FA5575-16-B-0001_RPL_AC_bldg_107.pdf

Project QUUG 13-1016, Replace A/C Unit, Building 107, Morón Air Base, Spain.

The magnitude of this project is betw een $250,000 and $500,000 U.S. Dollars. This is furnished for the convenience of all prospective bidders.

The actual extent of w orks required is governed by the specif ications and draw ings.

Offers w ill be evaluated according to criteria provided in Section M of this solicitation.

A pre-bid conference/site-visit w ill be held on 24 November, 2015 at 10:00 am, local time, in the Contracting Conference Room, Bldg. 106. A public bid opening w ill be held 10 December, 2015 at 10:00 am local time. Bids received after 10 December, 2015 at 10:00 am local time w ill NOT be accepted. Bids submitted by fascimile w ill NOT be accepted.

IN ACCORDANCE WITH THE AGREEMENT OF DEFENSE COOPERATION BETWEEN THE U.S.A. AND THE KINGDOM OF SPAIN, ANNEX 6, ARTICLE 1, "(5) SPANISH MATERIAL, LABOR AND EQUIPMENT SHALL BE USED WHENEVER FEASIBLE AND CONSISTENT WITH THE

REQUIREMENTS."

X

JACOB CALDWELL 722-8075

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

10-Nov-2015

(RFP)

(IFB)

CALL:

Replace A/C Unit, Bldg. 107

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________270 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________10 Dec 2015 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

496 ABS/LGC (FA5575)

APARTADO 221

41530 MORON

SEVILLA

FA5575

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

QUUG 13-1016

8. ADDRESS OFFER TO (If Other Than Item 7)

(34) 95 848 054FAX:TEL: (34) 955 848 076 TEL: FAX:

FA5575-16-B-0001 46

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA5575-16-B-0001

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot

Sustainment - Mechanical and Fire Alarm

FFP

Quug 13-1016 Replace A/C Unit Bldg 107

Line Item 0001 represents the work that will be completed for the Mechanical and Fire Alarm portions of the contract

(NEX Mart)

FFP

Replace A/C Units, Bldg 107 (NEX Mart) IAW project specifications, dated 19 June 2015 and project drawings, dated 19 June 2015.

FOB: Destination

PURCHASE REQUEST NUMBER: F3N7A05174A001

SIGNAL CODE: A

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Lot

Restoration - Electrical and Paint Work

FFP

Quug 13-1016 Replace A/C Unit Bldg 107

(NEX Mart)

Line Item 0002 represents the Electrical and Painting portions of the contract.

FFP

Replace A/C Units, Bldg 107 (NEX Mart) IAW project specifications, dated 19 June 2015 and project drawings, dated 19 June 2015.

FOB: Destination

PURCHASE REQUEST NUMBER: F3N7A05174A001

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996 252.229-7004 Status of Contractors as a Direct Contractor (Spain) JUN 1997

CLAUSES INCORPORATED BY FULL TEXT

252.246-7000 MATERIAL INSPECTION AND RECEIVING REPORT (MAR 2008)

(a) At the time of each delivery of supplies or services under this contract, the Contractor shall prepare and furnish to the Government a material inspection and receiving report in the manner and to the extent required by Appendix F, Material Inspection and Receiving Report, of the Defense FAR Supplement.

(b) Contractor submission of the material inspection and receiving information required by Appendix F of the Defense FAR Supplement by using the Wide Area WorkFlow (WAWF) electronic form (see paragraph (b) of the clause at 252.232-7003) fulfills the requirement for a material inspection and receiving report (DD Form 250). Two copies of the receiving report (paper copies of either the DD Form 250 or the WAWF report) shall be distributed with the shipment, in accordance with Appendix F, Part 4, F-401, Table 1, of the Defense FAR Supplement.

