F18SOL10019final.pdf

SOLICITATION/CONTRACT 1. THIS CONTRACT IS A RATED

5. SOLICITATION TYPE2. CONTRACT NO. 4. SOLICITATION NUMBER

PAGE OF PAGES

7. ISSUED BY CODE 8. THIS ACQUISITION IS

BIDDER/OFFEROR TO COMPLETE BLOCKS 11, 13, 15, 21, 22, & 27

RATING

ORDER UNDER DPAS (15 CFR 700)

3. AWARD/

EFFECTIVE DATE ISSUE DATE

6. SOLICITATION

UNRESTRICTED OR SET ASIDE:

SMALL BUSINESS

SIZE STANDARD:

9. (AGENCY USE)

NO COLLECT CALLS

10. ITEMS TO BE PURCHASED (BRIEF DESCRIPTION)

SUPPLIES SERVICES

11. IF OFFER IS ACCEPTED BY THE GOVERNMENT WITHIN

CALENDAR DAYS (60 CALENDAR DAYS UNLESS OFFEROR INSERTS A DIFFERENT

PERIOD) FROM THE DATE SET FORTH IN BLOCK 9 ABOVE, THE CONTRACTOR

AGREES TO HOLD ITS OFFERED PRICES FIRM FOR THE ITEMS SOLICITED

HEREIN AND TO ACCEPT ANY RESULTING CONTRACT SUBJECT TO THE TERMS

AND CONDITIONS STATED HEREIN.

CODE 12. ADMINISTERED BY

13. CONTRACTOR FACILITY 14. PAYMENT WILL BE MADE BY CODE CODE

OFFEROR CODE

TELEPHONE NO.

DUNS NO.

CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK:

15. PROMPT PAYMENT DISCOUNT 16. AUTHORITY FOR USING OTHER

THAN FULL AND OPEN COMPETITION

10 U.S.C. 2304 41 U.S.C. 253

NEGOTIATED

(RFP)

SEALED BIDS

(IFB)

1 291

SMITHSONIAN INSTITUTION

P.O. BOX 37012

MRC 1200

Washington DC 20013-7012

OCON

P.O. BOX 37012

MRC 1200

Washington DC 20013-7012

OCON

% FOR:X

x x

OCON

Maintenace support

F18SOL10019

NAICS:

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED VETERAN-

OWNED SMALL BUSINESS

8(A)

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOSB PROGRAM

EDWOSB

17.

ITEM NO.

18.

SCHEDULE OF SUPPLIES/SERVICES

19.

QUANTITY

20.

UNIT

21.

UNIT PRICE

22.

AMOUNT

This is a Maintenance support and services contract for the OCIO Facility Herndon VA proposals are due 7/27/2018 at 3:00 pm per instructions.

An organized site visit has been scheduled for

6/18/2018 10:00am, Participants will meet at -

OCIO Support Facility, 380 Herndon Parkway, Herndon VA

27. SIGNATURE OF OFFEROR/CONTACTOR 28. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

NAME AND TITLE OF SIGNER (TYPE OR PRINT) DATE SIGNED NAME OF CONTRACTING OFFICER DATE SIGNED

25. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS SET

FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY CONTINUATION SHEETS

SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED HEREIN.

26. AWARD OF CONTRACT: YOUR OFFER ON SOLICITATION

NUMBER SHOWN IN BLOCK 4 INCLUDING ANY ADDITIONS

OR CHANGES WHICH ARE SET FORTH HEREIN, IS

ACCEPTED AS TO ITEMS:

23. ACCOUNTING AND APPROPRIATION DATA 24. TOTAL AWARD AMOUNT

(FOR GOVERNMENT USE ONLY)

Thomas Dempsey x

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION NOT USABLE

STANDARD FORM 1447 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.214(d)

COPIES TO

F18SOL10019 - 06/12/2018 - Page 1 of 291

TYPE OR PRINT NAME AND TITLE OF SIGNER

SIGNATURENAME AND ADDRESS OF FIRM (Include ZIP Code)

WE DO NOT, DESIRE TO BE RETAINED ON THE MAILING LIST FOR FUTURE PROCUREMENT OF THE TYPE OF ITEMS INVOLVEDWE DO

DO NOT REGULARLY MANUFACTURE OR SELL THE TYPE OF ITEMS INVOLVED

CANNOT MEET DELIVERY REQUIREMENT

OTHER (Specify)

UNABLE TO IDENTIFY THE ITEM(S)

CANNOT COMPLY WITH SPECIFICATIONS

PAGE

NO RESPONSE FOR REASONS CHECKED

291 2 OF

DATE AND LOCAL TIME

AFFIX

STAMP

HERE

TO:

FROM:

SOLICITATION NO.

