FA4417-13-R-0020_-_Solicitation.pdf

- Project FTEV 12-1096, Specifications dated 19 Jun 2013, Drawings dated 19 Jun 2013.

- Enter prices in Section B, using TYPEWRITER or BLACK INK.

- THIS ACQUISITION IS AN TOTAL SMALL BUSINESS SET-ASIDE. NAICS CODE: 238210 SIZE STANDARD: $14,000,000.00

- Disclosure of Magnitude of Construction: The estimated amount of this project is between $500,000.00 and $1,000,000.00.

- This solicitation will be awarded IAW FAR Part 15, Contracting by Negotiations. Your attention is directed to Sections L and M for proposal preparation.

- DISCUSSION OF OFFER: The Government may award a contract based solely on initial offers received, without discussions of such offer.

Accordingly, each initial offer should be submitted on the most favorable terms from noth a price and technical standpoint.

- SEE CONTINUATION PAGE FOR ADDITIONAL INFORMATION

ASHLEY N. COLGROVE 850-884-3137

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

25-Jul-2013

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within _______10 calendar days and complete it within ________180 calendar days after receiving award, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the work required are due at the place specified in Item 8 by ___________ local time ______________26 Aug 2013 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______35 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

1 SOCONS

350 TULLY ST.

HURLBURT FIELD FL 32544

FA4417

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 850-884-7690 TEL: FAX:

FA4417-13-R-0020 45

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.)

Contractor agrees Your offer on this solicitation, is hereby accepted as to the items listed. This award con-to furnish and deliver all items or perform all work, requisitions identified summates the contract, which consists of (a) the Government solicitation and on this form and any continuation sheets for the consideration stated in this your offer, and (b) this contract award. No further contractual document is contract. The rights and obligations of the parties to this contract shall be necessary.

governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(Must be fully completed by offeror)OFFER

FA4417-13-R-0020

Section A - Solicitation/Contract Form

BLOCK 10 CONTINUATION PAGE

- All offerors MUST complete the Online Representations and Certifications application @ https://www.sam.gov. Failure to complete all required Representations and Certifications will make your proposal ineligible for award.

- ENTER CONTRACTOR DUNS NO. ________________. - ENTER CONTRACTOR CAGE CODE: ________.

PLEASE ENTER REQUIRED INFORMATION.

- EMAIL ADDRESS OF COMPANY REPRESENTATIVES:

PRIMARY: ____________________________________________________________________________

ALTERNATE: __________________________________________________________________________

- NOTE TO OFFERORS: Funds are not presently available for this effort. No award will be made under this solicitation until funds are available. The Government reserves the right to cancel this solicitation, eitehr before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse an offeror for any costs.

- A SITE VISIT HAS BEEN SCHEDULED FOR Tuesday, 13 Aug 2013 @ 10:00 a.m., CST AT THE 1ST

SPECIAL OPERATIONS CONTRACTING SQUADRON, 350 TULLY ST, BUILDING 90339, HURLBURT

FIELD, FL 32544. Fax or email written request with the name of those who will attend the site visit to Ashley

Colgrove, Contract Specialist, Fax (850) 884-1272 AND e-mail at ashley.colgrove@hurlburt.af.mil and Ms Tina

Kneip at tina.kneip@hurlburt.af.mil. Requests must be received NLT Monday, 12 Aug 2013 @ 11:00 a.m., CST.

You must enter the base from the main gate (Off Highway 98). Please allow extra time to obtain your pass.

- SUBMISSION OF QUESTIONS: Questions regarding this solicitation must be submitted in writing in Word format to the individuals listed above no later than the close of business 5 calendar days after the site visit.

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot Repair Runway Edge Lighting

FFP

The contractor shall furnish all labor, materials, tools, supervision, and equipment to perform all operations necessary to accomplish all work as shown on drawings, dated 19 Jun 13 and specifications, dated 19 Jun 13.

