards.

Each Response must be submitted electronically via the City's e-Procurement Portal located at https://procurement.opengov.com/portal/cityofhialeahfl no later than the date and time specified below.

Bids received after said date and time or in some other manner than as stated above will not be considered and no time extensions or waivers will be granted.

The City’s schedule for this Solicitation is as follows:

Advertisement Date: August 30, 2026

Pre-Bid Meeting (Non-Mandatory): September 8, 2026, 10:00am

1160 W 33 Street, Hialeah FL 33012-

Last Date for Receipt of Questions: September 22, 2026, 2:00pm

Deadline for Submittal of Bids: September 29, 2026, 11:00am

(The City reserves the right to delay, reschedule, or modify scheduled dates/times and will use its best efforts to notify Bidders of all changes in scheduled dates.)

Attention to all contractors this is a Federal and/or State-funded project and the contractor must ensure that employees and applicants for employment are not discriminated against because of their age, race, creed, color, religion, sex, disability, national origin, or familial status.

The City of Hialeah provides equal access and equal opportunity in employment and services. Section 3

Business, Minority, and Women-owned businesses are encouraged to apply. There is no “Local Preference" for business located in the City of Hialeah or Miami-Dade County applicable or provided for in this solicitation.

The City of Hialeah reserves the right to reject any and all responses, and to decide to re-advertise/re-bid or not, or to waive any informalities or minor irregularities, technicalities, or omissions, in the solicitation process. Responses may be held over by the City of Hialeah Purchasing Division, at its sole discretion, for a period not to exceed one hundred eighty (180) days from the date of opening for the purpose of reviewing the responses and investigating the qualifications of the respondents, prior to consideration of the awarding of the contract and must be honored by the Vendor on the same terms and conditions during this period.

Please be advised that this Solicitation is issued subject to the City of Hialeah’s Charter and Code of

Ordinances. and the Miami-Dade County “Cone of Silence”, see 2-11.1(t), Miami-Dade County Code, which are deemed as being incorporated by reference in this Solicitation. Communications with the Mayor, City Council, and City Staff are restricted.

2. GENERAL TERMS AND CONDITIONS

2.1. CITY OVERVIEW

Hialeah, Florida (Estimated population of approximately 221,300) is a diverse community, ideally located midway between Miami and Fort Lauderdale, and encompasses approximately 23 square miles. As the fifth largest city in the State of Florida, Hialeah is committed to growth in its business and residential communities, while also focusing on issues such as education, the arts, leisure activities, public safety, and sustainability to provide a viable future for our residents and preserve the City’s rich history since its incorporation in 1925. In

2025 the City is celebrated its centennial.

The City currently has 1500+ employees and provides a wide range of governmental services to its citizens, including public safety/police services, parks and recreation, public works, water and sewer, planning, building and zoning, code enforcement, and community development.

The City is a very large consumer of goods and services, and the purchasing decisions of our employees and contractors can positively or negatively affect the environment. By including environmental considerations in our procurement information, along with our traditional concerns with price, performance, and availability, we will remain fiscally responsible while promoting practices that improve public health and safety, reduce pollution, and conserve natural resources, while still evaluating the Proposals on applicable legal and technical criteria.

2.2. DEFINITIONS

Capitalized words and phrases in this Solicitation are defined in this section and in the Agreement. In addition, the following terms, phrases, words, and their derivations shall have the meaning given herein:

A. 'Invitation for Bid ('IFB')' means a written solicitation for competitive sealed bids with the title, date and hour of the public bid opening designated and specifically defining the commodity, group of commodities or services for which bids are sought. The Invitation for Bid includes instructions prescribing all conditions for bidding and shall be available for distribution to all prospective bidders at the same time. The Invitation for Bid is used when the city is capable of specifically defining the scope of work for which a contractual service is required or when the city is capable of establishing precise specifications defining the actual commodity or group of commodities required.

B. ‘Agreement, Contract' means the “SHIP Program Niurka Ortiz”, including all of the exhibits and addendums/amendments thereto. No contract rights or expectations can be alleged, anticipated, expected, or claimed unless and until the Agreement is fully executed and a Work

Order or similar document, as applicable, has been issued by the City.

C. 'Award' means the acceptance of a Response, offer, similar response, or proposal by the City

Council of the City of Hialeah.

D. 'Successful Respondent, Contractor’ means the Respondent that receives an award of the

Agreement from the City as a result of this Solicitation.

E. ‘Respondent, Bidder, Proposer, Vendor, Contractor’ means the Person, company, business entity, or organization submitting a Response in reply to this Solicitation. When the terms “Respondent, Bidder, Vendor, Proposer, or Contractor” are used they shall have the same meaning in this solicitation.

F. 'City' means, depending on the context, either (a) the geographic area contained within the municipal boundaries of the City of Hialeah, Florida, or (b) the government of the City, acting through Mayor and/or the City Council or its designees, as applicable.

