Solicitation_-_FA480319RA011.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA480319RA011

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

0001 INSTALL NATURAL GAS LINES B1955

VLSB 19-0018

Manufacturer's Part Number: Null Product Service Code: Y1NZ Standard Industry Classification (SIC) Code: 237120 Firm Fixed Price

CIN: 00000000000004842438

1.0 Lot

Section C - Description/Specifications/Statement of Work

Requirements The contractor shall Install and furnish plastic gas pipe to connect from the existing gas main to B1955.

The installation of the gas pipe shall be approximately 860 of 4 gas pipe along the roadway and approximately 215 of 2 gas pipe to the building and cap 4 pipe for future use. Provide and installation a smart meter and regulator. Tie-in government furnished tankless water heaters. The area around the facility contains geothermal wells. The installation shall be bored to avoid disturbing of the wells.

Section D - Packaging and Marking

Section E - Inspection and Acceptance

0001 Inspection and Acceptance Location

Both Destination Instructions: N/A

DoDAAC: FA4803 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

FA4803 20 CONS LGCA

321 CULLEN ST BLDG 216

CP 803 895 5403

SHAW AFB, SC 29152 5125

United States

OfficeCode:

Gary Graham Telephone: (803) 895-9604 Email:

Section F - Deliveries or Performance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.247-34 F.o.b. Destination 1991-11

FAR Clauses Incorporated by Full Text 52.211-10 Commencement, Prosecution, and Completion of Work. 1984-04 As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction. Commencement, Prosecution, and Completion of Work (Apr 1984) The Contractor shall be required to (a)commence work under this contract within __10__ [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b)prosecute the work diligently, and (c)complete the entire work ready for use not later than __21_.* The time stated for completion shall include final cleanup of the premises. * The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-10 Alternate I Commencement, Prosecution, and Completion of Work. - (Alternate I) 1984-04 As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction. Commencement, Prosecution, and Completion of Work (Apr 1984) The Contractor shall be required to (a)commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b)prosecute the work diligently, and (c)complete the entire work ready for use not later than 21 days. The time stated for completion shall include final cleanup of the premises. * The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date. Alternate I (Apr1984). If the completion date is expressed as a specific calendar date, computed on the basis of the contractor receiving the notice to proceed by a certain day, add the following paragraph to the basic clause: The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 13 September 2019. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

DFARS Clauses Incorporated by Full Text

252.247-7023 Transportation of Supplies by Sea. 2019-02 Basic. As prescribed in 247.574(b) and (b)(1), use the following clause: TRANSPORTATION OF SUPPLIES BY SEABASIC (FEB 2019) (a) Definitions. As used in this clause Components means articles, materials, and supplies incorporated directly into end products at any level of manufacture, fabrication, or assembly by the Contractor or any subcontractor. Department of Defense (DoD) means the Army, Navy, Air Force, Marine Corps, and defense agencies. Foreign-flag vessel means any vessel that is not a U.S.-flag vessel. Ocean transportation means any transportation aboard a ship, vessel, boat, barge, or ferry through international waters. Subcontractor means a supplier, materialman, distributor, or vendor at any level below the prime contractor whose contractual obligation to perform results from, or is conditioned upon, award of the prime contract and who is performing any part of the work or other requirement of the prime contract. Supplies means all property, except land and interests in land, that is clearly identifiable for eventual use by or owned by the DoD at the time of transportation by sea.

(i) An item is clearly identifiable for eventual use by the DoD if, for example, the contract documentation contains a reference to a DoD contract number or a military destination. (ii) Supplies includes (but is not limited to) public works; buildings and facilities; ships; floating equipment and vessels of every character, type, and description, with parts, subassemblies, accessories, and equipment; machine tools; material; equipment; stores of all kinds; end items; construction materials;

and components of the foregoing. U.S.-flag vessel means a vessel of the United States or belonging to the United States, including any vessel registered or having national status under the laws of the United States. (b)(1) The Contractor shall use U.S.-flag vessels when transporting any supplies by sea under this contract. (2) A subcontractor transporting supplies by sea under this contract shall use U.S.-flag vessels if (i) This contract is a construction contract; or (ii) The supplies being transported are (A) Noncommercial items; or (B) Commercial items that (1) The Contractor is reselling or distributing to the Government without adding value (generally, the Contractor does not add value to items that it subcontracts for f.o.b.