FOB: Destination

SIGNAL CODE: A

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

0001 180 dys. ADC 1 1SOCES

MARY MIKOS

1 SOCES/CEOS

415 INDEPENDENCE RD

HURLBURT FIELD FL 32544-5816

850-884-7972

FOB: Destination

F2F323

52.247-34 F.O.B. Destination NOV 1991

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 180 calendar days after issuance of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $ 191.11 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Section H - Special Contract Requirements

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2013) (DEVIATION)

(a) Definitions. As used in this clause—

“Department of Defense Activity Address Code (DoDAAC)” is a six position code that uniquely identifies a unit, activity, or organization.

“Document type” means the type of payment request or receiving report available for creation in Wide Area WorkFlow

(WAWF).

“Local processing office (LPO)” is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports

(c) WAWF access. To access WAWF, the Contractor shall—

(1) Have a designated electronic business point of contact in the Central Contractor Registration at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training

Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/

(e) WAWF methods of document submission. Document submissions may be via web entry, Electronic Data Interchange, File Transfer Protocol, or PayWeb.

(1) To access PayWeb, the vendor may go to the following site: https://onronline.onr.navy.mil/payweb/

(2) For instructions on PayWeb payment request submission, please contact the office identified below:

Atlanta Regional Office

Office of Naval Research (ONR)

100 Alabama St, Ste 4R15, Atlanta GA 30303-3104

Main Office (404)562-1600 Email:ONR_Atlanta@onr.navy.mil

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

http://www.acq.osd.mil/dpap/dars/dfars/html/current/252232.htm https://www.acquisition.gov/ https://wawf.eb.mil/ https://wawf.eb.mil/ https://onronline.onr.navy.mil/payweb/ mailto:ONR_Atlanta@onr.navy.mil

CONSTRUCTION INVOICE _(NOTE: Invoices to be submitted only AFTER receipt of approved AF Form

3065, Contract Progress Report_______________________________________

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in

WAWF, as specified by the contracting officer.

_______________N/A__________________________________________________

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable.”)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F67100

Issue By DoDAAC FA4417

Admin DoDAAC FA4417

Inspect By DoDAAC N/A

Ship To Code N/A

Ship From Code N/A

Mark For Code N/A

Service Approver (DoDAAC) N/A

Service Acceptor (DoDAAC) N/A

Accept at Other DoDAAC N/A

LPO DoDAAC N/A

DCAA Auditor DoDAAC N/A

Other DoDAAC(s)/ Contracting Officer F2F332

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the e-mail address identified below in the “Send

Additional Email Notifications” field of WAWF once a document is submitted in the system.

ENTER EMAIL FOR CONTRACT ADMINISTRATOR AND CONTRACTING OFFICER

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity’s

WAWF point of contact.

_________https://wawf.eb.mil/____________________________________________________

(3) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

HF004 REQUIRED INSURANCE (IAW FAR 28.306(b))

Reference FAR clause entitled “Insurance...” the Contractor shall, at its own expense, procure and thereafter maintain the following kinds of insurance with respect to performance under the contract. The Contractor will have the option to complete a form entitled “Notification of Compliance with Contract Insurance Requirements” that will be provided by the Government at time of award, or to submit an insurance certificate before any work commences on the installation.

a. Workman’s Compensation and Employers Liability Insurance as required by law except that if this contract is to be performed in a state which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such state will be satisfactory. The required Workmen’s compensation insurance shall extend to cover employer’s liability for accidental bodily injury or death and for occupational diseases with a minimum liability limit of $100,000.00.

b. General Liability Insurance. Bodily injury liability insurance, in the minimum limits of $500,000.00 per occurrence shall be required on the comprehensive form of policy.

c. Automobile Liability Insurance. This insurance shall be required on the comprehensive form of policy and shall provide bodily injury liability and property damage liability covering the operation of all automobile used in connection with the performance of the contract. At least the minimum limits of $200,000.00 per person and

$500,000.00 per occurrence for bodily injury and $20,000 per occurrence for property damage shall be required.

