Attach_2_-_DBEH_17-1612_ELEC_REDUND_-_100__Specs.pdf

AA 0002809

PROJECT SPECIFICATIONS

DBEH 17-1612, Repair Electrical

Redundancy System, CCAFS HQ 85125

Cape Canaveral Air Force Station

6/27/2019

100% Design Submittal

Contract Number FA2521-18-D-0002

Prime Consultant:

Rhodes+Brito Architects

605 E. Robinson Street, Suite 750 Orlando, FL 32801

Sub-Consultants:

Nelson Engineering Co.

5455 N Courtenay Pkwy Merritt Island, FL 32953

DBEH 17-1612, Repair Electrical Redundancy DBEH 17-1612

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00.00 30 SUMMARY OF WORK

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 03 - CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

DIVISION 26 - ELECTRICAL

26 05 00.00 40 COMMON WORK RESULTS FOR ELECTRICAL

26 05 13.00 40 MEDIUM-VOLTAGE CABLES

26 05 26.00 40 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS

26 12 19.00 40 PAD-MOUNTED, LIQUID-FILLED, MEDIUM-VOLTAGE TRANSFORMERS

26 32 15.00 10 DIESEL-GENERATOR SET STATIONARY 100-2500 KW, WITH

AUXILIARIES

26 36 00.00 10 AUTOMATIC TRANSFER SWITCH AND BY-PASS/ISOLATION SWITCH

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1 6/27/2019

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00.00 30

SUMMARY OF WORK

10/14

PART 1 GENERAL

1.1 SUMMARY

1.2 PROJECT DESCRIPTION

1.2.1 Civil/Site

1.2.2 Electrical

1.3 REFERENCES

1.4 SUBMITTALS

1.5 CONTRACT DRAWINGS

1.5.1 Layout of Work and Elevations

1.6 WORK SCHEDULING

1.6.1 Requirements

1.7 OCCUPANCY OF PREMISES/ACCESS REQUIREMENTS

1.7.1 Area Contents

1.7.1.1 Responsibilities

1.7.1.2 Maintain Clean Work Areas

1.7.1.3 Damage To Existing Equipment

1.7.1.4 New Material and Construction Equipment

1.7.2 Construction Area Access And Control

1.7.2.1 Access and Control Requirements

1.7.3 Vehicle Parking

1.7.3.1 Requirements

1.8 STORAGE, TRANSPORTATION AND PROTECTION

1.8.1 Storage

1.8.2 Protection

1.8.3 Transportation

1.8.4 Hazardous Materials

1.8.5 Site Protection Plan

1.9 GOVERNMENT-FURNISHED EQUIPMENT - None

1.10 ON-SITE PERMITS

1.10.1 Utility Outage Requests And Connection Requests

1.10.1.1 Requirements

1.10.2 Protection of Work

1.10.3 Burn Permits

1.11 SALVAGE AND DISPOSAL OF MATERIAL AND EQUIPMENT

1.11.1 Removal

1.11.2 Housekeeping

1.11.3 Salvage of Material And Equipment

1.11.3.1 Salvage Items - None

1.11.4 Waste Disposal

1.11.5 Cleanup

1.11.6 Salvage And Disposal Record Keeping

1.12 RADIO FREQUENCY MANAGEMENT PROCEDURES

1.13 COMMUNICATION SECURITY

PART 2 PRODUCTS

SECTION 01 11 00.00 30 Page 1

PART 3 EXECUTION

3.1 ACCESS REQUIREMENTS

3.1.1 Construction Site Requirement

3.1.2 Air Force Restricted Area Requirements (Black & Blue Restricted

Unescorted Badge)

3.2 CCAFS VEHICLE INSPECTION

3.3 CCAFS DELIVERIES

3.3.1 Non-Hazardous Deliveries

3.3.2 Hazardous Deliveries

3.4 RESPONSIBILITIES

3.5 EXCAVATION

3.5.1 Dig/Utility Locate Permit Requirements

3.5.1.1 Location of Buried Structures and Utility Lines

3.5.1.2 Excavation, Trenching, and Backfilling

3.5.1.3 Cutting of Roads, Streets, Driveways, and Paved Areas

3.5.2 Restrictions

3.5.3 Temporary Shoring, Bracing And Supports

3.5.4 Barricades

3.6 LAND SURVEYING REQUIREMENTS

3.6.1 Contractor Provided Survey Support

3.6.1.1 Horizontal Reference Datum

3.6.1.2 Vertical Reference Datum

3.7 HOISTING AND LIFTING

3.7.1 Lifting Operation Plan

3.8 QUALITY CONTROL

3.8.1 Licenses

3.8.2 Government Inspection/Approval

3.8.3 Inspection Files

3.9 SUPERINTENDENT

3.10 CONSTRUCTION SCHEDULING REQUIREMENTS

3.10.1 Contractor Coordination Meetings

3.10.2 On-Site Construction Sequence

-- End of Section Table of Contents --

SECTION 01 11 00.00 30 Page 2

SECTION 01 11 00.00 30

SUMMARY OF WORK

10/14

PART 1 GENERAL

1.1 SUMMARY

The work to be performed under this project is located at Cape Canaveral Air Force Station. Cape Canaveral Air Force Station is located at the end of State Road 401, north of Port Canaveral.