destination shipment); (2) Are shipped in direct support of U.S. military contingency operations, exercises, or forces deployed in humanitarian or peacekeeping operations; or (3) Are commissary or exchange cargoes transported outside of the Defense Transportation System in accordance with 10 U.S.C. 2643. (c) The Contractor and its subcontractors may request that the Contracting Officer authorize shipment in foreign-flag vessels, or designate available U.S.-flag vessels, if the Contractor or a subcontractor believes that (1) U.S.-flag vessels are not available for timely shipment; (2) The freight charges are inordinately excessive or unreasonable; or (3) Freight charges are higher than charges to private persons for transportation of like goods.

(d) The Contractor must submit any request for use of foreign-flag vessels in writing to the Contracting Officer at least 45 days prior to the sailing date necessary to meet its delivery schedules. The Contracting Officer will process requests submitted after such date(s) as expeditiously as possible, but the Contracting Officer's failure to grant approvals to meet the shipper's sailing date will not of itself constitute a compensable delay under this or any other clause of this contract. Requests shall contain at a minimum (1) Type, weight, and cube of cargo; (2) Required shipping date; (3) Special handling and discharge requirements;

(4) Loading and discharge points; (5) Name of shipper and consignee; (6) Prime contract number; and (7) A documented description of efforts made to secure U.S.-flag vessels, including points of contact (with names and telephone numbers) with at least two U.S.-flag carriers contacted. Copies of telephone notes, telegraphic and facsimile message or letters will be sufficient for this purpose. (e) The Contractor shall, within 30 days after each shipment covered by this clause, provide the Contracting Officer and the Maritime Administration, Office of Cargo Preference, U.S. Department of Transportation, 400 Seventh Street SW, Washington, DC 20590, one copy of the rated on board vessel operating carrier's ocean bill of lading, which shall contain the following information: (1) Prime contract number; (2) Name of vessel; (3) Vessel flag of registry; (4) Date of loading; (5) Port of loading; (6) Port of final discharge; (7) Description of commodity; (8) Gross weight in pounds and cubic feet if available; (9) Total ocean freight in U.S. dollars; and (10) Name of steamship company. (f) If this contract exceeds the simplified acquisition threshold, the Contractor shall provide with its final invoice under this contract a representation that to the best of its knowledge and belief (1) No ocean transportation was used in the performance of this contract; (2) Ocean transportation was used and only U.S.-flag vessels were used for all ocean shipments under the contract; (3) Ocean transportation was used, and the Contractor had the written consent of the Contracting Officer for all foreign-flag ocean transportation; or (4) Ocean transportation was used and some or all of the shipments were made on foreign-flag vessels without the written consent of the Contracting Officer. The Contractor shall describe these shipments in the following format: | || ITEM DESCRIPTION || CONTRACT LINE ITEMS ||QUANTITY || || ____ || ____ || ____ || TOTAL || ____ || ____ || ____ | (g) If this contract exceeds the simplified acquisition threshold and the final invoice does not include the required representation, the Government will reject and return it to the Contractor as an improper invoice for the purposes of the Prompt Payment clause of this contract. In the event there has been unauthorized use of foreign-flag vessels in the performance of this contract, the Contracting Officer is entitled to equitably adjust the contract, based on the unauthorized use. (h) If the Contractor indicated in response to the solicitation provision, Representation of Extent of Transportation by Sea, that it did not anticipate transporting by sea any supplies;

however, after the award of this contract, the Contractor learns that supplies will be transported by sea, the Contractor shall

(1) Notify the Contracting Officer of that fact; and (2) Comply with all the terms and conditions of this clause. (i) In the award of subcontracts, for the types of supplies described in paragraph (b)(2) of this clause, including subcontracts for commercial items, the Contractor shall flow down the requirements of this clause as follows: (1) The Contractor shall insert the substance of this clause, including this paragraph (i), in subcontracts that exceed the simplified acquisition threshold in part 2 of the Federal Acquisition Regulation. (2) The Contractor shall insert the substance of paragraphs (a) through (e) of this clause, and this paragraph (i), in subcontracts that are at or below the simplified acquisition threshold in part 2 of the Federal Acquisition Regulation.

