FA7000-12-R-0014.pdf

VANDENBERG HALL RENOVATION PHASE 9

- Project Title: Renovate Vandenberg Hall Phase 9, USAF Academy, CO

- Project Number: XQPZ11-0103J.

- Place of Performance: Vandenberg Hall (Building 2360), USAF Academy, CO

- Period of Performance: 301 calendar days after receiving notice of aw ard.

- Type of Contract: Firm Fixed Price Construction (See Section L).

- Magnitude of Construction: Betw een $10,000,000.00 and $20,000,000.00.

- NAICS Code 236220, Commercial and Institutional Building Construction. Size Standard: $33,500,000.00.

- Specif ications and Draw ings: Reference Section C of this Soliciation

- A Site Visit is planned for 9 August 2012 (See Section L)

- Notice to Proceed: Contingent upon receipt of acceptable bonds. It is anticipated a Notice to Proceed w ill be issued w ithin 15 days of contract aw ard.

- Liquidated Damages for this project w ill be accessed at a rate of $541.64 per day until w ork is completed if not completed w ithin the period of performance.

- Competition: This acquisition is a Service-Disabled Veteran-Ow ned Small Business Set-Aside in accordance w ith FAR Part 19.1405(b).

CHRISTINA LEARY 719-333-4986

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

03-Aug-2012

(RFP)

(IFB)

X

CALL:

Renovate Vandenberg Hall Phase 9

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______15 calendar days and complete it w ithin ________301 calendar days after receiving aw ard, notice to proceed. This performance period is X mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________04 Sep 2012 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

10 CONS - FA7000

LEARY, C.

5226 CEDAR DRIVE,

LGCA

USAF ACADEMY CO 80840-2315

FA7000

PAGE OF PAGES

1 OF

CODE FA7000

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

10 CONS - FA7000

LEARY, C.

8110 INDUSTRIAL DRIVE, STE 200

LGCA

USAF ACADEMY CO 80840-2315

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

XQPZ11-0103J

8. ADDRESS OFFER TO (If Other Than Item 7)

719-333-6608FAX:TEL: 719-333-4986 TEL: 719-333-4986 FAX: 719-333-6608

FA7000-12-R-0014 43

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA7000-12-R-0014

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot Renovate Vandenberg Hall Ph 9

FFP

Renovate Vandenberg Hall Phase 9, Building 2360. Furnish all labor, materials, equipment, transportation, and supervision necessary for a complete and functional project in accordance with the Project XQPZ 11-0103J Specifications and Drawings. STRADDLE A PROJECT.

FOB: Destination

SIGNAL CODE: A

NET AMT

0002 1 Lot OPTION Renovate Vandenberg Hall 9 Pavilllions

FFP

Renovate Vandenberg Hall Phase 9, Building 2360. Furnish all labor, materials, equipment, transportation, and supervision necessary for a complete and functional project in accordance with the Project XQPZ 11-0103J Specifications and Drawings for eight (8) barbeque pavillions. STRADDLE A PROJECT. Option may be exercised no later than 31 December 2012.

0003 1 Lot OPTION Renovate Vandenberg Hall 9 Landscaping

FFP

Renovate Vandenberg Hall Phase 9, Building 2360. Furnish all labor, materials, equipment, transportation, and supervision necessary for a complete and functional project in accordance with the Project XQPZ 11-0103J Specifications and Drawings for landscaping. STRADDLE A PROJECT. Option may be exercised no later than 31 December 2012

Section C - Descriptions and Specifications

DESCRIPTIONS/SPECIFICATIONS

C1 - DESCRIPTION OF SPECIFICATIONS

United States Air Force Academy Project No. XQPZ11-0103J SPECIFICATIONS to Renovate Vandenberg Hall Phase 9, dated 3 July2012, consisting of 640 pages. (See Section J)

C2 – DESCRIPTION OF DRAWINGS

United States Air Force Academy Project No. XQPZ11-0103J DRAWINGS to Renovate Vandenberg Hall Phase 9, dated 3 July 2012 2012, consisting of 184 pages. (See Section J)