The work to be performed under this project consists of providing the labor, equipment and materials as indicated in the attached drawing package.

1.2 PROJECT DESCRIPTION

Replace electrical service entrance equipment at Cape Canaveral Air Force Station Headquarters Building 85125 to provide electrical redundancy for entire building.

1.2.1 Civil/Site

New electrical equipment will be located on the exterior north west side of the building. Civil/Site work will include modification of existing concrete pads to support new transformers, automatic transfer switches, generator and associated trenching.

Refer to section 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS for existing environmental conditions.

1.2.2 Electrical

Replace two 13,200 to 480/277 Volts Alternating Current (VAC) pad mounted transformer with two new 750 Kilo Volt Amperes (KVA), 55-75 °C temperature rise, 13,200 to 480/277 VAC A-side and B-side pad mounted transformers.

Reconfigure existing service entrance equipment (switchboards, automatic transfer switches, enclosed circuit breakers, conduit and wiring) to make existing 2,000 Ampere (A) service entrance switchboard 1SWB1 supply the full building load. Install two new 1,200 A service rated enclosed circuit breakers (ECB) for A-side and B-side services. Install two new 1,200 A automatic transfer switches (ATS) and a manual transfer switch (MTS) fed from A-side and B-side service ECBs. Install new 480 VAC exterior underground distribution from new transformers to new service ECBs and ATS.

Install new 480 VAC conductors from new ATS and MTS into the building using the existing underground conduits as to the greatest extent possible.

Replace 1,000 Kilo Watts (kW), 4,160 VAC generator and 4,160 to 480/277 VAC generator transformer with new 600 kW, 480/277 VAC Emergency Generator.

The new generator will provide electrical redundancy for the full load of the building in the event of loss of both A and B side normal services.

New control system, wiring and programming will be required between the generator, ATS and existing switchboard 1SWB1 main circuit breakers to ensure proper sequence of operations and closed transition syncing.

SECTION 01 11 00.00 30 Page 3

1.3 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

45TH SPACE WING (SWI)

45 SWI 31-1 Integrated Defense Plan

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 101 (2018; TIA 18-1; TIA 18-2; TIA 18-3) Life Safety Code

U.S. AIR FORCE (USAF)

AFI 33-580 (2013) Spectrum Management

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910 Occupational Safety and Health Standards

29 CFR 1926 Safety and Health Regulations for Construction

1.4 SUBMITTALS

Contracting Organization approval is required for all submittals. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES in sufficient detail to show full compliance with the specification:

SD-01 Preconstruction Submittals

Submit the following items to the Contracting Officer:

Lifting Operation Plan

Utility Outage Requests

Connection Requests

Air Force Form 3952 (AF 3952), Chemical/Hazardous Material Request Authorization (including all paint)

SOLID WASTE DISPOSAL DIVERSION TRACKING

Premises/Access Plan

Storage Area Request

Phasing Plan

SECTION 01 11 00.00 30 Page 4

Superintendent Contact and Qualifications;G

SD-11 Closeout Submittals

Solid Waste Disposal Diversion Tracking

Contractor Survey Record Drawings

1.5 CONTRACT DRAWINGS

See Drawing Index for list of project drawings.

Contract drawings, maps, and specifications will be furnished to the Contractor either hard copy or electronic at the Government's discretion.

Reference publications will not be furnished.

Contractor shall immediately check furnished drawings and notify the Contracting Officer of any discrepancies.

The drawings indicate the general location and arrangement of existing conditions. Field measurements may be necessary to determine the size and quantity of materials. Conditions which are obvious/visible or which should be reasonably anticipated by the Contractor on inspection will not be considered under the Differing Site Conditions clause of this contract.

1.5.1 Layout of Work and Elevations

Dimensions and elevations indicated in the layout of work shall be verified by the Contractor. Discrepancies between the drawings, specifications and/or existing conditions shall be referred to the Contracting Officer in writing, for review, before the affected work is performed. Failure to make notification shall place the responsibility upon the Contractor to carry out the work in a satisfactory and workmanlike manner.

1.6 WORK SCHEDULING

Work Schedules for all on-site activities must be reviewed and approved by the Contracting Officer prior to start of the project; and all activities coordinated with the Contracting Officer once work has begun. Due to the critical nature of the work location, all work pertaining to this contract shall be completed without disrupting the operation of headquarters building 85125.

Contractor shall allow for non-access days where construction activity is prohibited due to hazardous operations or launch activity. When possible, the Government will provide 24 hour notification each time the restrictions are invoked.

1.6.1 Requirements

Working hours will normally range between the hours of 7:30 AM and 4:00 PM (0730-1600) excluding Saturdays, Sundays and Federal Holidays. If work must be done during periods other than above, additional Government inspection and Range Support personnel may be required. Notification must be given to the Contracting Officer five working days in advance of intention to work during other periods to allow assignment of additional inspection forces when the Contracting Officer determines that they are reasonably available. If such support is reasonably available, the Contracting Officer may authorize work to be performed during periods other

SECTION 01 11 00.00 30 Page 5 than normal duty hours/days. Work beyond normal hours/days may be required for major utility outages. Its is to the government's discretion to request copies of contractor inspection records for periods worked on holidays and weekends (FAR 52.246-12 Inspection of Construction).