G. ‘Department’ means the City of Hialeah, FL, Grants & Human Services and/or their successor City

Department, office, agency, or division.

H. 'Director' means the Director, or the Director's authorized designee.

I. 'Solicitation' means this Invitation for Bid (IFB).

J. ‘Response, Bid, Submission’ means the response submitted in reply to this Solicitation.

K. 'Response, Bidder, and Proposer' have similar meanings under this Solicitation insofar as that they refer to the person or entity submitting a response to the Solicitation.

L. ‘Work,’ ‘Services,’ ‘Program,’ ‘Project,’ or ‘Engagement’ mean all matters and things that will require to be done by the Successful Respondent(s) in accordance with the scope of work and all terms and conditions of this Solicitation.

M. ‘Project Manager’ means the individual in charge of serving as the day-to-day representative of the City for the project and contract administration. The City Project Manager will be designated by the Mayor or Director.

N. 'Mayor' means the Chief Executive Officer of the City who manages the day-to-day operations of the City. The Mayor or his authorized designee will be authorized to make needed routine contractual decisions on behalf of the City.

O. 'City Council' means the local legislative body of the City who would consider approving the

Award, or not, as the case may be, and would need to approve any resulting Agreement, and any Amendments or modifications to such Agreement.

P. 'Purchasing Division Director’ means the Director of the City’s Purchasing Division who is authorized to respond to and address procurement/purchasing issues relative to this Solicitation and/or the award or other action of the City regarding this Solicitation.

2.3. INVITATION

This Solicitation is extended to any Person, company, and organization that can satisfy the requirements specified herein. The requirements presented in this Solicitation represent the City’s anticipated needs.

2.4. PUBLIC ENTITY CRIME / DISCRIMINATORY VENDOR LIST

The Public Entity Crime Affidavit Form, found in the RESPONSE Section, includes documentation that shall be executed by an individual authorized to bind the Respondent. Any Respondent, or any of its suppliers, subcontractors, or consultants who shall provide goods and services and/or materials that are intended to benefit the City, shall not be a convicted vendor or included on the discriminatory vendor list. If the

Respondent or any affiliate of the Respondent has been convicted of a public entity crime or has been placed on the discriminatory vendor list, a period longer than 36 months must have passed since that person was placed on the convicted vendor or discriminatory vendor list. The Respondent further understands and accepts that any contract issued as a result of this Solicitation shall be either voidable or subject to immediate termination by the City. In the event there is any misrepresentation or lack of compliance with the mandates of Section 287.133 or Section 287.134, respectively, Florida Statutes. The City in the event in such termination, shall not incur any liability or cost to the Respondent for any goods, services, supplies, materials, and/or materials furnished. By submitting a response, the Respondent further affirms they are not in violation of Sections 287.1346 , 287.135, 287.1351, 287.136, 287.137 and 287.138, Florida Statutes.

2.5. LOBBYING

All Respondents, their agents and proposed sub-consultants or subcontractors, are hereby placed on notice that neither the City Council members, any evaluation committee members, employees of the City or employees of any other project sponsoring agencies shall be lobbied either individually or collectively regarding this Solicitation. Respondents, their agents, and proposed sub-consultants or subcontractors are hereby placed on notice that they are prohibited from contacting any of these individuals for any purpose relating to the Solicitation (e.g., general information, meetings of introduction, meals, etc.). Any Response submitted by a Respondent, its agents and potential subconsultants or subcontractors who violate these guidelines will not be considered for review. The Purchasing Division Director (identified on the cover page of this Solicitation) shall be the only point of contact for questions and/or clarifications concerning the

Solicitation, the selection process and the negotiation and award procedures. See, for general reference, Section 2-11.1. (t), Miami-Dade County Code, “Cone of Silence”, which is applicable and deemed as being incorporated by reference.

2.6. SUSPENSION/DEBARMENT OF CONTRACTORS FOR MATERIAL

BREACH OF CITY CONTRACTS

The City may temporarily or permanently suspend or debar contractor(s) from doing business with the City whenever a contractor materially breaches its contract with the City in accordance with the applicable provisions of the City Code. Any Response submitted by a Respondent, its proposed subcontractors or subconsultants who are included on the City’s Suspension List shall not be considered for evaluation or review.

In addition, the principles of any Respondents or its proposed subcontractors or sub-consultants shall not attempt to do business with the City under a different name or form a new legal entity in order to do business with the City while the principals of the Respondent or its proposed subcontractors or subconsultants remain on the Suspension List. In the event there is any intentional misrepresentation, the Respondent further understands and accepts that any contract issued as a result of this Solicitation shall be subject to immediate termination for default and suspension procedures by the City. The City, in the event of such termination, shall not incur any liability to the Respondent for any goods, services or materials furnished. For purposes of this Solicitation “Respondents”, "Bidders", "Proposers", “Contractors” and “Vendors” are synonymous terms.

2.7. POINTS OF CONTACT/TIMETABLE FOR INQUIRIES

While respondents may initially contact the Purchasing Division Director, all general and technical inquiries must be submitted and addressed via the City's e-Procurement Portal Question & Answer feature.

No inquiries will not be entertained or processed beyond Tuesday, September 22, 2026 at 2:00 pm. No extensions or exceptions.

2.8. ORAL REPRESENTATION

No oral representation, conversation, or statement made by any City staff or official shall be binding on the

City. The contents of this Solicitation and any subsequent addenda issued by the City shall govern all aspects of this Solicitation.

2.9. ADDENDA

If any revisions to the Solicitation become necessary (other than changes to the deadline for Response submission), the City will notify all registered Respondents requesting the corresponding document at least three (3) calendar days before the date scheduled for opening on Tuesday, September 29, 2026 at 11:00

am. The City may revise the deadline for Response submission at any time prior to the date and time scheduled for opening the Responses. It is the sole responsibility of all Respondents to ascertain whether any addenda have been issued before the Solicitation deadline by either calling or checking with the City’s

Purchasing Division Director or Purchasing staff.

2.10. CANCELLATION OF THE SOLICITATION

The City expressly reserves the right to cancel this Solicitation, to reject any or all responses, and/or readvertise and re-solicit the requirements at any time for any reason whatsoever when determined to be in the best interest of the City. This right is expressly reserved and clearly announced in this Solicitation.

2.11. DEVELOPMENT COSTS

Neither the City nor its officers, employees, or representatives shall be liable for any expenses incurred by any Person in connection with the preparation, submission, or presentation of a Response in response to this

Solicitation. The Response and the information in the Response shall be provided at no cost to the City.

2.12. TAX-EXEMPT STATUS

The City is exempt from Florida Sales and Federal Excise taxes on direct purchases of tangible property by the City.

2.13. SOLICITATION SUBMISSION AND OPENING

Responses will be electronically opened and may be received up to but not later than Tuesday, September

29, 2026 at 11:00 am as indicated on the cover page of this Solicitation. Submit Electronic Responses via the

City of Hialeah https://procurement.opengov.com/portal/cityofhialeahfl. A list of Respondents shall be available via the City of Hialeah e-Procurement Portal. A list of Respondents shall be available via the City of Hialeah e-Procurement Portal.

The City of Hialeah e-Procurement Portal Clock is the official clock/record for the determination of all deadline dates and times. Without exception, responses will not be accepted after the submission deadline regardless of any technical difficulties such as poor internet, connections, disruptions, or going offline. The

City strongly recommends completing and electronically submitting your response well ahead of the deadline. Paper responses may not be submitted nor will they be considered.

2.14. ASSIGNMENT OF SOLICITATION

A Respondent shall not transfer, sell, pledge, give, grant, or assign its Response, in whole or in part, directly or indirectly, to any third-party following submission of a Response to the City. No exceptions.

2.15. WITHDRAWAL OF SOLICITATION

A Respondent may withdraw their electronically submitted Response. Responses, once opened, shall not be withdrawn or modified except to the extent (if any) agreed to by the City in its sole discretion during subsequent contract negotiation.

2.16. PUBLIC RECORDS AND EXEMPTIONS

As provided specifically in Section 119.071 (1) (b), Florida Statutes, Responses become “public records” and shall be subject to public disclosure consistent with Chapter 119, Florida Statutes. Respondents shall invoke the exemptions to disclosure provided by law, in the Response, by providing the specific statutory authority for the claimed exemption, identifying the data or other materials to be protected, and stating the reasons why such exclusion from public disclosure is necessary.

The Respondent shall comply with the Public Records Laws, including but not limited to: (1) keeping and maintaining all public records that ordinarily and necessarily would be required by the City in order to perform the service; (2) providing the public with access to public records on the same terms and conditions that the City would provide the records and at a cost that does not exceed the cost provided in Chapter

119, Florida Statutes, or as otherwise provided by law; (3) ensuring that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law; and (4) meeting all requirements for retaining public records and transferring, at no cost, to the City all public records in possession of the Contractor upon termination of the Contract and destroying any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements upon such transfer. In addition, all records stored electronically must be provided to the City in a format that is compatible with the information technology systems of the City. Failure to meet any of these provisions or to comply with Florida’s Public Records Laws as applicable shall be a material breach of this Agreement and shall be enforced by the terms and conditions of the Agreement.

IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO

THE CONTRACTOR’S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS AGREEMENT, THE CONTRACTOR

SHOULD CONTACT THE CITY’S CUSTODIAN OF PUBLIC RECORDS: THE CITY CLERK, BY TELEPHONE (305/883-

5820), E-MAIL (CityClerk@hialeahfl.gov), OR MAIL (CITY OF HIALEAH, OFFICE OF THE CITY CLERK, 501 PALM

AVENUE, 3RD FLOOR, HIALEAH, FLORIDA 33010).

