B08 W9098S20R0011 FINAL.pdf

SEE ADDENDUM

(No Collect Calls)

W9098S20R0011 08-Jul-2020

b. TELEPHONE NUMBER

309-782-5885

8. OFFER DUE DATE/LOCAL TIME

10:00 AM 21 Jul 2020

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W9098S9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

LYNN BAKER

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

ROCK ISLAND ARSENAL (ACC-RI)

JOINT MANUFACTURING & TECHNOLOGY CENTER

BLDG 211 RODMAN AVENUE

1 ROCK ISLAND ARSENAL

ROCK ISLAND IL 61299-5000

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE W52H1B 16. ADMINISTERED BY

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

TRANSPORTATION OFFICER, W52H1C

TRANSPORTATION OFFICER

BLDG 299, BECK AND GILESPIE

EAST END, RECG DOOR 16A

ROCK ISLAND IL 61299-5000

TEL: FAX:

FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

1,000

NAICS:

333318

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF36

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

Section SF 30 - BLOCK 14 CONTINUATION PAGE

SOLICITATION NARRATIVE

ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS (OCT 2018):

1. The Army Contracting Command – Rock Island (ACC-RI) hereby issues solicitation W9098S20R0011 for the procurement of Waterjet Cutters, in support of the Rock Island Arsenal, Joint Manufacturing and Technology Center (RIA-JMTC). This solicitation is issued in accordance with FAR Part 12 (Acquisition of Commercial Items) and FAR Part 13 (Simplified Acquisition Procedures). The result of this solicitation will be a Firm Fixed Price (FFP) purchase order.

2. This solicitation is issued as 100% Small Business set aside.

3. This solicitation is not fully funded and is issued with a 100% evaluated option provision for a second Waterjet Cutter, CLIN 0002. This option is valid for 365 days after contract award.

4. The Government intends to award a firm fixed price type contract from this solicitation to the responsive, responsible offeror who submits the lowest priced technically acceptable proposal. Contractors should carefully review the technical requirements listed in Attachment 002, Technical Evaluation Criteria before submitting their proposal.

5. Delivery for these items is 84 days after the date of contract award for delivery of equipment and 144 days after date of contract for completed training and full acceptance. All proposals shall be submitted as FOB Destination – Rock Island, IL, see FAR 52.247-34.

Payments will be 75% of the contract value may be invoiced after the delivery of the equipment and the remaining 25% may be invoiced after training and full acceptance by the Government.

6. Delivery Information: Delivery is as specified in Attachment 001, Purchase Description. Failure to comply with the contractual delivery schedule after award may result in termination of the contract or require consideration if the Government elects to extend your delivery schedule. The Government is not required to extend your delivery schedule if you encounter delays. The non-availability of raw materials, subcontractor issues, scheduling conflict, etc., are not acceptable excuse for failing to meet your delivery schedule. If there is going to be a delay in delivery, the contractor is required to notify the Contract Specialist and/or Contracting Officer designated in this contract no later than 21 days prior to scheduled delivery date. Contractor must provide written notice of what the delay is, the new proposed delivery schedule, and offer consideration for the delay for Government consideration. If the Government elects to extend the delivery schedule, a formal modification will be executed.

It is the responsibility of the contractor to ensure they are providing quality products that conform to the contract terms and conditions (to include delivery schedule). Delivery of non-conforming products results in delivery/acceptance delays and increased cost to the Government.

7. The contractor shall submit tracking information with the purchase order number on all deliveries to the Rock Island Arsenal. The Tracking information shall be sent via email to the Contract Specialist:

LYNN.D.BAKER8.CIV@MAIL.MIL

Delivery Address is as follows:

TACOM-ROCK ISLAND

TRANSPORTATION OFFICER

BLDG 299, BECK AND GILESPIE

EAST END, RECG DOOR 16A

ROCK ISLAND, IL 61299-5000

RECEIVING HOURS OF OPERATION

MONDAY – THURSDAY 6:30 TO 2:00PM CST/CDT

Deliveries before or after the above delivery hours will be turned away

No appointments are necessary

8. Payment will be made by DFAS, via Wide Area Work Flow.

9. Proposed prices must remain valid for 60 days.

10. SHIPPING/DELIVERY INSTRUCTIONS AND INFORMATION

THE COMPLETE PURCHASE ORDER, DELIVERY ORDER, CALL ORDER, OR CONTRACT NUMBER (The Number that starts with W9098S----) MUST BE ON THE OUTSIDE OF THE SHIPPING CONTAINER. This number must also appear on all packing slips, invoices, bills, or any communications regarding this order.