(End of clause)

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 280 dys. ADC 1 496 ABS/CE (F3N7A0)

CIVIL ENGINEER FUNCTIONAL

COMMANDER

UNIT 6585

APO AE 09643

722-8060

F3N7A0

0002 280 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

F3N7A0

52.211-13 Time Extensions SEP 2000 52.247-34 F.O.B. Destination NOV 1991

Section G - Contract Administration Data

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow

(WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

Construction Invoice

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor's business systems, an “Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

N/A

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable”.)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F78900 Issue By DoDAAC FA5575 Admin DoDAAC FA5575 Inspect By DoDAAC F3N7A0 Ship To Code F3N7A0 Ship From Code ____ Mark For Code ____ Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____ Accept at Other DoDAAC ____ LPO DoDAAC ____ DCAA Auditor DoDAAC ____ Other DoDAAC(s) ____

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

496abs.lgc.contractorsupport@us.af.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

N/A

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

Section H - Special Contract Requirements

BANK LETTER OF GURANTEE

BANK LETTER OF GUARANTEE:

Within (10) calendar days after the date of contract award, the contractor shall furnish the Contracting Officer a Bank Letter of Guarantee for the performance of the work in the amount specified below. Failure to furnish the letter of guarantee may be deemed a breach of contract.

Amount of Contract Bank Letter

Under $100,000.00 None

(82,590 Euros)

$100,000.00 - $500,000.00 12% of award amount

(82,590 Euros – 412,950 Euros)

$500,000.00 and over 10% of award amount

(412,950 Euros)

The Bank Letter of Guarantee will be dated as of the contract date or as soon thereafter as possible. The Bank Letter of Guarantee shall state that a guarantee has been issued against the awarded contract and that the following conditions are in force.

1. When presented by a representative of the U.S. Government against debts due, redemption cannot be contested.

2. The value of the guarantee is to be cited in Euros.

3. The Bank Letter of Guarantee shall also state that the bank agrees and consents that the contract may be modified by change order or supplemental agreement without affecting the validity of the Bank Letter of Guarantee.

The Contracting Officer will not issue the Notice to Proceed until approval and acceptance of the Bank Letter of Guarantee.

The Bank Letter of Guarantee will continue in effect throughout the performance period. During the warranty period an amount equal to 12% of the original contract price shall be applicable.

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.223-19 Compliance with Environmental Management Systems MAY 2011 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

Section I - Contract Clauses

52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

MAY 2011

52.204-6 Data Universal Numbering System Number JUL 2013 52.204-7 System for Award Management JUL 2013 52.204-8 Annual Representations and Certifications DEC 2014 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier Subcontract

Awards

OCT 2015

52.204-13 System for Award Management Maintenance JUL 2013 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-28 Subcontracting Certified Cost Or Pricing Data--

Modifications--Sealed Bidding

OCT 2010

52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.214-34 Submission Of Offers In The English Language APR 1991 52.222-50 Combating Trafficking in Persons MAR 2015 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.225-14 Inconsistency Between English Version And Translation Of

Contract

FEB 2000

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.229-6 Taxes--Foreign Fixed-Price Contracts FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-18 Availability Of Funds APR 1984 52.232-19 Availability Of Funds For The Next Fiscal Year APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-25 Prompt Payment JUL 2013 52.232-27 Prompt Payment for Construction Contracts MAY 2014 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-19 Organization and Direction of the Work APR 1984 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-3 Changes--Time-And-Material Or Labor-Hours SEP 2000 52.243-5 Changes and Changed Conditions APR 1984 52.245-9 Use And Charges APR 2012 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2015 52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

OCT 2015

252.215-7008 Only One Offer OCT 2013 252.222-7002 Compliance With Local Labor Laws (Overseas) JUN 1997 252.222-7004 Compliance With Spanish Social Security Laws and

Regulations

JUN 1997

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7041 Correspondence in English JUN 1997 252.225-7042 Authorization to Perform APR 2003 252.228-7006 Compliance With Spanish Laws and Insurance DEC 1998 252.229-7005 Tax Exemptions (Spain) MAR 2012 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7008 Assignment of Claims (Overseas) JUN 1997 252.232-7010 Levies on Contract Payments DEC 2006 252.233-7001 Choice of Law (Overseas) JUN 1997 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2012 252.247-7023 Transportation of Supplies by Sea APR 2014 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 270 The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of 1305.75 Euro for the first day of delay and 1198.03 Euro for each calendar day after the first day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 12 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/vffara.htm http://farsite.hill.af.mil/vfdfara.htm http://farsite.hill.af.mil/vfaffara.htm

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation Supplement (48 CFR Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.204-7006 BILLING INSTRUCTIONS (OCT 2005)

When submitting a request for payment, the Contractor shall--

(a) Identify the contract line item(s) on the payment request that reasonably reflect contract work performance; and

(b) Separately identify a payment amount for each contract line item included in the payment request.

