CN-550000-C9C56-W0020000.pdf

1. SERVICES AND PERFORMANCE

STATE OF FLORIDA DEPARTMENT OF TRANSPORTATION

STANDARD PROFESSIONAL SERVICES AGREEMENT TERMS

July, 2013

A. Before making any additions or deletions to the work described in the Agreement, and before undertaking any changes or revisions to such work, the parties will negotiate any necessary cost changes and will enter into a Supplemental Agreement covering such work and compensation. Reference herein to the Agreement will be considered to include any Supplemental Agreement.

B. In the performance of professional services, the Consultant will use that degree of care and skill ordinarily exercised by other similar professionals in the field under similar conditions in similar localities. The Consultant will use due care in performing its services and will have due regard for acceptable engineering standards and principles. Consultant's standard of care shall not be altered by the application, interpretation, or construction of any other provision of this Agreement.

C. The Consultant agrees to provide project schedule progress reports in a format acceptable to the Department and at intervals established by the Department. The Department will be entitled at all times to be advised, at its request, as to the status of work being done by the Consultant and of the details thereof. Coordination will be maintained by the Consultant with representatives of the Department, or of other agencies interested in the project on behalf of the Department. Either party to the Agreement may request and be granted a conference.

D. All services will be performed by the Consultant to the satisfaction of the Director who will decide all questions, difficulties and disputes of any nature whatsoever that may arise under or by reason of the Agreement, the prosecution and fulfillment of the services hereunder and the character, quality, amount and value thereof; and the decision upon all claims, questions and disputes will be final and binding upon the parties hereto. Adjustments of compensation and contract time because of any major changes in the work that may become necessary or desirable as the work progresses will be subject to mutual agreement of the parties, and Supplemental Agreement(s) of such a nature as required will be entered into by the parties in accordance herewith.

In the event that the Consultant and the Department are not able to reach an agreement as to the amount of compensation to be paid to the Consultant for supplemental work desired by the Department, the Consultant will be obligated to proceed with the supplemental work in a timely manner for the amount determined by the Department to be reasonable. In such event, the Consultant will have the right to file a claim with the Department for such additional amounts as the consultant deems reasonable; however, in no event will the filing of the claim or the resolution or litigation thereof through administrative procedures or the courts relieve the Consultant from the obligation to timely perform the supplemental work.

E. In the event the work covered by this Agreement includes the preparation of construction plans, it is understood that the work may be divided into two or more construction projects by the Director and that, if this is done, the Consultant will supply construction plans for each project.

F. The Consultant is authorized to use the Department's computer facilities utilizing Department programs required for the performance of the services herein. The Consultant will identify the programs required and submit a written request to the Department's Project Manager for approval.

G. All design work performed by the Consultant for projects where anticipated construction cost is one million dollars ($1,000,000) or more will be subject to Value Engineering. The Department further reserves the right to subject projects of lesser construction cost to Value Engineering should the Department deem circumstances are present that warrant such a decision. Value Engineering may be performed at any stage of the design process. Unless specifically identified in the Agreement, the Consultant will not be required to perform the Value Engineering analysis.

PROCUREMENT

375-030-12

The Consultant will not be liable for use by the Department of plans, documents, studies or other data for any purpose other than intended by the terms of this Consultant Agreement.

H.

All tracings, plans, specifications, maps, computer files and/or reports prepared or obtained under this Agreement, as well as all data collected, together with summaries and charts derived therefrom, will be considered works made for hire and will become the property of the Department upon completion or termination without restriction or limitation on their use and will be made available, upon request, to the Department at any time during the performance of such services and/or upon completion or termination of this Agreement. Upon delivery to the Department of said document(s), the Department will become the custodian thereof in accordance with Chapter 119, Florida Statutes. The Consultant will not copyright any material and products or patent any invention developed under this agreement. The Department will have the right to visit the site for inspection of the work and the products of the Consultant at any time.

I.

Services required after completion of scheduled project services, including, but not limited to, design assistance, construction assistance, and litigation assistance, will be completed within the term of this Agreement at written direction of the department. Supplemental Agreements may be negotiated for any post project schedule services needed by the Department after scheduled project services.

A.

TERM:2.

In the event it becomes impracticable or impossible for the Consultant to complete the expected services within the term of this Agreement due to delays on the part of the department or circumstances beyond the control of the Consultant, the Agreement may be extended. An extension of the Agreement must be in writing.

Page A1 of 8

B. In the event there are delays caused by the Department in approval of any of the materials submitted by the Consultant or if there are delays occasioned by circumstances beyond the control and without fault or negligence of the Consultant which delay the scheduled project completion date, the Department may grant an extension of time equal to the aforementioned project schedule delay, as a minimum and not to exceed the Agreement term, by issuance of a Time Extension Letter. This letter will be for time only and does not include any additional compensation.