A Packing List must be included with each shipment.

SHIPMENT OR DELIVERY TO ANY ADDRESS OTHER THAN THE “SHIP TO” ADDRESS DESIGNATED

IN THE PURCHASE ORDER /DELIVERY ORDER/ CALL ORDER/ CONTRACT (Block 14 of the DD1155, Block 15 of the SF1449, or Block 11 of the SF 26) MAY RESULT IN A DELAY IN PAYMENT.

ANY CHANGE IN THE “SHIP TO” ADDRESS MUST BE APPROVED BY A WRITTEN CONTRACT

MODIFICATION FROM THE CONTRACTING OFFICER.

11. ROCK ISLAND ARSENAL SAFETY REQUIREMENTS

All Contractors and Contractor personnel coming on to Arsenal Island must comply with the Rock Island Arsenal/Joint Manufacturing and Technology Center (RIA-JMTC), other Arsenal Island safety requirements and all federal, state, and local safety laws and regulations.

Contractors must provide their employees with, and the employees must use, all required safety equipment necessary for the work they are performing and/or the areas they are in. This includes safety glasses, safety shoes, proper clothing, proper protective equipment and rigging. All drivers on Arsenal Island must use seatbelts at all times when driving a motor vehicle.

If in doubt about any safety requirements, contact the Rock Island Safety Office Phone: 309-782-2579.

12. ROCK ISLAND ARSENAL LAW ENFORCEMENT, SECURITY, AND FIRE PREVENTION

REQUIREMENTS

Any contractor personnel entering Rock Island Arsenal (RIA) as a result of this order/contract are required to adhere to all regulations governing safety, law enforcement, security, and fire prevention in effect at the time of entrance.

Failure to comply with said regulations may result in immediate removal from RIA. The contractor shall bear full responsibility of the consequences of said removal. Further clarifications of RIA regulations are available from the Contracting Officer of this order/contract.

BADGING: ALL contractors who are performing services within the confines of Rock Island Arsenal are required to obtain a visitor badge. Contractors shall coordinate with Contracting Officer/Specialist and (if applicable) the Contracting Officer’s Representative (COR) designated for the contract/order. Contractors are required to display provided visitor badges above the waist in a conspicuous place on the upper part of the body. Badges are accountable and are required by the recipient to be safeguarded at all times to prevent theft, loss of misuse by unauthorized personnel.

PARKING: All parking is on a first come, first served basis, provided the parking space is not posted with a reserved, visitor, or Handicapped parking sign. Parking is allowed in “marked” spaces only. All valid spaces are clearly marked with white lines on both sides of the space. Vehicles parked in other than valid spaces are subject to being issued parking tickets.

Contractors will not be allowed in restricted areas of the Arsenal without proper identification and authorization.

INSPECTIONS: All contractor employee’s vehicles, equipment, and packages are subject to inspection or examination at entry/exit of the Arsenal.

SMOKING POLICY: Indoor smoking is not permitted. Outside smoking must occur at least 50 feet from any building entrance and exit.

13. CONCEALED CARRY RESTRICTIONS

Concealed carry permits do not apply on military installations. Contractors and delivery drivers shall ensure there are NO weapons or ammunition in their vehicles prior to entering the installation; a K-9 unit will find and alert if any prohibited items are detected.

14. Effective Immediately: Rock Island Arsenal (RIA) Visitor Access Passes are issued to individuals, not companies or groups. All visitors, to include transportation and freight services, official and unofficial, are highly suggested to pre-register at least three (3) business days prior to their visit. Pre-registration of visitors allows for the National Crime Information Center NCIC-III background check to be conducted prior to the individual arriving at RIA, reducing their wait time upon arrival. It is the responsibility of the prime contractor to ensure that this information is passed along to any subcontractor or transportation provider used during the performance of this purchase order. DRIVERS WHO DO NOT MEET THE INSTALLATION ACCESS REQUIREMENTS WILL

NOT BE ALLOWED ON THE INSTALLLATION AND WILL BE TURNED AWAY.

NOTE: As of 31 Dec 2015, Department of Defense and Department of the Army has directed that Driver Licenses and ID cards from Minnesota, Missouri and Washington are not compliant with the standards of the REAL ID Act and cannot be used on their own as a primary means of identification to apply for access to Rock Island Arsenal.

