Contract No. C26146F

Request for Pre-Qualification of

Bidders

Guadalupe Division - Guard House

Issued September 21, 2026

This page intentionally left blank

Contract C26146F

Santa Clara Valley Transportation Authority Table of Contents Rev. 01/01/20 Page 1

TABLE OF CONTENTS

Table of Contents

NOTICE

A. SOLICITATION OF BIDS

B. OBTAINING THE REQUEST FOR PRE-QUALIFCATION

C. SUBMITTAL LOCATION AND DEADLINE

D. INQUIRIES

E. NOTICE OF DETERMINATION

F. BIDDING PERIOD

G. VALIDATION OF PRIOR PRE-QUALIFICATION

INTRODUCTION TO THE REQUEST FOR PRE-QUALIFICATION

A. PROJECT BACKGROUND

B. Reserved

C. PROCUREMENT PROCESS: PREQUALIFICATION PROCUREMENT

D. PROJECT SCHEDULE

E. PREPARATION OF THE SOQ SUBMITTAL

F. EVALUATION AND ANALYSIS

G. NOTICE OF APPEAL

H. GENERAL CONTRACTOR

I. CONFIDENTIALITY

J. RESERVATION OF RIGHTS OF VTA

EXHIBIT A: VALIDATION STATEMENT

PRE-QUALIFICATION QUESTIONNAIRE

PART I: CONTACT INFORMATION

A. BIDDER’S CONTACT INFORMATION

B. EXECUTION AND CERTIFICATION

PART II: ESSENTIAL REQUIREMENTS FOR QUALIFICATION

PART III: ORGANIZATION HISTORY, ORGANIZATIONAL PERFORMANCE, COMPLIANCE WITH CIVIL

AND CRIMINAL LAWS

A. Current Organization and Structure of the Business For Firms That Are Corporations:

For Firms That Are Partnerships:

For Firms That Are Sole Proprietorships:

For Firms That Intend to Make a Bid as Part of a Joint Venture:

History of the Business and Organizational Performance

Santa Clara Valley Transportation Authority Table of Contents Rev. 01/01/20 Page 2

Scored Questions Licenses Disputes Criminal Matters and Related Civil Suits Bonding Compliance with Occupational Safety and Health Laws and with Other Labor Legislation Safety Prevailing Wage and Apprenticeship Compliance Record Not Scored - For Information Only

PART IV: RECENT CONSTRUCTION PROJECTS COMPLETED

ATTACHMENT 1: STATEMENT OF QUALIFICATION CERTIFICATION FORM

APPENDIX A: PROJECT SITE INFORMATION

APPENDIX B: SCORING MATRIX

APPENDIX C: INTERVIEW QUESTIONNAIRE

NOTES:

ATTACHMENT 1 STATEMENT OF QUALIFICATION CERTIFICATION FORM

Applicant is required to turn this form in along with the Pre-Qualification Questionnaire.

APPENDIX A: PROJECT SITE INFORMATION

Appendix A does not require any action by the Bidder. The Project Site Information is included for Bidder’s information only.

APPENDIX B: SCORING MATRIX

Appendix B does not require any action by the Bidder. The scoring matrix is included for Bidder’s information only.

APPENDIX C: INTERVIEW QUESTIONNAIRE

Appendix C does not require any action by the Bidder. Appendix C contains only questions used by VTA staff to interview Bidders references. This is included for Bidder’s information only.

Santa Clara Valley Transportation Authority Appendix I - Request for Pre-Qualification of Bidders Rev. 01/01/20 Page I-3

REQUEST FOR PRE-QUALIFICATION

NOTICE

A. SOLICITATION OF BIDS

The Santa Clara Valley Transportation Authority (VTA) will be soliciting Bids (bid) for “Guadalupe Division - Guard House” (Project).

Notice is hereby given that VTA is now soliciting Statements of Qualifications (SOQ) from bidders (Bidders) with construction expertise to furnish all labor, materials, tools, equipment, services, supervision, and incidentals necessary to perform site, roadway, utility, security, access control, lighting, CCTV, barrier, and related improvements associated with the Guadalupe Division – Guard House including all demolition, installation, testing, coordination, restoration, and other incidental work required to provide a complete and fully functional project in accordance with the Contract.

This Request for Pre-Qualification of Bidders is intended to solicit information in the form of a qualification questionnaire and qualification statements. All Bidders that intend to submit a bid for the Project must fully complete the Pre-Qualification Questionnaire, provide all materials requested herein, and be approved by VTA in order to be included on the final qualified Bidders list. No bid will be accepted from a Bidder that has failed to comply with these requirements. If two or more firms submit a SOQ as part of a Joint Venture, or expect to submit a SOQ as part of a Joint Venture, each entity within the Joint Venture must be separately pre-qualified.

Answers to questions contained in the attached questionnaire, information about current bonding capacity, notarized statement from surety, and the most recent reviewed or audited financial statements, with accompanying notes and supplemental information, are required. VTA will use these documents as the basis of rating Contractors in respect to the Project size and scope. VTA reserves the right to check other sources available. VTA’s decision will be based on objective evaluation criteria.

B. OBTAINING THE REQUEST FOR PRE-QUALIFCATION

The details of the bidding procedure can be found at VTA’s eProcurement website https://secure.OpenGov.com/portal/vta. Click on the name/number of the solicitation that you are interested in. In this case: it is going to be the Pre-Qualification documents for C26146F.

To download documents for a solicitation, click “3. Attachment” from the right menu under “Project Documents” tap and select file to download. System will ask you to either enter your email address and password, or to sign up if you do not have an account yet. Once you are registered and logged in, click “Follow Project” in order to receive updates on this Project.