C3 – REPORTS AND OTHER PROJECT DOCUMENTATION

1. Environmental documents consisting of Appendix A Solid Waste Diversion Determination, Appendix B Solid Waste Report, and Appendix E Green Procurement Program.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE

A. The Civil Engineer or authorized representative is designated for the purpose of serving as the Government’s inspector. The designation will be provided to the contractor in writing following contract award. The inspector will perform duties including technical surveillance, ensuring compliance with workmanship and with the plans and specifications of this project. The provision does not authorize anyone other than the applicable Contracting Officer to commit the Government to changes in terms of this contract.

The only person authorized to make changes to the contract (to include contract specifications) is the Contracting Officer.

B. Inspection: The final inspection shall be requested in writing and must be submitted by the contractor seven (7) calendar days in advance of the requested inspection date. Final inspections will be conducted with the contractor and the Government’s contracting representative(s) present.

C. Acceptance: Only the Government’s COR will accept services performed for the Government under this contract when awarded.

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government 0003 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERIES OF PERFORMANCE

A. Unless otherwise specified within the contract, the Contractor shall be required to (a) commence work within the calendar days indicated in Block 11, SF 1442, after receipt of the Notice to Proceed (NTP), (b) prosecute the work diligently, and (c) complete the entire work ready within the number of calendar days indicated in Block 11 of the SF 1442, unless modified by a future change to the contract. The date computed from the NTP shall include final cleanup of the premises.

B. Exclusion periods: Exclusion period(s) are incorporated into the contract. These exclusion(s) may equate to, but are not limited to, scheduled events such as those relating to the sports season (soccer, football and golf), graduation, Corona Conference, cadet parades, parent’s weekend, etc. No work will be performed during the exclusion period(s) without the approval of the Contracting Officer. Such exclusion period(s) shall be considered in computing the time allowed for project completion. Upon receiving approval from the Contracting Officer, the contractor may perform work during all or any part of the exclusion period; however, the days worked during the exclusion period will be considered and applied toward the total project performance period reflected in the contract. See Specifications.

C. Winter exclusion: None

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 301 dys. ADC 1 10 CES - F4BQ00

CONSTRUCTION MANAGEMENT

8120 EDGERTON DRIVE

USAF ACADEMY CO 80840

719-333-4876

F4BQ00

0002 301 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0003 301 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

52.211-13 Time Extensions SEP 2000 52.236-1 Performance of Work by the Contractor APR 1984 52.242-14 Suspension of Work APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 301 days. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $541.64 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Section G - Contract Administration Data

WIDE AREA WORK FLOW

CONTRACT ADMINISTRATION DATA

USAFA INVOICING INSTRUCTIONS

Payment request (invoice) may not be entered into WAWF until all necessary documentation has been received and approved by the Contracting Officer. Documentation for a monthly invoice includes, but is not limited to, the invoice, approved progress reports (two monthly), and subcontractor payment log (if applicable).

Final invoice will include a Release of Claims, all documents listed above and approval of all final close-out documentation identified in the Contract.

WAWF INVOICING PROCEDURES

a. The contractor shall submit all necessary documentation and (1) copy of their invoice IAW FAR 52.232-5, Payments Under Fixed-Price Construction Contracts (Sep 2002) to the USAFA Contracting Office as stated in paragraph B. All invoices submitted under this contract must contain the following information and the “Contractor Certification: required by FAR 52.232-5, Payments Under Fixed-Price Construction Contracts”. Failure to follow these procedures may cause a delay in invoice payment.

Name of Contractor Invoice Date Contract Number Invoice Number Description of the services for which the invoice is being submitted.