SMITHSONIAN INSTITUTION

P.O. BOX 37012

MRC 1200

Washington DC 20013-7012

OCON

F18SOL10019

STANDARD FORM 1447 (REV. 2/2012) BACK

F18SOL10019 - 06/12/2018 - Page 2 of 291

A - Solicitation/Contract Form B - Supplies or Services/Prices C - Description/Specifications D - Packaging and Marking E - Inspection and Acceptance F - Deliveries or Performance G - Contract Administration Data H - Special Contract Requirements I - Contract Clauses J - List of Documents, Exhibits and Other Attachments K - Representations, Certifications, and Other Statements of Bidders L - Instructions,Conditions, and Notices to Bidders M - Evaluation Factors for Award

F18SOL10019 - 06/12/2018 - Page 3 of 291

A - Solicitation/Contract Form

52.204-15 Service Contract Reporting Requirements for Indefinite-Delivery Contracts. (OCT 2016)

(a) Definition.

First-tier subcontract means a subcontract awarded directly by the Contractor for the purpose of acquiring supplies or services (including construction) for performance of a prime contract. It does not include the Contractor's supplier agreements with vendors, such as long-term arrangements for materials or supplies that benefit multiple contracts and/or the costs of which are normally applied to a Contractor's general and administrative expenses or indirect costs.

(b) The Contractor shall report, in accordance with paragraphs (c) and (d) of this clause, annually by October 31, for services performed during the preceding Government fiscal year (October 1-

September 30) under this contract for orders that exceed the thresholds established in 4.1703(a)(2).

(c) The Contractor shall report the following information:

(1) Contract number and order number.

(2) The total dollar amount invoiced for services performed during the previous

Government fiscal year under the order.

(3) The number of Contractor direct labor hours expended on the services performed during the previous Government fiscal year.

(4) Data reported by subcontractors under paragraph (f) of this clause.

(d) The information required in paragraph (c) of this clause shall be submitted via the internet at www.sam.gov. (See SAM User Guide). If the Contractor fails to submit the report in a timely manner, the Contracting Officer will exercise appropriate contractual remedies. In addition, the

Contracting Officer will make the Contractor's failure to comply with the reporting requirements a part of the Contractor's performance information under FAR subpart 42.15.

(e) Agencies will review Contractor reported information for reasonableness and consistency with available contract information. In the event the agency believes that revisions to the Contractor reported information are warranted, the agency will notify the Contractor no later than November

15. By November 30, the Contractor shall revise the report, or document its rationale for the agency.

(f)(1) The Contractor shall require each first-tier subcontractor providing services under this contract, with subcontract(s) each valued at or above the thresholds set forth in 4.1703(a)(2), to provide the following detailed information to the Contractor in sufficient time to submit the report:

(i) Subcontract number (including subcontractor name and unique entity identifier), and

(ii) The number of first-tier subcontractor direct-labor hours expended on the services performed during the previous Government fiscal year.

(2) The Contractor shall advise the subcontractor that the information will be made available to the public as required by section 743 of Division C of the Consolidated

Appropriations Act, 2010.

F18SOL10019 - 06/12/2018 - Page 4 of 291

B - Supplies or Services/Prices

OCIO Support Operation and Maintenance Firm Fixed Price Annual Contract _______________

Additional services not included in base scope of work will be accomplished through task orders for services or minor repair and alterations

Hourly rate Fully Burdened rate not including profit

Automatic Controls Technician __________ ____________

Building /Shipping Distribution Person __________ ____________

Cabinet Maker __________ ____________

Carpenter (Journeyman level) __________ ____________

Carpet layer __________ ____________

Ceiling tile technical __________ ____________

Certified Welder _______ ___ ____________

Concrete Finisher __________ ____________

Door Mechanic __________ ____________

Drywall installer/finishers __________ ____________

Electrician (Journeyman level) __________ ____________

Equipment operator __________ ____________

Fire protection System mechanic __________ ____________

Generator Repair Technician __________ ____________

Glazier __________ ____________

High voltage Technician __________ ____________

HVAC Controls Technician __________ ____________

HVAC Mechanic (Journeyman level) __________ ____________

Insulation installer __________ ____________

Janitor __________ ____________

Jet Water drain cleaning mechanic __________ ____________

Kitchen Appliance Mechanic __________ ____________

Laborer __________ ____________

Landscaper __________ ____________

LIEBERT Certified Technician __________ ____________

Mason (Journeyman level) __________ ____________

Millwright __________ ____________

Office Furniture / Modular Systems Assembler________ ____________

Painter __________ ____________

Pest control Technician __________ ____________

Pipefitter __________ ____________

Plumber (Journeyman level) __________ ____________

Recycling collection Person __________ ____________

Roll up Door Mechanic __________ ____________

Sheet metal worker (Journeyman level) __________ ____________

Signage Mechanic __________ ____________

Telecommunications __________ ____________

UPS Technician __________ ____________

Window Mechanic __________ ____________

Other (as required)