No construction work shall take place over the Christmas/New Year holiday period. This period will start one full work day before the Federal Christmas holiday and end the first work day after the Federal New Year Holiday. The Contractor may request to work during this time at the discretion of the Contracting Officer, however no base support will be available.

If night work is required from 1 May to 31 October between 2100 to 0600 hours, a light management plan must be reviewed and approved through the Contracting Officer and 45 CES Environmental (45 CES/CEIE) at least 45 days prior to night work commencement.

1.7 OCCUPANCY OF PREMISES/ACCESS REQUIREMENTS

Building(s) will be occupied during performance of work under this Contract. Occupancy notifications will be posted in a prominent location in the work area. Contractor shall post warning signs in accordance with OSHA requirements.

Before work is started, the Contractor shall submit a Premises/Access Plan to the Contracting Officer or Representative for approval. The plan shall include a sequence of procedures, means of access, space plan for storage of materials and equipment, and use of approaches, corridors, and stairways.

This plan must comply with NFPA 101 requirements that all exits and exit access must be maintained at all times. Base Fire Department is required to approve any deviations which affect the exiting or exit access from the building.

1.7.1 Area Contents

1.7.1.1 Responsibilities

The schedule of work shall be closely coordinated with the Contracting Officer. Unless otherwise stated, all existing utilities and structures in the work area will be protected from damage. All relocated items shall also be protected from damage throughout the construction period. After completion of work and prior to final acceptance, replace removed items in their original location.

Demolition of critical utility and facility systems will be in accordance with phasing specified in attached drawing package and will not be started until replacement equipment is on site, installed, commissioned and accepted by Contracting Organization

1.7.1.2 Maintain Clean Work Areas

All work areas shall be kept clean at all times. Prevent introduction of dirt or dust into areas adjacent to the work areas. All materials, tools and equipment shall be thoroughly cleaned prior to being brought into the work areas or adjacent areas.

SECTION 01 11 00.00 30 Page 6

1.7.1.3 Damage To Existing Equipment

Any damage must be reported to the Contracting Officer immediately. Damage to existing materials, equipments, systems, or properties occurring from Contractor activities or neglect, shall, at the sole discretion of the Contracting Officer, be repaired or replaced by the Contractor at no cost to the Federal Government.

1.7.1.4 New Material and Construction Equipment

Only material and construction equipment designated for performance of contract work may be stored at the construction site or located in Government-controlled warehouses or shop facilities.

1.7.2 Construction Area Access And Control

1.7.2.1 Access and Control Requirements

Exclusive use or control of any area will not be allowed as the Government must have access to all areas at all times. All work must be scheduled around operational constraints.

1.7.3 Vehicle Parking

1.7.3.1 Requirements

Job and support vehicles for workers will be parked in designated parking areas within reasonable access to the worksite. All vehicle operators must comply with all traffic laws including mandatory seat belt usage, speed limits and hauling restrictions. Contractor shall be responsible for repairing or replacing any facility/grounds damaged areas.

1.8 STORAGE, TRANSPORTATION AND PROTECTION

1.8.1 Storage

At Government discretion, Contractor may be assigned a storage area upon submitting written Storage Area Request to the Contracting Officer.

Contractor's Storage Area Request shall indicate dimensions of trailer, size of storage area, and utilities required. All trailers shall be in good and safe condition. Storage space is normally co-located with construction site, at the Contracting Officer's discretion. Storage areas may require fence and screening as required by Government. Contractor shall secure storage areas during inclement weather situation.

1.8.2 Protection

Store and protect products in accordance with manufacturer's instructions.

Store products with seals, labels intact and legible. Store sensitive products in weather tight, climate controlled, enclosures in an environment favorable to the product. Products acceptable for exterior storage shall be on sloped supports above ground. Contractor shall not use swales, drainage ditches, or any other storm water permitted area to store materials or equipment. If swales, drainage ditches or any other storm water permitted areas must be used for storage, Contractor must get special permission from Contracting Officer.

SECTION 01 11 00.00 30 Page 7

1.8.3 Transportation

Transport and handle products in accordance with manufacturer's instructions. Promptly inspect shipments to ensure the products comply with requirements, quantities are correct, and products are undamaged.

Protect products subject to deterioration with impervious sheet covering.

Provide ventilation to prevent condensation and degradation of products.

Store loose granular materials on solid flat surfaces in a well drained area. Prevent mixing with foreign materials.

1.8.4 Hazardous Materials

Submit an Air Force Form 3952 (AF 3952), Chemical/Hazardous Material Request Authorization if hazardous materials & petroleum product will used on site. Hazardous Materials & petroleum product containers shall be stored on an impervious surface with containment. Incompatible materials shall be segregated and have separate containment systems. Additional HAZMAT requirements are provided in Section 01 57 19 TEMPORARY

ENVIRONMENTAL CONTROLS.

1.8.5 Site Protection Plan

Structures, utilities, sidewalks, pavements, and other facilities immediately adjacent to excavations shall be protected against damage.

Contractor shall comply with "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements" and is required to protect areas adjacent to the construction site. In addition to FAR 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.9 GOVERNMENT-FURNISHED EQUIPMENT - None

1.10 ON-SITE PERMITS

1.10.1 Utility Outage Requests And Connection Requests

Work shall be scheduled to hold outages to a minimum.