It will be the responsibility of the Consultant to ensure at all times that sufficient time remains in the Project Schedule within which to complete the services on the project. In the event there have been delays which would affect the project completion date, the Consultant will submit a written request to the Department which identifies the reason(s) for the delay, the amount of time related to each reason and specific indication as to whether or not the delays were concurrent with one another. The Department will review the request and make a determination as to granting all or part of the requested extension.

In the event time for performance of the scheduled project services expires and the Consultant has not requested, or if the Department has denied, an extension of the Project Schedule completion date; partial progress payments will be stopped on the date time expires. No payment shall be made for work performed after the Project Schedule completion date until a time extension is granted or all work has been completed and accepted by the Department if the Agreement term has not expired.

COMPENSATION:3.

Bills for fees or other compensation for services or expenses will be submitted to the Department in detail sufficient for a proper preaudit and postaudit thereof. The Department will render approval or disapproval of services within five working days of the receipt of a written progress report unless otherwise stated in the Agreement. The progress report will be accompanied by an appropriate invoice.

A.

PROCUREMENT

375-030-12

The bills for any travel expenses, when authorized by terms of this Agreement and by the Department's Project Manager, will be submitted in accordance with Section 112.061, Florida Statutes.

B.

Records of costs incurred under terms of this Agreement will be maintained and made available upon request to the Department at all times during the period of this Agreement and for three years after final payment for the work pursuant to this Agreement is made. Copies of these documents and records will be furnished to the Department upon request.

C.

Records of costs incurred will include the Consultant's general accounting records and the project records, together with supporting documents and records, of the Consultant and all subconsultants performing work on the project, and all other records of the Consultant and subconsultants considered necessary by the Department for a proper audit of project costs.

A Vendor Ombudsman has been established within the Department of Financial Services. The duties of this individual include acting as an advocate for vendors who may be experiencing problems in obtaining timely payment(s) from a state agency. The Vendor Ombudsman may be contacted at (850) 413-5516.

H.

If a payment is not available within 40 days, a separate interest penalty at a rate established pursuant to Section 215.422, Florida Statutes, will be due and payable, in addition to the invoice amount, to the Consultant. Interest penalties of less than one dollar will not be paid unless the Consultant requests payment. Invoices which have to be returned to a Consultant because of Consultant preparation errors will result in a delay in the payment. The invoice payment requirements do not start until a properly completed invoice is provided to the Department.

G.

The Consultant should be aware of the following time frames. Upon receipt, the Department has five (5) working days to inspect and approve the goods and services, unless the Agreement specifies otherwise. The Department has 20 days to deliver a request for payment (voucher) to the Department of Financial Services. The 20 days are measured from the latter of the date the invoice is received or the goods or services are received, inspected and approved.

F.

The general cost principles and procedures for the negotiation and administration, and the determination or allowance of costs under this Agreement will be as set forth in the Code of Federal Regulations, Titles 23, 48, 49, Rule Chapter 14-75, Florida Administrative Code, and other pertinent Federal and State Regulations, as applicable, with the understanding that there is no conflict between State regulations and Federal regulations in that the more restrictive of the applicable regulations will govern.

E.

D.

Except for issues arising from contract indemnification provisions, the Department will have the right to retain out of any payment due the Consultant under this Agreement an amount sufficient to satisfy any amount due and owing to the Department by the Consultant on any other Agreement between the Consultant and the Department. The Department may withhold payment on any invoice in the event that the Consultant is in default under any provision of this Agreement or any other Agreement between the Consultant and the Department as of the time of processing the invoice or as of the time payment is made available on the invoice. This right to withhold will continue until such time as the default has been cured, and, upon cure, the Department will have the right to retain an amount equal to the damages suffered as a result of the default.

I.

Page A2 of 8

J. It is mutually agreed and understood that the following provision will be applicable to this Agreement if the compensation to be paid to the Consultant, whether by lump sum or cost-plus-a-fixed-fee, will exceed the threshold amount provided in Section 287.017, Florida Statutes, for CATEGORY FOUR.

PROCUREMENT

375-030-12

The Department, during any fiscal year, will not expend money, incur any liability, or enter into any contract which, by its terms, involves the expenditure of money in excess of the amounts budgeted as available for expenditure during such fiscal year. Any contract, verbal or written, made in violation of this subsection is null and void, and no money may be paid on such contract. The Department will require a statement from the comptroller of the Department that funds are available prior to entering into any such contract or other binding commitment of funds. Nothing herein contained will prevent the making of contracts for periods exceeding one year, but any contract so made shall be executory only for the value of the services to be rendered or agreed to be paid for in succeeding fiscal years.

Accordingly, the Department's performance and obligation to pay under this Agreement is contingent upon an annual appropriation by the Legislature.

K.

The Consultant hereby certifies, covenants and warrants that wage rates and other factual unit costs provided the Department to support the compensation are accurate, complete and current as of the date of this Agreement. It is further agreed that the Agreement price will be adjusted to exclude any significant sums by which the Department determines the Agreement price was increased due to inaccurate, incomplete or non-current wage rates and other factual unit costs. All such Agreement adjustments must be made within one year following the end of the Agreement. For this purpose, the end of the Agreement is the date of final billing or acceptance of the work by the Department, whichever is later.

If the Consultant is an individual or entity licensed by the state of Florida who holds a current certificate of registration under Chapter 481, Florida Statutes, to practice architecture or landscape architecture, under Chapter 472, Florida Statutes, to practice land surveying and mapping, or under Chapter 471, Florida Statutes, to practice engineering, and who enters into a written agreement with the Department relating to the planning, design, construction, administration, study, evaluation, consulting, or other professional and technical support services furnished in connection with any actual or proposed construction improvement, alteration, repair, maintenance, operation, management, relocation, demolition, excavation, or other facility, land, air, water, or utility development or improvement, the Consultant will indemnify and hold harmless the Department, and its officers and employees, from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the Consultant and other persons employed or utilized by the Consultant in the performance of the contract.

The parties agree that 1% of the total compensation to the Consultant for performance of this Agreement is the specific consideration from the Department to the Consultant for the Consultant's indemnity agreement.

A.

INDEMNITY AND INSURANCE:4.

The Consultant will have and maintain during the term of this Agreement, a professional liability insurance policy or policies, or an irrevocable letter of credit established pursuant to Chapter 675 and Section 337.106, Florida Statutes, with a company or companies authorized to do business in the State of Florida, affording professional liability coverage for the professional services to be rendered in accordance with this Agreement in the amount specified in the Agreement.

Under the terms of this agreement, the plans, reports and recommendations of the Consultant will be reviewed by the Department for conformity with Department standards and agreement terms. However, review by the Department does not constitute detailed review or checking of design components and related details, or the accuracy with which designs are depicted on the plans.

C.

B.

Acceptance of the work by the Department or Agreement termination does not constitute Department approval and will not relieve the Consultant of the responsibility for subsequent corrections of any errors and/or omissions and the clarification of any ambiguities. The Consultant shall make all necessary revisions or corrections resulting from errors and/or omissions on the part of the Consultant without additional compensation. If these errors and/or omissions are discovered during the construction of the project, they shall be corrected without additional compensation.

D.

COMPLIANCE WITH LAWS:5.

All final plans, documents, reports, studies and other data prepared by the Consultant shall bear the professional's seal/ signature, in accordance with the applicable Florida Statute that governs and Administrative Rules promulgated by the Department of Business and Professional Regulation, and guidelines published by the Department, in effect at the time of execution of this Agreement. In the event that changes in the Statute or Rules create a conflict with the requirements of the published guidelines, requirements of the Statute and/or Rules shall take precedence.

Chapter 337.162 Florida Statutes applies as follows:B.

A.

If the Department has knowledge or reason to believe that any person has violated the provisions of state professional licensing laws or rules, it will submit a complaint about the violations to the Department of Business and Professional Regulation. The complaint will be confidential.

(1)

Page A3 of 8

PROCUREMENT

375-030-12

Any person who is employed by the Department and who is licensed by the Department of Business and Professional Regulation and who, through the course of his employment, has knowledge to believe that any person has violated the provisions of state professional licensing laws or rules will submit a complaint about the violations to the Department of Business and Professional Regulation. Failure to submit a complaint about the violations may be grounds for disciplinary action pursuant to Chapter 455 and the state licensing law applicable to that licensee. The complaint will be confidential.

(2)

Any confidential information submitted to the Department of Business and Professional Regulation will remain confidential pursuant to Chapter 455 and applicable state law.

(3)

The Consultant shall allow public access to all documents, papers, letters, or other material subject to the provisions of Chapter 119, Florida Statutes, and made or received by the Consultant in conjunction with this Agreement. Specifically, if the Consultant is acting on behalf of a public agency the Consultant shall:

E.

The Consultant warrants that the Consultant has not employed or retained any company or person, other than a bona fide employee working solely for the Consultant, to solicit or secure this Agreement, and that he has not paid or agreed to pay any person, company, corporation, individual, or firm any fee, commission, percentage, gift or any other consideration, contingent upon or resulting from the award or making of this Agreement. It is understood and agreed that the term "fee" shall also include brokerage fee, however denoted. For the breach or violation of this Paragraph, the Department shall have the right to terminate this Agreement without liability, and, at its discretion, to deduct from the contract price, or otherwise recover, the full amount of such fee, commission, percentage, gift or consideration.

D.

The Consultant will comply with all federal, state and local laws and ordinances applicable to the work or payment for work thereof, and will not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the performance of work under this Agreement.

C.

The Consultant agrees that it will make no statements, press releases or publicity releases concerning this Agreement or its subject matter or otherwise disclose or permit to be disclosed any of the data or other information obtained or furnished in compliance with this Agreement, or any particulars thereof, during the period of the Agreement, without first notifying the Department and securing its consent in writing. The Consultant also agrees that it will not publish, copyright or patent any of the data developed under this Agreement, it being understood that such data or information is the property of the Department.

F.

Meet all requirements for retaining public records and transfer, at no cost, to the Department all public records in possession of the Consultant upon termination of the contract and destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. All records stored electronically must be provided to the Department in a format that is compatible with the information technology systems of the Department.

(4)

Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law.

(3)

Provide the public with access to public records on the same terms and conditions that the Department would provide the records and at a cost that does not exceed the cost provided in Chapter 119, Florida Statutes, or as otherwise provided by law.

(2)

(1) Keep and maintain public records that ordinarily and necessarily would be required by the Department in order to perform the services being performed by the Consultant.

Consultant covenants and agrees that it and its employees will be bound by the standards of conduct provided in applicable Florida Statutes and applicable rules of the Department of Business and Professional Regulation as they relate to work performed under this Agreement. Consultant further covenants and agrees that when a former state employee is employed by the Consultant, the Consultant will require that strict adherence by the former state employee to Florida Statutes 112.313(9) and 112.3185 is a condition of employment of said former state employee. These statutes will by reference be made a part of this Agreement as though set forth in full. Consultant agrees to incorporate the provisions of this paragraph in any subcontract into which it might enter with reference to the work performed pursuant to this Agreement.

G.

Failure by the Consultant to grant such public access shall be grounds for immediate unilateral cancellation of this Agreement by the Department. The Consultant shall promptly provide the Department with a copy of any request to inspect or copy public records in possession of the Consultant and shall promptly provide the Department a copy of the Consultant's response to each such request.

Page A4 of 8

H. A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity, and may not transact business with any public entity in excess of the threshold amount provided in Section 287.017, for CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list.

I. The Department will consider the employment by any contractor of unauthorized aliens a violation of Section 274A(e) of the Immigration and Nationality Act. Such violation will be cause for unilateral cancellation of this Agreement, by the Department, if the Consultant knowingly employs unauthorized aliens.

DISCRIMINATION: An entity or affiliate who has been placed on the discriminatory vendor list may not submit a bid on a contract to provide goods or services to a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building or public work, may not submit bids on leases of real property to a public entity, may not award or perform work as a contractor, supplier, subcontractor, or consultant under contract with any public entity, and may not transact business with any public entity.

J.

The Department may terminate this Agreement in whole or in part at any time the interest of the Department requires such termination, as follows:

TERMINATION AND DEFAULT6.

A.

(1) If the Department determines that the performance of the Consultant is not satisfactory, the Department may notify the Consultant of the deficiency with the requirement that the deficiency be corrected within a specified time; but not less than 10 days. Otherwise the Agreement will be terminated at the end of such time or thirty

(30) days whichever is sooner.

(2) If the Department requires termination of the Agreement for reasons other than unsatisfactory performance of the Consultant, the Department will notify the Consultant of such termination, with instructions as to the effective date of work stoppage or specify the stage of work at which the Agreement is to be terminated.

(3) If the Agreement is terminated before performance is completed, the Consultant will be paid for the work satisfactorily performed. Payment is to be on the basis of substantiated costs, not to exceed an amount which is the same percentage of the contract price as the amount of work satisfactorily completed is a percentage of the total work called for by the Agreement.

B. The Department reserves the right to cancel and terminate this Agreement in the event the Consultant or any employee or agent of the Consultant is convicted for any crime arising out of or in conjunction with any work being performed by the consultant for or on behalf of the Department, without penalty. It is understood and agreed that in the event of such termination, all tracings, plans specifications, computer files, maps, and data prepared or obtained under this Agreement will immediately be turned over to the Department . The Department reserves the right to terminate or cancel this Agreement in the event the Consultant will be placed in either voluntary or involuntary bankruptcy or an assignment be made for the benefit of creditors. The Department further reserves the right to suspend the qualifications of the Consultant to do business with the Department upon any such conviction.

If the Agreement is for goods or services of $1 million or more and was entered into or renewed on or after July 1, 2011 and the Department determines that the Vendor submitted a false certification under Section 287.135(5), Florida Statutes, or if the Vendor has been placed on the Scrutinized Companies with Activities in the Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, the Department shall have the option of (1) terminating the Agreement after it has given the Vendor notice and an opportunity to demonstrate the agency's determination of false certification was in error pursuant to Section 287.135(5)(a), Florida Statutes, or (2) maintaining the Agreement if the conditions of Section 287.135(4), Florida Statutes, are met.

C.

The Consultant will maintain an adequate and competent professional staff so as to enable Consultant to timely perform under this Agreement and must be authorized to do business within the State of Florida and may associate with it such subconsultants, for the purpose of its services hereunder, without additional cost to the Department, other than those costs negotiated within the limits and terms of this Agreement. The Consultant is fully responsible for satisfactory completion of all subcontracted work. The Consultant, however, will not sublet, assign or transfer any work under this Agreement to other than subconsultants specified in the Agreement without the written consent of the Department.

A.

ASSIGNMENT AND SUBCONTRACTORS7.

Page A5 of 8

B. The Consultant must state in all subcontracts that services performed by any such subconsultant will be subject to the Professional Consultant Work Performance Evaluation System as defined in Chapter 14-75, Florida Administrative Code.

C. The following provision is hereby incorporated in and made a part of this Agreement when the services provided herein do not involve the expenditure of Federal funds:

It is expressly understood and agreed that any articles which are the subject of, or required to carry out this contract will be purchased from the Corporation identified under Chapter 946, Florida Statutes, in the same manner and under the same procedures set forth in Section 946.515(2) and (4), Florida Statutes; and for purposes of this contract the person, firm, or other business entity carrying out the provisions of this contract will be deemed to be substituted for this agency insofar as dealings with such Corporation.

PRIDE Enterprises 12425 28th Street North Suite 300 St Petersburg, Florida 33716

In any legal action related to this Agreement, instituted by either party, Consultant hereby waives any and all privileges and rights it may have under chapter 47 and Section 337.19, Florida Statutes, relating to venue, as it now exists or may hereafter be amended, and any and all such privileges and rights it may have under any other statute, rule or case law, including, but not limited to those grounded on convenience. Any such legal action may be brought in the appropriate Court in any county chosen by the Department and in the event that any such legal action is filed by Consultant, Consultant hereby consents to the transfer of venue to the county chosen by the Department upon the Department filing a motion requesting the same.

MISCELLANEOUS8.

A. All words used herein in the singular form will extend to and include the plural. All words used in the plural form will extend to and include the singular. All words used in any gender will extend to and include all genders.

B. In the event that a court of valid jurisdiction finally determines that any provision of this Agreement is illegal or unenforceable, this Agreement will be construed as not containing such provision, and all other provisions which are otherwise lawful will remain in full force and effect, and to this end the provisions of this Agreement are declared to be severable.

C. There are no understandings or agreements except as herein expressly stated.

D. This Agreement will be governed by and construed in accordance with the laws of the State of Florida.

E.

The Corporation referred to in the above paragraph is Prison Rehabilitative Industries and Diversified Enterprises, Inc.

Available pricing, products, and delivery schedules may be obtained by contacting:

shall utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the Consultant during the term of the contract; and

1.

2. shall expressly require any subcontractors performing work or providing services pursuant to the state contract to likewise utilize the U.S. Department of Homeland Security's E-Verify system to verify the employment eligibility of all new employees hired by the subcontractor during the contract term.

Consultant:F.

It is understood and agreed that, in order to permit federal participation, no supplemental agreement of any nature may be entered into by the parties hereto with regard to the work to be performed hereunder without the approval of the U.S.

Department of Transportation, anything to the contrary in this Agreement not withstanding.

B.

It is understood and agreed that all rights of the Department relating to inspection, review, approval, patents, copyrights, and audit of the work, tracing, plans, specifications, maps, data, and cost records relating to this Agreement shall also be reserved and held by authorized representatives of the United States of America.

A.

The following terms apply to all contracts in which it is indicated in Section 6.B of the Standard Professional Services Agreement that the services involve the expenditure of federal funds:

TERMS FOR FEDERAL AID CONTRACTS (APPENDIX I):9.

Page A6 of 8

C. Compliance with Regulations: The Consultant shall comply with the Regulations of the U.S. Department of Transportation Title 49, Code of Federal Regulations, Part 21, as they may be amended from time to time, (hereinafter referred to as the Regulations), which are herein incorporated by reference and made a part of this Agreement.

PROCUREMENT

375-030-12

D. Nondiscrimination: The Consultant, with regard to the work performed during the contract, shall not discriminate on the basis of race, color, national origin, sex, age, disability, religion or family status in the selection and retention of subcontractors, including procurements of material and leases of equipment. The Consultant will not participate either directly or indirectly in the discrimination prohibited by Section 21.5 of the Regulations, including employment practices when the contract covers a program set forth in Appendix B of the Regulations.

Solicitations for Subcontracts, Including Procurements of Materials and Equipment: In all solicitations made by the Consultant, either by competitive bidding or negotiation for work to be performed under a subcontract, including procurements of materials and leases of equipment, each potential subcontractor or supplier shall be notified by the Consultant of the Consultant's obligations under this contract and the Regulations relative to nondiscrimination on the basis of race, color, national origin, sex, age, disability, religion or family status.

1.

2. cancellation, termination or suspension of the contract, in whole or in part.

withholding of payments to the Consultant under the contract until the Consultant complies and/or

Sanctions for Noncompliance: In the event of the Consultant's noncompliance with the nondiscrimination provisions of this contract, the Florida Department of Transportation shall impose such contract sanctions as it or the Federal Highway Administration, Federal Transit Administration, Federal Aviation Administration, and/or Federal Motor Carrier Safety Administration may determine to be appropriate, including, but not limited to, G.

Information and Reports: The Consultant will provide all information and reports required by the Regulations, or directives issued pursuant thereto, and will permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the Florida Department of Transportation, Federal Highway Administration, Federal Transit Administration, Federal Aviation Administration, and/or Federal Motor Carrier Safety Administration to be pertinent to ascertain compliance with such Regulations, orders and instructions. Where any information required of the Consultant is in the exclusive possession of another who fails or refuses to furnish this information, the Consultant shall so certify to the Florida Department of Transportation, Federal Highway Administration, Federal Transit Administration, Federal Aviation Administration, and/or the Federal Motor Carrier Safety Administrationas appropriate, and shall set forth what efforts it has made to obtain the information.

F.

E.

Incorporation or Provisions: The Consultant will include the provisions of Paragraph C through H in every subcontract, including procurements of materials and leases of equipment unless exempt by the Regulations, order, or instructions issued pursuant thereto. The Consultant will take such action with respect to any subcontract or procurement as the Florida Department of Transportation, Federal Highway Administration, Federal Transit Administration, Federal Aviation Administration, and/or the Federal Motor Carrier Safety Administration may direct as a means of enforcing such provisions, including sanctions for noncompliance. In the event a Consultant becomes involved in, or is threatened with, litigation with a subcontractor or supplier as a result of such direction, the Consultant may request the Florida Department of Transportation to enter into such litigation to protect the interests of the Florida Department of Transportation, and, in addition, the Consultant may request the United States to enter into such litigation to protect the interests of the United States.

Interest of Public Officials: No member, officer, or employee of the public body or of a local public body during his tenure or for one year thereafter shall have any interest, direct or indirect, in this contract or the proceeds thereof. For purposes of this provision, public body shall include municipalities and other political subdivisions of States; and public corporations, boards, and commissions established under the laws of any State.

J.

Interest of Members of Congress: No member of or delegate to the Congress of the United States will be admitted to any share or part of this contract or to any benefit arising therefrom.

I.

H.

The Consultant, sub recipient or subcontractor shall not discriminate on the basis of race, color, national origin, or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 CFR Part 26 in the award and administration of DOT-assisted contracts. Failure by the Consultant to carry out these requirements is a material breach of this contract, which may result in termination of this contract or other such remedy as the recipient deems appropriate.

Participation by Disadvantaged Business Enterprises: The Consultant shall agree to abide by the following statement from 49 CFR 26.13(b). This statements shall be included in all subsequent agreements between the Consultant and any subconsultant or contractor.

K.

Page A7 of 8

L. It is mutually understood and agreed that the willful falsification, distortion or misrepresentation with respect to any facts related to the project(s) described in this Agreement is a violation of the Federal Law. Accordingly, United States Code, Title 18, Section 1020, is hereby incorporated by reference and made a part of this Agreement.

M. It is understood and agreed that if the Consultant at any time learns that the certification it provided the Department in compliance with 49 CFR, Section 26.51, was erroneous when submitted or has become erroneous by reason of changed circumstances, the Consultant shall provide immediate written notice to the Department. It is further agreed that the clause titled "Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transaction" as set forth in 49 CFR, Section 29.510, shall be included by the Consultant in all lower tier covered transactions and in all aforementioned federal regulation.

The Department hereby certifies that neither the consultant nor the consultant's representative has been required by the Department, directly or indirectly as an express or implied condition in connection with obtaining or carrying out this contract, to pay, or agree to pay, to any firm, person, or organization, any fee, contribution, donation, or consideration of any kind;

O. The Consultant hereby certifies that it has not:

1. employed or retained for a commission, percentage, brokerage, contingent fee, or other consideration, any firm or person (other than a bona fide employee working solely for the above contractor) to solicit or secure this contract;

2. agreed, as an express or implied condition for obtaining this contract, to employ or retain the services of any firm or person in connection with carrying out this contract; or

The consultant further acknowledges that this agreement will be furnished to the State of Florida Department of Transportation and a federal agency in connection with this contract involving participation of Federal-Aid funds, and is subject to applicable State and Federal Laws, both criminal and civil.

3. paid, or agreed to pay, to any firm, organization or person (other than a bona fide employee working solely for the above contractor) any fee contribution, donation, or consideration of any kind for, or in connection with, procuring or carrying out the contract.

N.

1. employ or retain, or agree to employ or retain, any firm or person, or

2.

The Department further acknowledges that this agreement will be furnished to a federal agency, in connection with this contract involving participation of Federal-Aid funds, and is subject to applicable State and Federal Laws, both criminal and civil.

Page A8 of 8

EXHIBIT "A"

CONSTRUCTION ENGINEERING AND INSPECTION

SCOPE OF SERVICES

FOR

US 17-92 Intersection @ SR 436

US 441 from Gore to South of Central Blvd

US 441 from 34th Street to SR 50

US 192 Lake County line to East of Secret Lake

I-4 Dynamic Message Sign Replacement Phase II

Financial Project ID(s):

404418-1-62-01

429054-1-62-01

427228-1-62-02

239304-1-62-02

432149-1-62-01

Federal Project No.:

3521 006 P

N/A

1.0 PURPOSE

TABLE OF CONTENTS

2.0 SCOPE

3.0 LENGTH OF SERVICE

4.0 DEFINITIONS

5.0 ITEMS TO BE FURNISHED BY THE DEPARTMENT TO CONSULTANT

6.0 ITEMS FURNISHED BY THE CONSULTANT

6.1 DEPARTMENT DOCUMENTS

6.2 OFFICE AUTOMATION

6.3 FIELD OFFICE

6.4 VEHICLES

6.5 FIELD EQUIPMENT

6.6 LICENSING FOR EQUIPMENT OPERATIONS

7.0 LIAISON

8.0 PERFORMANCE OF THE CONSULTANT

9.0 REQUIREMENTS

9.1 GENERAL

9.2 SURVEY CONTROL

9.3 ON-SITE INSPECTION

9.4 SAMPLING AND TESTING

9.5 ENGINEERING SERVICES

9.8 GEOTECHNICAL ENGINEERING

10.0 PERSONNEL

10.1 GENERAL REQUIREMENTS

10.2 PERSONNEL QUALIFICATIONS

10.3 STAFFING

11.0 QUALITY ASSURANCE PROGRAM

11.2 QA PLAN

11.1 QUALITY REVIEWS

11.3 QUALITY RECORDS

12.0 CERTIFICATION OF FINAL ESTIMATES

12.1 FINAL ESTIMATE AND AS-BUILT PLANS SUBMITTAL

12.2 CERTIFICATION

12.2 OFFER OF FINAL PAYMENT

13.0 AGREEMENT MANAGEMENT

13.1 GENERAL

13.2 INVOICING INSTRUCTIONS

14.0 OTHER SERVICES

15.0 POST CONSTRUCTION CLAIMS REVIEW

16.0 CONTRADICTIONS

17.0 THIRD PARTY BENEFICIARY

18.0 DEPARTMENT AUTHORITY

Financial Project ID (s): 404418-1-62-01, 4429054-1-62-01, 427228-1-62-02 , 239304-1-62-02 and432149-1-62-01

Stage III A-1 August 2013

1.0

SCOPE OF SERVICES

CONSTRUCTION ENGINEERING AND INSPECTION

This scope of services describes and defines the Construction Engineering and Inspection (CEI) services which are required for contract administration, inspection, and materials sampling and testing for the construction projects listed below.

PURPOSE:

2.0

Provide services as defined in this Scope of Services, the referenced Department manuals, and procedures.

SCOPE:

The projects for which the services are required are:

FPN Description County

404418-1-62-01 US 17-92 Intersection @ SR 436 Seminole

429054-1-62-01 US 441 From Gore to South of Central Blvd Orange

427228-1-62-02 US 441 from 34th Street to SR 50

239304-1-62-02 US 192 Lake County line to East of Secret Lake Orange

432149-1-62-01 I-4 Dynamic Message Sign Replacement Phase II Orange, Brevard, Osceola

Exercise independent professional judgment in performing obligations and responsibilities under this Agreement. Pursuant to Section 4.1.4 of the Construction Project Administration Manual (CPAM), the authority of the Consultant’s lead person, such as the Senior Project Engineer, and the Consultant’s Project Administrator shall be identical to the Department’s Resident Engineer and Project Administrator respectively and shall be interpreted as such.

Services provided by the Consultant shall comply with Department manuals, procedures, and memorandums in effect as of the date of execution of the Agreement unless otherwise directed in writing by the Department. Such Department manuals, procedures, and memorandums are found at the State Construction Office’s website.

On a single Construction Contract, it is a conflict of interest for a professional firm to receive compensation from both the Department and the Contractor either directly or indirectly.

Other projects developing within the geographical area of Orange, Osceola, Seminole, Lake, Volusia and Brevard counties may be added at the Department’s discretion. The Consultant must perform to the satisfaction of the Department’s representatives for consideration of additional CEI services.

Stage III A-2 August 2013

3.0

The services for each Construction Contract shall begin upon written notification to proceed by the Department.

LENGTH OF SERVICE:

Track the execution of the Construction Contract such that the Consultant is given timely authorization to begin work. While no personnel shall be assigned until written notification by the Department has been issued, the Consultant shall be ready to assign personnel within two weeks of notification. For the duration of the project, coordinate closely with the Department and Contractor to minimize rescheduling of Consultant activities due to construction delays or changes in scheduling of Contractor activities.

For estimating purposes, the Consultant will be allowed an accumulation of thirty (30) calendar days to perform preliminary administrative services prior to the issuance of the Contractor's notice to proceed on the first project and thirty (30) calendar days to demobilize after final acceptance of the last Construction Contract.

The anticipated letting schedules and construction times for the projects are tabulated below:

Construction Contract Estimate Financial Project ID

Letting Date (Mo/Day/Yr)

Start Date (Mo/Day/Yr)

Innovative Contract

Duration* (Days)

404418-1-62-01 07/25/13 09/24/13 Design Build 754 429054-1-62-01

05/22/13

08/20/13

N/A 380 427228-1-62-02 239304-1-62-02 06/26/13 08/26/13 Design Build 345 432149-1-62-01 TBD TBD Design Build 365*

*Preliminary Time Estimate: Design Build contract time will be established by D/B contractor.

4.0

A.

DEFINITIONS:

Agreement

B.

: The Professional Services Agreement between the Department and the Consultant setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of services, and the basis of payment.

Contractor

C.

: The individual, firm, or company contracting with the Department for performance of work or furnishing of materials.

Construction Contract

D.

: The written agreement between the Department and the Contrac-tor setting forth the obligations of the parties thereto, including but not limited to the performance of the work, furnishing of labor and materials, and the basis of payment.

Construction Project Manager

E.

: The Department employee assigned to manage the Construction Engineering and Inspection Contract and represent the Department during the performance of the services covered under this Agreement.

Construction Training/Qualification Program (CTQP): The Department program for training and qualifying technicians in Aggregates, Asphalt, Concrete, Earthwork, and Final Estimates Administration. Program information is available at CTQP website.

Stage III A-3 August 2013

F. Consultant

G.

: The Consulting firm under contract to the Department for administration of Construction Engineering and Inspection services.

Consultant Project Administrator

H.

: The employee assigned by the Consultant to be in charge of providing Construction Contract administration services for one or more Construction Projects.

Consultant Senior Project Engineer

I.

: The Engineer assigned by the Consultant to be in charge of providing Construction Contract administration for one or more Construction Projects. This person may supervise other Consultant employees and act as the lead Engineer for the Consultant.

District Construction Engineer

J.

: The administrative head of the District’s Construction Offices.

District Contract Compliance Manager:

K.

The administrative head of the District Contract Compliance Office.

District Consultant CEI Manager

L.

: The Department employee assigned to administer the Consultant Construction Engineering and Inspection (CCEI) Program in the District.

District Director of Transportation Operations

M.

: The Director of Construction, Maintenance, Traffic Operations, Materials, and Safety.

District Final Estimates Manager:

N.

The administrative head of the District Final Estimates Office.

District Professional Services Administrator

O.

: The Administrative Head of the Pro-fessional Services Office.

District Secretary

P.

: The Chief Executive Officer in each of the Department's eight (8) Districts.

Engineer of Record

Q.

: The Engineer noted on the Construction plans as the responsible person for the design and preparation of the plans.

Operations Engineer:

R.

The Engineer assigned to a particular County or area to administer Construction and Maintenance Contracts for the Department.

Public Information Office

S.

: The Department’s office assigned to manage the Public Information Program.

Resident Compliance Specialist:

T.

The employee assigned by the Consultant to oversee project specific compliance functions.

Resident Engineer: The Engineer assigned to a particular County or area to administer Construction Contracts for the Department.

Stage III A-4 August 2013

5.0

A. The Department, on an as needed basis, will furnish the following Construction Contract documents for each project. These documents may be provided in either paper or electronic format.

ITEMS TO BE FURNISHED BY THE DEPARTMENT TO THE CONSULTANT:

1. Construction Plans,

2. Specification Package,

3. Copy of the Executed Construction Contract, and

4. Utility Agency’s Approved Material List (if applicable).

B. The Department will allow connection to the FDOT Network by the Consultant through either dialup communications, authorized Virtual Private Network (VPN) or approved leased lines. Appropriate approvals must be received from the Department prior to their use.

C. The Department will furnish and support the software packages for SiteManager.

6.0

6.1

ITEMS FURNISHED BY THE CONSULTANT:

All applicable Department documents referenced herein shall be a condition of this Agreement. All Department documents, directives, procedures, and standard forms are available through the Department’s Internet website. Most items can be purchased through the following address.