There is no charge for downloading these documents.

Rev. 01/01/20 Page I-4

Register as a vendor and sign up for notifications for your North American Industry Classification System (“NAICS”) business codes at https://secure.OpenGov.com/signup. Please check your email inbox and follow the instructions to activate your account. If you need help activating your account, please email support@OpenGov.com. By registering as a VTA vendor, Bidder will automatically receive notifications by email of upcoming VTA bidding opportunities.

To ensure you continue receiving emails from OpenGov, please add support@OpenGov.com and notifications@OpenGov.com to your contacts or safe senders list.

C. SUBMITTAL LOCATION AND DEADLINE

VTA no longer accept SOQ submission by mail or hand-carried. Prospective Bidders that are not prequalified may qualify during the solicitation period, and are strongly encouraged to submit their Pre-Qualification package at least Fifteen (15) days before Bid Opening. Refer to the Invitation for Bid (IFB) for Bid Opening schedule. Prospective Bidders not currently pre-qualified, and intending to be pre-qualified, must request Pre-Qualification sufficiently in advance of the Bid Opening - as stated herein- so as to ensure there will be no need to extend the solicitation period or delay the award.

Please refer to Item D “Project Schedule” under Section “Introduction to The Request for Pre- Qualification” hereof.

To submit your response electronically, use your login credentials to access the project file at https://procurement.opengov.com/portal/vta then click on green button “Draft Response” and follow the steps.

Bidder is solely responsible for ensuring their responses are received on time. VTA should not be held responsible for the inadvertent release of any information, nor should it take responsibility for information that may be misdirected.

Contractors intending to be pre-qualified, must request pre-qualification sufficiently in advance of the closing date for bids so as to ensure there will be no need to extend the solicitation period or delay the award. Failure to provide a responsive SOQ by the time specified above will preclude the Bidder from subsequent participation in the IFB for the Project.

D. INQUIRIES

Inquiries regarding this Request for Pre-Qualification shall be directed by e-mail to Kelly Tran at kelly.tran@vta.org.

Bidders may also direct inquiries to the designated Contract Administrator via VTA eProcurement website at https://procurement.opengov.com/portal/vta using “Question & Answer” tap of the project file.

Rev. 01/01/20 Page I-5

E. NOTICE OF DETERMINATION

VTA will notify each Bidder that submits an SOQ regarding their qualification status by letter after submission of the pre-qualification package. The sooner you submit your response, the sooner you will get a notice of determination from VTA.

F. BIDDING PERIOD

Bidders are encouraged to submit pre-qualification packages as soon as possible, so that they may be notified of omissions of information to be remedied or of their pre-qualification status well in advance of the Bid Opening for this Project.

Bid Opening will not be changed in order to accommodate supplementation of incomplete submissions, or late submissions.

G. VALIDATION OF PRIOR PRE-QUALIFICATION

Bidders who have been Pre-Qualified by VTA will be considered prequalified for a project of similar size and scope for one year following the date of notification of prequalification. The Validation Statement (Exhibit A) is required to be submitted on the date stated for prequalification packages.

Rev. 01/01/20 Page I-6

Rev. 01/01/20 Page I-7

INTRODUCTION TO THE REQUEST FOR PRE-QUALIFICATION

A. PROJECT BACKGROUND

The Work will include furnishing all labor, supervision, materials, equipment and incidentals which are necessary to construct the following:

• Base Bid: Expand existing road south (see civil plans). install new concrete slab for Option 1 prefabricated guard house (see structural plans). install utilities electrical and data to stub ups at new concrete foundation (see utility plans). Install guard gates at entrance.

Install bollards. Install CCTV and exterior lighting. Design-build concrete accessible ramps, landings and walkways.

• Option 1: procurement and installation of pre-fabricated guard house. Connect to phase 1 utilities stubbed up to foundation. Boring from building A to utility box to connect existing water from Building A to guard house connection. Connect existing sewer from San Pedro to utility box from Phase 1 at Younger Avenue city permitting is required. Installation of casework, plumbing fixtures and accessories will be the responsibility of the contractor.

Design striping to complete the whole accessible path of travel to the guard house.

NOTE: Contractor to pothole and verify utility locations before trenching. Contractor responsible for coordination with VTA Real Estate regarding easements. This project is federally funded, all materials incorporated into the work shall meet all buy America provisions, including requirements for U.S.-produced iron, steel, manufactured products, and construction materials.

The estimated cost of construction for the Project is in the range of:

• Base Bid: $591,000.00 to $800,000.00,

• Base Bid + Option 1: $1,380,000.00 to $1,850,000.00.

B. Reserved

C. PROCUREMENT PROCESS: PREQUALIFICATION PROCUREMENT

The process for award of this Project includes this Request for Pre-Qualification and the issuance of the Invitation for Bids (IFB) to pre-qualified firms.

Only those Applicants that have been found to be qualified in the pre-qualification process are invited to submit sealed bids with pricing information “Bid”.

Award is then made to the lowest responsive and responsible Bidder as regular sealed-bid procurement.

Rev. 01/01/20 Page I-8

Prior to submitting an SOQ in response to this Request for Pre-Qualification, Bidders are advised to carefully review Section B “Project Description” in order to understand the requirements of this Project.

D. PROJECT SCHEDULE

It is anticipated that the Project will be advertised in November 2026 with Bid Opening in January 2027 (Solicitation Period). The estimated time for construction of the Project is 267 calendar days.

E. PREPARATION OF THE SOQ SUBMITTAL

Each prospective Bidder must provide a complete, responsive SOQ package which consists of contact information and general information, essential requirements for qualification, scored questions, and project experience, with all the required attachments and any other supplemental information. Submission of an incomplete and/or unclear SOQ could result in a determination by VTA that the prospective Bidder is nonresponsive and therefore not pre-qualified.

Bidders shall submit one (1) original copy of the SOQ package to be delivered to VTA at the required location and time specified in Section C of this Notice.

Each questionnaire must be signed under penalty of perjury in the manner designated on Attachment No. 1 Statement of Qualification Certification Form hereof, by an individual who has the legal authority to bind the Bidder on whose behalf that person is signing. If any information provided by a Bidder becomes inaccurate, the Bidder must immediately notify VTA and provide updated accurate information in writing, under penalty of perjury.

F. EVALUATION AND ANALYSIS

All SOQs will first be reviewed for their responsiveness, including timely receipt of the package and inclusion of all required forms. Any SOQ that is incomplete in any material respect may be deemed non-responsive and maybe rejected in its entirety.

Note: A Bidder may be found not pre-qualified for bidding on this specific Project until the Bidder meets VTA’s requirements. In addition, a Bidder may be found not pre-qualified for either:

(1) Omission of requested information or

(2) Falsification of information

Bidders will be scored based on the Request for Pre-Qualification Questionnaire Score Sheet (see Appendix B: Scoring Matrix).

G. NOTICE OF APPEAL

A Bidder can make an appeal in regards to its pre-qualification rating. The Bidder initiates the appeal by delivering a notice of appeal to VTA no later than ten business days prior to the closing time for

Rev. 01/01/20 Page I-9 the receipt of bids (refer to Procurement Process above). Without a timely appeal, the Bidder waives any and all rights to challenge the decision of VTA, whether by administrative process, judicial process or any other legal process or proceeding.

If the Bidder requests a hearing on its appeal, the hearing process shall be conducted and shall conclude no later than five business days after VTA’s receipt of the notice of appeal, and no later than five business days prior to the closing time for the receipt of bids The hearing shall be an informal process conducted by a panel to whom VTA’s Board of Directors has delegated responsibility to hear such appeals (the “Appeals Panel”). At or prior to the hearing, the Bidder will be advised of the basis for VTA’s pre-qualification determination. The Bidder will be given the opportunity to present information and reasons in opposition to the rating. Within one day after the conclusion of the hearing, the Appeals Panel will render its decision. It is the intention of VTA that the date for the submission and opening of bids will not be delayed or postponed toallow for completion of an appeal process.

H. GENERAL CONTRACTOR

Bidders are advised that they must have a California contractor’s license, classification Class B to bid on this Project. If pre-qualified, Bidder’s subcontractor must also have a California contractor’s license and must be reflected at his/her Bid. Bidders may meet the specialty license requirements by indicating a properly licensed subcontractor in their Bid.

The Request for Pre-Qualification requires the Bidder to identify and supply information regarding the General Contractor. All Bidders responding to this Request for Pre-Qualification are hereby cautioned that the Contractor’s State License Law regulates contractor licensing matters. The Bidder, in its pre-qualification submittals shall be required to disclose all of its license classifications, numbers, and expiration dates.

Bidders are also advised that Contractor and all subcontractors used for the Project shall be registered, pursuant to Section 1725.5 of the California Labor Code, at the time of bid opening. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations (“DIR”).

I. CONFIDENTIALITY

The pre-qualification packages (questionnaire answers) submitted by Bidders are not public records and are not open to public inspection. All information provided will be kept confidential to the extent permitted by law. However, the contents may be disclosed to third parties for purpose of verification, or investigation of substantial allegations, or in the appeal hearing. State law requires that the names of contractors applying for pre-qualification status shall be public records subject to disclosure, and the first page of the questionnaire will be used for that purpose.

Rev. 01/01/20 Page I-10

J. RESERVATION OF RIGHTS OF VTA

VTA reserves, holds and may exercise, at its sole discretion, the following rights and conditions with regard to this Request for Pre-Qualification, and by responding to this Request for Pre-Qualification, Bidder acknowledge and consent to the following rights and conditions:

1. VTA reserves the right to adjust, increase, limit, suspend or rescind the pre-qualification rating based on gathered information.

2. VTA reserves the right to waive minor irregularities and omissions in the information contained in the submitted Request for Pre-Qualification application.

While it is the intent of the pre-qualification questionnaire and documents to assist VTA in determining Bidder responsibility prior to bid and to aid VTA in selecting the lowest responsible bidder, neither the fact of pre-qualification, nor any pre-qualification rating, will preclude VTA from a post-bid consideration and determination of whether a bidder has the quality, fitness, capacity and experience to satisfactorily perform the proposed work, and has demonstrated the requisite trustworthiness.

Rev. 01/01/20 Page I-11

EXHIBIT A: VALIDATION STATEMENT

Rev. 01/01/20 Page I-12

Rev. 01/01/20 Page I-13

EXHIBIT A Applicant Firm:______________________________

Tax ID No. or SSN____________________________

PRIME CONTRACTOR PRE-QUALIFICATION VALIDATION STATEMENT

A copy of this VALIDATION FORM must be completed and signed by at least one General Partner, Owner, Principal or Officer Authorized to Legally Commit the Applicant Firm. Submit to VTA on or before the date specified for PreQualification Packages are due.

NOT TO BE SUBMITTED WITH APPLICATION – FOR VALIDATION ONLY

RFP or IFB Name and Number __________________________________________

DECLARATION

I, (printed full name) _________________________________, being first duly sworn, hereby declare that I am the (position or title) _____________________ of (firm name) ________________________________________, and that I am duly authorized to execute this Validation Statement on behalf of this entity. I acknowledge that any false, deceptive or fraudulent statements on this Validation Statement will result in denial of pre-qualification. I hereby state:

The Pre-Qualification Application dated ________________ on file with VTA is correct and current as submitted.

-OR-

The Pre-Qualification Application dated ________________ on file with VTA is correct and current as submitted, except as modified by the attached changed pages and/or attachments to said application.

(Applicants may attach additional sheets to describe changes). Attach recent financial statements if previous are more than one year old.

________________________________________________ Date: ___/___/___ Signature of Person Certifying for Applicant Firm

Subscribed and sworn to before me this ______ day of _______________________

(Notary Seal or Stamp) Notary Public Signature

My Commission expires ___/___/___

A MATERIAL FALSE STATEMENT, OMISSION OR FRAUDULENT INDUCEMENT MADE INCONNECTION WITH THIS PRE-QUALIFICATION IS SUFFICIENT CAUSE FOR DENIAL OF THE APPLICATION OR REVOCATION OF A PRIOR APPROVAL, THEREBY PRECLUDING THE APPLICANT FIRM FROM DOING BUSINESS WITH, OR PERFORMING WORK FOR VTA, EITHER AS A PRIME CONTRACTOR, SUBCONTRACTOR OR SUPPLIER FOR A PERIOD OF THREE YEARS. IN ADDITION, SUCH FALSE SUBMISSION MAY SUBJECT THE PERSON AND/OR ENTITY MAKING THE FALSE STATEM TO CRIMINAL CHARGES. [TITLE 18 USC 1001, FALSE STATEMENTS; CALIFORNIA PENAL CODE SECTION 132, OFFERING ALTERED OR ATEDATED OR FORGED DOCUMENTS OR RECORDS; AND

SECTION 134, PREPARING FALSE DOCUMENTARY EVIDENCE].

Rev. 01/01/20 Page I-14

Rev. 01/01/20 Page I-15

PRE-QUALIFICATION QUESTIONNAIRE

CONTRACT NO. C26146F

BIDDER:

(provide name of firm)

DATE:

Note: Only this cover page, Parts I through IV of this document (along with any requested or required supporting documents), and Attachment 1 Statement of Qualification Certification Form are to be submitted.

Rev. 01/01/20 Page I-16 page intentionally left blank

Rev. 01/01/20 Page I-17

PART I: CONTACT INFORMATION

The Bidder must provide all of the following contact information to be considered for further review.

The Bidder is the contractor that will execute the Project contract.

A. BIDDER’S CONTACT INFORMATION

1. Firm Name:

(as it appears on license)

2. Address:

3. Phone Number of Firm: Fax:

4. Contact Person & Title:

(contact person for this SOQ; contact does not need to be the firm’s owner)

5. Contact Person Email:

6. Bidder is: a Corporation a Partnership a Sole Proprietorship a Joint Venture

Other legal entity (specify): ______________________________

7. Date of company formation or incorporation:

8. Under the laws of what state:

B. EXECUTION AND CERTIFICATION

Complete and attach ATTACHMENT 1 STATEMENT OF QUALIFICATION CERTIFICATION FORM. All Information set forth in this SOQ shall be certified under penalty of perjury by the Bidder and, if a partnership or joint venture, its general partners or joint venture members.

- END OF PART I -

Rev. 01/01/20 Page I-18

Rev. 01/01/20 Page I-19

PART II: ESSENTIAL REQUIREMENTS FOR QUALIFICATION

Contractor will be immediately disqualified if the answer to any of questions 1 through 5 is “no.”1

1. Contractor possesses a valid and current California Contractor’s license for this Project for which it intends to submit a bid.

Yes No

2. Contractor has a liability insurance policy with a policy limit of at least $1,000,000 per occurrence and $2,000,000 aggregate.

Yes No

3. Contractor has current workers’ compensation insurance policy as required by the Labor Code or is legally self-insured pursuant to Labor Code section 3700 et. seq.

Yes No Contractor is exempt from this requirement, because it has no employees

4. Have you attached your latest copy of a reviewed or audited financial statement with accompanying notes and supplemental information?

Yes No

NOTE: A financial statement that is not either reviewed or audited is not acceptable. A letter verifying availability of a line of credit may also be attached; however, it will be considered as supplemental information only, and is not a substitute for the required financial statement.

5. Have you attached a notarized statement from an admitted surety insurer (approved by the California Department of Insurance) and authorized to issue bonds in the State of California, which states: (a) that your current bonding capacity is sufficient for the project for which you seek pre-qualification if you are seeking pre-qualification for a single project; or (if you are seeking pre-qualification valid for eighteen months) (b) your current available bonding capacity?2

Yes No

NOTE: Notarized statement must be from the surety company, not an agent or broker.

1 A “no” answer to Question 4 will not be disqualifying if the contractor is exempt from complying with Question 4, for reasons explained in footnote 2.

2 An additional notarized statement from the surety may be requested by VTA at the time of submission of a Bid, if this pre-qualification package is submitted more than 60 days prior to submission of the Bid.

Rev. 01/01/20 Page I-20

6. Has your contractor’s license been revoked at any time in the last five years?

Yes No

7. Has a surety firm completed a contract on your behalf, or paid for completion because your firm was default terminated by the project owner within the last five (5) years?

Yes No

8. At the time of submitting this pre-qualification form, is your firm ineligible to bid on or be awarded a public works contract, or perform as a subcontractor on a public works contract, pursuant to either Labor Code section 1777.1 or Labor Code section 1777.7?

If the answer is “Yes,” state the beginning and ending dates of the period of debarment:

9. At any time during the last five years, has your firm, or any of its owners or officers been convicted of a crime involving the awarding of a contract of a government construction project, or the bidding or performance of a government contract?

- End of Part II -

Rev. 01/01/20 Page I-21

PART III: ORGANIZATION HISTORY, ORGANIZATIONAL PERFORMANCE,

COMPLIANCE WITH CIVIL AND CRIMINAL LAWS

A. Current Organization and Structure of the Business

For Firms That Are Corporations:

1a. Date incorporated:

1b. Under the laws of what state:

1c. Provide all the following information for each person who is either (a) an officer of the corporation (president, vice president, secretary, treasurer), or (b) the owner of at least ten per cent of the corporation’s stock. Not Applicable for Sole Proprietorships.

Name Position Years with Co. % Ownership Social Security #

CEO

President Secretary Treasurer

1d. Identify every construction firm that any person listed above has been associated with (as owner, general partner, limited partner or officer) at any time during the last five years.

NOTE: For this question, “owner” and “partner” refer to ownership of ten per cent or more of the business, or 10 per cent or more of its stock, if the business is a corporation.

Person’s Name Construction Firm Dates of Person’s Participation with Firm

Rev. 01/01/20 Page I-22

For Firms That Are Partnerships:

1a. Date of formation:

1b. Under the laws of what state:

1c. Provide all the following information for each partner who owns 10 per cent or more of the firm. (attach additional pages if necessary)

Name Position Years with Co. % Ownership Social Security #

1d. Identify every construction company that any partner has been associated with (as owner, general partner, limited partner or officer) at any time during the last five years.

NOTE: For this question, “owner” and “partner” refer to ownership of ten per cent or more of the business, or ten per cent or more of its stock, if the business is a corporation.

Person’s Name Construction Company Dates of Person’s Participation with Company

For Firms That Are Sole Proprietorships:

1a. Date of commencement of business.

1b. Social security number of company owner.

1c. Identify every construction firm that the business owner has been associated with (as owner, general partner, limited partner or officer) at any time during the last five years.

NOTE: For this question, “owner” and “partner” refer to ownership of ten per cent or more of the business, or ten per cent or more of its stock, if the business is a corporation.

Person’s Name Construction Company Dates of Person’s Participation with Company

Rev. 01/01/20 Page I-23

For Firms That Intend to Make a Bid as Part of a Joint Venture:

1a. Date of commencement of joint venture.

1b. Provide all of the following information for each firm that is a member of the joint venture that expects to bid on one or more projects:

Name of firm % Ownership of Joint Venture

History of the Business and Organizational Performance

2. Has there been any change in ownership of the firm at any time during the last three years?

NOTE: A corporation whose shares are publicly traded is not required to answer this question.

Yes No

If “yes,” explain on a separate signed page.

3. Is the firm a subsidiary, parent, holding company or affiliate of another construction firm?

NOTE: Include information about other firms if one firm owns 50 per cent or more of another, or if an owner, partner, or officer of your firm holds a similar position in another firm.

Yes No

If “yes,” explain on a separate signed page.

4. Are any corporate officers, partners or owners connected to any other construction firms?

NOTE: Include information about other firms if an owner, partner, or officer of your firm holds a similar position in another firm.

If “yes,” explain on a separate signed page.

Rev. 01/01/20 Page I-24

5. State your firm’s gross revenues for each of the last three years:

2016: $ 2017: $ 2018: $

Scored Questions

6. How many years has your organization been in business in California as a contractor under your present business name and license number? Years

7. Is your firm currently the debtor in a bankruptcy case?

If “yes,” please attach a copy of the bankruptcy petition, showing the case number, and the date on which the petition was filed.

8. Was your firm in bankruptcy at any time during the last five years? (This question refers only to a bankruptcy action that was not described in answer to question 7, above)

Yes No

If “yes,” please attach a copy of the bankruptcy petition, showing the case number and the date on which the petition was filed, and a copy of the Bankruptcy Court’s discharge order, or of any other document that ended the case, if no discharge order was issued.

Licenses

9. List all California construction license numbers, classifications and expiration dates of the California contractor licenses held by your firm:

License Number Trade Classification Date Issued Expiration Date

10. If any of your firm’s license(s) are held in the name of a corporation or partnership, list below the names of the qualifying individual(s) listed on the California State Licensing Board (CSLB) records who meet(s) the experience and examination requirements for each license.

Rev. 01/01/20 Page I-25

11. Has your firm changed names or license number in the past five years?

If “yes,” explain on a separate signed page, including the reason for the change.

12. Has any owner, partner or (for corporations) officer of your firm operated a construction firm under any other name in the last five years?

Yes No

If “yes,” explain on a separate signed page, including the reason for the change.

13. Has any CSLB license held by your firm or its Responsible Managing Employee (RME) or Responsible Managing Officer (RMO) been suspended within the last five years?

Yes No

If “yes,” explain on a separate signed page.

Disputes

14. At any time in the last five years has your firm been assessed and paid liquidated damages after completion of a project under a construction contract with either a public or private owner?

Yes No

If yes, explain on a separate signed page, identifying all such projects by owner, owner’s address, the date of completion of the project, amount of liquidated damages assessed and all other information necessary to fully explain the assessment of liquidated damages.

15. In the last five years has your firm, or any firm with which any of your company’s owners, officers or partners was associated, been debarred, disqualified, removed or otherwise prevented from bidding on, or completing, any government agency or public works project for any reason?

NOTE: “Associated with” refers to another construction firm in which an owner, partner or officer of your firm held a similar position, and which is listed in response to Part II question 1c or 1d on this form.

Rev. 01/01/20 Page I-26

If “yes,” explain on a separate signed page. State whether the firm involved was the firm applying for pre-qualification here or another firm. Identify the name of the company, the name of the person within your firm who was associated with that company, the year of the event, the owner of the project, the project and the basis for the action.

16. In the last five years has your firm been denied an award of a public works contract based on a finding by a public agency that your firm was not a responsible bidder?

If “yes,” explain on a separate signed page. Identify the year of the event, the owner, the project and the basis for the finding by the public agency.

NOTE: The following two (2) questions, refer only to disputes between your firm and the owner of a project. You need not include information about disputes between your firm and a supplier, another contractor, or subcontractor. You need not include information about “pass-through” disputes in which the actual dispute is between a sub-contractor and a project owner. Also, you may omit reference to all disputes with amounts of less than $50,000.

17. In the past five years has any claim against your firm concerning your firm’s work on a construction project been filed in court or arbitration?

Yes No

If “yes,” on separate signed page identify the claim(s) and provide the project name, date of the claim, name of claimant, a brief description of the nature of the claim, the court in which the case was filed and a brief description of the status of the claim (pending or, if resolved, a brief description of the resolution).

18. In the past five years has your firm made any claim against a project owner concerning work on a project or payment for a contract and filed that claim in court or arbitration?

Yes No

If “yes,” on separate signed page identify the claim and provide the project name, date of the claim, name of the entity (or entities) against whom the claim was filed, a brief description of the nature of the claim, the court in which the case was filed and a brief description of the status of the claim (pending, or if resolved, a brief description of the resolution).

Rev. 01/01/20 Page I-27

19. At any time during the past five years, has any surety company made any payments on your firm’s behalf as a result of a default, to satisfy any claims made against a performance or payment bond issued on your firm’s behalf, in connection with a construction project, either public or private?

Yes No

If “yes,” explain on a separate signed page the amount of each such claim, the name and telephone number of the claimant, the date of the claim, the grounds for the claim, the present status of the claim, the date of resolution of such claim if resolved, the method by which such was resolved, the nature of the resolution and the amount, if any, at which the claim was resolved.

20. In the last five years has any insurance carrier, for any form of insurance, refused to renew the insurance policy for your firm?

Yes No

If “yes,” explain on a separate signed page. Name the insurance carrier, the form of insurance and the year of the refusal.

Criminal Matters and Related Civil Suits

21. Has your firm or any of its owners, officers or partners ever been found liable in a civil suit or found guilty in a criminal action for making any false claim or material misrepresentation to any public agency or entity?

Yes No

If “yes,” explain on a separate signed page, identifying who was involved, name of the public agency, date of the investigation and the grounds for the finding.

22. Has your firm or any of its owners, officers or partners ever been convicted of a crime involving any federal, state, or local law related to construction?

Yes No

If “yes,” explain on a separate signed page, identifying who was involved, name of the public agency, date of the conviction and the grounds for the conviction.

23. Has your firm or any of its owners, officers or partners ever been convicted of a federal or state crime of fraud, theft, or any other act of dishonesty?

Rev. 01/01/20 Page I-28

If “yes,” identify on a separate signed page the person or persons convicted, the court (the county if a state court, the district or location of the federal court), the year and the criminal conduct.

Bonding

24. Bonding Capacity: Provide documentation from your surety identifying the following:

Name of bonding company/surety: ________________________________

Name of surety agent, address and telephone number:

Name Address Telephone Number

25. If your firm was required to pay a premium of more than one per cent for a performance and payment bond on any project(s) on which your firm worked at any time during the last three years, state the percentage that your firm was required to pay. You may provide an explanation for a percentage rate higher than one per cent, if you wish to do so.

26. List all other sureties (name and full address) that have written bonds for your firm during the last five years, including the dates during which each wrote the bonds:

Surety Name Surety Address Bond Date

27. During the last five years, has your firm ever been denied bond coverage by a surety company, or has there ever been a period of time when your firm had no surety bond in place during a public construction project when one was required?

Rev. 01/01/20 Page I-29

Yes No

If yes, provide details on a separate signed sheet indicating the date when your firm was denied coverage and the name of the company or companies which denied coverage; and the period during which you had no surety bond in place.

Compliance with Occupational Safety and Health Laws and with Other Labor Legislation Safety

28. Has CAL OSHA cited and assessed penalties against your firm for any “serious,” “willful” or “repeat” violations of its safety or health regulations in the past five years?

NOTE: If you have filed an appeal of a citation, and the Occupational Safety and Health Appeals Board has not yet ruled on your appeal, you need not include the information about the citation.

Yes No

If “yes,” attached a separate signed page describing the citations, including information about the dates of the citations, the nature of the violation, the project on which the citation(s) was or were issued, the amount of penalty paid, if any. If the citation was appealed to the Occupational Safety and Health Appeals Board and a decision has been issued, state the case number and the date of the decision.

29. Has the Federal Occupational Safety and Health Administration cited and assessed penalties against your firm in the past five years?

NOTE: If you have filed an appeal of a citation and the Appeals Board has not yet ruled on your appeal, or if there is a court appeal pending, you need not include information about the citation.

Yes No

If “yes,” attach a separate signed page describing each citation.

30. Has the EPA or any Air Quality Management District or any Regional Water Quality Control Board cited and assessed penalties against either your firm or the owner of a project on which your firm was the contractor, in the past five years?

NOTE: If you have filed an appeal of a citation and the Appeals Board has not yet ruled on your appeal, or if there is a court appeal pending, you need not include information about the citation.

If “yes,” attach a separate signed page describing each citation.

Rev. 01/01/20 Page I-30

31. How often do you require documented safety meetings to be held for construction employees and field supervisors during the course of a project?

Once each week or more often

Less than once each week

32. List your firm’s Experience Modification Rate (EMR) (California workers’ compensation insurance) for each of the past three premium years:

NOTE: An Experience Modification Rate is issued to your firm annually by your workers’ compensation insurance carrier.

Year List

EMR

Most recent available year

Previous year

Year prior to previous year

Three-year average EMR:

If your EMR for any of these three years is or was 1.00 or higher, attach a letter of explanation.

33. Within the last five years has there ever been a period when your firm had employees but was without workers’ compensation insurance or state-approved self-insurance?

If “yes,” please explain the reason for the absence of workers’ compensation insurance on a separate signed page. If “No,” please provide a statement by your current workers’ compensation insurance carrier that verifies periods of workers’ compensation insurance coverage for the last five years. (If your firm has been in the construction business for less than five years, provide a statement by your workers’ compensation insurance carrier verifying continuous workers’ compensation insurance coverage for the period that your firm has been in the construction business.)

Prevailing Wage and Apprenticeship Compliance Record

34. Has there been more than one occasion during the last five years in which your firm was required to pay either back wages or penalties for your own firm’s failure to comply with the State’s prevailing wage laws?

Rev. 01/01/20 Page I-31

NOTE: This question refers only to your own firm’s violation of prevailing wage laws, not to violations of the prevailing wage laws by a subcontractor.

Yes No

If “yes,” attach a separate signed page or pages, describing the nature of each violation, identifying the name of the project, the date of its completion, the public agency for which it was constructed; the number of employees who were initially underpaid and the amount of back wages and penalties that you were required to pay.

35. During the last five years, has there been more than one occasion in which your own firm has been penalized or required to pay back wages for failure to comply with the Federal Davis-Bacon prevailing wage requirements?

If “yes,” attach a separate signed page or pages describing the nature of the violation, identifying the name of the project, the date of its completion, the public agency for which it was constructed; the number of employees who were initially underpaid, the amount of back wages you were required to pay along with the amount of any penalty paid.

Rev. 01/01/20 Page I-32

36. Provide the name, address and telephone number of the apprenticeship program (approved by the California Apprenticeship Council) from whom you intend to request the dispatch of apprentices to your company for use on any public work project for which you are awarded a contract by VTA.

Name Address Telephone Number

37. If your firm operates its own State-approved apprenticeship program, provide the following information on a separate page and insert in this Part III.

a. Identify the craft or crafts in which your firm provided apprenticeship training in the past year.

b. State the year in which each such apprenticeship program was approved, and attach evidence of the most recent California Apprenticeship Council approval(s) of your apprenticeship program(s).

c. State the number of individuals who were employed by your firm as apprentices at any time during the past three years in each apprenticeship and the number of persons who, during the past three years, completed apprenticeships in each craft while employed by your firm.

38. At any time during the last five years, has your firm been found to have violated any provision of California apprenticeship laws or regulations, or the laws pertaining to use of apprentices on public works?

NOTE: You may omit reference to any incident that occurred prior to January 1, 1998, if the violation was by a subcontractor and your firm, as general contractor on a project, had no knowledge of the subcontractor’s violation at the time they occurred.

Yes No

If “yes,” provide the date(s) of such findings, and attach copies of the Department’s final decision(s).

Rev. 01/01/20 Page I-33

Not Scored - For Information Only

39. The following is required for information only and will not be used as prequalification criteria.

In the past five years, has a governmental agency claimed that your firm violated any law, rule or regulation including the laws of any country, state or locality?

Yes No

In the latter situation, indicate whether your firm has been required to pay a penalty or fine equal to greater than $10,000 or required to take remedial action costing $10,000 or more, or whether members of the firm have been subject to periods of incarceration of 30 days or more.

- End of Part III -

Rev. 01/01/20 Page I-34

Rev. 01/01/20 Page I-35

PART IV: RECENT CONSTRUCTION PROJECTS COMPLETED

Contractor shall provide information about its six most recently completed public works projects and its three largest completed private projects within the last three years.3 Names and references must be current and verifiable.

Use separate sheets of paper for each project. Use the form on the next page or substitute a similar form that has the same order of requested information.

3 If you wish, you may, using the same format, also provide information about other projects that you have completed that are similar to the project(s) for which you expect to bid.

Rev. 01/01/20 Page I-36

PROJECT DATA SHEET #___

(One data sheet per project; number each sheet)

NAME OF BIDDER: _____________________________________________

- End of Part IV -

Project Name

Project Location

Owner

Owner Contact Name Owner Contact Phone # Architect or Engineer (A/E)

A/E Contact Name A/E Contact Phone # Construction Manager Name

Construction Manager Phone #

Description of Project and Scope of Work Performed

Total Value of Construction (including change orders)

Original Scheduled Completion Date

Time Extensions Granted (number of days)

Actual Date of Completion

Rev. 01/01/20 Page I-37

ATTACHMENT 1: STATEMENT OF QUALIFICATION CERTIFICATION FORM

CERTIFICATION:

The undersigned is/are a legally authorized representative(s) of the Entity, and hereby declare that

I am/ we are submitting this Request for Pre-Qualifications; I am/we are duly authorized to sign this

Request for Pre-Qualifications on behalf of the above named firm; and I/we have read all the answers herein and know all of their contents and that all information set forth in this Request for

Pre-Qualifications and all attachments hereto are, to the best of my/our knowledge, true, accurate and complete as of its submission date.