Utility outages and Connection Requests required during the execution of work that affect existing systems shall be arranged at the convenience of the Government, which may require scheduling outside of the regular working hours or on weekends, at no additional cost to the Government.

Each Utility Outage and Connection Requests shall state the system involved, area involved, approximate duration of outage, and the nature of work involved.

1.10.1.1 Requirements

A written request for a utilities outage (electricity, communication, SECTION 01 11 00.00 30 Page 8 water, compressed air, gas, steam, air conditioning, fire detection and suppression systems, etc.) must be submitted to the Contracting Officer at least 14 calendar days in advance of the desired outage. Approval is required prior to scheduling any outage. All limitations noted on the approved outage authorization shall be carefully observed. A utilities outage without prior approval and coordination is prohibited.

Utility outages affecting fire alarm, fire detection, fire suppression, fire pumps and water supplies to fire protection systems greater than 4 hours will require a fire watch.

Since many systems are critical to facility operations, the number and duration of utility outages shall be kept to an absolute minimum. All work effort shall be coordinated and sufficient manpower, materials, and equipment shall be provided to complete the work within the authorized outage window.

Existing utility services may be interrupted only when approved by the Contracting Officer. The interruption shall be scheduled at a time of minimum demand on the utility, convenient to the Government. Outages on weekends, holidays, or evenings shall be performed at no additional cost to the Government.

Contractor shall make all necessary arrangements to schedule and provide connections to existing utilities and to cause minimum interruption to system operation. All temporary utility hook-ups and disconnects shall be made by the Contractor.

If the Contractor fails to comply with a scheduled outage, the cost to reschedule the outage will be deducted from the final contract payment.

1.10.2 Protection of Work

All construction work requires a Work Clearance Request, AF Form 103. This permit is processed by the Government and provided to the Contractor. It is required prior to the start of any construction at the project site and must be posted in a conspicuous location on site during all construction activities.

Contractor shall obtain (from technical representative), prepare, and properly complete "Base Civil Engineering Work Clearance Request" AF Form

103. Prior to submitting 103 for review and approval, contractor shall mark in white paint all locations requiring utility locates and a commercial utility locate ticket number must be obtained by calling SUNSHINE at 1-800-432-4770. Contractor shall provide coordination for location of buried structures and utility lines before beginning any work involving digging/excavation. Contact the Government Technical Representative to schedule locates prior to any excavation. The Technical representative shall be the first and the last to coordinate on the AF Form 103.

After excavation permit has been obtained and prior to any excavating, verify with Cape Support (853-5211) that there are no "Critical Days" that would prevent excavation.

Contractor shall temporarily halt any machine excavation work or other surface penetration when approaching within 5 feet of the existing utility line until the Contractor has exposed the utility line by hand excavation to fix its location.

SECTION 01 11 00.00 30 Page 9

1.10.3 Burn Permits

Burn permits are required for any spark,flame, or welding activity. Burn Permits shall be obtained with technical representative guidance, through the CES Customer Services for all hot work on the project site.

Permits shall be posted at a conspicuous location in the construction area.

Burning of trash or rubbish is not permitted on any USAF facility.

1.11 SALVAGE AND DISPOSAL OF MATERIAL AND EQUIPMENT

1.11.1 Removal

Remove and/or relocate only those materials or items of equipment specifically indicated in the drawings and specifications. Removal operations shall be performed in such a manner that adjacent areas, installed equipment, or existing utilities are not damaged. Repair all openings that occur due to removal or demolition operations to match adjacent, existing surfaces. Any damage incurred during removal operations shall be repaired at no additional cost to the Government.

1.11.2 Housekeeping

Sufficient personnel and equipment shall be provided to ensure compliance with all housekeeping requirements. Work will not be allowed in those areas that do not comply with the requirements of Section 14.C of EM 385-1-1.

Job sites are to be kept clean on an ongoing, daily basis. All areas are to be thoroughly cleaned prior to leaving the jobsite at completion of project work.

1.11.3 Salvage of Material And Equipment

All salvageable materials or items to be removed shall remain the property of the Federal Government. Salvageable items are listed below in the paragraph entitled, "Salvage Items". Salvageable items shall be transported to and deposited at the Defense Logistics Agency Office - Disposition Services (DLA) at Jacksonville, Florida at the contractor's expense.

Salvageable material must be segregated and separated into categories before transport. Material shall be palletized or moveable by forklift (maximum 10,000 lbs). For material that is not palletized, it will be the responsibility of the Contractor to provide labor support for material removal.

Deliveries to DLA shall be scheduled through the Contracting Officer a minimum of 72 hours in advance. All salvageable items delivered to DLA shall be accompanied by a properly prepared DD Form 1348. This form will be furnished by the Contracting Officer. A signed copy by DLA reflecting the turn in materials shall be furnished to the Contracting Officer.

Contractor shall maintain property control records for material or equipment designated as salvage. Contractor's system of property control may be used if approved by the Contracting Officer. Contractor shall be responsible for storage and protection of salvaged materials and equipment until disposition by the Contracting Officer.

SECTION 01 11 00.00 30 Page 10

Material to be salvaged and reinstalled by the Contractor shall be protected during removal and stored to prevent damage.

For reference purposes salvageable is defined as: items, material, equipment which can be refitted, reworked, and restored and put to use or sold. The Contracting Officer shall have sole discretion as to determining whether any particular item is salvageable.

