Attach_1_-_Specifications_-_Dry_Burn_Training_Facility.pdf

SPECIFICATIONS

FOR

CONSTRUCTION STRUCTURAL DRY TRAINER

GOODFELLOW AFB, TX

OPPORTUNITY # 107293

Mar 2019

PREPARED BY: Brian Narvid

17 CES

Goodfellow AFB

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00.00 44 CONSTRUCTION SCHEDULE

01 31 19.00 44 PROJECT MEETINGS

01 33 00 SUBMITTAL PROCEDURES

01 35 16.00 44 SPECIAL PROJECT PROCEDURES FOR GOODFELLOW AIR FORCE BASE

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 56 00.00 44 DUST CONTROL

01 57 20.16 10 ENVIRONMENTAL PROTECTION FOR GOODFELLOW AFB

01 57 24.01 44 STORM WATER POLLUTION PREVENTION PLAN (TEXAS)

01 62 35 RECYCLED / RECOVERED MATERIALS

01 71 23.00 44 SURVEY, LAYOUT, AND OTHER DATA

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 78 24.00 10 FACILITY DATA REQUIREMENTS

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 03 - CONCRETE

03 11 13.00 10 STRUCTURAL CAST-IN-PLACE CONCRETE FORMING

03 15 00.00 10 CONCRETE ACCESSORIES

03 20 00.00 10 CONCRETE REINFORCING

03 30 00 CAST-IN-PLACE CONCRETE

03 30 00.00 10 CAST-IN-PLACE CONCRETE

03 30 01 CAST-IN-PLACE CONCRETE (WET TRAINER ONLY)

03 35 00.00 10 CONCRETE FINISHING

03 39 00.00 10 CONCRETE CURING

DIVISION 05 - METALS

05 12 00 STRUCTURAL STEEL

05 30 00 STEEL DECKS

05 40 00 COLD-FORMED METAL FRAMING

05 42 50 PRE-ENGINEERED COLD-FORMED STEEL TRUSSES

05 51 00 METAL STAIRS

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 26 16 BELOW GRADE VAPOR RETARDERS

07 41 63 FABRICATED ROOF PANEL ASSEMBLIES

07 42 13 METAL WALL PANELS

07 60 00 FLASHING AND SHEET METAL

07 84 00 FIRESTOPPING

7 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

8 11 13 STEEL DOORS AND FRAMES

08 51 13 ALUMINUM WINDOWS

08 71 00 DOOR HARDWARE

8 81 00 GLAZING

DIVISION 09 - FINISHES

9 29 00 GYPSUM BOARD

09 51 00 ACOUSTICAL CEILINGS

09 90 00 PAINTS AND COATINGS

DIVISION 11 - EQUIPMENT

11 00 00 GAS FIRED TRAINING SYSTEMS

DIVISION 21 - FIRE SUPPRESSION

21 13 16.00 20 DRY-PIPE FIRE SPRINKLER SYSTEMS

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 41 00 LIGHTNING PROTECTION SYSTEM

26 51 00 INTERIOR LIGHTING

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 31 76 INTERIOR FIRE ALARM

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID

PAVEMENTS

32 11 23 AGGREGATE BASE COURSES

32 13 11 CONCRETE PAVEMENT FOR AIRFIELDS AND OTHER HEAVY-DUTY

PAVEMENTS

-- End of Project Table of Contents --

Goodfellow AFB Structural Dry Trainer

SECTION 01 00 00.00 44

CONSTRUCTION SCHEDULE

PART 1 GENERAL

1.1 SCHEDULE

Commence, prosecute, and complete the work under this contract in accordance with the following schedule and Section 00 72 00 CONTRACT CLAUSES COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK and LIQUIDATED

DAMAGES:

Item of Work Commencement of Work

(Calendar days)

Completion of Work

(Calendar days)

Liquidated Damages per calendar days

(1) All work, including O&M Manuals and Final Record Drawings Goodfellow AFB Structural Burn Dry Trainer.

See NTP. 365 See Solicitation clause 52.211-12

NOTE: All work on this project shall be completed within the number of calender days stated in Item of Work (1) above, inclusive of all review periods and Government phasing requirements specified. The liquidated damages stated above will be applied for each calendar day the Contractor exceeds the Contract scheduled duration.

** Operation and Maintenance Manuals: See Section 01 78 00 CLOSEOUT

SECTION 01 00 00.00 44 Page 1

SECTION 01 00 00.00 44 Page 2

SUBMITTALS, paragraph OPERATION AND MAINTENANCE MANUALS for requirements and 00 11 00 CLIN Schedule for withholding amount to ensure completion of O&M Manuals.

*** Record Drawings: See Section 01 78 00 CLOSEOUT SUBMITTALS, paragraph titled RECORD DRAWINGS for requirements and 00 11 00 CLIN Schedule for withholding amount to ensure completion of record drawings.