Driver’s Licenses that have written on the top of them “NOT FOR FEDERAL IDENTIFICATION PURPOSES” are also non-compliant. These non-compliant driver’s license or state issued identification cards may still be presented at the Rock Island Visitor Control Center, but they must be accompanied by one of the following secondary forms of identification before a records check is conducted and installation access is granted:

*Current vehicle registration showing name and address *Social Security card *US passport or passport card *US Military or Draft Record (DD-214 or Selective Service Registration Card) *Veteran Health Identification Card issued by the US Department of Veterans Affairs *Transportation Worker Identification Credential *Personal Identification Verification card issued by the Federal Government *Personal Identification Verification 0 Interoperable card issued by the Federal Government *US Certificate of Naturalization or certificate of citizenship (Form N-550) *US Department of Homeland Security “Trusted Traveler” card (Global Entry, NEXUS, SENTRI, or

FAST)

*Driver’s license issued by the US Department of State *US Military Identification Card for military members, dependents and retirees *US Permanent Resident/Alien Registration Receipt Card (Form 1-551) *US Coast Guard or Department of Homeland Security Merchant Mariner card *Native American Tribal Photo Identification card

Visitor Access Request Forms and a complete list of acceptable identification can be found at https://home.army.mil/ria/ (click on Menu, then Visitor Information, and then under How to Visit Rock Island Arsenal click on the second bullet “How to obtain a visitor pass”. Then on the right side of the screen click on “Access Request Process”) or call 309-782-0551.

Forms may be emailed for faxed

All visitors must process through the Moline Visitor Center Gate (I-74) off of River Drive in Moline, IL.

Visitors (to include transportation and freight providers) will require proper identification to access RIA POC for this Policy are: RIA Visitor Center, Phone 309-782-0551, FAX 309-782-5029, email:

usarmy.ria.imcom.mbx.usag-access-request@mail.mil

RECEIVING HOURS OF OPERATION:

Monday – Friday, 6:30am to 2:00pm CST

Deliveries before or after the above stated hours will be turned away. Appointments are not necessary.

For Directions call: 309-782-8539 (Automated)

S ECTION L - INSTRUCTIONS TO OFFERORS

1. GENERAL INSTRUCTIONS: These instructions are a guide for preparing your submission. These instructions generally describe the type and extent of information contractors should provide and emphasize the specific areas you must address in your submittal. You are expected to review the solicitation and its attachments, which will serve as the guideline and item list for any future requirement. You should include in your submission, sufficient information to enable the Government to determine your ability to meet technical evaluation requirements.

2. It is the Government's intent to award one firm fixed price contract under this solicitation to responsible, Small Business determined to be technically acceptable in accordance with the criteria within the solicitation Sections L and M. Contractor submissions should include addressing all of the technical requirements as outlined in Attachment 002, Technical Evaluation Criteria, outlined below.

EXPERIENCE

In the regular course of its business for a period of at least 3-yrs preceding this solicitation, the manufacturer of this equipment shall have previously supplied or offered for sale this type of equipment to industry for other than its own use. The following shall be provided as evidence:

PUBLISHED DATA: Each contractor shall provide a brochure, catalog, or published data describing the equipment offered.

REFERENCES: Each contractor shall provide contact information (including at least Company Name, Contact Name, Contact Telephone Number, and a description of the equipment the contact purchased) for minimum of (3) projects of similar scope and scale. For projects to be considered similar means that it must have a work envelop within 20% smaller than the volume of the requested equipment or larger.

TECHNICAL

Each contractor shall submit a package containing the following information. Failure to provide all the data required with the package may result in a contractor being considered unresponsive and eliminated from further consideration.

Compliance Statement Each contractor shall provide a statement of compliance. It shall be a copy of the solicitation’s Attachment 001, Purchase Description. At the end of each and every paragraph the contractor shall type or write exactly either “COMPLY” or “NON-COMPLY” as it relates to their ability to meet the paragraph. Other formats will not be considered acceptable. If “NON-COMPLY” is written, a brief description of the non-compliance is required.

Equipment Identification At the end of the Purchase Description indicating the statement of compliance, each contractor shall identify the manufacture and model number of the equipment being offered. The contractor shall also identify all the options by number that are offered in order to meet this purchase description. The contractor shall also identify items that are not normally numbered for ordering such as installation, freight, and training.