HF005 EXCLUSION OF PAYMENT FOR MATERIALS STORED ON SITE

Payment in advance of installation, for materials stored on site, will not be considered under this contract.

HF009 DESIGNATION OF GOVERNMENT INSPECTOR

https://wawf.eb.mil/

The Base Civil Engineer (or his/her authorized representative) is designated as the representative of the Contracting

Officer for purpose of serving as the Government's Construction Contract Inspector (CCI). This includes performing technical surveillance, including workmanship, and ensuring compliance with the plans and specifications under this contract. This provision in no way authorizes anyone other than the Contracting Officer to commit the Government to changes in the terms of this contract.

HF010 PREPARATION OF MATERIAL APPROVAL SUBMITTALS

Submittals contemplated by the clause herein entitled "Material and Workmanship" shall be accomplished on and in accordance with instructions pertaining to AF Form 3000 (Material Approval Submittal).

HF011 PREPARATION OF SCHEDULE FOR CONSTRUCTION CONTRACTS

The reports contemplated by clause entitled "Schedule for Construction Contracts" shall be accomplished on and in accordance with instructions pertaining to AF Form 3064 (Contract Progress Schedule) and AF Form 3065 (Contract

Progress Report).

HF012 POST-AWARD/PRE-PERFORMANCE CONFERENCE

A Pre-Performance Conference shall be conducted in accordance with FAR 52.236-26 (IAW FAR 36.522).

HF015 TELEPHONE COMSEC MONITORING

All communications with DOD organizations are subject to COMSEC review. Contractor personnel will be aware that telecommunications networks are continually subject to intercept by unfriendly intelligence organizations. The

DOD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls originating from or terminating at DOD organizations. Therefore, civilian contractor personnel are advised that any time they place a call to or receive a call from a military organization, they are subject to COMSEC procedures. The contractor will assume the responsibility for ensuring wide and frequent dissemination of the above information to all employees dealing with official DOD information.

HF016 AVAILABILITY OF UTILITIES SERVICES

Notwithstanding provisions of Contract Clause, FAR 52.236-14, "AVAILABILITY AND USE OF UTILITY

SERVICES," reasonable required amounts of water, gas, electricity, etc., essential to contract performance, will be made available at no cost to the contractor from existing systems, outlets, and supplies. Temporary connections, outlets, and distribution lines as required shall be installed by the contractor at his own expense.

HF017 VEHICLE OPERATION AND REGISTRATION

The prime contractor is responsible for all employees or sub-contracting employees performing duties on the Air

Force installation cited in the contract. The contractor shall obtain base identification and a vehicle pass for all contractor personnel who make frequent visits to or perform work while on the Air Force installation cited in the contract. Upon receipt of award, the contractor will be provided a letter signed by the Contracting Officer to be taken to the Pass and Registration section to obtain a visitor pass.

HF018 HOURS OF WORK

Normal hours of work on Hurlburt Field are 7:00 AM to 4:00 PM (CST), Monday through Friday, excluding holidays. Access to work sites is restricted to these hours and days unless otherwise approved by the Contracting

Officer three (3) workdays in advance.

HF019 INSTALLATION RULES AND REGULATIONS

Rules and regulations of Hurlburt Field apply to all contractors and their employees. Regulations include, but are not limited to, presenting valid picture identification for base entrance, obtaining and using vehicle passes for all contractor-owned and/or privately owned vehicles, obeying all posted directives, and strictly adhering to security police direction where security police have been dispatched to a particular location.

HF020 HURRICANE SEASON

Hurricane season for the state of Florida is normally the period from 1 June through 30 November. During an actual hurricane condition, you may be contacted by this office and requested to secure equipment and clean up your work area. In accordance with contracts clauses FAR 52.236-9 and FAR 52.236-12, you are required to maintain your work area free of debris and in a safe and secure condition at the completion of each workday, with particular care during the hurricane season.

HF029 WORK BY THE GOVERNMENT OR OTHERS

The government reserves the right to undertake performance by government forces or other contractors the same type or similar work as the government deems necessary or desirable and to do so will not breach or otherwise violate this contract.

HF038 BASE RECYCLE PROGRAM

The contractor shall make every attempt to reduce the generation of solid waste to the maximum extent possible. The contractor shall utilize the Base Recycling Center (884-7577) for any office paper, cardboard, plastic, or metal wastes related to a project whenever possible. A complete list of recyclable items can be procured from Base Recycling Center Manager (884-7577). All wastes, whether recycled or landfilled, shall be weighed prior to disposal and disposition information shall be reported 1 SOCES/CEA.

The Contractor shall provide on-site instruction of appropriate separation, handling, and recycling, salvage, reuse, and return methods to be used by all parties.

This task is to be accomplished in compliance with all local, state, federal and Hurlburt Field rules and instructions, including mandated recycling requirements. Any questions pertaining to Hurlburt Field’s

Recycling program, contact 1 SOCES/CEAN, 884-4651.

HF042 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (JUN 08)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) Contractors will be required to complete the following forms (to be provided at the pre-performance conference) in order for employees to gain access to the installation:

(1) Contractor Employee Listing

(2) Hurlburt Field Contractor Access Badge Affidavit (CAB)

(3) Department of Homeland Security Form I-9 (DHS I-9)

(i) The Contractor Employee List. This form must list every employee requiring access. Every time employees change, it must be updated to reflect additions and/or deletions. Identify those individuals you wish to have escort authority by including the word “escort” next to their names. Limit the number of individuals designated as escorts to a reasonable number (i.e. one or two). For work locations please use building numbers or areas (i.e.

Bldg 90618 or Red Horse, AMMO Area, etc.). Once completed, email the list to the Contracting Office representative in EXCEL or WORD format. The Contracting Officer will then prepare and attach a cover letter, and forward the Employee List to the Visitor Control Center.

(ii) Upon notification that your employee list has been forwarded to the Visitor Control Center, the other two forms (DHS I-9 & CAB) must be completed and hand carried to the Visitor Control Center by the employee. If everything is in order, they will receive a contractor badge. If an employee will be driving on Hurlburt Field they are required to provide a valid driver’s license, vehicle registration, and proof of insurance. NOTE: The section of the

Visitor Control Center administrating this function is closed after 1400 (2:00 p.m.), therefore, employees must arrive prior to this time in order for their documentation to be processed.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-101, Volume 1, The Air Force Installation Security Program, and AFI 31-501, Personnel

Security Program Management, citing the appropriate paragraphs as applicable.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) Failure to comply with these requirements may result in withholding of final payment.

(End of clause) http://www.e-publishing.af.mil/search.asp?keyword=AFI+31-101&Go.x=8&Go.y=10 http://www.e-publishing.af.mil/pubfiles/af/31/afi31-501/afi31-501.pdf

Section I - Contract Clauses

52.202-1 Definitions JAN 2012

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees APR 1984

52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006

52.203-7 Anti-Kickback Procedures OCT 2010

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

JAN 1997

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity JAN 1997

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-7 Central Contractor Registration DEC 2012