1.1.1 Testing of Heating and Air-Conditioning Systems

The times stated for completion of this project includes all required testing specified in appropriate specification sections of heating, air conditioning and ventilation systems including HVAC Commissioning.

Exception: boiler combustion efficiency test, boiler full load tests, cooling tower performance tests, and refrigeration equipment full load tests, when specified in the applicable specifications, shall be performed in the appropriate heating/cooling season as determined by the Contracting Officer.

1.2 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (OCT 1989)

(ER 415-1-15)(52.0001-4038 1/96)

a. This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the contract clause FAR 52.249-10 entitled "DEFAULT: (FIXED PRICE CONSTRUCTION)." In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

b. The following schedule of monthly anticipated adverse weather delays due to precipitation and temperature is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations.

The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. Wind is not considered in the Monthly Anticipated Adverse Weather Calendar Day Schedule.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

SAN ANGELO, TX AREA (GOODFELLOW AFB AND O.C. FISHER LAKE)

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

2 3 1 1 4 3 1 2 3 2 1 2

c. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day.

SECTION 01 00 00.00 44 Page 3

d. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph "b", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled "Default (Fixed Price Construction)."

1.3 CONSTRUCTION PHASING

1.4 WORK RESTRICTIONS

1.4.1 Working Hours

Normal working hours are Monday through Friday, 0730 to 1630 hours, unless otherwise indicated at the preconstruction conference. Requests to work at times other than the stated working hours, including scheduled utility outages discussed below, shall be submitted to the Contracting Officer for approval. Contractor shall not work outside of the above stated working hours without prior written approval of the Contracting Officer received by COB on the Wednesday prior to the weekend worked to the COR and QAR by email..

1.4.2 Security Requirements

1.4.2.1 Installation Entrance Requirements

Entrance requirements to the Installation are specified in Section 01 35

16.1 44 SPECIAL PROJECT PROCEDURES FOR GOODFELLOW AIR FORCE BASE.

For the duration of this Contract, access to Goodfellow AFB will be delayed between 5 minutes to 30 minutes or more due to increased security precautions, including the checking of vehicle occupants' IDs, vehicle manifests, and the searching of all vehicles. Any general or specific threat to the safety of those working or living at the Installation could result in longer waiting times at the access points to the Installation.

The following are the minimum requirements for contractor employees entering Goodfellow AFB:

a. One form of picture ID.

b. A memo from the construction company on their letterhead stating the reason for entry, contract number, and the location at Goodfellow AFB where the jobsite is located.

c. All delivery trucks must have a bill of lading and delivery truck drivers must have a picture ID.

1.4.3 Identification of Employees

The Contractor shall be responsible for furnishing to each employee, and for requiring each employee engaged on the work to display, identification as approved and directed by the Contracting Officer. Prescribed identification shall immediately be delivered to the Contracting Officer for cancellation upon release of any employee. When required, the

SECTION 01 00 00.00 44 Page 4

Contractor shall obtain and provide fingerprints of persons employed on the project. Contractor and subcontractor personnel shall wear identifying markings on hard hats clearly identifying the company for whom the employee works.

Contractor personnel shall wear visible Contractor-furnished employee identification badges while physically on the Installation. Each badge shall include, as a minimum, the company name, employee name, photograph, Contract Title, Contract Number, and the expiration date of the badge.

1.4.4 Anti-Terrorism Site Security

The Contractor shall restrict access to the worksite by posting a flagman at all open gates to restrict access. Such flagman shall have radio or telephone communications with suitable law enforcement agencies to immediately report any illegal trespassing activities. All gates without a flagman shall be locked at all time with high strength chain and locks.

All Contractor employees shall have a completed local law enforcement background verification completed before they may enter Government property.

1.5 UTILITIES

1.5.1 Payment for Utility Services

Utility availability and Payment For Utility Services are specified in Section 01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROL.

1.5.2 Coordination

For Contractor Telephone And Internet Service, the Contractor shall coordinate with ITBC and the local phone company for contractor telephone and internet service during construction.

1.5.3 Outages

The Contractor shall coordinate all requests for utility outages with the Contracting Officer in writing 14 days prior to date of requested outage:

1.6 PAPERLESS CONTRACT SUBMISSION

a. GENERAL INFORMATION ON PAPERLESS CONTRACT SUBMISSION

The goal is to reduce waste, decrease time, decrease associated costs, and to streamline most file transmission procedures.

b. METHODS OF DIGITAL SUBMISSION

This contract shall use digital submission methods to the greatest extent practicable. Acceptable methods are as follows, in order of precedence:

1. QCS/RMS - will be used to the greatest extent practicable. Some items may not be submittable via QCS/RMS due to program constraints. Those items shall use an alternate method. All ENGR 4025’s shall be generated and submitted in QCS.