A point of contact to include the name, phone number and e-mail

b. Contract Administration Office:

USAF Contracting Office

10 MSG/LGC

8110 Industrial Drive, Suite 200

USAFA, CO 80840

c. Payment will be made by:

Defense Finance and Accounting Service (DFAS) Limestone

DFAS BAASD/CC

P.O. Box 369020 Columbus, Ohio 43236-9020

d. Accounting and Appropriation Data: Account and Appropriation Data cited on the contract.

The procedures for the use of WAWF will be addressed in the Pre Performance Conference held prior to receipt of the Notice to Proceed.

52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002

252.232-7003 Electronic Submission of Payment Requests and Receiving Reports

MAR 2008

252.232-7010 Levies on Contract Payments DEC 2006

Section I - Contract Clauses

52.202-1 Definitions JAN 2012 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees APR 1984 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures OCT 2010 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997 52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-12 Limitation On Payments To Influence Certain Federal Transactions

OCT 2010

52.203-13 Contractor Code of Business Ethics and Conduct APR 2010 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 Central Contractor Registration FEB 2012 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

FEB 2012

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

DEC 2010

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

FEB 2012

52.210-1 Market Research APR 2011 52.215-2 Audit and Records--Negotiation OCT 2010 52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.215-10 Price Reduction for Defective Certified Cost or Pricing Data AUG 2011 52.215-11 Price Reduction for Defective Certified Cost or Pricing Data--

Modifications

AUG 2011

52.215-12 Subcontractor Certified Cost or Pricing Data OCT 2010 52.215-13 Subcontractor Certified Cost or Pricing Data--Modifications OCT 2010 52.215-21 Requirements for Certified Cost or Pricing Data or

Information Other Than Certified Cost or Pricing Data-- Modifications

OCT 2010

52.215-23 Limitations on Pass-Through Charges OCT 2009 52.219-8 Utilization of Small Business Concerns JAN 2011 52.219-14 Limitations On Subcontracting NOV 2011 52.219-27 Notice of Service-Disabled Veteran-Owned Small Business

Set-Aside

NOV 2011

52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-6 Davis Bacon Act JUL 2005 52.222-7 Withholding of Funds FEB 1988 52.222-8 Payrolls and Basic Records JUN 2010 52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) JUL 2005 52.222-12 Contract Termination-Debarment FEB 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988 52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility FEB 1988 52.222-21 Prohibition Of Segregated Facilities FEB 1999 52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.222-26 Equal Opportunity MAR 2007 52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

52.222-35 Equal Opportunity for Veterans SEP 2010 52.222-36 Affirmative Action For Workers With Disabilities OCT 2010 52.222-37 Employment Reports on Veterans SEP 2010 52.222-50 Combating Trafficking in Persons FEB 2009 52.222-54 Employment Eligibility Verification JAN 2009 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-12 Notice of Buy American Act Requirement - Construction Materials Under Trade Agreements

FEB 2009

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds OCT 1995 52.228-14 Irrevocable Letter of Credit DEC 1999 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes APR 2003 52.232-17 Interest OCT 2010 52.232-23 Assignment Of Claims JAN 1986 52.232-27 Prompt Payment for Construction Contracts OCT 2008 52.232-33 Payment by Electronic Funds Transfer--Central Contractor

Registration

OCT 2003

52.233-1 Disputes JUL 2002 52.233-1 Alt I Disputes (Jul 2002) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-13 Alt I Accident Prevention (Nov 1991) - Alternate I NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Items DEC 2010 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2010 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-2 Alt I Termination for Convenience of the Government (Fixed- Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights JAN 2009 252.203-7003 Agency Office of the Inspector General APR 2012 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A Central Contractor Registration Alternate A SEP 2007 252.205-7000 Provision Of Information To Cooperative Agreement Holders DEC 1991 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

DEC 2006

252.215-7002 Cost Estimating System Requirements FEB 2012 252.223-7001 Hazard Warning Labels DEC 1991 252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage And Disposal Of Toxic And

Hazardous Materials

APR 2012

252.225-7012 Preference For Certain Domestic Commodities JUN 2010 252.227-7022 Government Rights (Unlimited) MAR 1979 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7004 DOD Progress Payment Rates OCT 2001 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7001 Contract Drawings, and Specifications AUG 2000 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment MAR 1998 252.247-7007 Liability and Insurance DEC 1991 252.247-7023 Transportation of Supplies by Sea MAY 2002

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

(a) The Contractor shall make the following notifications in writing:

(1) When the Contractor becomes aware that a change in its ownership has occurred, or is certain to occur, that could result in changes in the valuation of its capitalized assets in the accounting records, the Contractor shall notify the Administrative Contracting Officer (ACO) within 30 days.