Warranty The proposal must include a minimum warranty of one year parts and labor and will begin upon final acceptance. The contractor will indicate after the manufacture and model number information in the Purchase Description, a statement of COMPLY or NON-COMPLY regarding the requested warranty.

S ECTION M - EVALUATION FACTORS

1. Each contractor's submission should include all information requested by the Government at the time the Government receives it. The Government is not obligated to request further information from any contractors to determine technical acceptability or responsibility, but does reserve the right to obtain additional information if determined necessary by the Contracting Officer.

2. All submittals will be subject to evaluation by Government personnel, with strict adherence to the evaluation criteria.

3. The Government will determine responsibility by analyzing whether the potential contractor complies with the requirements at FAR Part 9.1.

4. The following factors will be evaluated to determine contractors' submission technical acceptability:

a) Experience

b) Technical

These factors are outlined below with the Government's criteria to determine contractors technically acceptable. Contractors must be found acceptable under both factors (Experience and Technical) to be determined technically acceptable.

A. EXPERIENCE:

1. The contractor provided the published data describing equipment offered.

2. The contractor's experience demonstrates that within the last three years the contractor has provided similar scope and scale equipment to at least three customers.

B. TECHNICAL CAPABILITIES: The contractor's submission will be evaluated to determine if the contractor has clearly indicated the following:

W9098S20R0011

1. The contractor can comply with all items mentioned in the Purchase Description.

2. The contractor can provide equipment to meet the specifications outlined in the Purchase Description.

3. The contractor can provide a warranty as specified for the equipment indicated.

A DDITIONAL EVALUATION INFORMATION:

The above evaluation criteria will determine the initial pool of technically acceptable contractors. Those determined technically acceptable will then be evaluated to determine the lowest total evaluated price.

END OF ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS (OCT

2018)

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot

10' X 20' WATER JET CUTTING SYSTEM

FFP

10' X 20' WORK ENVELOPE WATER JET CUTTING SYSTEM IAW RIPD

E4000-20-9-33. WATER JET CUTTING SYSTEM IS COMPRISED OF THE

WATER JET (TANK, BRIDGE, NOZZLE, PUMP CHILLER) AS WELL AS

AUXILIARY EQUIPMENT TO INCLUDE: GARNET HOPPER, GARNET

REMOVAL SYSTEM, WATER RECYCLER ETC., AS REFERENCED IN

ATTACHMENT 001 PURCHASE DESCRIPTION.

PAYMENTS WILL BE 75% OF CLIN VALUE MAY BE INVOICED AFTER

DELIVERY OF EQUIPMENT AND THE REMAINING 25% OF CLIN VALUE

MAY BE INVOICED AFTER TRAINING IS COMPLETED AND FULLY

ACCEPTED BY THE GOVERNMENT.

E40000121PSF1

FOR INTERNAL USE ONLY:

PR 67697232

FOB: Destination

PSC CD: 3695

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Each

OPTION 6' X 12' WATERJET CUTTING SYSTEM

FFP

6' X 12' WORK ENVELOPE WATERJET CUTTING SYSTEM IAW RIPD

E4000-19-1-05. WATERJET CUTTING SYSTEM IS COMPRISED OF THE

(TANK, BRIDGE, NOZZLE, PUMP CHILLER) AS WELL AS AUXILIARY

EQUIPENT TO INCLUDE GARNET HOPPER, GARNET REMOVAL

SYSTEM, WATER RECYCLER ETC. AS REFERENCED IN ATTACHMENT

001 PURCHASE DESCRIPTION.

PAYMENTS WILL BE 75% OF CLIN VALUE MAY BE INVOICED AFTER

DELIVERY OF EQUIPMENT AND THE REMAINING 25% OF CLIN VALUE

MAY BE INVOICED AFTER TRAINING IS COMPLETED AND FULLY

ACCEPTED BY THE GOVERNMENT.

E40000115PSF2

FOR INTERNAL USE ONLY:

PR 67679055

PSC CD: 3695

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 84 dys. ADC 1 TRANSPORTATION OFFICER, W52H1C

TRANSPORTATION OFFICER

BLDG 299, BECK AND GILESPIE

EAST END, RECG DOOR 16A

ROCK ISLAND IL 61299-5000

W52H1B

0002 84 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

W52H1B

CLAUSES INCORPORATED BY REFERENCE

52.212-4 Contract Terms and Conditions--Commercial Items OCT 2018 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

252.203-7000 Requirements Relating to Compensation of Former DoD Officials

SEP 2011

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.215-7004 Requirement for Submission of Data Other Than Certified Cost or Pricing Data--Modifications-Canadian Commercial Corporation.