1.11.3.1 Salvage Items - None

1.11.4 Waste Disposal

Non-salvageable material and debris shall be removed from work areas and disposed of daily. Contractor shall dispose of C&D at a State approved disposal site.

Refer to Section 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS for further waste disposal and record keeping requirements.

1.11.5 Cleanup

Upon completion of the construction each day, the Contractor shall leave the work premises in a clean, neat and workmanlike condition, satisfactory to the Contracting Officer.

1.11.6 Salvage And Disposal Record Keeping

Contractor shall maintain and submit quarterly and at the completion of the project the SOLID WASTE DISPOSAL DIVERSION TRACKING form to the Contracting Officer of all materials removed from the job site. This inventory shall include waste materials disposed in landfills and materials reused on the job, sold for salvage and recycled.

1.12 RADIO FREQUENCY MANAGEMENT PROCEDURES

The following procedures shall be followed in obtaining radio frequency authorization:

The policy and procedures contained in AFI 33-580 shall be followed to obtain frequency allocation approval of electronic devices and USAF Radio Frequency Assignment.

1.13 COMMUNICATION SECURITY

Government telecommunications networks are continually subject to interception by hostile/unfriendly intelligent organizations. Therefore, the DOD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls from, or terminating at, DOD organizations. Contractor shall assume the responsibility for ensuring frequent dissemination of this information to all employees dealing with official DOD information.

PART 2 PRODUCTS

Not Used

SECTION 01 11 00.00 30 Page 11

PART 3 EXECUTION

3.1 ACCESS REQUIREMENTS

3.1.1 Construction Site Requirement

All on-site project work is confined to non-restricted areas. That is, no restricted area badge shall be necessary to accomplish the on-site work.

However, normal access requirements into CCAFS must still be accomplished.

3.1.2 Air Force Restricted Area Requirements (Black & Blue Restricted Unescorted Badge)

Access to construction sites located in restricted areas requires a Black & Blue Restricted Area Unescorted Badge. Contractor is responsible for satisfying the prerequisites for unescorted entry and/or providing escorted entry to a restricted area for all their personnel and subcontractor personnel. Escort services will not be provided by the Government. It is the Contractor's responsibility to determine the minimum number of personnel needed and obtain the required badges with escort authority in order to meet the contract requirements. Failure to do so could result in denied access to the construction site, interruption of performance and negatively impact timely contract completion.

Individuals meeting the 45 SWI 31-1 security requirements will be allowed to acquire restricted area badges. If the Contractor has proper clearance in JPAS, the Contractor may complete an AF Form 2586 "Unescorted Entry Authorization Certificate" (signed by the CE Security Manage in signature block #2) and transmit it to the Facility Manager of the restricted area for signature. After obtaining signatures, the individual must make an appointment with Visitor Control Center (321-853-5261) to obtain a Restricted Area Badge.

In order for Contractor personnel to enter restricted areas, a Restricted Area Badge for the area is required. Those individuals not in possession of a Restricted Area Badge (RAB) must remain under the surveillance of the escorts at all times while working in the restricted area. Escorts are subject to having their base access privileges revoked if it is found that they are not in visual contact with the employees they are escorting. The required responsibilities and duties of an escort shall be adhered to by all Contractor and subcontractor personnel. 45 SWI 31-1 and Restricted Area Badge Processing Guide outline the requirements and procedures in obtaining a restricted area badge.

Contingent upon the location and nature of the work, a construction site "Free Zone" may be established by the Commander of the restricted area site. If the area is designated as a construction site "Free Zone", only normal access requirements will apply.

3.2 CCAFS VEHICLE INSPECTION

The Oversized Vehicle Search Area is located on State Road 401 near the Visitor Control Center. Manned Operating hours are scheduled from 0600-1700. For after hours access, call CCAFS Security Forces at (321) 853-2121 to coordinate entry. Mandatory inspection is required for all:

Commercial Vehicles, Tractor Trailers, Trailers, RVs and Boats. Allow ample time for inspections, especially for the critical delivery period of mixed concrete. The government will not be responsible for rejected batches, caused by Contractor delays. Advance coordination is highly recommended.

SECTION 01 11 00.00 30 Page 12

3.3 CCAFS DELIVERIES

3.3.1 Non-Hazardous Deliveries

All deliveries of construction material and equipment to job sites (including cement trucks) shall use the South Commercial Gate. To the maximum extent possible, deliveries shall be scheduled between 1000 and 1500 hours to avoid the peak traffic volume times. The driver of each delivery vehicle and their passengers must have the following:

a. A valid photo ID; and

b. A valid bill of lading; and

c. A known delivery point on CCAFS; and

d. An on-base or local phone number and POC to vouch for delivery

Only deliveries that can be verified will be allowed to proceed. Special deliveries, deliveries after normal business hours, or deliveries that cannot negotiate through the barricades must be coordinated in advance.

All delivery vehicles shall be inspected by Security Forces personnel prior to being allowed to proceed onto the installation.