F18SOL10019 - 06/12/2018 - Page 5 of 291

C - Description/Specifications

The purpose of this requirement is to procure a contractor to provide operation and maintenance of

Institutional equipment, facility maintenance, custodial services, support services, minor furniture repair, repair support services, and IDIQ projects, for the Smithsonian Institution (SI) Office of the

Chief Information Officer (OCIO) Support Facility in Herndon, Virginia

DESCRIPTION OF SERVICES:

1. Operation and maintenance of all building and equipment and utilities

a. Electrical systems

b. Fire protection

c. HVAC for both data center and administrative offices

d. Water/sewage

e. Building maintenance

f. Grounds/Courtyard

g. Pest Control

h. Snow and Ice removal

i. Minor task

j. Repairs

k. Emergency repairs

2. Facility maintenance

3. Custodial Services

4. Support Services

5. Management /Quality Control

6. Compliance to Codes and Standards

7. Option to Provide IDIQ services for building alteration and repair

a. Upgrades and modernizations

b. Existing conditions Upgrades

1. ASSUMPTIONS:

1. The Smithsonian Institution (SI) Office of the Chief Information Officer (OCIO) support facility will have a total area of approximately 47,462 square feet. The facility will have two areas, a data center with raised floor covering approximately 12,000 square feet and an office area that will cover approximately 35,462 square feet.

2. The leased property is located in Fairfax County, State of Virginia at the following location:

3. 380 Herndon Parkway Herndon, VA 20170 4881

4. The building consists of one (1) floor; the SI will occupy the entire floor.

F18SOL10019 - 06/12/2018 - Page 6 of 291

5. All area’s square footage described are approximate.

Contract will have two parts

1. The main contract will be a firm fixed price contract for Operations and

Maintenance, one year base, with nine (one year options)

2. The second part will be the ability/option to do IDIQ task orders on this contract on project specific needs for this facility both repair and alteration and service contracts

F18SOL10019 - 06/12/2018 - Page 7 of 291

D - Packaging and Marking

All proposals and correspondence shall be labeled

Contractor’s Name:

Qualification No.: F18SOL10019 Location: Herndon VA Project: OCIO Operation and Support Due Date: 7/27/2018 3:00pm

Provide one original and three copies of technical proposal And separately Provide one original and three copies of price proposal with backup for how price was arrived at

F18SOL10019 - 06/12/2018 - Page 8 of 291

E - Inspection and Acceptance

52.246-4 Inspection of Services - Fixed-Price. (AUG 1996)

(a) Definitions. Services, as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.

(b) The Contractor shall provide and maintain an inspection system acceptable to the Government covering the services under this contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the Government during contract performance and for as long afterwards as the contract requires.

(c) The Government has the right to inspect and test all services called for by the contract, to the extent practicable at all times and places during the term of the contract. The Government shall perform inspections and tests in a manner that will not unduly delay the work.

(d) If the Government performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.

(e) If any of the services do not conform with contract requirements, the Government may require the Contractor to perform the services again in conformity with contract requirements, at no increase in contract amount. When the defects in services cannot be corrected by reperformance, the Government may (1) require the Contractor to take necessary action to ensure that future performance conforms to contract requirements; and (2) reduce the contract price to reflect the reduced value of the services performed.

(f) If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with contract requirements, the Government may (1) by contract or otherwise, perform the services and charge to the Contractor any cost incurred by the

Government that is directly related to the performance of such service; or (2) terminate the contract for default.

52.246-12 Inspection of Construction. (AUG 1996)

(a) Definition. Work includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The

Contractor shall maintain complete inspection records and make them available to the

Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not -

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) below.

F18SOL10019 - 06/12/2018 - Page 9 of 291

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The

Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the

Government's rights under any warranty or guarantee.

52.246-16 Responsibility for Supplies. (APR 1984)

(a) Title to supplies furnished under this contract shall pass to the Government upon formal acceptance, regardless of when or where the Government takes physical possession, unless the contract specifically provides for earlier passage of title.

(b) Unless the contract specifically provides otherwise, risk of loss of or damage to supplies shall remain with the Contractor until, and shall pass to the Government upon -

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Acceptance by the Government or delivery of the supplies to the Government at the destination specified in the contract, whichever is later, if transportation is f.o.b.

destination.

(c) Paragraph (b) above shall not apply to supplies that so fail to conform to contract requirements as to give a right of rejection. The risk of loss of or damage to such nonconforming supplies remains with the Contractor until cure or acceptance. After cure or acceptance, paragraph (b) above shall apply.

F18SOL10019 - 06/12/2018 - Page 10 of 291

(d) Under paragraph (b) above, the Contractor shall not be liable for loss of or damage to supplies caused by the negligence of officers, agents, or employees of the Government acting within the scope of their employment.

52.246-S0038 Smithsonian Institution Inspection and Acceptance (Jun 2000)

Inspection and acceptance may be made on a daily basis on work performed at the job site, by the

Contracting Officers Technical Representative. All work shall be coordinated through the COTR for acceptance of work, payrolls and invoice(s).

52.246-S0039 Final Inspection and Tests (Jun 2000)

The requirements of the Inspection of Construction clause prescribed in FAR 52.246-12, are supplemented to provide that the Contractor shall give the Contracting Officer at least 10 calendar days advance written notice of the date the work will be fully completed and ready for final inspection and tests. Final inspection and tests will be started within 10 calendar days from the date specified in the aforesaid notice unless the

Contracting Officer determines that the work is not ready for final inspection and so informs the

Contractor.

52.246-S0057 Inspection

(a) Upon proper notice and during normal working hours, the Smithsonian Institution reserves the right to perform any inspections and tests as deemed necessary to assure that the Contractor is performing in accordance with the terms and specifications as set forth herein.

(b) Inspection may be at the Contractor's place of business or at any location where work is being performed in conjunction with this contract.

(c) Inspection by the Smithsonian Institution shall not relieve the Contractor of responsibility for any or all quality control aspects during the life of the contract. This shall include quality control for items covered by this contract that may be subcontracted.

52.246-S0058 Acceptance

(a) The supplies and services rendered under this contract will be accepted and approved by the Contracting

Officer or a designated representative thereto. Such approval will indicate acceptability to the Smithsonian

Institution of performance in accordance with the terms and conditions of this contract, and will be subject to applicable warranties. The Smithsonian Institution reserves the right to reject works not conforming to prescribed contract requirements.

(b) Neither the Smithsonian Institution's reviews, approval, or acceptance of services and/or supplies, nor payment for any of the services or supplies required under this contract shall be construed to operate as a waiver of action arising out of the performance of this contract. Furthermore, the Contractor shall be and remain liable to the Smithsonian Institution in accordance with applicable law for all damages to the

Smithsonian Institution caused by the Contractor's negligent performance of any of the supplies or services furnished under this contract.

(c) Acceptance by the Smithsonian Institution does not relieve the Contractor of responsibility for correction of errors or omissions that may arise after such acceptance if the errors and omissions are clearly a fault in Contractor performance.

F18SOL10019 - 06/12/2018 - Page 11 of 291

F - Deliveries or Performance

52.242-15 Stop-Work Order. (AUG 1989)

(a) The Contracting Officer may, at any time, by written order to the Contractor, require the

Contractor to stop all, or any part, of the work called for by this contract for a period of 90 days after the order is delivered to the Contractor, and for any further period to which the parties may agree. The order shall be specifically identified as a stop-work order issued under this clause.

Upon receipt of the order, the Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the work covered by the order during the period of work stoppage. Within a period of 90 days after a stop-work order is delivered to the Contractor, or within any extension of that period to which the parties shall have agreed, the

Contracting Officer shall either -

(1) Cancel the stop-work order; or

(2) Terminate the work covered by the order as provided in the Default, or the

Termination for Convenience of the Government, clause of this contract.

(b) If a stop-work order issued under this clause is canceled or the period of the order or any extension thereof expires, the Contractor shall resume work. The Contracting Officer shall make an equitable adjustment in the delivery schedule or contract price, or both, and the contract shall be modified, in writing, accordingly, if -

(1) The stop-work order results in an increase in the time required for, or in the

Contractor's cost properly allocable to, the performance of any part of this contract; and

(2) The Contractor asserts its right to the adjustment within 30 days after the end of the period of work stoppage; provided, that, if the Contracting Officer decides the facts justify the action, the Contracting Officer may receive and act upon a proposal submitted at any time before final payment under this contract.

(c) If a stop-work order is not canceled and the work covered by the order is terminated for the convenience of the Government, the Contracting Officer shall allow reasonable costs resulting from the stop-work order in arriving at the termination settlement.

(d) If a stop-work order is not canceled and the work covered by the order is terminated for default, the Contracting Officer shall allow, by equitable adjustment or otherwise, reasonable costs resulting from the stop-work order.

52.211-S0025 Commencement, Prosecution, and Completion of Work (Jun 2000)

(a) Definitions.

(1) The Contract Time is the period of time allotted in the Contract Documents for Final Completion of the

Work as defined in this Construction Contract Clause, including authorized extensions thereto. The

Contractor shall complete his Work within the Contract Time as stated in the SF 1442, or as modified.

(2) The date of commencement of the Work is the date established in the Notice To Proceed issued by the

C.O. Submission by the Contractor of its Performance and Payment Bonds, Preliminary Schedule and all

Certificates of Insurance and their approval by the S.I. are conditions precedent to the issuance of the

Notice to Proceed. The Contractor shall not commence the Work or store materials or equipment on site until written Notice to Proceed is issued or until the Contractor otherwise receives the written consent of the C.O.

(3) The date of Substantial Completion of the Work or designated portion thereof is the date certified by the

COTR when the Work or a designated portion thereof is sufficiently complete, in accordance with the

Contract Documents, so the S.I. can fully occupy the Work or designated portion thereof for the use for

F18SOL10019 - 06/12/2018 - Page 12 of 291 which it is intended, with all of the Project's parts and systems operable as required by the Contract

Documents. Only punch list work and any final cleaning beyond that needed for the S.I.'s full use may remain for Final Completion.

(4) The date of Final Completion of the Work is the date certified by the COTR when the Work is totally complete, to include punch list work and final clean up, in accordance with the Contract Documents and the

S.I. may fully occupy and fully utilize the Work for the use for which it is intended.

(5) If a date or time of completion is included in the Contract, it shall be the Date of Final Completion as defined in this Construction Contract Clause, including authorized extensions thereto, unless otherwise provided.

(6) The term Day as used in the Contract Documents shall mean calendar day unless otherwise specifically designated. All dates shall mean midnight of the indicated day unless otherwise stipulated.

(b) Progress and Completion.

(1) All time limits stated in the Contract Documents are of the essence of the Contract.

(2) The Contractor shall prosecute the Work diligently to Final Completion.

(c) Delays and Extensions of Time.

(1) The time during which the Contractor is delayed in the performance of the Work, by the acts or omissions of the S.I., the Architect, or their employees or agents, acts of God, unusually severe and abnormal climatic conditions, fires, floods, epidemics, quarantine restrictions, strikes, riots, civil commotion or freight embargoes, or other conditions beyond the Contractor's control and which the

Contractor could not reasonably have foreseen and provided against, shall be added to the Contract Time;

provided, however, that no claim by the Contractor for an extension of time for delays will be considered unless made in compliance with the requirements of this Article and other provisions of the Contract

Documents.

(2) Neither the S.I., nor the Architect shall be obligated or liable to the Contractor for, and the Contractor hereby expressly waives any claims against the S.I. and the Architect on account of any indirect or direct damages, costs or expenses of any nature which the Contractor, Subcontractors, of Suppliers or any other person may incur as a result of any delays, interference, changes in sequence or the like, which are reasonable, foreseeable, contemplated, or avoidable by the Contractor, arising from or out of any act or omission of the S.I. of the Architect, or their agents, employees, consultants, separate contractors or any governmental representative, it being understood and agreed that the Contractor's sole and exclusive remedy in any such events shall be an extension of the Contract Time, but only as determined in accordance with the provisions of the Contract Documents.

(3) The Contract Time shall be adjusted only for Change Orders pursuant to the Construction Contract

Clause entitled "Changes", excusable delays pursuant to Construction Contract Clause entitled "Delays and

Extensions of Time" and Construction Contract Clause entitled "Smithsonian Institution's Right to Stop or to Suspend the Work". In the event the Contractor requests an extension of the Contract Time, he shall furnish such justification and supporting evidence as the C.O. may deem necessary for a determination of whether the Contractor is entitled to an extension of time under the provisions of the Contract. The burden of proof to substantiate a claim for an extension of the Contract Time shall rest with the Contractor, including evidence that the cause was beyond his control. The C.O. shall base his findings of fact and decision on such justification and supporting evidence and shall advise the Contractor in writing thereof. If the C.O. finds that the Contractor is entitled to any extension of the Contract Time, the C.O.'s determination of the total number of days' extension shall be based upon the currently approved Progress Schedule and on all data relevant to the extension. Such data will be incorporated into the Progress Schedule in the form of a revision thereto, accomplished in a timely manner. The Contractor acknowledges and agrees that actual delays (due to said changes, suspensions of work or excusable delays) in activities which, according to the

Progress Schedule, do not affect the Contract Time, do not have any effect upon the Contract Time and

F18SOL10019 - 06/12/2018 - Page 13 of 291 therefore will not be the basis for a change therein. The Contractor acknowledges and agrees that time extensions will be granted only to the extent that excusable delays exceed the available float in the

Contractor's Progress Schedule.

(4) Subject to other provisions of the Contract, the Contractor may be entitled to an extension of the

Contract Time (but no increase in the Contract Price) for delays arising from unforeseeable causes beyond the control and without the fault or negligence of the Contractor, his Subcontractors or Suppliers as follows:

(i) Labor disputes and strikes (including strikes affecting transportation), that do, in fact, directly and critically affect the progress of the Work; however, an extension of Contract time on account of an individual labor strike shall not exceed the number of days of said strike;

(ii) Acts of God, tornado, fire, hurricane, blizzard, earthquake, typhoon, or flood that damage completed work or stored materials.

(iii) Abnormal inclement weather; however, the Contract Time will not be extended due to normal inclement weather. The time for performance of this Contract, as stated in the Contract Documents, includes an allowance for calendar days, which may not be available for construction out-of-doors; for the purposes of the Contract, the Contractor agrees that said number of calendar days per month are to be considered as normal inclement weather. Unless the Contractor can substantiate to the satisfaction of the

S.I. that there was greater than normal inclement weather considering the full term of the Contract Time using a ten year average of accumulated record mean values from climatological data compiled by the U.S.

Department of Commerce, National Oceanic and Atmospheric Administration for the locale of the Project and that such alleged greater than normal inclement weather actually delayed the Work or portions thereof which had an effect upon the Contract Time, the Contractor shall not be entitled to an extension of time. If the total accumulated number of calendar days lost due to inclement weather, from the start of Work until

Final Completion, exceeds the total accumulated number to be expected for the same period from the aforesaid climatological data, time for completion will be extended by the number of calendar days needed to include the excess number of calendar days lost.

(iv) Acts of the public enemy, acts of the state, Federal or local government in its sovereign capacity, and acts of a separate contractor in the performance of its contract with the S.I. relating to the Project.

(5) The Contractor shall not be entitled to and hereby expressly waives any extension of time resulting from any conditions or cause unless said claim for extensions of time is made in writing to the C.O. within seven

(7) days of the first instance of delay. Circumstances and activities leading to such claim shall be indicated or referenced in a daily field inspection report for the day(s) affected; otherwise, all such claims are waived by the Contractor. In every such written claim, the Contractor shall provide the following information:

(i) Nature of the delay;

(ii) Date (or anticipated date) of commencement of delay;

(iii) Activities on the Progress Schedule affected by the delay, and/or new activities created by the delay and their relationship with existing activities;

(iv) Identification of person(s) or organizations(s) or event(s) responsible for the delay;

(v) Anticipated extent of the delay;

(vi) Recommended action to avoid or minimize the delay.

(d) Responsibility for Completion.

(1) The Contractor shall furnish such manpower, materials, facilities and equipment and shall work such hours, including night shifts, overtime operations and Sundays and holidays, as may be necessary to insure the progress and completion of the Work in accordance with the approved and currently updated Progress

F18SOL10019 - 06/12/2018 - Page 14 of 291

Schedule. If Work actually in place falls behind the currently updated and approved Progress Schedule and it becomes apparent from the current Progress Schedule that the Work will not be completed within the

Contract Time, the Contractor agrees that he will, as necessary, take some or all of the following actions at no additional cost to the S.I., as required to eliminate substantially the backlog of the Work:

(i) Increase manpower in quantities and crafts necessary

(ii) Increase the number of work hours per shift, shifts per working day, working days per week, the amount of equipment, or any combination of the foregoing; and/or

(iii) Re-schedule activities to achieve maximum practical concurrence.

(2) The COTR may require the Contractor to submit a Recovery Schedule in accordance with the

Supplementary Construction Contract Clause, demonstrating his program and proposed plan to make up the lag in scheduled progress and to ensure completion of the Work within the Contract Time. If the COTR finds the proposed plan not acceptable, he may require the Contractor to submit a new plan. If the actions taken by the Contractor or the second plan proposed are not satisfactory, the COTR may require the contractor to take any of the actions set forth in this Construction Contract Clause without additional costs to the S.I., to make up the lag in scheduled progress.

(3) Failure of the Contractor to comply substantially with the requirements of this Construction Contract

Clause may be considered grounds for a determination by the S.I., pursuant to the Construction Contract

Clause entitled "Default", that the Contractor is failing to prosecute the Work with the sufficient diligence to ensure its completion with the Contract Time.

52.217-S0093R Auto Renewal Option Clause (Feb 2009)

A. The period of performance for this Contract shall be automatically renewed for 10 successive one (1) year periods, unless the Smithsonian provides a minimum of thirty (30) calendar days notice prior to the end of the current year's expiration date of its desire not to renew the Contract. The term of this agreement shall not extend beyond based on award date plus 10 years. The terms and conditions of the Contract shall remain unchanged for the successive renewal period(s), unless a party provides to the other party, a written request to change the terms and conditions of the Contract a minimum of thirty (30) calendar days prior to the then current expiration date. Said changes shall be mutually agreed upon by the parties and set forth in a separate written modification to the Contract.

The Contract Period of Performance is as follows:

Base of 1year plus 9 one year renewals

B. The above periods represent timeframes in which the Smithsonian Institution may issue Work Orders to the Contractor. The Smithsonian Institution does not guarantee any minimum work or dollar amounts for either the base year or for any renewal year.

C. All requests for increases in Contract Pricing, shall be requested in advance in accordance with not more than annually; adjustment based on changes in the service contract rates applicable to this contract; and shall be set forth as part of a separate written modification to the Contract mutually agreed upon by the parties.

52.228-S0081R Period of Performance-Bonds & Insurance-Construction

Contractor must submit approved Certificate of Insurance and Performance/Payment Bonds within ten (10) days of contract award.