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

DEC 2010

52.215-2 Audit and Records--Negotiation OCT 2010

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011

52.219-8 Utilization of Small Business Concerns JAN 2011

52.219-14 Limitations On Subcontracting NOV 2011

52.222-1 Notice To The Government Of Labor Disputes FEB 1997

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation

JUL 2005

52.222-6 Davis Bacon Act JUL 2005

52.222-7 Withholding of Funds FEB 1988

52.222-8 Payrolls and Basic Records JUN 2010

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) JUL 2005

52.222-12 Contract Termination-Debarment FEB 1988

52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility FEB 1988

52.222-21 Prohibition Of Segregated Facilities FEB 1999

52.222-26 Equal Opportunity MAR 2007

52.222-27 Affirmative Action Compliance Requirements for

Construction

FEB 1999

52.222-35 Equal Opportunity for Veterans SEP 2010

52.222-36 Affirmative Action For Workers With Disabilities OCT 2010

52.222-37 Employment Reports on Veterans SEP 2010

52.222-50 Combating Trafficking in Persons FEB 2009

52.222-54 Employment Eligibility Verification JUL 2012

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 Pledges Of Assets JAN 2012

52.228-12 Prospective Subcontractor Requests for Bonds OCT 1995

52.228-14 Irrevocable Letter of Credit DEC 1999

52.228-15 Performance and Payment Bonds--Construction OCT 2010

52.229-3 Federal, State And Local Taxes FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002

52.232-17 Interest OCT 2010

52.232-18 Availability Of Funds APR 1984

52.232-23 Assignment Of Claims JAN 1986

52.232-27 Prompt Payment for Construction Contracts OCT 2008

52.232-33 Payment by Electronic Funds Transfer--Central Contractor

Registration

OCT 2003

52.233-1 Disputes JUL 2002

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-17 Layout of Work APR 1984

52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995

52.242-13 Bankruptcy JUL 1995

52.242-14 Suspension of Work APR 1984

52.243-4 Changes JUN 2007

52.244-6 Subcontracts for Commercial Items DEC 2010

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2010

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Alt A Central Contractor Registration Alternate A MAY 2013

252.204-7006 Billing Instructions OCT 2005

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Terrorist Country

DEC 2006

252.209-7999 (Dev) Representation by Corporations Regarding an Unpaid

Delinquent Tax Liability or a Felony Conviction under any

Federal Law (Deviation)

JAN 2012

252.223-7001 Hazard Warning Labels DEC 1991

252.223-7006 Prohibition On Storage And Disposal Of Toxic And

Hazardous Materials

APR 2012

252.225-7012 Preference For Certain Domestic Commodities FEB 2013

252.227-7033 Rights in Shop Drawings APR 1966

252.231-7000 Supplemental Cost Principles DEC 1991

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.236-7006 Cost Limitation JAN 1997

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.244-7000 Subcontracts for Commercial Items and Commercial

Components (DoD Contracts)

MAR 2013

252.247-7023 Transportation of Supplies by Sea MAY 2002

252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000

52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)

(a) The Contractor shall make the following notifications in writing:

(1) When the Contractor becomes aware that a change in its ownership has occurred, or is certain to occur, that could result in changes in the valuation of its capitalized assets in the accounting records, the Contractor shall notify the

Administrative Contracting Officer (ACO) within 30 days.

(2) The Contractor shall also notify the ACO within 30 days whenever changes to asset valuations or any other cost changes have occurred or are certain to occur as a result of a change in ownership.

(b) The Contractor shall--

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the ACO or designated representative ready access to the records upon request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of the Contractor's ownership changes; and

(4) Retain and continue to maintain depreciation and amortization schedules based on the asset records maintained before each Contractor ownership change.

The Contractor shall include the substance of this clause in all subcontracts under this contract that meet the applicability requirement of FAR 15.408(k).

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (APR 2012)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and

Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the

Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in

ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 238210 assigned to contract number TBD.

(Contractor to sign and date and insert authorized signer's name and title).

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-

DESIGNATED ITEMS (MAY 2008)

(a) Definitions. As used in this clause--

Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall--

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to 1 st Special Operations Contracting Squadron

350 Tully Street, Building 90339

Hurlburt Field, FL 32544

52.225-9 BUY AMERICAN ACT—CONSTRUCTION MATERIALS (SEP 2010)

(b) Domestic preference.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: NONE

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

(a) Except as authorized by the Office of Foreign Assets Control (OFAC) in the Department of the Treasury, the

Contractor shall not acquire, for use in the performance of this contract, any supplies or services if any proclamation, Executive order, or statute administered by OFAC, or if OFAC's implementing regulations at 31 CFR chapter V, would prohibit such a transaction by a person subject to the jurisdiction of the United States.

(b) Except as authorized by OFAC, most transactions involving Cuba, Iran, and Sudan are prohibited, as are most imports from Burma or North Korea, into the United States or its outlying areas. Lists of entities and individuals subject to economic sanctions are included in OFAC's List of Specially Designated Nationals and Blocked Persons at

TerList1.html. More information about these restrictions, as well as updates, is available in the OFAC's regulations at

31 CFR chapter V and/or on OFAC's Web site at http://www.treas.gov/offices/enforcement/ofac/.

(c) The Contractor shall insert this clause, including this paragraph (c), in all subcontracts.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% percent of the bid price or not to exceed $3 million, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulation Supplements (48 CFR

Chapter 2) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Title Drawing No.

Repair Runway Edge Lighting FTEV- 12-1096

5352.201-9101 OMBUDSMAN (NOV 2012)

OMBUDSMAN (APR 2010)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the

Center/MAJCOM/DRU or AFISRA ombudsmen Colonel Tara L. Morrison, HQ AFSOC/A7K, 427 Cody Avenue, Suite 225, Hurlburt Field, FL 32544; Phone: (850) 884-3990, fax: (850) 884-2476. Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU or AFISRA level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary

(ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571)

256-2397, facsimile number (571) 256-2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

http://www.whitehouse.gov/omb/circulars/a076/a76_rev2003.pdf

5352.223-9000 ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODSs) (NOV

2012)

(a) Contractors shall not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS as part of this contract/order.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

(c) The requiring activity has obtained SAO approval to permit the contractor to use the following Class I ODS(s):

Class I ODS/ Application or Use/Quantity (lbs.) per contract period of performance NONE

(d) The offeror/contractor is required to notify the contracting officer if any Class I ODS that is not specifically listed above is required in the test, operation, or maintenance of any system, subsystem, item, component, or process.

5352.242-9000 Contractor access to Air Force installations.

http://www.e-publishing.af.mil/pubfiles/af/32/afi32-7086/afi32-7086.pdf

As prescribed in 5342.490-1, insert a clause substantially the same as the following clause in solicitations and contracts:

Clause replaced by HF042 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS http://farsite.hill.af.mil/reghtml/regs/far2afmcfars/af_afmc/affars/5342.htm#P35_364

Section J - List of Documents, Exhibits and Other Attachments

LIST OF ATTACHMENTS

ATCH TITLE DATE NO. OF PAGES

1. SPECIFICATIONS 19 Jun 2013 95

FTEV 12-1096

2. DRAWINGS 4/24/2012 19 Jun 2013 16

FTEV 12-1096

3. SCHEDULE OF WAGE RATES 29 March 2013 3

Decision Number: FL130029

4. PAST PERFORMANCE QUESTIONNAIRE UNDATED 3

TO BE REMOVED AT AWARD

5. FINANCIAL INSTITUTION REFERENCE SHEET UNDATED 1

TO BE REMOVED AT AWARD

AMENDMENTS: Amendments issued to this solicitation will be part of any resultant contract and will be listed above at the time of award.

Section K - Representations, Certifications and Other Statements of Offerors

52.236-28 Preparation of Proposals--Construction OCT 1997

252.209-7001 Disclosure of Ownership or Control by the Government of a

Terrorist Country

JAN 2009

252.225-7031 Secondary Arab Boycott Of Israel JUN 2005

252.247-7022 Representation Of Extent Of Transportation Of Supplies By

Sea

AUG 1992

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JUNE 2013)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238210.

(2) The small business size standard is $14,000,000.00

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, Central Contractor Registration, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in CCR, and has completed the ORCA electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

(X) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in ORCA are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless--

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at

52.204-7, Central Contractor Registration.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business).This provision applies to solicitations that--

(A) Are not set aside for small business concerns;

(B) Exceed…