(2) The Contractor shall also notify the ACO within 30 days whenever changes to asset valuations or any other cost changes have occurred or are certain to occur as a result of a change in ownership.

(b) The Contractor shall--

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the ACO or designated representative ready access to the records upon request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of the Contractor's ownership changes;

and

(4) Retain and continue to maintain depreciation and amortization schedules based on the asset records maintained before each Contractor ownership change.

The Contractor shall include the substance of this clause in all subcontracts under this contract that meet the applicability requirement of FAR 15.408(k).

52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR 1989)

The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor no later than 31 December 2012. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.

52.223-11 OZONE-DEPLETING SUBSTANCES (MAY 2001)

(a) Definition. Ozone-depleting substance, as used in this clause, means any substance the Environmental Protection Agency designates in 40 CFR part 82 as--

(1) Class I, including, but not limited to, chlorofluorocarbons, halons, carbon tetrachloride, and methyl chloroform;

or

(2) Class II, including, but not limited to, hydrochlorofluorocarbons.

(b) The Contractor shall label products which contain or are manufactured with ozone-depleting substances in the manner and to the extent required by 42 U.S.C. 7671j (b), (c), and (d) and 40 CFR Part 82, Subpart E, as follows:

“WARNING: Contains (or manufactured with, if applicable), a substance(s) which harm(s) public health and environment by destroying ozone in the upper atmosphere.”----------------------------

The Contractor shall insert the name of the substance(s).

52.225-11 BUY AMERICAN ACT--CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS

(MAY 2012)

(a) Definitions. As used in this clause--

Caribbean Basin country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a Caribbean Basin country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a Caribbean Basin country into a new and different construction material distinct from the materials from which it was transformed.

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Designated country means any of the following countries:

(1) A World Trade Organization Government Procurement Agreement country (Armenia, Aruba, Austria, Belgium, Bulgaria, Canada, Cyprus, Czech Republic, Denmark, Estonia, Finland, France, Germany, Greece, Hong Kong, Hungary, Iceland, Ireland, Israel, Italy, Japan, Korea (Republic of), Latvia, Liechtenstein, Lithuania, Luxembourg, Malta, Netherlands, Norway, Poland, Portugal, Romania, Singapore, Slovak Republic, Slovenia, Spain, Sweden, Switzerland, Taiwan or United Kingdom);

(2) A Free Trade Agreement country (Australia, Bahrain, Canada, Chile, Colombia, Costa Rica, Dominican Republic, El Salvador, Guatemala, Honduras, Korea (Republic of), Mexico, Morocco, Nicaragua, Oman, Peru, or Singapore);

(3) A least developed country (Afghanistan, Angola, Bangladesh, Benin, Bhutan, Burkina Faso, Burundi, Cambodia, Central African Republic, Chad, Comoros, Democratic Republic of Congo, Djibouti, East Timor, Equatorial Guinea, Eritrea, Ethiopia, Gambia, Guinea, Guinea-Bissau, Haiti, Kiribati, Laos, Lesotho, Liberia, Madagascar, Malawi, Maldives, Mali, Mauritania, Mozambique, Nepal, Niger, Rwanda, Samoa, Sao Tome and Principe, Senegal, Sierra Leone, Solomon Islands, Somalia, Tanzania, Togo, Tuvalu, Uganda, Vanuatu, Yemen, or Zambia); or

(4) A Caribbean Basin country (Antigua and Barbuda, Aruba, Bahamas, Barbados, Belize, Bonaire, British Virgin Islands, Curacao, Dominica, Grenada, Guyana, Haiti, Jamaica, Montserrat, Saba, St. Kitts and Nevis, St. Lucia, St.