0001 Delivery Schedule Ship To Address

Delivery Schedule From date of lead time event to completion of performance 21 Calendar Days Date of Notice to Proceed Receipt

Ship To

DoDAAC: F3U3CE Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

20 CES CERF

428 CHAPIN ST

AF BPN NO MILSBILLS PROCESSES

SHAW AFB, SC 29152

United States

OfficeCode:

Gary Graham Telephone: (803) 895-9604 Email:

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.236-7000 Modification Proposals--Price Breakdown. 1991-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12 As prescribed in 232.7004(b), use the following clause: WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause- Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization. Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF). Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system. Payment request and receiving report are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. (c) WAWF access. To access WAWF, the Contractor shall- (1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site. (d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the Web Based Training link on the WAWF home page at https://wawf.eb.mil/ (e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol. (f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order: (1) Document type. The Contractor shall submit payment requests using the following document type(s): (i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher. (ii) For fixed price line items (A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer. N/A (Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.) (B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer. Construction type invoice (Contracting Officer: Insert either Invoice 2in1 or the applicable invoice and receiving report document type(s) for fixed price line items for services.) (iii) For customary progress payments based on costs incurred, submit a progress payment request. (iv) For performance based payments, submit a performance based payment request. (v) For commercial item financing, submit a commercial item financing request. (2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract. (f) [Note: The Contractor may use a WAWF combo document type to create some combinations of invoice and receiving report in one step.] (3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* | Field Name in WAWF || Data to be entered in WAWF || Pay Official DoDAAC || F3U3CE || Issue By DoDAAC || FA4803 || Admin DoDAAC || FA4803 || Inspect By DoDAAC || F3U3CE || Ship To Code || F3U3CE || Ship From Code || N/A || Mark For Code || N/A || Service Approver (DoDAAC) || FA4803 || Service Acceptor (DoDAAC) || F3U3CE || Accept at Other DoDAAC || N/A || LPO DoDAAC || N/A || DCAA Auditor DoDAAC || N/A || Other DoDAAC(s) || N/A | (*Contracting Officer: Insert applicable DoDAAC information.

If multiple ship to/acceptance locations apply, insert See Schedule or Not applicable.) (**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).) (4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable. (5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. (g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activitys WAWF point of contact. Jackson.woods@us.af.mil (Contracting Officer: Insert applicable information or Not applicable.) (2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed. (End of clause)

Section H - Special Contract Requirements

Section I - Contract Clauses

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) - ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for 10:00 pm EST on 09 September 2019

(c) Participants will meet at Bldg 1955, Shaw AFB, SC for the purpose of reviewing the work site and submitting questions regarding this solicitation. For those interested parties that do not have base passes, you must arrive at the Visitors Center (located at the main gate) no later than 30 minutes prior to the start of the site visit. This will allow time to obtain a temporary pass from the Visitors Center and to have vehicles searched before entering the installation. Each individual must hand-carry and submit to the Visitors Center his or her driver's license, vehicle registration, and current proof of insurance to receive a temporary base pass.

*NOTE: Please contact SSgt Jackson Woods at 803-895-9434 / e-mail: jackson.woods@us.af.mil or Mrs. Shaunannette Watson at 803-895-5396 / e-mail: shaunannette.watson@us.af.mil for assistance obtaining a base pass.

FAR Clauses Incorporated by Reference

Number Title Effective Date

52.204-1 Approval of Contract. 1989-12 52.204-7 System for Award Management.