This applies to repair and alteration task orders greater than $50,000.00 in value

52.236-S0036 Smithsonian Institution's Right to Stop or to Suspend the Work (Jun 2000)

F18SOL10019 - 06/12/2018 - Page 15 of 291

(a) If the Contractor fails to correct defective Work as required by the Construction Contract Clause entitled "Correction of Work", or fails to carry out the Work or supply labor and materials in accordance with the Contract Documents, the C.O. by a written order may order the Contractor to stop the Work, or any portion thereof, without monetary compensation to the Contractor until the cause for such order has been eliminated.

(b) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the Work for such period of time as he may determine to be appropriate for the convenience of the

S.I.

(c) If the performance of all or any part of the Work is, for an unreasonable period of time, suspended, delayed, or interrupted by the S.I. or its authorized representatives in the administration of this Contract, or by failure of any one of them to act within the time specified in this Contract (or if no time is specified, within a reasonable time), an adjustment shall be made for an increase in the actual time required for performance of the Work by the Contractor, due solely to such unreasonable suspension, delay, or interruption and the Contract modified in writing accordingly. However, no claim for an extension of time shall be made under this Construction Contract Clause for any suspension, delay, or interruption pursuant to this Construction Contract Clause, or for which claim is provided or excluded under any other provision of this Contract. No claim under this Construction Contract Clause shall be allowed for any claim for an extension of time required for performance, unless within twenty (20) days after the act or failure to act involved, the Contractor submits to the COTR a written statement setting forth, as then practicable, the extent of such claimed time extension and unless the claim for an extension of time is asserted in writing as soon as practicable after the termination of such suspension, delay, or interruption. No claim shall be made for direct or indirect costs incurred by Contractor as a result of the events described in this Construction

Contract Clause, a time extension being the Contractor's sole remedy.

(d) A claim under this clause shall not be allowed (1) for any costs incurred more than twenty (20) days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order), and (2) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

(e) In the event of a suspension of work or delay or interruption of work, the Contractor will and will cause his subcontractors to protect carefully his, and their materials and work against damage or injury from the weather and maintain completed and uncompleted portions of the work as required by the Contract

Documents. If, in the opinion of the COTR, any work or material shall have been damaged or injured by reason of failure on the part of the Contractor or any of his subcontractors to so protect same, such work and materials shall be removed and replaced at the expense of the Contractor.

(f) No claim by the Contractor for an equitable adjustment under the Construction Contract Clause entitled

"Equitable Adjustments", shall be allowed if asserted after Final Payment under this Contract.

52.246-S0041 Additional Warranties and Guarantees (Jun 2000)

(a) The Contractor guarantees and warrants to the S.I. all work as follows:

(1) That all materials and equipment furnished under this Contract will be new and the best of its respective kind unless otherwise specified;

(2) That all Work will be first-class quality and free of omissions and faulty, poor quality, imperfect or defective material or workmanship;

(3) That where no standard is specified for such workmanship or materials, they shall be the best of their respective kinds;

F18SOL10019 - 06/12/2018 - Page 16 of 291

(4) That the Work shall be entirely watertight and leakproof in accordance with all applicable industry customs and practices, and shall be free of shrinkage and settlement, (normal shrinkage inherent in the specified materials is acceptable);

(5) That the Work, including but not limited to, mechanical and electrical machines, devices and equipment shall be fit and fully usable for its intended and specified purpose and shall operate satisfactorily with ordinary care;

(6) That consistent with requirements of the Contract Documents the Work shall be installed and oriented in such a manner as to facilitate unrestricted access for the operation and maintenance of fixed equipment;

(7) That the Work will be free of abnormal or unusual deterioration which occurs because of poor quality materials, workmanship or unsuitable storage.

(b) All work not conforming to guarantees and warranties specified in the Contract Documents, including substitutions not properly approved and authorized, may be considered defective. If required by the COTR, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment.

This warranty is not limited by the provisions of the Construction Contract Clauses entitled "Uncovering of

Work" and "Correction of Work".

(c) The warranties set forth in this Construction Contract Clause entitled "Additional Warranties and

Guarantees" and elsewhere in the Contract Documents shall survive Final Completion of the Work under the Construction Contract Clause entitled "Payments and Completion".

(d) If, within one year after the Date of Final Completion of the Work or designated portion thereof or within one year after acceptance by the S.I. of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract

Documents, any of the Work is found to be defective, not in accordance with the Contract Documents, or not in accordance with the guarantees and warranties specified in the Contract Documents, the Contractor shall correct it within five (5) working days, or such other period as mutually agreed, after receipt of a written notice from the COTR to do so.

(e) Any materials or other portions of the Work, installed, furnished or stored on site which are not of the character or quality required by the specifications, or are otherwise not acceptable to the COTR, shall be immediately removed and replaced by the Contractor to the satisfaction of the COTR, when notified to do so by the COTR.