Vincent and the Grenadines, Sint Eustatius, Sint Maarten, or Trinidad and Tobago).

Designated country construction material means a construction material that is a WTO GPA country construction material, an FTA country construction material, a least developed country construction material, or a Caribbean Basin country construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

Least developed country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a least developed country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a least developed country into a new and different construction material distinct from the materials from which it was transformed.

“Free Trade Agreement country construction material” means a construction material that—

(1) Is wholly the growth, product, or manufacture of a Free Trade Agreement (FTA) country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a FTA country into a new and different construction material distinct from the materials from which it was transformed.

“Least developed country construction material” means a construction material that—

(1) Is wholly the growth, product, or manufacture of a least developed country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a least developed country into a new and different construction material distinct from the materials from which it was transformed.

United States means the 50 States, the District of Columbia, and outlying areas.

WTO GPA country construction material means a construction material that--

(1) Is wholly the growth, product, or manufacture of a WTO GPA country; or

(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in a WTO GPA country into a new and different construction material distinct from the materials from which it was transformed.

(b) Construction materials.

(1) This clause implements the Buy American Act (41 U.S.C. chapter 83) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). In addition, the Contracting Officer has determined that the WTO GPA and Free Trade Agreements (FTAs) apply to this acquisition. Therefore, the Buy American Act restrictions are waived for designated county construction materials.

(2) The Contractor shall use only domestic or designated country construction material in performing this contract, except as provided in paragraphs (b)(3) and (b)(4) of this clause.

(3) The requirement in paragraph (b)(2) of this clause does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

None

(4) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(3) of this clause if the Government determines that--

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the restrictions of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(4) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(4)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American Act applies, use of foreign construction material is noncompliant with the Buy American Act.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction material description Unit of measure Quantity Price (dollars) \1\ Item 1:

Foreign construction material Domestic construction material Item 2:

Foreign construction material

Domestic construction material \1\ Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

(a) The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be promptly submitted to the Contracting Officer, who shall promptly make a determination in writing. Any adjustment by the Contractor without such a determination shall be at its own risk and expense. The Contracting Officer shall furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided.

(b) Wherever in the specifications or upon the drawings the words "directed", "required", "ordered", "designated", "prescribed", or words of like import are used, it shall be understood that the "direction", "requirement", "order", "designation", or "prescription", of the Contracting Officer is intended and similarly the words "approved", "acceptable", "satisfactory", or words of like import shall mean "approved by," or "acceptable to", or "satisfactory to" the Contracting Officer, unless otherwise expressly stated.

(c) Where "as shown," as indicated", "as detailed", or words of similar import are used, it shall be understood that the reference is made to the drawings accompanying this contract unless stated otherwise. The word "provided" as used herein shall be understood to mean "provide complete in place," that is "furnished and installed".

(d) Shop drawings means drawings, submitted to the Government by the Contractor, subcontractor, or any lower tier subcontractor pursuant to a construction contract, showing in detail (1) the proposed fabrication and assembly of structural elements, and (2) the installation (i.e., fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials furnished by the contractor to explain in detail specific portions of the work required by the contract. The Government may duplicate, use, and disclose in any manner and for any purpose shop drawings delivered under this contract.

(e) If this contract requires shop drawings, the Contractor shall coordinate all such drawings, and review them for accuracy, completeness, and compliance with contract requirements and shall indicate its approval thereon as evidence of such coordination and review. Shop drawings submitted to the Contracting Officer without evidence of the Contractor's approval may be returned for resubmission. The Contracting Officer will indicate an approval or disapproval of the shop drawings and if not approved as submitted shall indicate the Government's reasons therefor.