252.229-7001 TAX RELIEF (SEPT 2014)

(a) Prices set forth in this contract are exclusive of all taxes and duties from which the United States Government is exempt by virtue of tax agreements between the United States Government and the Contractor's government. The following taxes or duties have been excluded from the contract price:

NAME OF TAX: IVA

RATE (PERCENTAGE): ___

(b) The Contractor's invoice shall list separately the gross price, amount of tax deducted, and net price charged.

(c) When items manufactured to United States Government specifications are being acquired, the Contractor shall identify the materials or components intended to be imported in order to ensure that relief from import duties is obtained. If the Contractor intends to use imported products from inventories on hand, the price of which includes a factor for import duties, the Contractor shall ensure the United States Government's exemption from these taxes. The Contractor may obtain a refund of the import duties from its government or request the duty-free import of an amount of supplies or components corresponding to that used from inventory for this contract.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

SEE SECTION J

(End of clause

OMBUDSMAN (APR 2014)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, Primary:

Mr. Douglas Guldan

AFICA/KU, UNIT 3103, APO, AE 09094-3103

AFICA/KU, Geb 404, Flugplatz Ramstein, 66877 Ramstein-Miesenbach, Germany E-mail: douglas.guldan@us.af.mil Tel: DSN: (314)480-2209 Fax: (49)-6731-47-2025

Alternate:

Ms. Heidi Hoehn

AFICA/KU, UNIT 3103, APO, AE 09094-3103

AFICA/KU, Geb 404, Flugplatz Ramstein, 66877 Ramstein-Miesenbach, Germany E-mail: heidi.hoehn.de@us.af.mil Tel: DSN: (314)480-9330 Fax: (49)-6731-47-2025

Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/HQ AFICA/AFISRA/SMC ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571) 256-2395, facsimile number (571) 256-2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

As prescribed in 5323.804, insert the following clause in solicitations and contracts:

http://pklunx.hill.af.mil/farsite/reghtml/regs/far2afmcfars/af_afmc/affars/5323.htm#P32_477

ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODSs)

(APR 2003)

(a) Unless the requiring activity has obtained prior Senior Acquisition Official (SAO) approval, contractors may not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC- 217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

(c) The requiring activity has obtained SAO approval to permit the contractor to use the following Class I ODS(s):

Class I ODS/ Application or Use/Quantity (lbs.) per contract period of performance

NONE

(d) The offeror/contractor is required to notify the contracting officer if any Class I ODS that is not specifically listed above is required in the test, operation, or maintenance of any system, subsystem, item, component, or process.

http://www.e-publishing.af.mil/pubfiles/af/32/afi32-7086/afi32-7086.pdf

(d) The offeror/contractor is required to notify the contracting officer if any Class I ODS that is not specifically listed above is required in the test, operation, or maintenance of any system, subsystem, item, component, or process.

As prescribed in 5323.9001, insert the following clause in solicitations and contracts:

HEALTH AND SAFETY ON GOVERNMENT INSTALLATIONS (JUN 1997)

(a) In performing work under this contract on a Government installation, the contractor shall:

(1) Comply with the specific health and safety requirements established by this contract;

(2) Comply with the health and safety rules of the Government installation that concern related activities not directly addressed in this contract;

(3) Take all reasonable steps and precautions to prevent accidents and preserve the health and safety of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(4) Take such additional immediate precautions as the contracting officer may reasonably require for health and safety purposes.