52.213-4 Terms and Conditions-Simplified Acquisitions (Other Than Commercial

2018-10 2019-01

2011-11 Items).

52.219-6 Deviation 2019- Notice of Total Small Business Set-Aside (DEVIATION 2019-O0003) O0003 52.219-13 Notice of Set-Aside of Orders. 2011-11 52.222-6 Construction Wage Rate Requirements. 2018-08 52.222-7 52.222-8

Withholding of Funds.

Payrolls and Basic Records.

2014-05 2018-08

52.222-9 Apprentices and Trainees.

52.222-10 Compliance with Copland Act Requirements .

52.222-11 Subcontracts (Labor Standards)

2005-07 1988-02 2014-05

52.222-12 Contract Termination-Debarment. 2014-05 52.222-13 Compliance with Construction Wage Rate Requirements and Rate Regulations 2014-05 52.222-14 1988-02 52.222-15 2014-05 52.222-21 2015-04 52.223-5 52.223-18 52.223-19

2011-05 2011-08 2011-05

52.223-21 2016-06

52.225-13 2008-06 52.227-1 52.232-33

Disputes Concerning Labor Standards Certification of Eligibility Prohibition of Segregated Facilities.

Pollution Prevention and Right-to-Know Information.

Encouraging Contractor Policies to Ban Text Messaging While Driving.

Compliance with Environmental Management Systems.

Foams.

Restrictions on Certain Foreign Purchases.

Authorization and Consent.

Payment by Electronic Funds Transfer-System for Award Management.

2007-12 2018-10

52.233-1 2014-05 52.233-3 1996-08 52.236-2 1984-04 52.236-5 1984-04 52.236-6 1984-04 52.236-7

Disputes.

Protest after Award.

Differing Site Conditions Material and Workmanship.

Superintendence by the Contractor Permits and Responsibilities. 1991-11

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements 1984-04 52.242-14 Suspension of Work. 1984-04 52.243-5 Changes and Changed Conditions.

52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short

1984-04 1984-04

Form).

DFARS Clauses Incorporated by Reference

Number Effective Date 252.203-7000 252.203-7002

2011-09 2013-09

252.223-7008 2013-06 252.227-7003 1984-08 252.227-7024 1984-04 252.243-7001 252.246-7004

Title

Requirements Relating to Compensation of Former DoD Officials Requirement to Inform Employees of Whistleblower Rights.

Prohibition of Hexavalent Chromium.

Termination.

Notice and Approval of Restricted Designs.

Pricing of Contract Modifications.

Safety of Facilities, Infrastructure, and Equipment for Military

1991-12 2010-10

Operations.

AFFARS Clauses Incorporated by Reference

Number

5352.223-9001

Title Effective Date

Health and Safety on Government Installations 11/1/2012

FAR Clauses Incorporated by Full Text

52.204-13 System for Award Management Maintenance. 2018-10 As prescribed in 4.1105(b), use the following clause:

System for Award Management Maintenance. (Oct 2018) (a) Definitions. As used in this clause- "Electronic Funds Transfer (EFT) indicator" means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management (SAM) records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. "Registered in the System for Award Management (SAM)" means that- (1) The Contractor has entered all mandatory information, including the unique entity identifier and the EFT indicator (if applicable), the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into SAM; (2) The Contractor has completed the Core, Assertions, Representations and Certifications, and Points of Contact sections of the registration in SAM; (3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and (4) The Government has marked the record "Active". "System for Award Management (SAM)" means the primary Government repository for prospective Federal awardee and Federal awardee information and the centralized Government system for certain contracting, grants, and other assistance-related processes. It includes- (1) Data collected from prospective Federal awardees required for the conduct of business with the Government; (2) Prospective contractor-submitted annual representations and certifications in accordance with FAR subpart 4.12; and (3) Identification of those parties excluded from receiving Federal contracts, certain subcontracts, and certain types of Federal financial and non-financial assistance and benefits. "Unique entity identifier" means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers. (b) If the solicitation for this contract contained the provision 52.204-7 with its Alternate I, and the Contractor was unable to register prior to award, the Contractor shall be registered in SAM within 30 days after award or before three days prior to submission of the first invoice, whichever occurs first. (c) The Contractor shall maintain registration in SAM during contract performance and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement. The Contractor is responsible for the currency, accuracy and completeness of the data within SAM, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in SAM after the initial registration, the Contractor is required to review and update on an annual basis, from the date of initial registration or subsequent updates, its information in SAM to ensure it is current, accurate and complete.

Updating information in SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. (d) (1) (i) If a Contractor has legally changed its business name or "doing business as" name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to- (A) Change the name in SAM; (B) Comply with the requirements of subpart 42.12 of the FAR; and (C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor shall provide with the notification sufficient documentation to support the legally changed name. (ii) If the Contractor fails to comply with the requirements of paragraph (d)(1)(i) of this clause, or fails to perform the agreement at paragraph (d)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract. (2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in SAM record to reflect an assignee for the purpose of assignment of claims (see FAR subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the EFT clause of this contract. (3) The Contractor shall ensure that the unique entity identifier is maintained with the entity designated at www.sam.gov for establishment of the unique entity identifier throughout the life of the contract. The Contractor shall communicate any change to the unique entity identifier to the Contracting Officer within 30 days after the change, so an appropriate modification can be issued to update the data on the contract. A change in the unique entity identifier does not necessarily require a novation be accomplished. (e) Contractors may obtain additional information on registration and annual confirmation requirements at https://www.sam.gov. (End of clause)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 As prescribed in 9.108-5(b), insert the following clause: Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015) (a) Definitions. As used in this clause- "Inverted domestic corporation" means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). "Subsidiary" means an entity in which more than 50 percent of the entity is owned- (1) Directly by a parent corporation; or (2) Through another subsidiary of a parent corporation. (b) If the contractor reorganizes as an inverted domestic corporation or becomes a subsidiary of an inverted domestic corporation at any time during the period of performance of this contract, the Government may be prohibited from paying for Contractor activities performed after the date when it becomes an inverted domestic corporation or subsidiary. The Government may seek any available remedies in the event the Contractor fails to perform in accordance with the terms and conditions of the contract as a result of Government action under this clause. (c) Exceptions to this prohibition are located at 9.108-2. (d) In the event the Contractor becomes either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation during contract performance, the Contractor shall give written notice to the Contracting Officer within five business days from the date of the inversion event.

(End of clause)

52.211-12 Liquidated Damages-Construction. 2000-09 As prescribed in 11.503(b), insert the following clause in solicitations and contracts: Liquidated Damages-Construction (Sept 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $872 for the first day then $348 for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (End of clause)

52.219-28 Post-Award Small Business Program Rerepresentation. 2013-07 As prescribed in 19.309(c), insert the following clause: Post-Award Small Business Program Rerepresentation (Jul 2013)

(a) Definitions. As used in this clause- Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority. Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is not dominant in its field of operation when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity. (b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following: (1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract. (2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract. (3) For long-term contracts- (i) Within 60 to 120 days prior to the end of the fifth year of the contract; and (ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter. (c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/ table-small-business-size-standards. (d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees. (e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update. (f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause. (g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed: The Contractor represents that it [_X_] is, [_] is not a small business concern under NAICS Code 237120 assigned to contract number FA480319RA011. [Contractor to sign and date and insert authorized signer's name and title]. (End of clause)

52.222-26 Equal Opportunity. 2015-09 As prescribed in 22.810(e), insert the following clause:

Equal Opportunity (Sept 2015)

(a) Definition. As used in this clause.

"Compensation" means any payments made to, or on behalf of, an employee or offered to an applicant as remuneration for employment, including but not limited to salary, wages, overtime pay, shift differentials, bonuses, commissions, vacation and holiday pay, allowances, insurance and other benefits, stock options and awards, profit sharing, and retirement.