3.3.2 Hazardous Deliveries

Deliveries of fuel, large volume of chemicals, or other hazardous materials shall comply with this section. All hazardous deliveries shall enter through the same gates as non-hazardous delivers and have the information required for non-hazardous deliveries (see subpart entitled "Non-Hazardous Deliveries" of this section). Only deliveries that can be verified will be allowed to proceed. In addition, hazardous deliveries must be scheduled a minimum of 48 hours in advance for escort by Security Forces to and from job site. Contractors shall contact the CCAFS Security at 321-853-2121 to arrange for hazardous delivery escorts. Deliveries that have not arranged in advance for Security Forces escorts will be turned away and must be re-scheduled.

3.4 RESPONSIBILITIES

The Government reserves the right to revoke badging authority, escort authority and/or base access privileges for any person, at any time and for any reason. Contractor understands that the Government has made every attempt to identify potential delays associated with background checks and badging requirements and those delays have been considered in the construction schedule. Delays resulting from the Contractor's failure to follow the badging guidelines above shall not be considered grounds for contract extension or compensation.

3.5 EXCAVATION

3.5.1 Dig/Utility Locate Permit Requirements

Excavation shall be accomplished only after the Dig permit is received and utility locates accomplished and then with extreme caution to prevent damage to the existing buried utilities in the area. All open trenches must comply with OSHA regulations. All excavation must be further approved

SECTION 01 11 00.00 30 Page 13 by daily contact with Cape Support (321-853-5211).

3.5.1.1 Location of Buried Structures and Utility Lines

Accurately locate and stake structures and utility lines indicated by the Government provided Utility Locators on CCAFS. If unidentified underground utilities are encountered during excavation, notify the Contracting Officer and cease operations until they are properly identified.

3.5.1.2 Excavation, Trenching, and Backfilling

Open only those trenches for which material is ready to be placed. As soon as approved by the Technical Representative, trenches shall be backfilled and tamped as required by the drawings and specifications. As a minimum, the topsoil shall be replaced and the disturbed area shall be grassed by seeding, watered and maintained for a minimum of 60 calendar days. All excavation shall be in compliance with OSHA regulations. Mark or barricade construction work which may present a hazard.

3.5.1.3 Cutting of Roads, Streets, Driveways, and Paved Areas

Repair roads, streets, and paved parking areas which require surface cutting under this project within 10 calendar days after initial cutting.

The topping shall be a minimum of 2 inches of asphalt and match existing (concrete topping on asphalt areas is not allowed). Mark, barricade, and illuminate construction work on or near roads or streets which may present a traffic hazard per OSHA 29 CFR 1910. Contractor shall provide signaling, lighting, and barricades in the construction area conforming to the Manual on Uniform Traffic Control Devices, OSHA 29 CFR 1926.201 and 1926.202.

Closures of Streets, parking lots, and other traffic areas will not be permitted unless approved by the Contracting Officer after written request 14 calendar days before the scheduled closure.

3.5.2 Restrictions

All excavation at the work site must be accomplished by hand only.

Excavating machinery is prohibited.

Hand digging is required within five feet of located underground utilities.

3.5.3 Temporary Shoring, Bracing And Supports

All new excavation and trenching work shall be securely and safely supported during installation with temporary, but substantial, shoring, bracing, hangers and other supports as required by OSHA regulations. After new work is completed and completely cured (if required) and all permanent fasteners, anchors and supports are properly installed, the temporary supports shall be removed.

3.5.4 Barricades

Guardrails, fences or other suitable barricades and warning lights shall be placed at all open excavations/trenches which are adjacent to paths, walkways, sidewalks, vehicle parking areas, and other pedestrian or vehicle thoroughfares. Coordinate with 45 CE Environmental prior to placing warning lights.

SECTION 01 11 00.00 30 Page 14

3.6 LAND SURVEYING REQUIREMENTS

Land surveying, to include all projections and datum points, shall be required for all modifications affecting civil site plans (e.g., utilities, additions, new construction or storm water modifications). The survey shall be performed by a State of Florida Professional Licensed Surveyor (PLS) and shall be submitted by the Contractor in digital and hard copy format.

3.6.1 Contractor Provided Survey Support

Record drawings shall reflect all civil site developments such as new facility and/or land modifications, external structural changes to aboveground structures, and changes to underground structures and utilities external to facilities located on lands owned by or held in leasehold interest of the federal government.

Information in record drawings shall include, but not be limited to:

Location of all new lines, conduits, valves, fittings, fire hydrants, meters, terminal points using at least two ties to permanent points (manholes, power poles, curbs, or storm water inlets), or GPS coordinates with accuracy to 1 foot or better unless more stringent accuracy requirements are specified in other sections of this contract.

Locate manhole, catch basin, and storm water control structures noting top of rim, inverts, weirs, dimensions and conduit sizes and material entering the structure. An acceptable station and offset system may be used for service lines and fittings only.

Location of new lines from property easement lines or edges of pavement at intervals of 300 feet.

All utility routing and interface changes shall be reflected on the drawings to scale and defined with sufficient dimensions.

Locate with elevation all improvements constructed or modified including but not limited to pavement, striping, curbs, sidewalks, signs, gutters, walls, fences, buildings, pads, open stormwater conveyance systems, stormwater retention/detention ponds, etc.

Elevation information should be adequate to illustrate flow patterns, retention capacity and overflow levels. Ground contours at intervals of 1 foot in elevation shall be shown on unpaved areas of the site on the sketch of survey

Facilitate the receipt of surveyed coordinates for facility footprint corners coordinates and underground structures and utilities external to facilities by submitting digital data using the spatial reference identified below to 45 CES through the Contracting Officer within five

(5) working days of foundation construction, or open excavation.