SECTION 01 00 00.00 44 Page 5

2. Secure, Password Protected Web-Based System Access must be allowed and approved by the Government Representative. Access must be allowed and approved by the Government Representative. This method shall not be used for security sensitive documents.

3. E-mail – Items not submitted via QCS/RMS, as discussed above, shall be submitted via e-mail, if possible. E-mail limitations for file size must be considered prior to submission. Under current conditions, 5 megabytes is the limitation for any single file/e-mail.

4. CD/DVD – Will be accepted if no other method is possible and upon prior approval.

c. ITEMS TO BE SUBMITTED VIA HARDCOPY

Product samples, color boards, and any other item not feasible to submit digitally, shall be submitted hard copy. ENGR 4025 shall be submitted digitally always. The Government reserves the right to request hard copy submission on any item, if deemed necessary.

Contractor shall be prepared to provide requested hard copy at any time.

1.7 CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201 (Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract. The United States Army US Air Force(USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $100,000.00, the USACE will evaluate contractor’s performance and prepare a performance report using the Contractor Performance Assessment Reporting System (CPARS), which is now a web-based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 30 days. Accessing and using CPARS requires specific software, called PKI certification, which is installed on the user’s computer. The certification is a Department of Defense requirement and was implemented to provide security in electronic transactions. The certification software could cost approximately $110 - $125 per certificate per year and is purchased from an External Certificate Authorities (ECA) vendor. Current information about the PKI certification process and for contacting vendors can be found on the web site: http://www.cpars.csd.disa.mil/. If the Contractor wishes to participate in the performance evaluation process, access to CPARS and PKI certification is the sole responsibility of the Contractor.

1.8 CONTRACTOR PAYROLL RECORD

Contractor shall be required to log payrolls for all their own employees and subcontractors utilizing ENG Form 3180. Each subcontractor requires a separate ENG 3180 for their payrolls. The Contractor shall maintain the ENG 3180, along with the payrolls, on site and available for review by the Contracting Officer's Representative. The ENG 3180's shall be updated weekly as payrolls are submitted. After making copies for their files, the Contractor is required to submit the originals of each week’s payrolls to the Resident Office. Before final payment, the Contractor shall provide the completed ENG 3180’s to the Contracting Officer's Representatives.

SECTION 01 00 00.00 44 Page 6

1.9 (S-102) CONTRACTOR SUPPLY and USE OF ELECTRONIC SOFTWARE FOR PROCESSING DAVIS-BACON ACT CERTIFIED LABOR PAYROLLS (April 2011)

The contractor is required to use a commercially-available electronic system to process and submit certified payrolls electronically to the Government. The requirements for preparing, processing and providing certified labor payrolls are established by the Davis-Bacon Act as stated in FAR 52.222-8, PAYROLLS AND BASIC RECORDS and FAR 52.222-13, COMPLIANCE

WITH DAVIS-BACON AND RELATED ACT REGULATIONS.

If the contractor elects to use an electronic payroll processing system, then the contractor shall be responsible for obtaining and providing for all access, licenses, and other services required to provide for receipt, processing, certifying, electronically transmitting to the Government, and storing weekly payrolls and other data required for the contractor to comply with Davis-Bacon and related Act regulations. When the contractor uses an electronic Davis-Bacon payroll system, the electronic payroll service shall be used by the contractor to prepare, process, and maintain the relevant payrolls and basic records during all work under this construction contract and the electronic payroll service shall be capable of preserving these payrolls and related basic records for the required 3 years after contract completion. The contractor shall obtain and provide electronic system access to the Government, as required to comply with the Davis-Bacon and related Act regulations over the duration of this construction contract. The access shall include electronic review access by the Government contract administration office to the electronic payroll processing system used by the contractor.

The contractor's provision and use of an electronic payroll processing system shall meet the following basic functional criteria: commercially available; compliant with appropriate Davis Bacon Act payroll provisions in the FAR; able to accommodate the required numbers of employees and subcontractors planned to be employed under the contract; demonstrated security of data and data entry rights; ability to produce contractor-certified electronic versions of weekly payroll data; ability to identify erroneous entries and track the data/time of all versions of the certified Davis Bacon payrolls submitted to the government over the life of the contract; capable of generating a durable record copy, that is, a CD or DVD and PDF file record of data from the system database at end of the contract closeout. This durable record copy of data from the electronic Davis-Bacon payroll processing system shall be provided to the Government during contract closeout.

All contractor-incurred costs related to the contractor's provision and use of an electronic payroll processing service shall be included in the contractor's price for the overall work under the contract. The costs for Davis-Bacon Act compliance using electronic payroll processing services shall not be a separately bid/proposed or reimbursed item under this contract.

1.10 ADDITIONAL CONTRACTOR PAYROLL RECORD

(1) Reference the Special Contract Requirement (S-102) CONTRACTOR SUPPLY

AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING DAVIS-BACON ACT CERTIFIED

LABOR PAYROLLS. The Fort Worth District encourages the contractor and all sub-contractors to use an electronic payroll system meeting the requirements of S-102 and the following requirements.

SECTION 01 00 00.00 44 Page 7

(a) The Certified Labor Payrolls must be tracked electronically via WEB-based software and all data must be submitted via WEB. Payroll guidelines,"Instructions to Contractors on Contract Labor Requirements, published as "Appendix A, SWFP 1185-1-1" (also known as the Green book), will be provided to advise/inform contractors how these labor provisions will be administered and enforced.

(b) The WEB-based software must be capable of downloading data directly from existing electronic payrolls, track workers to ensure that overtime is being paid when overtime status is reached on Government contracts whether on one or multiple contracts or different sub-contractors. The software must track apprentices and journeyman ratios, create and track SF-1444 "Request for Authorization of Additional Classification and Rate", track workers by name/address/with or without Social Security Numbers, allow automated redaction of information appearing on payroll statements for agency response to Freedom of Information Act (FOIA requests), and provide free online training by the software provider to any user of the software.

(c) The software must allow fringe benefit statement to track fringe benefits "whether cash or into an approved plan, fund, or program. If the fringe benefits are paid into a plan, fund, or program the company's name (receiving benefits), phone number, and address shall be listed on the Statement of Compliance Form (DD Form 879 or WH-347).

(d) Software must provide a method of tracking standard and non-standard deductions such as restitution, alimony, child support, and allow for custom entries. Method of tracking must list the deductions on the statement of compliance or be listed as an attachment.

(e) The Contractor is required to provide the updated 3080's and notify the Contracting Officer's Representatives weekly by email when the current payrolls are complete and ready for inspection/review on the WEB. Before final payment, the Contractor shall provide the completed ENG For 3180's and 3 disks (CD/DVD) which include complete copies of the Contractor and sub-contractor's payrolls/attachments, to the Contracting Officer's Representatives.

(2) Electronic copies of electronically/manually signed forms/memos/letters such as SF 1413 Statement of Acknowledgement (sub-contractor agreement), SF-1444 "Request for Authorization of Additional Classification and Rate", employee deduction authorization, certification of apprentices and trainees shall be provided to the Contracting Officer's Representative as required by FAR.

1.11 STREET CLOSINGS

Street closure requirements are specified in Section 01 35 16.00 44 SPECIAL

PROJECT PROCEDURES FOR GOODFELLOW AIR FORCE BASE.

1.12 Veterans Employment Emphasis for U.S. Army US Air ForceContracts

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS

222.13 and Department of Labor regulations, U.S. Army US Air Force(USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, SECTION 01 00 00.00 44 Page 8

USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

Federal Veteran employment information at http://www.fedshirevets.gov/index.aspx Department of Labor Veterans Employment Assistance http://www.dol.gov/vets/ Department of Veteran Affairs - VOW to Hire Heroes Act http://benefits.va.gov/vow Army Wounded Warrior Program -http://wtc.army.mil/modules/employers/index.html U.S. Chamber of Commerce Foundation - Hiring Our Heroes http://www.hiringourheroes.org/

PART 2 PRODUCTS (NOT USED)

PART 3 EXECUTION (NOT USED)

-- End of Section --

SECTION 01 31 19.00 44 Page 1

SECTION 01 31 19.00 44

PROJECT MEETINGS

1.1 PRECONSTRUCTION CONFERENCE

Approximately three weeks after award of the contract and prior to the start of any construction work an authorized representative of the Contracting Officer will schedule and conduct a preconstruction conference.

The Contractor's Project Manager, Superintendent, and Quality Control Manager will attend this meeting. The Contractor is encouraged to have an officer of his company and representation from his sub-contractors at this conference. This conference will be held at the location specified by the Contracting Officer's authorized representative. Minutes of the meeting will be prepared by the Government and signed by both the Contractor and the Contracting Officer. The minutes shall become a part of the contract file.

1.1.1 Start of Construction Work

If the Contractor has submitted the Accident Prevention (Safety) Plan, Quality Control Plan, Environmental Protection Plan, and the Storm Water Pollution Prevention Plan for review prior to this meeting, these may be accepted in to or accepted with comments at the conference. Construction work will not proceed until after this meeting has been held, the plans noted above have been accepted, and the Notice to Proceed has been received and acknowledged by the Contractor.

1.2 OTHER MEETINGS

Construction Quality Control meetings and conferences are specified in Section 01 45 00.00 10 QUALITY CONTROL. Other meetings are specified in various Division 1 and technical sections.

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

SECTION 01 32 01.00 10 Page 10

SECTION 01 33 00 Page 1

SECTION 01 33 00

SUBMITTAL PROCEDURES

1.1 SUMMARY

The Contracting Officer may request submittals in addition to those specified when deemed necessary to adequately describe the work covered in the respective sections.

Units of weights and measures used on all submittals are to be the same as those used in the contract drawings.

Each submittal is to be complete and in sufficient detail to allow ready determination of compliance with contract requirements.

Contractor's Quality Control (CQC) System Manager and the Designer of Record, if applicable, to check and approve all items prior to submittal and stamp, sign, and date indicating action taken. Proposed deviations from the contract requirements are to be clearly identified. Include within submittals items such as: Contractor's, manufacturer's, or fabricator's drawings; descriptive literature including (but not limited

to) catalog cuts, diagrams, operating charts or curves; test reports; test cylinders; samples; O&M manuals (including parts list); certifications;

warranties; and other such required submittals.

Submittals requiring Government approval are to be scheduled and made prior to the acquisition of the material or equipment covered thereby. Pick up and dispose of samples not incorporated into the work in accordance with manufacturer's Material Safety Data Sheets (MSDS) and in compliance with existing laws and regulations.

A submittal register showing items of equipment and materials for when submittals are required by the specifications is provided as "Appendix A - Submittal Register".

1.2 DEFINITIONS

1.2.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by Submittal Description (SD) numbers and titles as follows:

SD-01 Preconstruction Submittals

Submittals which are required prior to the start of the next major phase of the construction on a multi-phase contract, includes schedules, tabular list of data, or tabular list including location, features, or other pertinent information regarding products, materials, equipment, or components to be used in the work.

Certificates of insurance

Surety bonds

SECTION 01 33 00 Page 2

List of proposed Subcontractors

List of proposed products

Construction progress schedule

Accident Prevention Plan

Submittal register

Schedule of prices or Earned Value Report

Health and safety plan

Work plan

Quality Control(QC) plan

Environmental protection plan

AF Form 103 Base Civil

Engineer Work Clearance

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. Unless specified in another section, testing must have been within three years of date of contract award for the project.

Report which includes findings of a test required to be performed by the Contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports.

Daily logs and checklists.

Final acceptance test and operational test procedure.

SECTION 01 33 00 Page 3

SD-07 Certificates

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material

SECTION 01 33 00 Page 4 attesting that the product, system, or material meets specification requirements. Must be dated after award of project contract and clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor. The document purpose is to further promote the orderly progression of a portion of the work by documenting procedures, acceptability of methods, or personnel qualifications.

Confined space entry permits.

Text of posted operating instructions.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Submittals required for Guiding Principle Validation (GPV) or Third Party Certification (TPC).

Special requirements necessary to properly close out a construction contract. For example, Record Drawings and as-built drawings. Also, submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

1.2.2 Approving Authority

Office or designated person authorized to approve submittal.

1.2.3 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce submittals, except those SD-01 Pre-Construction Submittals noted above, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with this section.

SD-01 Preconstruction Submittals

Submittal Register; G

1.4 SUBMITTAL CLASSIFICATION

Submittals are classified as follows:

1.4.1 Government Approved (G)

Government approval is required for extensions of design, critical materials, deviations, equipment whose compatibility with the entire system

SECTION 01 33 00 Page 5 must be checked, and other items as designated by the Contracting Officer.

Within the terms of the Contract Clause SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION, they are considered to be "shop drawings."

1.5 PREPARATION

1.5.1 Transmittal Form

Use the attached sample transmittal form in Appendix B ENG Form 4025-R for submitting both Government approved and information only submittals in accordance with the instructions on the reverse side of the form. These forms are included in the QCS software that the Contractor is required to use for this contract. Properly complete this form by filling out all the heading blank spaces and identifying each item submitted. Exercise special care to ensure proper listing of the specification paragraph and sheet number of the contract drawings pertinent to the data submitted for each item.

1.5.2 Source Drawings for Shop Drawings

The entire set of Source Drawing files (DWG) will not be provided to the Contractor. Only those requested by the Contractor to prepare shop drawings may be provided. Request the specific Drawing Number only for the preparation of Shop Drawings. These drawings may only be provided after award.

1.5.2.1 Terms and Conditions

Data contained on these electronic files must not be used for any purpose other than as a convenience in the preparation of construction data for the referenced project. Any other use or reuse shall be at the sole risk of the Contractor and without liability or legal exposure to the Government.

The Contractor must make no claim and waives to the fullest extent permitted by law, any claim or cause of action of any nature against the Government, its agents or sub consultants that may arise out of or in connection with the use of these electronic files. The Contractor must, to the fullest extent permitted by law, indemnify and hold the Government harmless against all damages, liabilities or costs, including reasonable attorney's fees and defense costs, arising out of or resulting from the use of these electronic files.

These electronic Source Drawing files are not construction documents.

Differences may exist between the Source Drawing files and the corresponding construction documents. The Government makes no representation regarding the accuracy or completeness of the electronic Source Drawing files, nor does it make representation to the compatibility of these files with the Contractor hardware or software. In the event that a conflict arises between the signed and sealed construction documents prepared by the Government and the furnished Source Drawing files, the signed and sealed construction documents govern. The Contractor is responsible for determining if any conflict exists. Use of these Source Drawing files does not relieve the Contractor of duty to fully comply with the contract documents, including and without limitation, the need to check, confirm and coordinate the work of all contractors for the project.

If the Contractor uses, duplicates or modifies these electronic Source Drawing files for use in producing construction data related to this contract, remove all previous indicia of ownership (seals, logos, signatures, initials and dates).

SECTION 01 33 00 Page 6

1.5.3 Electronic File Format

Provide submittals in electronic format, with the exception of material samples required for SD-04 Samples items. In addition to the electronic submittal, provide three hard copies of the submittals. Compile the submittal file as a single, complete document, to include the Transmittal Form described within. Name the electronic submittal file specifically according to its contents, coordinate the file naming convention with the Contracting Officer. Electronic files must be of sufficient quality that all information is legible. Use PDF as the electronic format, unless otherwise specified or directed by the Contracting Officer. Generate PDF files from original documents with bookmarks so that the text included in the PDF file is both searchable and can be copied. If documents are scanned, Optical Character Resolution (OCR) routines are required. Index and bookmark files exceeding 30 pages to allow efficient navigation of the file. When required, the electronic file must include a valid electronic signature, or scan of a signature.

Email electronic submittal documents fewer than 10MB to an email address as directed by the Contracting Officer. Provide electronic documents over 10MB on an optical disc, or through an electronic file sharing system such as the AMRDEC SAFE Web Application located at the following website:

https://safe.amrdec.army.mil/safe/.

Provide hard copies of submittals when requested by the Contracting Officer. Up to three additional hard copies of any submittal may be requested at the discretion of the Contracting Officer, at no additional cost to the Government.

1.6 QUANTITY OF SUBMITTALS

1.6.1 Number of Copies of SD-02 Shop Drawings

Submit six copies of submittals of shop drawings requiring review and approval only by QC organization and seven copies of shop drawings requiring review and approval by Contracting Officer.

1.6.2 Number of Copies of SD-03 Product Data and SD-08 Manufacturer's Instructions

Submit in compliance with quantity requirements specified for shop drawings.

1.6.3 Number of Samples SD-04 Samples

a. Submit two samples, or two sets of samples showing range of variation, of each required item. One approved sample or set of samples will be retained by approving authority and one will be returned to Contractor.

b. Submit one sample panel or provide one sample installation where directed. Include components listed in technical section or as directed.

c. Submit one sample installation, where directed.

d. Submit one sample of non-solid materials.

1.6.4 Number of Copies SD-05 Design Data and SD-07 Certificates

Submit in compliance with quantity requirements specified for shop drawings.

SECTION 01 33 00 Page 7

1.6.5 Number of Copies SD-06 Test Reports and SD-09 Manufacturer's Field Reports

Submit in compliance with quantity and quality requirements specified for shop drawings other than field test results that will be submitted with QC reports.

1.6.6 Number of Copies of SD-10 Operation and Maintenance Data

Submit three copies of O&M Data to the Contracting Officer for review and approval.

1.6.7 Number of Copies of SD-01 Preconstruction Submittals and SD-11 Closeout Submittals

Unless otherwise specified, submit two sets of administrative submittals.

1.7 INFORMATION ONLY SUBMITTALS

Normally submittals for information only will not be returned. Approval of the Contracting Officer is not required on information only submittals.

The Government reserves the right to require the Contractor to resubmit any item found not to comply with the contract. This does not relieve the Contractor from the obligation to furnish material conforming to the plans and specifications; will not prevent the Contracting Officer from requiring removal and replacement of nonconforming material incorporated in the work;

and does not relieve the Contractor of the requirement to furnish samples for testing by the Government laboratory or for check testing by the Government in those instances where the technical specifications so prescribe.

1.8 SUBMITTAL REGISTER

Prepare and maintain submittal register, as the work progresses. Do not change data which is output in columns (c), (d), (e), and (f) as delivered by Government; retain data which is output in columns (a), (g), (h), and

(i) as approved. A submittal register showing items of equipment and materials for which submittals are required by the specifications is provided as an attachment. This list may not be all inclusive and additional submittals may be required. Maintain a submittal register for the project in accordance with Section 01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)). The Government will provide the initial submittal register in electronic format with the following fields completed, to the extent that will be required by the Government during subsequent usage.