(f) If the Contractor fails to correct defective or nonconforming Work as required by the Construction

Contract Clause entitled "Correction of Work", or if the Contractor fails to remove defective or nonconforming Work from the site, as required by the Construction Contract Clause entitled "Uncovering of Work", the S.I. may elect to either correct such work in accordance with the Construction Contract

Clause entitled "Smithsonian Institution's Right to Carry Out The Work", or remove and store materials and equipment at the expense of the Contractor.

(g) The Contractor shall bear the cost of making good all work of the S.I., separate contractors or others, destroyed or damaged by such correction or removal required under this Construction Contract Clause or the Construction Contract Clauses entitled "Uncovering of Work" and "Correction of Work", or elsewhere in the Contract Documents.

F18SOL10019 - 06/12/2018 - Page 17 of 291

G - Contract Administration Data

52.202-S0059 Contract Management

Notwithstanding the Contractor's responsibility for total management during the performance of this contract, the administration of the contract will require maximum coordination between the Smithsonian and the Contractor. The following individuals will be the Smithsonian points of contact during the performance of the contract.

52.202-S0060 Contracting Officer

All contract administration will be effected by the Contracting Officer. Communications pertaining to contractual administrative matters will be addressed to the Contracting Officer. No changes in or deviation from the scope of work shall be effected without a written modification to the contract executed by the

Contracting Officer authorizing such changes.

52.202-S0061 Contracting Officer's Technical Representative (COTR) (Apr 1988)

(a) The Contracting Officer's Technical Representative (COTR) Daniel Hoff or his authorized representative shall act for and on behalf of the Contracting Officer in the administration of any resultant contract with respect to:

1. Resolution of issues that may arise between the Contractor and the Smithsonian Institution in connection with such matters as acceptability of workmanship and other technical requirements;

2. Evaluation on an overall basis of the acceptability of workmanship and Contractor's compliance with technical requirements; and

3. The approval and acceptance of work performed under this contract.

(b) This delegation does not authorize the modification of any of the contract's provisions, terms or conditions. All authorities not herein delegated are reserved to the Contracting Officer.

(c) The Contractor shall make available such records, reports and facilities as may be required to carry out this assignment.

52.202-S0062 Authorities

The Contractor is advised that only the Contracting Officer can change or modify the terms of this contract or take any other action which obligates the Smithsonian and then such action must be set forth in a formal modification to the Contract. The authority of the COTR is strictly limited to the specific duties set forth in her letter of appointment, a copy of which will be furnished the Contractor. Contractors who rely on direction from persons other than the Contracting Officer (or a COTR acting within the strict limits of his/her responsibilities as set forth in his/her letter of appointment) do so at their own risk and expense, as such actions do not bind the Smithsonian contractually. All questions concerning the authority of a

Smithsonian employee to direct the Contractor contractually should be referred to the Contracting Officer.

52.213-S0094 Application for Payment

The Contractor shall submit Application for Payment in triplicate copies and in accordance with the

Construction Contract Clauses. All Applications for Payment shall identify the Contract Number and

Project Title and shall be submitted to the COTR at the address specified by the Work Order.

Note: The Prompt Payment Act (31 U.S.C. Section 3901) is not applicable to the Smithsonian Institution.

The Smithsonian Institution shall take all reasonable measures to ensure that payment for invoice(s) properly documented and submitted shall be paid within thirty (30) days from receipt of an approved proper invoice.

F18SOL10019 - 06/12/2018 - Page 18 of 291

52.215-S0002 Authorized Negotiators (Apr 1984)

The offeror or quoter represents that the following persons are authorized to negotiate on its behalf with the

Government in connection with this request for proposals or quotations: [list names, titles, and telephone numbers of the authorized negotiators].

52.215-S0063 Key Personnel

(a) The Contractor shall include the key personnel to be assigned under this contract those persons listed below:

NAME LABOR CATEGORY

Offerors shall also provide this information in their technical proposal.

(b) The persons named above are considered key personnel. The Contractor shall give at least 14 calendar days advance notice if any of these persons are to be removed or diverted from this contract, and shall supply written justification as part of this notice, and shall name the proposed substitute or replacement; but the Contractor will not remove or divert such persons unless authorized by written consent of the

Contracting Officer.

(c) General Approval. All Contractor personnel assigned to this contract are subject to Smithsonian review in accordance with the defined labor categories herein. Contractor personnel found unacceptable by the

Smithsonian at any time shall be removed from performing under this contract within 14 calendar days after notification. Such notification shall be delivered in writing by the Contracting Officer to the

Contractor.

F18SOL10019 - 06/12/2018 - Page 19 of 291

H - Special Contract Requirements

52.202-S0010 Use of Smithsonian Name (Jun 2000)

It is recognized and acknowledged that Contractor shall have no right to use the name "Smithsonian" or

"Smithsonian Institution", or the name of any Smithsonian Museum or part thereof, including the Facilities, in connection with any of its own advertising, marketing or promotion.