Record drawing prints will be drawn at a minimum scale of 1 inch = 100 feet. Areas requiring additional detail shall be enlarged as necessary.

Record drawings shall be provided in digital format (AutoCAD Civil 3D, version 2012 or later). Information should be provided in separate layers/levels as specified by GIS/GeoBase Development Manager and in at least the same degree of separation as the design drawings that were provided. Designation for naming of layers/levels shall adhere to current DOD, A/E/C CAD Standards with strict adherence to layer

SECTION 01 11 00.00 30 Page 15 format. https://cadbim.usace.army.mil/. New like items shall be contained in the same levels to permit easy conversion to ArcGIS layers.

All Civil features contained within the drawing package shall be drawn in ArcGIS layers conforming to the most current SDSFIE schema standard.

All applicable attribution will be filled in prior to final delivery.

Layers will be in shape file, personal geodatabase or file geodatabase.

Upon completion of survey, the as-built drawings will be certified by professional licensed surveyor.

All lines, letters, and details shall be sharp, clean, and fully legible.

5 (Five) reproducible print and one digital copy in an electronic storage media (AutoCAD Civil 3D, version 2012 or later, drawn in ArcGIS layers conforming to the most current SDSFIE schema standard) and PDF of the Contractor Survey Record Drawings are required for submittal.

3.6.1.1 Horizontal Reference Datum

All surveys shall be referenced to WGS1984 17 North UTM (G1674) - 2012 aligned to with ITRF08 (epoch date 2005.0), unless specified otherwise by the GIS/GeoBase Development Manager.

3.6.1.2 Vertical Reference Datum

All surveys shall be referenced to EGM96, unless specified otherwise by the GIS/GeoBase Development Manager. The survey shall include a description of the reference benchmarks from which the EGM96 has been determined.

3.7 HOISTING AND LIFTING

3.7.1 Lifting Operation Plan

Contractor shall have a Lifting Operation Plan and procedure that is fully in accordance with the requirements of OSHA regulations, and shall include drawings/sketches of lifting slings, lifting equipment, and tag lines. The plan shall show weights, center of gravity, and clearances of load over entire lift. Plans shall have details showing any structural mounting of hoisting equipment on sheaves or structural steel, and shall show loading calculations on any such structural mounting showing forces, weights, turning moments, etc. A procedure shall accompany the drawings describing all lifting operations. Use spreader bars wherever necessary to prevent hoisting cables from contacting equipment/material.

3.8 QUALITY CONTROL

It is the Contractor's responsibility to provide, inspect and document the level of quality that has been established by all applicable standards, codes and guidelines. The Contractor shall use skilled workers, an adequate number of which are thoroughly trained and have a minimum of 3 years experience in the necessary crafts and who are completely familiar with the specified requirements and the methods needed for the proper performance of the work in each section of these specifications. Contractor shall submit Superintendent Contact and Qualifications to the Contracting Officer.

3.8.1 Licenses

Contractor or their subcontractors shall be licensed by the State of

SECTION 01 11 00.00 30 Page 16

Florida or have an equivalent out-of-state license in all areas applicable to this contract or as otherwise stated elsewhere in this contract. Copies of licenses and certificates shall be provided to the Contracting Officer.

Asbestos Abatement Contractor shall be licensed by the State of Florida.

3.8.2 Government Inspection/Approval

When the Contractor considers that the work is acceptable to the Government and is complete, he/she shall inform the Contracting Officer, or designated representative, and the Government Project Manager that the work is complete and ready for inspections. In the event that the work is not acceptable, the Contractor shall record a list of items noted by the Government Project Manager, A subsequent inspection may take place in order to review the corrected items. The Government is not required to inspect all work.

3.8.3 Inspection Files

The Contractor shall be responsible for keeping inspection files for all projects. Files shall include on site records of all inspections conducted by the Contractor and the necessary corrective actions taken. Daily Reports shall be kept and made available to the Government throughout the contract performance period and for the period after completion until final settlement of any claims made under this contract.

3.9 SUPERINTENDENT

Provide name and qualifications and past experience for review. Designate a competent superintendent who shall have full authority to act for the Contractor and who shall be the primary contact with the Government until acceptance. Contractor's superintendent shall be at the job site at all times when work is taking place and shall have full authority to act for the Contractor.

3.10 CONSTRUCTION SCHEDULING REQUIREMENTS

3.10.1 Contractor Coordination Meetings

Contractor shall attend weekly project meetings, not to exceed 3 hours, scheduled by the Government. Contractor's Superintendent shall attend the scheduled coordination meetings. Subcontractor representatives shall attend as required.

Discussion shall address the progress schedule, potential factors of delay, deficiencies, material delivery schedules, submittals, and safety issues.

3.10.2 On-Site Construction Sequence

Contractor will plan all work and provide additional labor, extend shifts, work non-standard hours, provide temporary normal and stand-by power if required at no additional cost to the government to ensure the facility is fully operational and has electrical redundancy during operation hours.

Electrical phasing plan provided in contract drawings is notional and for information purposes only. Contractor must develop an independent electrical phasing plan based on construction schedule and means and methods employed. Submit Phasing Plan plan to the contracting officer for approval prior to beginning work.

SECTION 01 11 00.00 30 Page 17

-- End of Section --

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

08/18

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

1.1.2 Approving Authority

1.1.3 Work

1.2 SUBMITTALS

1.3 PREPARATION

1.3.1 Submittal Format

1.3.1.1 Format of SD-01 Preconstruction Submittals

1.3.1.2 Format for SD-02 Shop Drawings

1.3.1.2.1 Drawing Identification

1.3.1.3 Format of SD-03 Product Data

1.3.1.3.1 Product Information

1.3.1.3.2 Standards

1.3.1.3.3 Data Submission

1.3.1.4 Format of SD-05 Design Data

1.3.1.5 Format of SD-06 Test Reports

1.3.1.6 Format of SD-07 Certificates

1.3.1.7 Format of SD-08 Manufacturer's Instructions

1.3.1.7.1 Standards

1.3.1.8 Format of SD-09 Manufacturer's Field Reports

1.3.1.9 Format of SD-10 Operation and Maintenance Data (O&M)

1.3.1.10 Format of SD-11 Closeout Submittals

1.3.2 Source Drawings for Shop Drawings

1.3.2.1 Source Drawings

1.3.2.2 Terms and Conditions

1.4 QUANTITY OF SUBMITTALS

1.4.1 Number of SD-01 Preconstruction Submittal Copies

1.5 INFORMATION ONLY SUBMITTALS

1.6 PROJECT SUBMITTAL REGISTER

1.6.1 Submittal Management

1.6.2 Preconstruction Use of Submittal Register

1.6.3 Contractor Use of Submittal Register

1.6.4 Approving Authority Use of Submittal Register

1.6.5 Delivery of Copies

1.7 VARIATIONS

1.7.1 Considering Variations

1.7.2 Proposing Variations

1.7.3 Warranting that Variations are Compatible

1.7.4 Review Schedule Extension

1.8 SCHEDULING

1.9 GOVERNMENT APPROVING AUTHORITY

1.9.1 Review Notations

1.10 DISAPPROVED SUBMITTALS

1.11 APPROVED SUBMITTALS

SECTION 01 33 00 Page 1

PART 2 PRODUCTS

PART 3 EXECUTION

ATTACHMENTS:

Appendix A - Submittal Register

-- End of Section Table of Contents --

SECTION 01 33 00 Page 2

SECTION 01 33 00

SUBMITTAL PROCEDURES

08/18

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Submittal requirements are specified in the technical sections. Examples and descriptions of submittals identified by the Submittal Description (SD) numbers and titles follow:

SD-01 Preconstruction Submittals

Preconstruction Submittals include schedules and a tabular list of locations, features, and other pertinent information regarding products, materials, equipment, or components to be used in the work.

Certificates Of Insurance

Surety Bonds

List Of Proposed Subcontractors

List Of Proposed Products

Baseline Network Analysis Schedule (NAS)

Submittal Register

Schedule Of Prices Or Earned Value Report

Work Plan

Quality Control (QC) plan

Environmental Protection Plan

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and

SECTION 01 33 00 Page 3 other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-05 Design Data

Design calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. Unless specified in another section, testing must have been within three years of date of contract award for the project.

Report that includes findings of a test required to be performed on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report that includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Final acceptance test and operational test procedure

SD-07 Certificates

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor. The document purpose is to further promote the orderly progression of a portion of the work by documenting procedures, acceptability of methods, or personnel qualifications.

Confined space entry permits

Text of posted operating instructions

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and (SDS)concerning impedances, hazards and safety precautions.

SD-09 Manufacturer's Field Reports

Documentation of the testing and verification actions taken by manufacturer's representative at the job site, in the vicinity of the job site, or on a sample taken from the job site, on a portion of the work, during or after installation, to confirm compliance with manufacturer's standards or instructions. The documentation must be signed by an authorized official of a testing laboratory or agency and state the test results; and indicate whether the material, product, or system has passed or failed the test.

Factory test reports.

SECTION 01 33 00 Page 4

SD-10 Operation and Maintenance Data

Data provided by the manufacturer, or the system provider, including manufacturer's help and product line documentation, necessary to maintain and install equipment, for operating and maintenance use by facility personnel.

Data required by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

Data incorporated in an operations and maintenance manual or control system.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Submittals required for Guiding Principle Validation (GPV) or Third Party Certification (TPC).

Special requirements necessary to properly close out a construction contract. For example, Record Drawings and as-built drawings. Also, submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

1.1.2 Approving Authority

Office or designated person authorized to approve the submittal.

1.1.3 Work

As used in this section, on-site and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction. In exception, excludes work to produce SD-01 submittals.

1.2 SUBMITTALS

Contracting Organization approval is required for all submittals. Submit the following in accordance with this section.

SD-01 Preconstruction Submittals

Submittal Register; G

1.3 PREPARATION

1.3.1 Submittal Format

1.3.1.1 Format of SD-01 Preconstruction Submittals

When the submittal includes a document that is to be used in the project, or is to become part of the project record, other than as a submittal, do not apply the Contractor's approval stamp to the document itself, but to a separate sheet accompanying the document.

SECTION 01 33 00 Page 5

Provide data in the unit…