Column (c): Lists specification section in which submittal is required.

Column (d): Lists each submittal description (SD No. and type, e.g. SD-02 Shop Drawings) required in each specification section.

Column (e): Lists one principal paragraph in specification section where a material or product is specified. This listing is only to facilitate locating submitted requirements. Do not consider entries in column (e) as limiting project requirements.

Thereafter, the Contractor is to track all submittals by maintaining a

SECTION 01 33 00 Page 8 complete list, including completion of all data columns, including dates on which submittals are received and returned by the Government.

1.8.1 Use of Submittal Register

Submit submittal register. Submit with QC plan and project schedule.

Verify that all submittals required for project are listed and add missing submittals. Coordinate and complete the following fields on the register submitted with the QC plan and the project schedule:

Column (a) Activity Number: Activity number from the project schedule.

Column (g) Contractor Submit Date: Scheduled date for approving authority to receive submittals.

Column (h) Contractor Approval Date: Date Contractor needs approval of submittal.

Column (i) Contractor Material: Date that Contractor needs material delivered to Contractor control.

1.8.2 Contractor Use of Submittal Register

Update the following fields in the Government-furnished submittal register program or equivalent fields in program utilized by Contractor with each submittal throughout contract.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (j) Action Code (k): Date of action used to record Contractor's review when forwarding submittals to QC.

Column (l) List date of submittal transmission.

Column (q) List date approval received.

1.8.3 Approving Authority Use of Submittal Register

Update the following fields in the Government-furnished submittal register program or equivalent fields in program utilized by Contractor.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (l) List date of submittal receipt.

Column (m) through (p) List Date related to review actions.

Column (q) List date returned to Contractor.

1.8.4 Government Review Action Codes

Entries for columns (j) and (o), are to be used as follows (others may be prescribed by Transmittal Form):

SECTION 01 33 00 Page 9

"A" - "Approved as submitted"; "Completed"

"B" - "Approved, except as noted on drawings"; "Completed"

"C" - "Approved, except as noted on drawings; resubmission required"; "Resubmit"

"D" - "Returned by separate correspondence"; "Completed"

"E" - "Disapproved (See attached)"; "Resubmit"

"F" - "Receipt acknowledged"; "Completed"

"G" - "Other (Specify)"; "Resubmit"

"X" - "Receipt acknowledged, does not comply with contract requirements"; "Resubmit"

1.8.5 Copies Delivered to the Government

Deliver one copy of submittal register updated by Contractor to Government with each invoice request.

1.9 VARIATIONS

Variations from contract requirements require both Designer of Record (DOR) and Government approval pursuant to contract Clause FAR 52.236-21 and will be considered where advantageous to Government.

1.9.1 Considering Variations

Discussion with Contracting Officer prior to submission, after consulting with the DOR, will help ensure functional and quality requirements are met and minimize rejections and re-submittals. When contemplating a variation which results in lower cost, consider submission of the variation as a Value Engineering Change Proposal (VECP).

Specifically point out variations from contract requirements in transmittal letters. Failure to point out deviations may result in the Government requiring rejection and removal of such work at no additional cost to the Government.

1.9.2 Proposing Variations

When proposing variation, deliver written request to the Contracting Officer, with documentation of the nature and features of the variation and why the variation is desirable and beneficial to Government, including the DOR's written analysis and approval. If lower cost is a benefit, also include an estimate of the cost savings. In addition to documentation required for variation, include the submittals required for the item.

Clearly mark the proposed variation in all documentation.

Check the column "variation" of ENG Form 4025 for submittals which include proposed deviations requested by the Contractor. Set forth in writing the reason for any deviations and annotate such deviations on the submittal.

The Government reserves the right to rescind inadvertent approval of submittals containing unnoted deviations.

SECTION 01 33 00 Page 10

1.9.3 Warranting that Variations are Compatible

When delivering a variation for approval, Contractor, including its Designer(s) of Record, warrants that this contract has been reviewed to establish that the variation, if incorporated, will be compatible with other elements of work.

1.9.4 Review Schedule Extension

In addition to normal submittal review period, a period of 10 working days will be allowed for consideration by the Government of submittals with variations.

1.10 SCHEDULING

Schedule and submit concurrently submittals covering component items forming a system or items that are interrelated. Include certifications to be submitted with the pertinent drawings at the same time. No delay damages or time extensions will be allowed for time lost in late submittals. An additional seven calendar days will be allowed and shown on the register for review and approval of submittals for refrigeration and HVAC control systems.

a. Coordinate scheduling, sequencing, preparing and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow for potential resubmittal of requirements.

b. Submittals called for by the contract documents will be listed on the register. If a submittal is called for but does not pertain to the contract work, the Contractor is to include the submittal in the register and annotate it "N/A" with a brief explanation. Approval by the Contracting Officer does not relieve the Contractor of supplying submittals required by the contract documents but which have been omitted from the register or marked "N/A."

c. Re-submit register and annotate monthly by the Contractor with actual submission and approval dates. When all items on the register have been fully approved, no further re-submittal is required.

d. Carefully control procurement operations to ensure that each individual submittal is made on or before the Contractor scheduled submittal date shown on the approved "Submittal Register."

1.11 GOVERNMENT APPROVING AUTHORITY

When approving authority is Contracting Officer, the Government will:

a. Note date on which submittal was received.

b. Review submittals for approval within scheduling period specified and only for conformance with project design concepts and compliance with contract documents.

c. Identify returned submittals with one of the actions defined in paragraph REVIEW NOTATIONS and with markings appropriate for action indicated.

Upon completion of review of submittals requiring Government approval, stamp and date submittals. One copy of the submittal will be retained by the Contracting Officer

SECTION 01 33 00 Page 11

1.11.1 Review Notations

Contracting Officer review will be completed within seven calendar days after date of submission. Submittals will be returned to the Contractor with the following notations:

a. Submittals marked "approved" or "accepted" authorize the Contractor to proceed with the work covered.

b. Submittals marked "approved as noted" or "approved, except as noted, resubmittal not required," authorize the Contractor to proceed with the work covered provided he takes no exception to the corrections.

c. Submittals marked "not approved" or "disapproved," or "revise and resubmit," indicate noncompliance with the contract requirements or design concept, or that submittal is incomplete. Resubmit with appropriate changes. No work shall proceed for this item until resubmittal is approved.

d. Submittals marked "not reviewed" will indicate submittal has been previously reviewed and approved, is not required, does not have evidence of being reviewed and approved by Contractor, or is not complete. A submittal marked "not reviewed" will be returned with an explanation of the reason it is not reviewed. Resubmit submittals returned for lack of review by Contractor or for being incomplete, with appropriate action, coordination, or change.

1.12 DISAPPROVED OR REJECTED SUBMITTALS

Make corrections required by the Contracting Officer. If the Contractor considers any correction or notation on the returned submittals to constitute a change to the contract drawings or specifications; notice as required under the FAR clause entitled CHANGES, is to be given to the Contracting Officer. Contractor is responsible for the dimensions and design of connection details and construction of work. Failure to point out deviations may result in the Government requiring rejection and removal of such work at the Contractor's expense.

If changes are necessary to submittals, make such revisions and submission of the submittals in accordance with the procedures above. No item of work requiring a submittal change is to be accomplished until the changed submittals are approved.

1.13 APPROVED/ACCEPTED SUBMITTALS

The Contracting Officer's approval or acceptance of submittals is not to be construed as a complete check, and indicates only that the general method of construction, materials, detailing and other information are satisfactory.

Approval or acceptance will not relieve the Contractor of the responsibility for any error which may exist, as the Contractor under the Contractor Quality Control (CQC) requirements of this contract is responsible for dimensions, the design of adequate connections and details, and the satisfactory construction of all work.

After submittals have been approved or accepted by the Contracting Officer, no resubmittal for the purpose of substituting materials or equipment will

SECTION 01 33 00 Page 12 be considered unless accompanied by an explanation of why a substitution is necessary.

1.14 APPROVED SAMPLES

Approval of a sample is only for the characteristics or use named in such approval and is not be construed to change or modify any contract requirements. Before submitting samples, the Contractor to assure that the materials or equipment will be available in quantities required in the project. No change or substitution will be permitted after a sample has been approved.

Match the approved samples for materials and equipment incorporated in the work. If requested, approved samples, including those which may be damaged in testing, will be returned to the Contractor, at his expense, upon completion of the contract. Samples not approved will also be returned to the Contractor at its expense, if so requested.

Failure of any materials to pass the specified tests will be sufficient cause for refusal to consider, under this contract, any further samples of the same brand or make of that material. Government reserves the right to disapprove any material or equipment which previously has proved unsatisfactory in service.

Samples of various materials or equipment delivered on the site or in place may be taken by the Contracting Officer for testing. Samples failing to meet contract requirements will automatically void previous approvals.

Contractor to replace such materials or equipment to meet contract requirements.

Approval of the Contractor's samples by the Contracting Officer does not relieve the Contractor of his responsibilities under the contract.

1.15 WITHHOLDING OF PAYMENT

Payment for materials incorporated in the work will not be made if required approvals have not been obtained.

1.16 STAMPS

Stamps used by the Contractor on the submittal data to certify that the submittal meets contract requirements is to be similar to the following:

SECTION 01 33 00 Page 13

| CONTRACTOR |

| (Firm Name) | | Approved | | Approved with corrections as noted on submittal data and/or |…