"Compensation information" means the amount and type of compensation provided to employees or offered to applicants, including, but not limited to, the desire of the Contractor to attract and retain a particular employee for the value the employee is perceived to add to the Contractor's profit or productivity; the availability of employees with like skills in the marketplace;

market research about the worth of similar jobs in the relevant marketplace; job analysis, descriptions, and evaluations; salary and pay structures; salary surveys; labor union agreements; and Contractor decisions, statements and policies related to setting or altering employee compensation.

"Essential job functions" means the fundamental job duties of the employment position an individual holds. A job function may be considered essential if-

(1) The access to compensation information is necessary in order to perform that function or another routinely assigned business task; or

(2) The function or duties of the position include protecting and maintaining the privacy of employee personnel records, including compensation information.

"Gender identity" has the meaning given by the Department of Labor's Office of Federal Contract Compliance Programs, and is found at http://www.dol.gov/ofccp/LGBT/LGBT_FAQs.html.

"Sexual orientation" has the meaning given by the Department of Labor's Office of Federal Contract Compliance Programs, and is found at http://www.dol.gov/ofccp/LGBT/LGBT_FAQs.html.

"United States," means the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.

(b)

(1) If, during any 12-month period (including the 12 months preceding the award of this contract), the Contractor has been or is awarded nonexempt Federal contracts and/or subcontracts that have an aggregate value in excess of $10,000, the Contractor shall comply with this clause, except for work performed outside the United States by employees who were not recruited within the United States. Upon request, the Contractor shall provide information necessary to determine the applicability of this clause.

(2) If the Contractor is a religious corporation, association, educational institution, or society, the requirements of this clause do not apply with respect to the employment of individuals of a particular religion to perform work connected with the carrying on of the Contractor's activities (41 CFR 60-1.5).

(c)

(1) The Contractor shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, sexual orientation, gender identity, or national origin. However, it shall not be a violation of this clause for the Contractor to extend a publicly announced preference in employment to Indians living on or near an Indian reservation, in connection with employment opportunities on or near an Indian reservation, as permitted by 41 CFR 60-1.5.

(2) The Contractor shall take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, religion, sex, sexual orientation, gender identity, or national origin. This shall include, but not be limited to-

(i) Employment;

(ii) Upgrading;

(iii) Demotion;

(iv) Transfer;

(v) Recruitment or recruitment advertising;

(vi) Layoff or termination;

(vii) Rates of pay or other forms of compensation; and

(viii) Selection for training, including apprenticeship.

(3) The Contractor shall post in conspicuous places available to employees and applicants for employment the notices to be provided by the Contracting Officer that explain this clause.

(4) The Contractor shall, in all solicitations or advertisements for employees placed by or on behalf of the Contractor, state that all qualified applicants will receive consideration for employment without regard to race, color, religion, sex, sexual orientation, gender identity, or national origin.

(5)

(i) The Contractor shall not discharge or in any other manner discriminate against any employee or applicant for employment because such employee or applicant has inquired about, discussed, or disclosed the compensation of the employee or applicant or another employee or applicant. This prohibition against discrimination does not apply to instances in which an employee who has access to the compensation information of other employees or applicants as a part of such employee's essential job functions discloses the compensation of such other employees or applicants to individuals who do not otherwise have access to such information, unless such disclosure is in response to a formal complaint or charge, in furtherance of an investigation, proceeding, hearing, or action, including an investigation conducted by the employer, or is consistent with the Contractor's legal duty to furnish information.

(ii) The Contractor shall disseminate the prohibition on discrimination in paragraph (c)(5)(i) of this clause, using language prescribed by the Director of the Office of Federal Contract Compliance Programs (OFCCP), to employees and applicants by-

(A) Incorporation into existing employee manuals or handbooks; and

(B) Electronic posting or by posting a copy of the provision in conspicuous places available to employees and applicants for employment.

(6) The Contractor shall send, to each labor union or representative of workers with which it has a collective bargaining agreement or other contract or understanding, the notice to be provided by the Contracting Officer advising the labor union or workers' representative of the Contractor's commitments under this clause, and post copies of the notice in conspicuous places available to employees and applicants for employment.