(b) The contracting officer may, by written order, direct Air Force Occupational Safety and Health (AFOSH) Standards and/or health/safety standards as may be required in the performance of this contract and any adjustments resulting from such direction will be in accordance with the Changes clause of this contract.

http://pklunx.hill.af.mil/farsite/reghtml/regs/far2afmcfars/af_afmc/affars/5323.htm#P51_1525

(c) Any violation of these health and safety rules and requirements, unless promptly corrected as directed by the contracting officer, shall be grounds for termination of this contract in accordance with the Default clause of this contract.

As prescribed at 5328.310(b), insert the following clause in solicitations and contracts:

SPANISH INSURANCE CERTIFICATE (USAFE) (JUNE 2006)

(a) Below follows the Insurance Certificate required for any Third Country National Contractor (TCN), other than U.S. or Spanish, required for use under this contract. The certificate is provided to standardize base access procedures. It must be completed and signed by the policyholder and the insurer.

(b) The amount of coverage minimum is 90,151.82 Euros per insured party (personal injury), 60,101.21 Euros per accident (property damage), and 6, 010.12 Euros security deposit for legal fees. In all cases the amount of coverage, if different from the above amounts, will be determined by the insurer, except in situations where the minimum coverage applies.

(c) The request for base access and the insurance certificate should be processed to the Spanish authorities 15 days prior to the actual time of arrival for contract performance.

(d) Complete the following certification:

SPANISH INSURANCE CERTIFICATION

CERTIFICATE OF INSURANCE COVERAGE OF THE CIVIL LIABILITY REFERRED TO

UNDER ARTICLE 5 OF ANNEX 6 TO THE AGREEMENT BETWEEN THE KINGDOM OF

http://pklunx.hill.af.mil/farsite/reghtml/regs/far2afmcfars/af_afmc/affars/5328.htm#P47_789

SPAIN AND THE UNITED STATES OF AMERICA ON COOPERATION FOR THE

DEFENSE, SIGNED THE 1st OF DECEMBER 1988.

The insurance Company _______________________________________________ with legal domicile in _______________________________________________________________ Tel: __________________________ of Spanish/US nationality, registered in the Mercantile Registry of_______________________________________ Date:____________________, Number________, Book:_______, Section _____, Volume________, Page_______.

CERTIFIES

That Mr./Mrs. ____________________of_____________________ nationality, with passport number_______________, has contracted with this company Policy Number _____________ of civil liability against damages to persons or property which could arise from his/her actions or omissions in the performance of his/her official functions/professional activities in Spain because of the contract of ______________________________________________________ for the U.S.

forces, and during the visit which, in respect of such contract, he/she may make to the _______________ Military Base, according to the general conditions in force for this type of insurance and also to the special conditions created for this purpose in the Spanish-U.S.

Permanent Committee; that he/she has paid the premium according to the agreed conditions; and that such Policy is in force.

The Policy establishes as coverage of the mentioned risks the following amounts:

INDEMNITY LIMITS:

- For casualty: -------------------------- 601,012.10 Euros

With the following sub-limits for each injured person:

- For personal liability:----------------- 90,151.82 Euros

- For property damage:----------------- 60,101.21 Euros

- For Judiciary Bond:-------------------- 6, 010.12 Euros

The granted coverage is effective from ________________ through________________, and does not include any type of franchise, or similar limitation, to be deducted from the mentioned guarantees or any clause which requires the submission to any type of arbitration. The underwriting insurance company considers that the established amounts adequately cover the insured risks.

The policy sets forth the following clauses:

1. “The insurance company waives any right of subrogation against the United States of America which may arise by reason of any payment under this Policy.”

2. “The parties hereto explicitly agree to submit to the jurisdiction of the Spanish Courts of Law and to the Spanish Laws to settle any matter related to the construction or enforcement of the clauses and conditions of this Policy.”

IN WITNESS HEREOF, the present document is signed in______________________________, on the____________of_____________20____ For the Insured Company (signature) For the Insurance (signature)

CERTIFICADO DE COBERTURA DE SEGURO DE LA RESPONSABILIDAD CIVIL A QUE

SE REFIERE EL ARTICULO 5 DEL ANEXO 6 AL CONVENIO ENTRE EL REINO DE

ESPAÑA Y LOS ESTADOS UNIDOS DE AMERICA SOBRE COOPERACION PARA LA

DEFENSA, FIRMADO EL DIA 1 DE DICIEMBRE DE 1988.