2.17. GROUNDS FOR REJECTING RESPONSES

The City reserves the right to reject any and all Responses for reasons including, but not limited to, the following: (1) when such rejection is in the best interests of the City; (2) if such Response is deemed non-responsive; (3) if the Respondent is deemed non-responsible; or (4) if the Response contains any material misstatements, irregularities, defects, errors, mistakes or omissions. Minor irregularities contained in a

Response may be waived by the City in its discretion. A minor irregularity, technicality, error, mistake, or omission is a variation from the Solicitation that does not affect the price of the contract nor does it give a

Respondent an advantage or benefit not enjoyed by other Respondents and does not adversely impact the City.

Responses found to be non-responsive may not be considered. A Response may be found to be non-responsive because, among other things, the Respondent: failed to utilize or complete or sign the required forms; failed to provide any information requested by the City; provided incomplete, indefinite, or ambiguous responses; failed to comply with the applicable deadlines; or provided improper or undated signatures. The City’s grounds for rejecting Responses include, but are not limited to, evidence of: collusion among Respondents; a lack of experience, expertise, or other qualifications to perform the required work;

a submission of more than one Response by any Person under the same or different names; the failure to perform satisfactorily or meet financial obligations on previous contracts; the employment of unauthorized aliens in violation of Section 274(A)(e) of the Immigration and Naturalization Act; the listing of a Respondent on the U.S. Comptroller General’s List of Ineligible Companies for Federally Financed or Assisted Projects; or the listing of a Respondent on the City’s or the State’s Debarred, Convicted or Discriminatory Contractor’s

List or a listing of the Respondent as a debarred or discriminatory vendor per Section 287.133, Florida Statutes or discriminatory vendor under Section 287.134, Florida Statutes or is contracting with scrutinized companies under Section 287.135, Florida Statutes or is a suspended vendor under Section 287.1351, Florida Statutes or has antitrust violations per Section 287.137, Florida Statutes, or is in violation of Section 287.138, Florida

Statutes, prohibiting contracting with entities of foreign countries of concern . In addition, Responses will be rejected if the Responses are not delivered to the City’s Purchasing Division on or before the date and in the manner and time specified for the submittal of the Response.

2.18. CONE OF SILENCE / CONFLICT OF INTEREST AND CODE OF

ETHICS

After the advertisement of this Solicitation, all communications concerning this Solicitation shall be directed to the City’s Purchasing Division Department. Potential Respondents and their agents and employees shall not contact the Mayor, any member of the City Council, or any member of the City staff, except the

Purchasing Division Director, to discuss this Solicitation. Notwithstanding any other provision of this section, the imposition of a cone of silence on this Solicitation shall not preclude purchasing staff from obtaining industry or trade comments, input, or performing market research provided all communications related thereto with a potential offeror, service provider, Respondent, lobbyist, or consultant are in writing or are made at a duly noticed public meeting. The Miami-Dade County Cone of Silence Ordinance, Section 2-

11.1(t), Miami-Dade County Code is deemed as being incorporated by reference herein and made applicable to this solicitation. This Section does not apply to oral communications at pre-solicitation meetings, oral and/or written presentations before selection committees, contract negotiations, and public presentations made to the City Council during any duly noticed public meeting. A copy of all written communications must be filed with the City Clerk and a copy will be forwarded to other respondents who are on record for this Solicitation.

2.19. BUSINESS ENTITY REGISTRATION

The City of Hialeah requires business entities to complete and file a registration application before doing business with the City. Respondents need not register with the City to present a Response; however, the selected Respondent(s) must register before the award of a contract because the failure to register may result in the rejection of the Response. To register, contact the Purchasing Division at (305) 883-5865. It is the responsibility of the business entity to update and renew its application concerning any changes, such as new address, telephone number, etc. during the performance of any agreement, purchase order, or similar document obtained as a result of this Solicitation.

2.20. STATE REGISTRATION REQUIREMENTS

Any Respondent required by Florida law to register to do business in this state shall either be registered or have applied for registration with the Florida Department of State in accordance with the provisions of

Chapters 607, 608, 617, and/or 621 Florida Statutes. A copy of the registration/application and current certificate of good standing will be required prior to the award of a contract. Any partnership submitting in response to this Solicitation shall have complied with the applicable provisions of Chapter 321, Florida

Statutes. Any Limited Liability Company submitting in response to this Solicitation shall have complied with the applicable provisions of Chapter 605, Florida Statutes.

2.21. EXECUTION OF SOLICITATION

The Response must contain a manual signature (an electronic signature conforming to the requirements of

Florida law is acceptable) of an authorized representative in the space provided on the Response Form.

Failure to properly sign the Response shall invalidate the same and it shall NOT be considered for award eligible for consideration or award. If a correction is necessary, draw a single line through the entered figure and enter the corrected figure above it. Corrections must be dated and initialed by the person signing the

Response. Electronic initialing approved by Florida Law is acceptable. Any illegible entries, pencil

Responses, or corrections not initialed will not be tabulated. The original Response conditions and specifications CANNOT be changed or altered in any way after being submitted to the City.

2.22. LEGAL REQUIREMENTS

Federal, State, County and City laws, ordinances, codes, rules, and regulations that in any manner affect the items covered herein apply. Lack of knowledge by the Respondent will in no way be a cause for relief from responsibility for compliance by the Respondent.

The individual executing this Response on behalf of the Company warrants to the City that the Company is a Florida corporation duly constituted and authorized to do business in the State of Florida, is in good standing and that Company possesses all of the required licenses and certificates of competency required by the State of Florida and the County of Miami-Dade to provide the goods or perform the services herein described.

2.23. SOLICITATION OPENING

Solicitations shall be opened electronically on the date and at the time and in the manner specified on the City’s e-Procurement Portal. Solicitations will not be opened except as provided in this section.

2.24. DISPUTES

In case of any doubt or difference of opinion as to the services to be furnished hereunder, the decision of the Purchasing Director, after consultation with the City Attorney shall be final and binding on both parties.

Any timely protest meeting the requirements of Section 2-815.1 of the City Code shall be handled pursuant to Section 2-815.1 of the City Code.

2.25. PATENTS & ROYALTIES

The Respondent, without exception, shall indemnify, defend (at its own cost and expense), hold, and save harmless the City of Hialeah, Florida, and its officials & employees from liability of any nature or kind, including costs and expenses for, or on account of, any copyrighted, patented, or unpatented invention, intellectual property rights, process, goods, or articles manufactured or used in the performance of the contract, including their use by the City. If the Respondent uses any design, device, or materials covered by letters, patent, copyright, and/or any other intellectual property rights it is mutually understood and agreed, without exception, that the Response prices shall include all royalties and/or costs arising from the use of such design, device, or materials in any way involved in providing the required goods or services. This

Section shall survive the cancellation/expiration of the Contract and the Work.

2.26. OSHA

The Respondent warrants that the product and services supplied to the City shall conform in all respects to the standards outlined in the Occupational Safety and Health Act of 1970, as amended, and the failure to comply with this condition will be considered as a breach of contract. Any fines levied because of inadequacies to comply with these requirements shall be borne solely by the Respondent responsible for same.

2.27. SPECIAL CONDITIONS

Any Special Conditions that vary from these General Conditions shall have precedence and in the event of an express conflict, the Special Condition(s) will govern and control.

2.28. ANTI-DISCRIMINATION

The Respondent certifies compliance with the non-discrimination clause contained in Section 202, Executive

Order 11246, as amended by Executive Order 11375, relative to equal employment opportunity for all persons without regard to race, color, religion, sex, or national origin.

2.29. INSURANCE/PERMIT

Respondents are required to assume the full duty, obligation and expense of obtaining all necessary licenses, permits and insurance and assure all work complies with all Miami-Dade County and City of

Hialeah Code and building requirements, and the Florida Building Code. The Respondent shall be liable for any damages or loss to the City occasioned by negligence of the Respondent (or agent) or any person the

Respondent has designated in the completion of the contract as a result of the Response. The Insurance

Coverage required by the City for this Work is provided in the Response. Any modifications to the Insurance

Coverage must be approved in advance and in writing by the City Risk Manager or designee prior to solicitation closing on Tuesday, September 29, 2026. This Section shall survive the cancellation/expiration of the Contract and the Work.

NO MODIFICATIONS TO THE INSURANCE REQUIREMENTS WILL BE ALLOWED AFTER THE SOLICITATION CLOSING.

2.30. BID BOND/BID SECURITY/BID DEPOSIT

A bid bond will be required if the bid amount exceeds $100,000.00. A Bid Bond, a certified check, cashier’s check, Treasurer’s check or bank draft of any State or National Bank in the amount of five percent (5%) of the total bid amount must be submitted as an original hard copy prior to the closing date and time of the solicitation. The bonding company must appear on the US Treasury List. The Bid Bond of the successful

Respondent will be retained until receipt and acceptance of a performance bond and all other required documents. Bid Bonds of all other Bidders will be returned without interest upon Award of Contract. Failure to provide the bid bond when required shall result in the Bidder being “non-responsive” and rejected. The original bid bond must be delivered prior to the closing of the solicitation to the Purchasing Division with the name of the solicitation clearly indicated.

2.31. PERFORMANCE AND PAYMENT BOND

Performance and Payment Bonds will be required if the contract amount exceeds $ 200,000.00. The successful Bidder shall post a Performance and Payment Bond from a Corporate Surety after an approved award, which is satisfactory to the City as security for the performance and prompt payment to all persons supplying labor and material in the execution of the work to be performed under this Contract and on any and/or all duly authorized modifications hereof. A bond will be posted on a per project basis and shall be a sum equal to one hundred percent (100%) of each project(s) total, unless otherwise specified. The bond may be in the form of a Cash Bond or Surety bond written through an approved, reputable, and responsible company authorized to do business in the State of Florida. Attorneys-in-fact who sign bid bonds or contract bonds must file with such bond a certified copy of power of attorney to sign said bond.

Performance Bond must be filed by the Contractor with the City Clerk, in the full amount of the contract price, as set forth here within this section in form and with corporate surety currently authorized to transact business in Florida, conditioned upon the performance of the work in accordance with the Contract and the Plans and Specifications thereof, and for the payment of all persons performing labor and furnishing goods, services, equipment, supplies, and/or materials in connection with the Contract and indemnifying, defending, and holding harmless said City of Hialeah from any expense, loss, action, claim, or cost arising from and out of the improper/deficient/defective/substandard/negligent performance of said Contract and/or the failure to make required payments to all such persons.

2.32. BID BOND/BID SECURITY/BID DEPOSIT FORFEITED LIQUIDATED

DAMAGES

The following specification shall apply to bid/proposal, performance, payment, maintenance, and all other types of bonds:

All Bonds shall be written through surety insurers authorized to do business in the State of Florida as surety, with the following qualifications as to management and financial strength according to the latest edition of Bests Insurance Guide, published by A.M. Best Company, Oldwick, New Jersey.

Bond Amount Best Rating

500,000 to 1,499,999 A VI

1,500,000 to 2,499,999 A VIII

2,500,000 to 4,999,999 A X

5,000,000 to 9,999,999 A XII over 10,000,000 A XV

On bond amount of $500,000 or less, the provisions of Section 287.0935, Florida Statutes shall be in effect and surety companies not otherwise qualifying with this paragraph may optionally qualify by:

1. Providing evidence that the surety has twice the minimum surplus and capital required by the Florida

Insurance Code at the time the Invitation for Bid and/or Request for Proposals is issued.

2.Certifying that the surety is otherwise in compliance with the Florida Insurance Code.

3.Providing a copy of the currently valid Certificate of Authority issued by the United States Department of the Treasury under ss. U.S.C. 9304-9308.

Surety insurers shall be listed in the latest Circular 570 of the U.S. Department of Treasury entitled A Surety

Companies Acceptable to the Federal Bonds, published annually. The bond amount shall not exceed the underwriting limitations.

2.33. FACILITIES

The City reserves the right to inspect the Respondent’s facilities and /or local office at any time during regular business hours with prior oral or written notice.

2.34. SOLICITATION TABULATIONS

Solicitation Tabulations will be made available electronically to all Respondents upon award of this solicitation via the City of Hialeah e-Procurement

Portal https://procurement.opengov.com/portal/cityofhialeahfl.

2.35. APPLICABLE LAW AND VENUE; ATTORNEY'S FEES

The laws of the State of Florida shall govern this Solicitation and the contract between the City of Hialeah and the successful Respondent. Any action or proceeding including, without limitation, dispute resolution and/or mediation, concerning this Solicitation or the Agreement shall be brought exclusively in the State or

Federal Courts or administrative officers in and for Miami-Dade County, Florida. Parties consent to jurisdiction within Miami-Dade County, Florida. Each party shall bear their own attorney’s fees.

2.36. CLARIFICATION AND ADDENDA TO SOLICITATION

SPECIFICATIONS

If any person contemplating submitting a Response under this Solicitation is in doubt as to the true meaning of the specifications or other Solicitation documents or any part thereof, the Respondent must submit a request for clarification to the City of Hialeah Purchasing Director. Respondents shall submit all inquiries regarding this Solicitation via the City of Hialeah e-Procurement Portal, located at https://procurement.opengov.com/portal/cityofhialeahfl.Please note the deadline for submitting inquiries.

All answers to inquiries will be posted on the City of Hialeah e-Procurement Portal. Respondents may also click “Follow” on this Solicitation to receive an email notification when answers are posted. It is the responsibility of the respondent to check the website for answers to inquiries.

Any interpretation of the Solicitation, if made, will be made only by Addendum duly issued by the City of

Hialeah Purchasing Division Director. The City shall issue an Informational Addendum if clarification or minimal changes are required. The City shall issue a Formal Addendum if substantial changes which impact the technical submission of Responses are required.

2.37. AWARD OF CONTRACT

Firm Offer and Pricing Hold: By submitting a Response to this Solicitation, the Respondent acknowledges and agrees that their Response and all submitted pricing constitute a firm, irrevocable offer. The Respondent explicitly agrees to honor and hold firm all pricing, terms, and conditions proposed in their Response for a minimum period of one-hundred and eighty

(180) calendar days from the official date and time of the Bid opening. No price escalation, surcharge, market adjustment or additional fee shall apply during such period.

A. The Formal Solicitation, any addenda issued, the Respondent's response, and the

Purchase Order, which for purposes of this Solicitation collectively serve as the

Contract Documents, and any Work Order(s) or similar document issued by the City, shall constitute the entire Contract unless modified in accordance with any ensuing

Contract, or amendment approved by the City and executed by the parties.

B. The City may award a contract to a Respondent only through action taken by the

City Council.

C. While the City may determine to award a contract to a Respondent(s) under this

Solicitation, said Award may be conditional on the subsequent submission of other documents as specified in the Special Conditions. The Respondent shall be in default of any conditional award if any of these documents are not submitted in a timely manner and in the form required by the City. If the Respondent is in default, the City, through the Purchasing Division Director, will void/rescind its acceptance of the

Respondent’s offer and may determine to select the second lowest most responsive, responsible Respondent, reject remaining responses and/or re-solicit Responses. The

City may, at its sole option, seek monetary restitution from the defaulting Respondent as a result of damages or excess costs sustained and/or may prohibit the Respondent from submitting future Responses for one (1) year.

D. The City reserves the right to exercise the option to renew a term contract of any successful Respondent(s) to a subsequent optional renewal period; provided that such option is stipulated in the contract ultimately awarded in regard to this

Response; provided that such option is agreed in the contract awarded in regard to this Response.

E. The City reserves the right to automatically extend any contract for a maximum period not to exceed ninety (90) calendar days in order to provide City departments with continual service and supplies while a new contract is being solicited, evaluated and/or awarded, provided this is expressly made a part of any contract awarded in regard to this Response. Any such extension shall be upon the same terms and conditions contained in the original contract unless otherwise approved in writing by the City.

F. The City reserves the right to award the Contract on a split-order, lump sum, individual-item, multiple item/respondent(s) basis, or such method of award in the best interest of the City, unless otherwise specified.

G. Where the Contract involves a single shipment of goods to the City, the Contract term shall conclude upon completion of the expressed or implied warranty periods.

2.38. ASSIGNMENT

The City has relied on the Respondent’s submission in selecting the Respondent. The Respondent shall not assign, transfer, convey, sell, pledge, grant, or otherwise dispose of any contract, or similar document, in whole or in part, including any or all of its right, title, or interest therein, or its power to execute such contract to any person, company, incorporated business entity including a corporation or LLC without the prior written consent of the City, which may be withheld, refused or conditioned.

2.39. LAW, PERMIT AND REGULATIONS

The Respondent shall apply for, obtain and pay all licenses, permits, regulatory and other required approval(s), and inspection fees as may be required by the Agreement , by law, and this Solicitation. The

Respondent shall comply with all applicable laws, ordinances, regulations, and Florida Building Code requirements applicable to the construction, goods or services contemplated herein.

2.40. SPOT MARKET PURCHASES

It is the intent of the City to purchase the goods and/or services specifically listed in this Solicitation from the selected Respondent. However, items that are to be “Spot Market Purchased” may be purchased by other methods, i.e., Federal, State, County, Entities or Agencies, Special Districts, other public agency, or local contracts.

2.41. INCENTIVES/ DISCENTIVES

The City has EXCLUDED incentive/disincentive for early completion provisions in the contract. Liquidated damages may apply for untimely delivery of goods, materials, supplies, or services if included in the

Contract Documents. .

2.42. NON-COLLUSION

By submitting this Response, Respondent certifies that this offer is made without prior understanding, agreement, or connection with any corporation, firm or person submitting an offer for the same materials, services, supplies, or equipment and is in all respects fair and without collusion or fraud.

No premiums, rebates or gratuities are permitted, either with, before to or after any delivery of material or provision of services. Any violation of this provision may result in the Contract cancellation, return of materials or discontinuation of services and the possible removal from the vendor Response list(s).

2.43. STANDARDIZED CHANGES

Contract documents shall be modified, if necessary, to reflect the requirements of 23 Code of Federal

Regulations ("CFR") 635.109, as amended. The changed conditions contract clauses shall be made part of, and incorporated in this project which has been approved under 23 United States Code ("U.S.C.") 106, as amended.

2.44. LOCAL PREFERENCE

In a competitive bid process where an award, if any, is to be made to the responsive and responsible bidder offering the lowest bid, the local Bidder shall be entitled to the preference subject to Section 2-820. Local

Business Preference of the Code, which, except where contrary to federal or state law, or any other funding source requirements, provides that preference be given to local businesses.

a. A Local Business who is within two (2%) percent of the lowest bidder, who is not entitled to preference, and is determined to be the lowest bidder, shall be provided an opportunity to offer a price that must be at least two (2%) percent less than the lowest bidder.

NOTE: THE FOREGOING LOCAL PREFERENCE WILL NOT APPLY IF THIS WORK IS BEING FUNDED BY

THE STATE OF FLORIDA OR THE UNITED STATES OR A DEPARTMENT OR AGENCY OF THE STATE OF

FLORIDA OR A FEDERAL GOVERNMENT AGENCY OR IF DISALLOWED BY LAW OR A FUNDING

SOURCE BEING USED FOR PAYMENT

2.45. E-VERIFY EMPLOYMENT VERIFICATION

The Successful Respondent shall E-Verify the employment status of all employees and subcontractors to the extent required by federal, state, and local laws, rules, and regulations. The Successful Respondent shall not employ, contract, hire, or retain any person who is not legally authorized under federal law to be employed in the United States, as set forth in 8 U.S.C. Section 132a(h)(3), as interpreted by any applicable federal rule or regulation and pursuant to Chapter 448.95 of the Florida Statutes. The City shall consider the employment by any Successful Respondent of unauthorized aliens a violation of Section 274A(e) of the Immigration and

Nationality Act. If the Successful Respondent knowingly employs unauthorized aliens, such violation shall be cause for termination of the Contract. Furthermore, the Successful Respondent agrees to utilize the U.S.

Agency of Homeland Security’s E-Verify System, https://everify.uscis.gov/emp, to verify the employment eligibility of all employees during the term of this Contract. The Successful Respondent shall also include a requirement in subcontracts that the subcontractor shall also utilize the E-Verify System to verify the employment eligibility of all employees of the subcontractor during the term of this Contract. A sample E-

Verify affidavit to be submitted to the City is attached.

By entering into this Contract, the Contractor and its Subcontractors are jointly and severally obligated to comply with the provisions of Section 448.095, Florida Statutes, as amended, titled “Employment Eligibility.”

The Contractor affirms that (a) it has registered and uses the U.S. Department of Homeland Security’s E-

Verify system to verify the work authorization status of all new employees of the Contractor; (b) it has required all Subcontractors to this Contract to register and use the E-Verify system to verify the work authorization status of all new employees of the Subcontractor; (c) it has an affidavit from all Subcontractors to this Contract attesting that the Subcontractor does not employ, contract with, or subcontract with, unauthorized aliens; and (d) it shall maintain copies of any such affidavits for the duration of the Contract.

Registration information is available at: (http://www.uscis.gov/e-verify)

If the City has a good faith belief that the Contractor has knowingly violated Section 448.09(1), Florida

Statutes, then the City shall terminate this contract in accordance with Section 448.095(5)(c), Florida

Statutes. In the event of such termination, the Contractor agrees and acknowledges that it may not be awarded a public contract for at least one (1) year from the date of such termination and that the

Contractor shall be liable for any additional costs incurred by the City because of such termination.

In addition, if the City has a good faith belief that a Subcontractor has knowingly violated any provisions of

Sections 448.09(1) or 448.095, Florida Statutes, but the Contractor has otherwise complied with its requirements under those statutes, then the Contractor agrees that it shall terminate its contract with the

Subcontractor upon receipt of notice from the City of such violation by the Subcontractor in accordance with Section 448.095(5)(c), Florida Statutes.

Any challenge to termination under this provision must be filed in the Circuit or County Court by the City, Contractor, or Subcontractor no later than twenty (20) calendar days after the date of contract termination.

2.46. DRAFT AGREEMENT

Respondents should fully review the Draft Agreement in its ENTIRETY. Exceptions not expressly and timely taken by addendum process of clarifications to questions posed are expressly and unconditionally waived. A copy of the Draft Professional Services Agreement is attached to this solicitation.

2.47. NO SHARING OF DATA WITH CERTAIN FOREIGN COUNTRIES OF

CONCERN

Respondent affirms by the Form included in this Solicitation that it does not meet any of the criteria listed in

Section 287.138 (2) (a) ---(c), Florida Statutes.

A. The Respondent intending to provide goods or services to the City during any contract renewal, extension, or amendment, as applicable, affirms and stipulates that it is not in violation of Florida

Statutes (F.S.) 287.138 entitled “Contracting with entities of foreign countries of concern prohibited.”

B. The Respondent further affirms to the City, as a governmental entity defined in Florida Statutes

(F.S.) 287.138, that: it is not giving access to an individual’s personal identifying information if the foreign country of concern, as defined in F.S. 287.138, owns the entity or has a controlling interest in the entity or the entity is organized under the laws of or has its principal place of business in a foreign country of concern.

C. A sample affidavit concerning Contracting with foreign countries of concern is attached. This

Affidavit will affirm under penalty of perjury that the Contractor does not meet any of the criteria in paragraphs (2) (a)-(c) of 287.138, F.S.. All Affidavits must be executed and submitted to the

City prior to any award of this Contract. Affidavit forms are available, upon request, from the City

Purchasing Divisions.

2.48. NO LABOR THROUGH COERCION

Respondent affirms that it does not use coercion for labor or services it uses as defined in 787.06, F.S.

Respondent, prior to entering into an Agreement with the City shall furnish an Affidavit, under penalty of perjury, that is does not use coercion for labor or services.

2.49. NO ILLEGAL TRANSPORT OF ALIENS

Prohibition Against Governmental Entity Contracts With Common Carrier or Contracted Carrier By entering into, amending, or renewing this Contract, including, without limitation, a grant agreement or economic incentive program…