(7) The Contractor shall comply with Executive Order11246, as amended, and the rules, regulations, and orders of the Secretary of Labor.

(8) The Contractor shall furnish to the contracting agency all information required by Executive Order11246, as amended, and by the rules, regulations, and orders of the Secretary of Labor. The Contractor shall also file Standard Form100 (EEO-1), or any successor form, as prescribed in 41 CFR Part60-1. Unless the Contractor has filed within the 12 months preceding the date of contract award, the Contractor shall, within 30 days after contract award, apply to either the regional Office of Federal Contract Compliance Programs (OFCCP) or the local office of the Equal Employment Opportunity Commission for the necessary forms.

(9) The Contractor shall permit access to its premises, during normal business hours, by the contracting agency or the OFCCP for the purpose of conducting on-site compliance evaluations and complaint investigations. The Contractor shall permit the Government to inspect and copy any books, accounts, records (including computerized records), and other material that may be relevant to the matter under investigation and pertinent to compliance with Executive Order11246, as amended, and rules and regulations that implement the Executive Order.

(10) If the OFCCP determines that the Contractor is not in compliance with this clause or any rule, regulation, or order of the Secretary of Labor, this contract may be canceled, terminated, or suspended in whole or in part and the Contractor may be declared ineligible for further Government contracts, under the procedures authorized in Executive Order11246, as amended.

In addition, sanctions may be imposed and remedies invoked against the Contractor as provided in Executive Order11246, as amended; in the rules, regulations, and orders of the Secretary of Labor; or as otherwise provided by law.

(11) The Contractor shall include the terms and conditions of this clause in every subcontract or purchase order that is not exempted by the rules, regulations, or orders of the Secretary of Labor issued under Executive Order11246, as amended, so that these terms and conditions will be binding upon each subcontractor or vendor.

(12) The Contractor shall take such action with respect to any subcontract or purchase order as the Director of OFCCP may direct as a means of enforcing these terms and conditions, including sanctions for noncompliance, provided, that if the Contractor becomes involved in, or is threatened with, litigation with a subcontractor or vendor as a result of any direction, the Contractor may request the United States to enter into the litigation to protect the interests of the United States.

(d) Notwithstanding any other clause in this contract, disputes relative to this clause will be governed by the procedures in 41

CFR 60-1.

52.222-50 Combating Trafficking in Persons. 2019-01 As prescribed in 22.1705(a)(1), insert the following clause: Combating Trafficking in Persons (Jan 2019)

(a) Definitions. As used in this clause- "Agent" means any individual, including a director, an officer, an employee, or an independent contractor, authorized to act on behalf of the organization.

"Coercion" means-

(1) Threats of serious harm to or physical restraint against any person;

(2) Any scheme, plan, or pattern intended to cause a person to believe that failure to perform an act would result in serious harm to or physical restraint against any person; or

(3) The abuse or threatened abuse of the legal process.

"Commercial sex act" means any sex act on account of which anything of value is given to or received by any person.

"Commercially available off-the-shelf (COTS) item" means-

(1) Any item of supply (including construction material) that is-

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Debt bondage" means the status or condition of a debtor arising from a pledge by the debtor of his or her personal services or of those of a person under his or her control as a security for debt, if the value of those services as reasonably assessed is not applied toward the liquidation of the debt or the length and nature of those services are not respectively limited and defined.

"Employee" means an employee of the Contractor directly engaged in the performance of work under the contract who has other than a minimal impact or involvement in contract performance.

"Forced Labor" means knowingly providing or obtaining the labor or services of a person-

(1) By threats of serious harm to, or physical restraint against, that person or another person;

(2) By means of any scheme, plan, or pattern intended to cause the person to believe that, if the person did not perform such labor or services, that person or another person would suffer serious harm or physical restraint; or

(3) By means of the abuse or threatened abuse of law or the legal process. "Involuntary servitude" includes a condition of servitude induced by means of-

(1) Any scheme, plan, or pattern…