La Compañia de Seguros ______________________________________ con domicilio social en la Calle/Avda./Pla.

____________________________________________________________________, Tlfo.:

_________________ , de nacionalidad española/norteamericana, inscrita en el Registro Mercantil de______________________________, fecha _________________, Número ________, Libro _________, Sección ______, Tomo _______, Folio_______.

CERTIFICA:

Que D. __________________________, de nacionalidad _________________________, provisto del pasaporte número _______________________, tiene suscrita con esta Compañia la Póliza número ____________________________, de responsabilidad civil contra daños a personas y cosas que pudieran derivarse de acciones u omisiones realizadas en el desempeño de sus funciones oficiales/actividades profesionales en España con ocasión del contrato de __________________________________________, para las Fuerzas de los EE.UU. y con la visita que en relación con dicho contrato realice a la Base Militar de

___________________________, según las condiciones generales vigentes para este tipo de seguros y además las condiciones especiales elaboradas a este fin en el Comité Permanente Hispano-Norteamericano; habiéndose satisfecho la prima según las condiciones pactadas, y encontrándose dicha Póliza en vigor.

La Póliza establece como cobertura de los riesgos mencionados las siguientes cuantías:

LIMITES DE INDEMNIZACION:

- Por siniestro: -------------------------- 601.012,10 Euros

Con los siguientes sublímites por perjudicado:

- Por daños personales:----------------- 90.151,82 Euros

- Por daños materiales: ----------------- 60.101,21 Euros

- Por fianzas judiciales:-_--------------- 6.010,12 Euros

Las coberturas otorgadas son efectivas desde el ___________________________, hasta el _________________________, no incluyéndose en las mismas ningún tipo de franquicia o limitación similar a deducir de las garantías indicadas ni ninguna disposición que requiera la sumisión a cualquier tipo de arbitraje. La Compañia aseguradora que suscribe considera que las cuantías establecidas cubren adecuadamente los riesgos asegurados.

La Póliza establece las siguientes cláusulas:

1. “La Compañia Aseguradora renuncia a cualquier derecho de subrogación contra los Estados Unidos de América que pueda provenir por razones diferentes a pago, bajo la Póliza epígrafiada.”

2. “Las partes se someten expresamente a la jurisdicción de los tribunales españoles y al derecho español para resolver cualquier cuestión relativa a la interpretación o aplicación de las cláusulas y condiciones de la Póliza.”

Y para que conste a los efectos oportunos, se firma el presente en __________________ a _______________ de _____________ 2.0___._______________________________________ Tomador: Asegurador:

(END OF CERTIFICATE)

(End of Clause)

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (AUGUST

2007)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or security police for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, valid vehicle insurance certificate, and IVA to obtain a vehicle pass.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-101, Volume 1, The Air Force Installation Security Program, and AFI 31-501, Personnel Security Program Management.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) Failure to comply with these requirements may result in withholding of final payment.

http://www.e-publishing.af.mil/shared/media/epubs/AFI31-101.pdf http://www.e-publishing.af.mil/shared/media/epubs/AFI31-501.pdf

Section J - List of Documents, Exhibits and Other Attachments

LIST OF ATTACHMENTS

LIST OF ATTACHMENTS

Attachment

Number Title Date Number of Pages

1 Contract Specifications for QUUG 13-1016, RPL A/C Unit, 107 (Exchange) Moron Air Base, Spain (English)

19 June 2015 134

2 Contract Specifications for

QUUG 13-1016, Reemplazar Sistema Be Aire Acondicionado Moron Air Base, Spain (Spanish)

3 Drawings QUUG 13-1016

19 June 2015

4 Submittal Schedule (2 Tabs) Undated 5

5 AF Form 3052 Cost Breakdown Undated 14 (not part of any resultant award)

6 Past Performance Reference List Undated 1

19 June 2015

Section K - Representations, Certifications and Other Statements of Offerors

52.203-11 Certification And Disclosure Regarding Payments To Influence Certain Federal Transactions

SEP 2007

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via…