The undersigned certifies and declares under penalty of perjury under the laws of the State of

California, that the foregoing is true and correct and that this declaration was executed in

________________________County, California, on _______________________.

(Date)

Signature: ______________________________________________ Date: ____________

Bidders Typed Name and Title:

Rev. 01/01/20 Page I-38

Rev. 01/01/20 Page I-39

APPENDIX A: PROJECT SITE INFORMATION

Rev. 01/01/20 Page I-40

Rev. 01/01/20 Page I-41

PROJECT Guadalupe Division 101 W. Younger Ave. San Jose CA 95110

[INSERT PROJECT SITE LOCATION HERE]

Rev. 01/01/20 Page I-42

Rev. 01/01/20 Page I-43

APPENDIX B: SCORING MATRIX

Note: References to Part I, Part II, Part III and Part IV refer to the Parts of the Pre-Qualification Questionnaire.

A. PART I: CONTACT INFORMATION

Part I seeks information about the makeup of the Bidder, and is for identification purposes only.

There is no evaluative scoring value for these parts.

B. PART II: ESSENTIAL REQUIREMENTS FOR QUALIFICATION

This part seeks information about the Bidder, and consists of pass/fail questions. This is the first step in rating the Bidder. A Bidder that “fails” any one of the questions 1-9 listed in Part II will be disqualified (except with respect to certain questions providing additional requirements for consideration).

C. PART III: ORGANIZATION, HISTORY, ORGANIZATIONAL PERFORMANCE, COMPLIANCE

WITH CIVIL AND CRIMINAL LAWS

The first set of questions (Questions 1 to 5) seek information about the organization and structure of the Bidder. There is no evaluative scoring value for these questions.

The next sets of questions (Questions 6 to 38) are scored. Refer to the Scoring Matrix on the next page.

D. PART IV:

This part seeks information about the Bidders project experience and requests contact information for each project.

Interviews will be conducted based on this information and scored. Refer to APPENDIX C:

INTERVIEW QUESTIONNAIRE for the set of questions and passing score.

To prequalify, the Bidder must have a passing grade within each of the two sections identified below.

Rev. 01/01/20 Page I-44

Question # Quantity Yes No Score

6 yrs + = 5 pts 5 yrs = 4 pts 4 yrs = 3 pts 3 yrs or less = 2 pts

N/A

7 N/A 0 3

8 N/A 0 3

Questions 9 to 12 are not scored

13 N/A 0 5

5 pts for 0 project with $50,000+ LDs or 1 project with LD 3 pts for 2 projects with $50,000+ LD 0 pt for any other answer

N/A N/A

15 N/A 0 5

16 N/A 0 5

If firm’s average gross revenue for the last 3 years was <$50M:

5 pts for “No” or “Yes” with 1 instance 3 pts for “Yes” with 2 instances 0 pts for “Yes” with more than 2 instances

If firm’s average gross revenue for the last 3 years was ˃$50M:

5 pts for “No” or “Yes” with 1, 2, or 3 instances 3 pts for “Yes” with 4 or 5 instances 0 pts for “Yes” with more than 5 instances

N/A N/A years was <$50M:

5 pts for “No” or “Yes” with 1 instance 3 pts for “Yes” with 2 instances 0 pts for “Yes” with more than 2 instances

If firm’s average gross revenue for the last 3 years was ˃$50M:

5 pts for “No” or “Yes” with 1, 2, or 3 instances 3 pts for “Yes” with 4 or 5 instances

Rev. 01/01/20 Page I-45

Question # Quantity Yes No Score

0 pts for “Yes” with more than 5 instances

5 pts for “No” or “Yes” with 1 claim 3 pts for 2 claims -5 pts for more than 2 claims

N/A N/A

5 pts for “No” or “Yes” with 1 instance 3 pts for 2 instances 0 pt for more than 2 instances

N/A N/A

21 N/A -5 5

22 N/A -5 5

23 N/A -5 5

Questions 24 and 26 are not scored

5 pts for rate ≤1% 3 pts for rate no higher than 1.10% 0 pts for any other answer

27 N/A 0 5

Total Score – Questions 6 to 27

Pass (scored 57 to 76) Disqualified - total score is less than 57

5 pts for “No” or “Yes” with 1 instance 3 pts for “Yes” with 2 instances 0 pts for “Yes” with more than 2 instances

If firm’s average gross revenue for the last 3 years was ˃$50M:

5 pts for “No” or “Yes” with 1, 2, or 3 instances 3 pts for “Yes” with 4 or 5 instances

Rev. 01/01/20 Page I-46

Question # Quantity Yes No Score

5 pts for “No” or “Yes” with 1 instance 3 pts for “Yes” with 2 instances 0 pts for “Yes” with more than 2 instances

(continuance of Question 29)

If firm’s average gross revenue for the last 3 years was ˃$50M:

5 pts for “No” or “Yes” with 1, 2, or 3 instances 3 pts for “Yes” with 4 or 5 instances

5 pts for “No” or “Yes” with 1 instance 3 pts for “Yes” with 2 instances 0 pts for “Yes” with more than 2 instances

If firm’s average gross revenue for the last 3 years was ˃$50M:

5 pts for “No” or “Yes” with 1, 2, or 3 instances 3 pts for “Yes” with 4 or 5 instances

3 pts for once a week or more often 0 pts for any other answer N/A N/A

5 pts for 3- year average EMR of ≤0.95 3 pts for 3- year average EMR of 0.95 to 1.00 0 pts for any other EMR

N/A N/A

33 5 pts for “No” or “Yes” with 1 instance 0 pts for any other answer N/A N/A

Rev. 01/01/20 Page I-47

Question # Quantity Yes No Score

If firm’s average gross…