Any work done before such approval shall be at the Contractor's risk. Approval by the Contracting Officer shall not relieve the Contractor from responsibility for any errors or omissions in such drawings, nor from responsibility for complying with the requirements of this contract, except with respect to variations described and approved in accordance with (f) below.

(f) If shop drawings show variations from the contract requirements, the Contractor shall describe such variations in writing, separate from the drawings, at the time of submission. If the Contracting Officer approves any such variation, the Contracting Officer shall issue an appropriate contract modification, except that, if the variation is minor or does not involve a change in price or in time of performance, a modification need not be issued.

(g) The Contractor shall submit to the Contracting Officer for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. Three sets (unless otherwise indicated) of all shop drawings, will be retained by the Contracting Officer and one set will be returned to the Contractor.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

See Section C of this Solicitation for Project XQPZ11-0103J Specifications and Drawings

252.247-7022 REPRESENTATION OF EXTENT OF TRANSPORTATION BY SEA (AUG 1992)

(a) The Offeror shall indicate by checking the appropriate blank in paragraph (b) of this provision whether transportation of supplies by sea is anticipated under the resultant contract. The term supplies is defined in the Transportation of Supplies by Sea clause of this solicitation.

(b) Representation. The Offeror represents that it:

____ (1) Does anticipate that supplies will be transported by sea in the performance of any contract or subcontract resulting from this solicitation.

____ (2) Does not anticipate that supplies will be transported by sea in the performance of any contract or subcontract resulting from this solicitation.

(c) Any contract resulting from this solicitation will include the Transportation of Supplies by Sea clause. If the Offeror represents that it will not use ocean transportation, the resulting contract will also include the Defense FAR Supplement clause at 252.247-7024, Notification of Transportation of Supplies by Sea.

(End of provision)

5352.201-9101 OMBUDSMAN (APR 10)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, concerned parties may contact the USAF Academy Ombudsmen, Kelly S. Snyder 8110 Industrial Drive, Ste 103

USAFA, CO 80840

Telephone number 719-333-2074

FAX 719-333-9018

email: kelly.snyder@usafa.af.mil

Concerns, issues, disagreements, and recommendations that cannot be resolved at the MAJCOM/DRU level, may be brought by the concerned party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (703) 588-7004, facsimile number (703) 588-1067.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

5352.223-9000 ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODS) (APR 03)

(a) Unless the requiring activity has obtained prior Senior Acquisition Official (SAO) approval, contractors may not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that use one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

(c) The requiring activity has obtained SAO approval to permit the contractor to use the following Class I ODS(s):

Class I ODS/ Application or Use/Quantity (lbs.) per contract period of performance

[List each Class I ODS, its applications or use and the approved quantities for use throughout the length of the contract. If "None," so state.]

(d) The offeror/contractor is required to notify the contracting officer if any Class I ODS that is not specifically listed above is required in the test, operation, or maintenance of any system, subsystem, item, component, or process.

5352.223-9001 HEALTH AND SAFETY ON GOVERNMENT INSTALLATIONS (JUN 1997)

(a) In performing work under this contract on a Government installation, the contractor shall:

(1) Comply with the specific health and safety requirements established by this contract;

(2) Comply with the health and safety rules of the Government installation that concern related activities not directly addressed in this contract;

(3) Take all reasonable steps and precautions to prevent accidents and preserve the health and safety of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(4) Take such additional immediate precautions as the contracting officer may reasonably require for health and safety purposes.

(b) The contracting officer may, by written order, direct Air Force Occupational Safety and Health (AFOSH) Standards and/or health/safety standards as may be required in the performance of this contract and any adjustments resulting from such direction will be in accordance with the Changes clause of this contract.

(c) Any violation of these health and safety rules and requirements, unless promptly corrected as directed by the contracting officer, shall be grounds for termination of this contract in accordance with the Default clause of this contract.

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (AUG 07)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or security police for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, valid vehicle insurance certificate, and (refer to USAFA A-01 Contractor Access to USAFA Instruction) to obtain a vehicle pass.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and…