OCT 2013

252.215-7007 Notice of Intent to Resolicit JUN 2012 252.223-7003 Changes In Place Of Performance--Ammunition And

Explosives

DEC 1991

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7001 Buy American And Balance Of Payments Program-- Basic DEC 2017 252.225-7012 Preference For Certain Domestic Commodities DEC 2017 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

APR 2019

252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of provision)

52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (JUN 2020)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code(s) and small business size standard(s) for this acquisition appear elsewhere in the solicitation. However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show--

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) "Remit to" address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation.

Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers:

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers.

Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision.

Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers that exceed the micro-purchase threshold, and offers at or below the micro-purchase threshold if the solicitation requires the Contractor to be registered in the System for Award Management (SAM).) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "Unique Entity Identifier" followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see FAR subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) Reserved.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

ADDENDUM TO 52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (JUN 2020)

CLAUSES INCORPORATED BY REFERENCE

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.203-18 Prohibition on Contracting With Entities That Require Certain Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.204-7 System for Award Management OCT 2018 52.204-17 Ownership or Control of Offeror JUL 2016 52.204-22 Alternative Line Item Proposal JAN 2017 52.217-3 Evaluation Exclusive Of Options APR 1984 252.215-7007 Notice of Intent to Resolicit JUN 2012 252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business Concerns

APR 2019

CLAUSES INCORPORATED BY FULL TEXT

52.204-20 Predecessor of Offeror (JUL 2016)

Commercial and Government Entity (CAGE) code means--

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Predecessor means an entity that is replaced by a successor and includes any predecessors of the predecessor.

Successor means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

(b) The Offeror represents that it [____] is or [____] is not a successor to a predecessor that held a Federal contract or grant within the last three years.

(c) If the Offeror has indicated “is” in paragraph (b) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order):

Predecessor CAGE code: ____ (or mark “Unknown”).

Predecessor legal name: ____.

(Do not use a “doing business as” name).

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.223-22 PUBLIC DISCLOSURE OF GREENHOUSE GAS EMISSIONS AND REDUCTION GOALS--

REPRESENTATION (DEC 2016)

(a) This representation shall be completed if the Offeror received $7.5 million or more in Federal contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year.

(b) Representation. [Offeror is to check applicable blocks in paragraphs (b)(1) and (2).]

(1) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., make available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard.

(2) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly available Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage.

(3) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program.

(c) If the Offeror checked ``does'' in paragraphs (b)(1) or (b)(2) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported:

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

______________________. (Contracting Officer designate the official or location where a protest may be served on the Contracting Officer.)

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

The use in this solicitation of any Defense Federal Acquisition Regulations Supplement (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.243-7002 REQUESTS FOR EQUITABLE ADJUSTMENT (DEC 2012)

(a) The amount of any request for equitable adjustment to contract terms shall accurately reflect the contract adjustment for which the Contractor believes the Government is liable. The request shall include only costs for performing the change, and shall not include any costs that already have been reimbursed or that have been separately claimed. All indirect costs included in the request shall be properly allocable to the change in accordance with applicable acquisition regulations.

(b) In accordance with 10 U.S.C. 2410(a), any request for equitable adjustment to contract terms that exceeds the simplified acquisition threshold shall bear, at the time of submission, the following certificate executed by an individual authorized to certify the request on behalf of the Contractor:

I certify that the request is made in good faith, and that the supporting data are accurate and complete to the best of my knowledge and belief.

(Official's Name)

(Title)

(c) The certification in paragraph (b) of this clause requires full disclosure of all relevant facts, including--

(1) Certified cost or pricing data if required in accordance with subsection 15.403-4 of the Federal Acquisition Regulation (FAR); and

(2) Data other than certified cost or pricing data, in accordance with subsection 15.403-3 of the FAR, including actual cost data and data to support any estimated costs, even if certified cost or pricing data are not required.

(d) The certification requirement in paragraph (b) of this clause does not apply to----

(1) Requests for routine contract payments; for example, requests for payment for accepted supplies and services, routine vouchers under a cost-reimbursement type contract, or progress payment invoices; or

(2) Final adjustment under an incentive provision of the contract.

END ADDENDUM TO 52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (JUN 2020)

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS--COMMERCIAL ITEMS (JUN 2020)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided…