Atch 1 Technical Specifications .pdf

PATRICK AIR FORCE BASE

Technical Specifications for

SXHT 13-1232

Repair Street Light Poles and Fixtures, Various

DATE: August 2016

RRAAEEIISS

Range Architect-Engineer Inspection Services

Replace Street Light Poles and Fixtures, Various SXHT 13-1232

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00.00 30 SUMMARY OF WORK

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 78 00 CLOSEOUT SUBMITTALS

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 05 00.00 40 COMMON WORK RESULTS FOR ELECTRICAL

26 56 13.00 40 LIGHTING POLES AND STANDARDS

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 01 19 FIELD MOLDED SEALANTS FOR SEALING JOINTS IN RIGID

PAVEMENTS

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1 8/30/2016

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00.00 30

SUMMARY OF WORK

10/14

PART 1 GENERAL

1.1 SUMMARY

1.2 PROJECT DESCRIPTION

1.2.1 Electrical

1.3 REFERENCES

1.4 SUBMITTALS

1.5 CONTRACT DRAWINGS

1.5.1 Layout of Work and Elevations

1.6 WORK SCHEDULING

1.6.1 Requirements

1.7 OCCUPANCY OF PREMISES/ACCESS REQUIREMENTS

1.7.1 Facility Contents

1.7.1.1 Responsibilities

1.7.1.2 Maintain Clean Work Areas

1.7.1.3 Damage To Existing Equipment

1.7.1.4 New Material and Construction Equipment

1.7.2 Construction Area Access And Control

1.7.2.1 Access and Control Requirements

1.7.3 Vehicle Parking

1.7.3.1 Requirements

1.8 STORAGE, TRANSPORTATION AND PROTECTION

1.8.1 Storage

1.8.2 Protection

1.8.3 Transportation

1.8.4 Hazardous Materials

1.8.5 Site Protection Plan

1.9 GOVERNMENT-FURNISHED EQUIPMENT

1.10 ON-SITE PERMITS

1.10.1 Utility Outage Requests And Connection Requests

1.10.1.1 Requirements

1.10.2 Protection of Work

1.10.3 Burn Permits

1.11 SALVAGE AND DISPOSAL OF MATERIAL AND EQUIPMENT

1.11.1 Removal

1.11.2 Housekeeping

1.11.3 Salvage of Material And Equipment

1.11.3.1 Salvage Items - see attached drawings

1.11.4 Waste Disposal

1.11.5 Cleanup

1.11.6 Salvage And Disposal Record Keeping

1.12 RADIO FREQUENCY MANAGEMENT PROCEDURES

1.13 COMMUNICATION SECURITY

PART 2 PRODUCTS

SECTION 01 11 00.00 30 Page 1

PART 3 EXECUTION

3.1 ACCESS REQUIREMENTS

3.1.1 Construction Site Requirement

3.2 PAFB VEHICLE INSPECTION

3.3 PAFB DELIVERIES

3.3.1 Non-Hazardous Deliveries

3.3.2 Hazardous Deliveries

3.4 RESPONSIBILITIES

3.5 EXCAVATION

3.5.1 Dig/Utility Locate Permit Requirements

3.5.1.1 Location of Buried Structures and Utility Lines

3.5.1.2 Excavation, Trenching, and Backfilling

3.5.1.3 Cutting of Roads, Streets, Driveways, and Paved Areas

3.5.2 Restrictions

3.5.3 Temporary Shoring, Bracing And Supports

3.5.4 Barricades

3.6 WELDER QUALIFICATION REQUIREMENTS

3.7 HOISTING AND LIFTING

3.7.1 Lifting Operation Plan

3.8 QUALITY CONTROL

3.8.1 Licenses

3.8.2 Quality Control Manager

3.8.3 Government Inspection/Approval

3.8.4 Inspection Files

3.9 SUPERINTENDENT

3.10 CONSTRUCTION SCHEDULING REQUIREMENTS

3.10.1 Contractor Coordination Meetings

3.10.2 On-Site Construction Sequence

-- End of Section Table of Contents --

SECTION 01 11 00.00 30 Page 2

SECTION 01 11 00.00 30

SUMMARY OF WORK

10/14

PART 1 GENERAL

1.1 SUMMARY

The work to be performed under this project is located at Patrick Air Force Base. Patrick Air Force Base is located approximately three miles south of Cocoa Beach on State Road A1A.

The work to be performed under this project consists of replacing Street Light Poles and Fixtures, Various. Remove and replace existing concrete light poles throughout Patrick AFB. Existing LED light fixtures shall be relocated to the new poles as indicated on the drawings. Project shall also include replacing damaged handholes near light poles. Replace existing low pressure sodium fixtures with LED. And add LED lights to poles that don't have fixtures per the drawings.

1.2 PROJECT DESCRIPTION

1.2.1 Electrical

Remove and replace existing concrete light poles throughout Patrick AFB.

The drawings indicate power disconnect point for each lighting circuit.

Remove existing LED lights and install on new concrete light poles as indicated on the drawings.

Install new handholes per the schedule on the drawings.

Replace existing low pressure sodium fixtures with new LED fixtures as indicated on the drawings.

Furnish and install new brackets for fixtures as indicated on the drawings.

1.3 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 101 (2015; ERTA 2015) Life Safety Code

U.S. AIR FORCE (USAF)

AFI 33-580 (2013) Spectrum Management

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements

SECTION 01 11 00.00 30 Page 3

Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910 Occupational Safety and Health Standards

29 CFR 1926 Safety and Health Regulations for Construction

1.4 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control information only. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES in sufficient detail to show full compliance with the specification:

SD-01 Preconstruction Submittals

Submit the following items to the Contracting Officer:

Lifting Operation Plan;G

Utility Outage Requests;G

Connection Requests;G

Air Force Form 3952 (AF 3952), Chemical/Hazardous Material Request Authorization;G (including all paint)

SOLID WASTE DISPOSAL DIVERSION TRACKING;G

Premises/Access Plan;G

Storage Area Request;G

Superintendent Contact and Qualifications;G

1.5 CONTRACT DRAWINGS

See Drawing Index for list of project drawings.

Contract drawings, maps, and specifications will be furnished to the Contractor either hard copy or electronic at the Government's discretion.

Reference publications will not be furnished.

Contractor shall immediately check furnished drawings and notify the Contracting Officer of any discrepancies.

The drawings indicate the general location and arrangement of existing conditions. Field measurements may be necessary to determine the size and quantity of materials. Conditions which are obvious/visible or which should be reasonably anticipated by the Contractor on inspection will not be considered under the Differing Site Conditions clause of this contract.

1.5.1 Layout of Work and Elevations

Dimensions and elevations indicated in the layout of work shall be verified by the Contractor. Discrepancies between the drawings, specifications

SECTION 01 11 00.00 30 Page 4 and/or existing conditions shall be referred to the Contracting Officer in writing, for review, before the affected work is performed. Failure to make notification shall place the responsibility upon the Contractor to carry out the work in a satisfactory and workmanlike manner.

1.6 WORK SCHEDULING

Work Schedules for all on-site activities must be reviewed and approved by the Contracting Officer prior to start of the project; and all activities coordinated with the Contracting Officer once work has begun. Due to the critical nature of the work location, all work pertaining to this contract shall be completed with minimal disruption to the operation throughout Patrick AFB.

Contractor shall allow for non-access days where construction activity is prohibited due to hazardous operations or launch activity. When possible, the Government will provide 24 hour notification each time the restrictions are invoked.

1.6.1 Requirements

Working hours will normally range between the hours of 7:30 AM and 4:00 PM (0730-1600) excluding Saturdays, Sundays and Federal Holidays. If work must be done during periods other than above, additional Government inspection and Range Support personnel may be required. Notification must be given to the Contracting Officer five working days in advance of intention to work during other periods to allow assignment of additional inspection forces when the Contracting Officer determines that they are reasonably available. If such support is reasonably available, the Contracting Officer may authorize work to be performed during periods other than normal duty hours/days. Work beyond normal hours/days may be required for major utility outages. Its is to the government's discretion to request copies of contractor inspection records for periods worked on holidays and weekends (FAR 52.246-12 Inspection of Construction).

No construction work shall take place over the Christmas/New Year holiday period. This period will start one full work day before the Federal Christmas holiday and end the first work day after the Federal New Year Holiday. The Contractor may request to work during this time at the discretion of the Contracting Officer, however no base support will be available.

1.7 OCCUPANCY OF PREMISES/ACCESS REQUIREMENTS

Occupancy notifications will be posted in a prominent location in the work area. Contractor shall post warning signs in accordance with OSHA requirements.

Before work is started, the Contractor shall submit a Premises/Access Plan to the Contracting Officer or Representative for approval. The plan shall include a sequence of procedures, means of access, space plan for storage of materials and equipment, and use of approaches.

This plan must comply with NFPA 101 requirements that all exits and exit access must be maintained at all times. Base Fire Department is required to approve any deviations which affect the exiting or exit access.

SECTION 01 11 00.00 30 Page 5

1.7.1 Facility Contents

1.7.1.1 Responsibilities

The schedule of work shall be closely coordinated with the Contracting Officer. Unless otherwise stated, remove all equipment, etc., as required to perform the work. Any movable or fixed furniture, equipment, carpet, etc., remaining in the work area shall be covered and protected from damage. All relocated items shall also be protected from damage throughout the construction period. After completion of work and prior to final acceptance, replace removed items in their original location.

The entire area will not be available to the Contractor at one time.

The Contractor shall coordinate availability of areas of work with the Contracting Officer.

Demolition of critical facility systems electrical, etc. shall not be started until replacement equipment is on site.

1.7.1.2 Maintain Clean Work Areas

All work areas shall be kept clean at all times. Contractor shall prevent introduction of dirt or dust into areas adjacent to the work areas. All materials, tools and equipment shall be thoroughly cleaned prior to being brought into the work areas or adjacent areas.

1.7.1.3 Damage To Existing Equipment

Any damage must be reported to the Contracting Officer immediately. Damage to existing materials, equipments, systems, or properties occurring from Contractor activities or neglect, shall, at the sole discretion of the Contracting Officer, be repaired or replaced by the Contractor at no cost to the Federal Government.

1.7.1.4 New Material and Construction Equipment

Only material and construction equipment designated for performance of contract work may be stored at the construction site or located in Government-controlled warehouses or shop facilities.

1.7.2 Construction Area Access And Control

1.7.2.1 Access and Control Requirements

Exclusive use or control of any area will not be allowed as the Government must have access to all areas at all times. All work must be scheduled around operational constraints.

1.7.3 Vehicle Parking

1.7.3.1 Requirements

Job and support vehicles for workers will be parked in designated parking areas within reasonable access to the worksite. All vehicle operators must comply with all traffic laws including mandatory seat belt usage, speed limits and hauling restrictions. Contractor shall be responsible for repairing or replacing any facility/grounds damaged areas.

SECTION 01 11 00.00 30 Page 6

1.8 STORAGE, TRANSPORTATION AND PROTECTION

1.8.1 Storage

At Government discretion, Contractor may be assigned a storage area upon submitting written Storage Area Request to the Contracting Officer.

Contractor's Storage Area Request shall indicate dimensions of trailer, size of storage area, and utilities required. All trailers shall be in good and safe condition. Storage space is normally co-located with construction site, at the Contracting Officer's discretion. Storage areas may require fence and screening as required by Government. Contractor shall secure storage areas during inclement weather situation.

Contractor is to submit a Work Order Management System (WOMS) through CE to request a telephone number and line for their office trailer. Commercial Internet service is available through local Internet service provider at contractor cost.

Office trailers and long term (longer than one year) storage trailers shall be painted to match the base approved color", as noted in the base Facilities Sustainment guide. Trailers located on site for short term storage, less than one year, will not need to meet this requirement. In addition, all office trailers and long term storage trailers shall be skirted along the entire perimeter with a wood lattice material. This skirting shall be painted to match the same trailer color as described above. Contractor shall be responsible for the storage and protection of all of their materials and equipment, whether incorporated into the job or not.

1.8.2 Protection

Store and protect products in accordance with manufacturer's instructions.

Store products with seals, labels intact and legible. Store sensitive products in weather tight, climate controlled, enclosures in an environment favorable to the product. Products acceptable for exterior storage shall be on sloped supports above ground. Contractor shall not use swales, drainage ditches, or any other storm water permitted area to store materials or equipment. If swales, drainage ditches or any other storm water permitted areas must be used for storage, Contractor must get special permission from Contracting Officer.

1.8.3 Transportation

Transport and handle products in accordance with manufacturer's instructions. Promptly inspect shipments to ensure the products comply with requirements, quantities are correct, and products are undamaged.

Protect products subject to deterioration with impervious sheet covering.

Provide ventilation to prevent condensation and degradation of products.

Store loose granular materials on solid flat surfaces in a well drained area. Prevent mixing with foreign materials.

1.8.4 Hazardous Materials

Submit an Air Force Form 3952 (AF 3952), Chemical/Hazardous Material Request Authorization if hazardous materials & petroleum product will be used on site. Hazardous Materials & petroleum product containers shall be stored on an impervious surface with containment. Incompatible materials shall be segregated and have separate containment systems. Additional HAZMAT requirements are provided in Section 01 57 19 TEMPORARY

SECTION 01 11 00.00 30 Page 7

ENVIRONMENTAL CONTROLS.

1.8.5 Site Protection Plan

Structures, utilities, sidewalks, pavements, and other facilities immediately adjacent to excavations shall be protected against damage.

Contractor shall comply with "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements" and is required to protect areas adjacent to the construction site.

1.9 GOVERNMENT-FURNISHED EQUIPMENT

ITEM QUANTITY AVAILABLE

Existing LED Light Fixture Commencement of Work

1.10 ON-SITE PERMITS

1.10.1 Utility Outage Requests And Connection Requests

Work shall be scheduled to hold outages to a minimum.

Utility outages and Connection Requests required during the execution of work that affect existing systems shall be arranged at the convenience of the Government, which may require scheduling outside of the regular working hours or on weekends, at no additional cost to the Government.

Each Utility Outage and Connection Requests shall state the system involved, area involved, approximate duration of outage, and the nature of work involved.

1.10.1.1 Requirements

A written request for a utilities outage (electricity, communication, water, compressed air, gas, steam, air conditioning, fire detection and suppression systems, etc.) must be submitted to the Contracting Officer at least 21 calendar days in advance of the desired outage. Approval is required prior to scheduling any outage. All limitations noted on the approved outage authorization shall be carefully observed. A utilities outage without prior approval and coordination is prohibited.

Utility outages affecting fire alarm, fire detection, fire suppression, fire pumps and water supplies to fire protection systems greater than 4 hours will require a fire watch.

Since many systems are critical to facility operations, the number and duration of utility outages shall be kept to an absolute minimum. All work effort shall be coordinated and sufficient manpower, materials, and equipment shall be provided to complete the work within the authorized outage window.

Existing utility services may be interrupted only when approved by the Contracting Officer. The interruption shall be scheduled at a time of minimum demand on the utility, convenient to the Government. Outages on weekends, holidays, or evenings shall be performed at no additional cost to the Government.

SECTION 01 11 00.00 30 Page 8

Contractor shall make all necessary arrangements to schedule and provide connections to existing utilities and to cause minimum interruption to system operation. All temporary utility hook-ups and disconnects shall be made by the Contractor.

If the Contractor fails to comply with a scheduled outage, the cost to reschedule the outage will be deducted from the final contract payment.

1.10.2 Protection of Work

All construction work requires a Work Clearance Request, AF Form 103. This permit is processed by the Government and provided to the Contractor. It is required prior to the start of any construction at the project site and must be posted in a conspicuous location on site during all construction activities.

Contractor shall obtain (from technical representative), prepare, and properly complete "Base Civil Engineering Work Clearance Request" AF Form

103. Prior to submitting 103 for review and approval, contractor shall mark in white paint all locations requiring utility locates and a commercial utility locate ticket number must be obtained by calling SUNSHINE at 1-800-432-4770. Contractor shall provide coordination for location of buried structures and utility lines before beginning any work involving digging/excavation. Contact the Government Technical Representative to schedule locates prior to any excavation. The Technical representative shall be the first and the last to coordinate on the AF Form 103.

After excavation permit has been obtained and prior to any excavating, verify with Cape Support (853-5211) that there are no "Critical Days" that would prevent excavation.

Contractor shall temporarily halt any machine excavation work or other surface penetration when approaching within 5 feet of the existing utility line until the Contractor has exposed the utility line by hand excavation to fix its location.

1.10.3 Burn Permits

Burn permits are required for any spark,flame, or welding activity. Burn Permits shall be obtained thru PAFB Fire Department (494-7642).

Permits shall be posted at a conspicuous location in the construction area.

Burning of trash or rubbish is not permitted on any USAF facility.

1.11 SALVAGE AND DISPOSAL OF MATERIAL AND EQUIPMENT

1.11.1 Removal

Remove and/or relocate only those materials or items of equipment specifically indicated in the drawings and specifications. Removal operations shall be performed in such a manner that adjacent areas, installed equipment, or existing utilities are not damaged. Repair all openings that occur due to removal or demolition operations to match adjacent, existing surfaces. Any damage incurred during removal operations shall be repaired at no additional cost to the Government.

SECTION 01 11 00.00 30 Page 9

1.11.2 Housekeeping

Sufficient personnel and equipment shall be provided to ensure compliance with all housekeeping requirements. Work will not be allowed in those areas that do not comply with the requirements of Section 14.C of EM 385-1-1.

Job sites are to be kept clean on an ongoing, daily basis. All areas are to be thoroughly cleaned prior to leaving the jobsite at completion of project work.

1.11.3 Salvage of Material And Equipment

All salvageable materials or items to be removed shall remain the property of the Federal Government. Salvageable items are listed below in the paragraph entitled, "Salvage Items". Salvageable items shall be transported to and deposited at the Defense Logistics Agency Office (DLA) at Cape Canaveral Air Force Station at the contractor's expense.

Salvageable material must be segregated and separated into categories before transport. Material shall be palletized or moveable by forklift (maximum 10,000 lbs). For material that is not palletized, it will be the responsibility of the Contractor to provide labor support for material removal.

Deliveries to DLA shall be scheduled through the Contracting Officer a minimum of 72 hours in advance. All salvageable items delivered to DLA shall be accompanied by a properly prepared DD Form 1348. This form will be furnished by the Contracting Officer. A signed copy by DLA reflecting the turn in materials shall be furnished to the Contracting Officer.

Contractor shall maintain property control records for material or equipment designated as salvage. Contractor's system of property control may be used if approved by the Contracting Officer. Contractor shall be responsible for storage and protection of salvaged materials and equipment until disposition by the Contracting Officer.

Material to be salvaged and reinstalled by the Contractor shall be protected during removal and stored to prevent damage.

For reference purposes salvageable is defined as: items, material, equipment which can be refitted, reworked, and restored and put to use or sold. The Contracting Officer shall have sole discretion as to determining whether any particular item is salvageable.

1.11.3.1 Salvage Items - see attached drawings

Any additional items shall be inspected by the Contracting Officer to determine whether salvageable or debris. All salvageable materials shall be delivered to the DLA facility within Cape Canaveral Air Force Station at Contractor's expense. Salvageable material delivery shall also be accompanied by a properly prepared DD Form 1348.

1.11.4 Waste Disposal

Non-salvageable material and debris shall be removed from work areas and disposed of daily. Contractor shall dispose of C&D at a State approved disposal site.

Refer to Section 01 57 19 TEMPORARY ENVIRONMENTAL CONTROLS for further waste disposal and record keeping requirements.

SECTION 01 11 00.00 30 Page 10

1.11.5 Cleanup

All waste materials, except indicated salvaged items, generated by the construction shall be hauled off U.S. Government property at the end of each work day and deposited at a disposal site selected by the Contractor.

Disposal shall be in accordance with federal, state, county and city ordinances and at the expense of the Contractor.

Upon completion of the construction each day, the Contractor shall leave the work premises in a clean, neat and workmanlike condition, satisfactory to the Contracting Officer.

1.11.6 Salvage And Disposal Record Keeping

Contractor shall maintain and submit quarterly and at the completion of the project the SOLID WASTE DISPOSAL DIVERSION TRACKING form to the Contracting Officer of all materials removed from the job site. This inventory shall include waste materials disposed in landfills and materials reused on the job, sold for salvage and recycled.

1.12 RADIO FREQUENCY MANAGEMENT PROCEDURES

The following procedures shall be followed in obtaining radio frequency authorization:

The policy and procedures contained in AFI 33-580 shall be followed to obtain frequency allocation approval of electronic devices and USAF Radio Frequency Assignment.

1.13 COMMUNICATION SECURITY

Government telecommunications networks are continually subject to interception by hostile/unfriendly intelligent organizations. Therefore, the DOD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls from, or terminating at, DOD organizations. Contractor shall assume the responsibility for ensuring frequent dissemination of this information to all employees dealing with official DOD information.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

3.1 ACCESS REQUIREMENTS

3.1.1 Construction Site Requirement

All on-site project work is confined to non-restricted areas. That is, no restricted area badge shall be necessary to accomplish the on-site work.

However, normal access requirements into PAFB must still be accomplished.

3.2 PAFB VEHICLE INSPECTION

The Oversized Vehicle Search Area is located on State Road A1A approximately 1 mile north of Pineda Causeway. Manned Operating hours are scheduled from 0600-1700. For after hours access, call PAFB Security

SECTION 01 11 00.00 30 Page 11

Forces at (321) 494-2000 to co-ordinate entry. Mandatory inspection is required for all: Commercial Vehicles, Tractor Trailers, Trailers, RVs and Boats. All other passenger vehicles will be turned away from this gate and are required to enter at either the Main Gate or South Gate. Allow ample time for inspections, especially for the critical delivery period of mixed concrete. The government will not be responsible for rejected batches, caused by Contractor delays. Advance coordination is highly recommended.

3.3 PAFB DELIVERIES

3.3.1 Non-Hazardous Deliveries

All deliveries of construction material and equipment to job sites (including cement trucks) shall use the PAFB Oversized Vehicle Search Area (located on State Road A1A approximately 1 mile north of Pineda Causeway) for access. The operating hours for the Oversized Vehicle Search Area are 0600-1700. After hours access shall be through the South Gate. The driver of each delivery vehicle and their passengers must have the following:

a. A valid photo ID; and

b. A valid bill of lading; and

c. A known delivery point on PAFB; and

d. An on-base or local phone number and POC to vouch for delivery

Only deliveries that can be verified will be allowed to proceed. Special deliveries, deliveries after normal business hours, or deliveries that cannot negotiate through the barricades must be coordinated in advance.

All delivery vehicles shall be inspected by Security Forces personnel prior to being allowed to proceed onto the installation.

3.3.2 Hazardous Deliveries

Deliveries of fuel, large volume of chemicals, or other hazardous materials shall comply with this section. All hazardous deliveries shall enter through the same gates as non-hazardous delivers and have the information required for non-hazardous deliveries (see subpart entitled "Non-Hazardous Deliveries" of this section). Only deliveries that can be verified will be allowed to proceed. In addition, hazardous deliveries must be scheduled a minimum of 48 hours in advance for escort by Security Forces to and from job site. Contractors shall contact the PAFB Security Forces at 321-494-2000 to arrange for hazardous delivery escorts. Deliveries that have not arranged in advance for Security Forces escorts will be turned away and must be re-scheduled.

3.4 RESPONSIBILITIES

The Government reserves the right to revoke badging authority, escort authority and/or base access privileges for any person, at any time and for any reason. Contractor understands that the Government has made every attempt to identify potential delays associated with background checks and badging requirements and those delays have been considered in the construction schedule. Delays resulting from the Contractor's failure to follow the badging guidelines above shall not be considered grounds for contract extension or compensation.

SECTION 01 11 00.00 30 Page 12

3.5 EXCAVATION

3.5.1 Dig/Utility Locate Permit Requirements

3.5.1.1 Location of Buried Structures and Utility Lines

Accurately locate and paint structures and utility lines indicated by the Government provided Utility Locators on PAFB. If unidentified underground utilities are encountered during excavation, notify the Contracting Officer and cease operations until they are properly identified.

3.5.1.2 Excavation, Trenching, and Backfilling

Open only those trenches for which material is ready to be placed. As soon as approved by the Technical Representative, trenches shall be backfilled and tamped as required by the drawings and specifications. As a minimum, the topsoil shall be replaced and the disturbed area shall be grassed by seeding, watered and maintained for a minimum of 60 calendar days. All excavation shall be in compliance with OSHA regulations. Mark or barricade construction work which may present a hazard.

3.5.1.3 Cutting of Roads, Streets, Driveways, and Paved Areas

Repair roads, streets, and paved parking areas which require surface cutting under this project within 10 calendar days after initial cutting.

The topping shall be a minimum of 2 inches of asphalt and match existing (concrete topping on asphalt areas is not allowed). Mark, barricade, and illuminate construction work on or near roads or streets which may present a traffic hazard per OSHA 29 CFR 1910. Contractor shall provide signaling, lighting, and barricades in the construction area conforming to the Manual on Uniform Traffic Control Devices, OSHA 29 CFR 1926.201 and 1926.202.

Closures of Streets, parking lots, and other traffic areas will not be permitted unless approved by the Contracting Officer after written request 14 calendar days before the scheduled closure.

3.5.2 Restrictions

Excavation at the work site may be accomplished with machinery only after underground utilities have been identified and with approval by Contracting Officer.

Hand digging is required within five feet of located underground utilities.

3.5.3 Temporary Shoring, Bracing And Supports

All new excavation and trenching work shall be securely and safely supported during installation with temporary, but substantial, shoring, bracing, hangers and other supports as required by OSHA regulations. After new work is completed and completely cured (if required) and all permanent fasteners, anchors and supports are properly installed, the temporary supports shall be removed.

3.5.4 Barricades

Guardrails, fences or other suitable barricades and warning lights shall be placed at all open excavations/trenches which are adjacent to paths, walkways, sidewalks, vehicle parking areas, and other pedestrian or vehicle thoroughfares. Coordinate with 45 CE Environmental prior to placing warning lights.

SECTION 01 11 00.00 30 Page 13

3.6 WELDER QUALIFICATION REQUIREMENTS

3.7 HOISTING AND LIFTING

3.7.1 Lifting Operation Plan

Contractor shall have a Lifting Operation Plan and procedure that is fully in accordance with the requirements of OSHA regulations, and shall include drawings/sketches of lifting slings, lifting equipment, and tag lines. The plan shall show weights, center of gravity, and clearances of load over entire lift. Plans shall have details showing any structural mounting of hoisting equipment on sheaves or structural steel, and shall show loading calculations on any such structural mounting showing forces, weights, turning moments, etc. A procedure shall accompany the drawings describing all lifting operations. Use spreader bars wherever necessary to prevent hoisting cables from contacting equipment/material.

3.8 QUALITY CONTROL

It is the Contractor's responsibility to provide, inspect and document the level of quality that has been established by all applicable standards, codes and guidelines. The Contractor shall use skilled workers, an adequate number of which are thoroughly trained and have a minimum of 3 years experience in the necessary crafts and who are completely familiar with the specified requirements and the methods needed for the proper performance of the work in each section of these specifications. Contractor shall submit Superintendent Contact and Qualifications to the Contracting Officer.

3.8.1 Licenses

Contractor or their subcontractors shall be licensed by the State of Florida or have an equivalent out-of-state license in all areas applicable to this contract or as otherwise stated elsewhere in this contract. Copies of licenses and certificates shall be provided to the Contracting Officer.

Asbestos Abatement Contractor shall be licensed by the State of Florida.

3.8.2 Quality Control Manager

The Quality Control Manager shall direct the execution of the Contractor's approved Quality Control Plan with exclusive responsibility for administration of the plan and inspections of work. The Quality Control Manager shall be available during normal duty within thirty (30) minutes after notification to meet with the Contracting Officer, or designated representative. The Quality Control Manager shall be a different individual than the project superintendent.

3.8.3 Government Inspection/Approval

When the Contractor considers that the work is acceptable to the Government and is complete, he/she shall inform the Contracting Officer, or designated representative, and the Government Project Manager that the work is complete and ready for inspections. In the event that the work is not acceptable, the Contractor shall record a list of items noted by the Government Project Manager, A subsequent inspection may take place in order to review the corrected items. The Government is not required to inspect all work.

SECTION 01 11 00.00 30 Page 14

3.8.4 Inspection Files

The Contractor shall be responsible for keeping inspection files for all projects. Files shall include on site records of all inspections conducted by the Contractor and the necessary corrective actions taken. Daily Reports shall be kept and made available to the Government throughout the contract performance period and for the period after completion until final settlement of any claims made under this contract.

3.9 SUPERINTENDENT

Provide name and qualifications and past experience for review. Designate a competent superintendent who shall have full authority to act for the Contractor and who shall be the primary contact with the Government until acceptance. Contractor's superintendent shall be at the job site at all times when work is taking place and shall have full authority to act for the Contractor.

3.10 CONSTRUCTION SCHEDULING REQUIREMENTS

3.10.1 Contractor Coordination Meetings

Contractor shall attend weekly project meetings, not to exceed 3 hours, scheduled by the Government. Contractor's Superintendent shall attend the scheduled coordination meetings. Subcontractor representatives shall attend as required.

Discussion shall address the progress schedule, potential factors of delay, deficiencies, material delivery schedules, submittals, and safety issues.

3.10.2 On-Site Construction Sequence

The required work shall be performed in a sequence to minimize the time when potable water, air conditioning, panelboards, transformers, power supply, etc. are inoperative or out-of-service. Remove a single item of equipment, install the new replacement item, tie in required utilities, test, and restore the new item of equipment to fully operational status before removing subsequent equipment.

-- End of Section --

SECTION 01 11 00.00 30 Page 15

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

1.1.2 Approving Authority

1.1.3 Work

1.2 SUBMITTALS

1.3 SUBMITTAL CLASSIFICATION

1.3.1 Government Approved (G)

1.4 PREPARATION

1.4.1 Transmittal Form

1.5 QUANTITY OF SUBMITTALS

1.5.1 Number of Copies of SD-02 Shop Drawings

1.5.2 Number of Copies of SD-03 Product Data and SD-08

Manufacturer's Instructions

1.5.3 Number of Samples SD-04 Samples

1.5.4 Number of Copies SD-05 Design Data and SD-07 Certificates

1.5.5 Number of Copies SD-06 Test Reports and SD-09 Manufacturer's

Field Reports

1.5.6 Number of Copies of SD-10 Operation and Maintenance Data

1.5.7 Number of Copies of SD-01 Preconstruction Submittals and SD-11

Closeout Submittals

1.6 SUBMITTAL REGISTER

1.6.1 Use of Submittal Register

1.6.2 Contractor Use of Submittal Register

1.6.3 Approving Authority Use of Submittal Register

1.7 SCHEDULING

1.8 GOVERNMENT APPROVING AUTHORITY

1.8.1 Review Notations

1.9 DISAPPROVED SUBMITTALS

1.10 APPROVED SUBMITTALS

1.11 APPROVED SAMPLES

PART 2 PRODUCTS

2.1 Material Submittals

PART 3 EXECUTION

3.1 General

-- End of Section Table of Contents --

SECTION 01 33 00 Page 1

SECTION 01 33 00

SUBMITTAL PROCEDURES

05/11

PART 1 GENERAL

1.1 DEFINITIONS

1.1.1 Submittal Descriptions (SD)

Submittals requirements are specified in the technical sections.

Submittals are identified by Submittal Description (SD) numbers and titles as follows:

SD-01 Preconstruction Submittals

Submittals which are required prior to

Certificates of insurance

Surety bonds

List of proposed Subcontractors

List of proposed products

Construction progress schedule

Network Analysis Schedule (NAS)

Submittal register

Schedule of prices or Earned Value Report

Health and safety plan

Work plan

Quality Control(QC) plan

Environmental protection plan

SD-02 Shop Drawings

Drawings, diagrams and schedules specifically prepared to illustrate some portion of the work.

Diagrams and instructions from a manufacturer or fabricator for use in producing the product and as aids to the Contractor for integrating the product or system into the project.

Drawings prepared by or for the Contractor to show how multiple systems and interdisciplinary work will be coordinated.

SD-03 Product Data

SECTION 01 33 00 Page 2

Catalog cuts, illustrations, schedules, diagrams, performance charts, instructions and brochures illustrating size, physical appearance and other characteristics of materials, systems or equipment for some portion of the work.

Samples of warranty language when the contract requires extended product warranties.

SD-04 Samples

Fabricated or unfabricated physical examples of materials, equipment or workmanship that illustrate functional and aesthetic characteristics of a material or product and establish standards by which the work can be judged.

Color samples from the manufacturer's standard line (or custom color samples if specified) to be used in selecting or approving colors for the project.

When required by the design or requested by the Contracting Officer as part of the construction process, provide field samples and mock-ups constructed on the project site establish standards by which the ensuring work can be judged. Includes assemblies or portions of assemblies which are to be incorporated into the project and those which will be removed at conclusion of the work.

SD-05 Design Data

Design calculations, mix designs, analyses or other data pertaining to a part of work.

SD-06 Test Reports

Report signed by authorized official of testing laboratory that a material, product or system identical to the material, product or system to be provided has been tested in accord with specified requirements. Unless specified in another section, testing must have been within three years of date of contract award for the project.

Report which includes findings of a test required to be performed by the Contractor on an actual portion of the work or prototype prepared for the project before shipment to job site.

Report which includes finding of a test made at the job site or on sample taken from the job site, on portion of work during or after installation.

Investigation reports.

Daily logs and checklists.

Final acceptance test and operational test procedure.

SD-07 Certificates

Statements printed on the manufacturer's letterhead and signed by responsible officials of manufacturer of product, system or material attesting that product, system or material meets specification requirements. Must be dated after award of project contract and

SECTION 01 33 00 Page 3 clearly name the project.

Document required of Contractor, or of a manufacturer, supplier, installer or Subcontractor through Contractor. The document purpose is to further promote the orderly progression of a portion of the work by documenting procedures, acceptability of methods or personnel qualifications.

Confined space entry permits.

Text of posted operating instructions.

SD-08 Manufacturer's Instructions

Preprinted material describing installation of a product, system or material, including special notices and (SDS)concerning impedances, hazards and safety precautions.

SD-10 Operation and Maintenance Data

Data that is furnished by the manufacturer, or the system provider, to the equipment operating and maintenance personnel, including manufacturer's help and product line documentation necessary to maintain and install equipment. This data is needed by operating and maintenance personnel for the safe and efficient operation, maintenance and repair of the item.

This data is intended to be incorporated in an operations and maintenance manual or control system.

SD-11 Closeout Submittals

Documentation to record compliance with technical or administrative requirements or to establish an administrative mechanism.

Submittals required for Guiding Principle Validation (GPV) or Third Party Certification (TPC).

Special requirements necessary to properly close out a construction contract. For example, Record Drawings and as-built drawings. Also, submittal requirements necessary to properly close out a major phase of construction on a multi-phase contract.

Interim "DD Form 1354" with cost breakout for all assets 30 days prior to facility turnover.

1.1.2 Approving Authority

Office or designated person authorized to approve submittal.

1.1.3 Work

As used in this section, on- and off-site construction required by contract documents, including labor necessary to produce submittals, construction, materials, products, equipment, and systems incorporated or to be incorporated in such construction.

SECTION 01 33 00 Page 4

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor QC approval.

Submit the following in accordance with this section.

SD-01 Preconstruction Submittals

Submittal Register; G

1.3 SUBMITTAL CLASSIFICATION

Submittals are classified as follows:

1.3.1 Government Approved (G)

Government approval is required for extensions of design, critical materials, deviations, equipment whose compatibility with the entire system must be checked, and other items as designated by the Contracting Officer.

Within the terms of the Contract Clause entitled, "Specifications and Drawings for Construction," they are considered to be "shop drawings."

1.4 PREPARATION

1.4.1 Transmittal Form

1.5 QUANTITY OF SUBMITTALS

1.5.1 Number of Copies of SD-02 Shop Drawings

Submit 5 copies of submittals of shop drawings requiring review and approval only by QC organization and by Contracting Officer.

1.5.2 Number of Copies of SD-03 Product Data and SD-08 Manufacturer's Instructions

Submit in compliance with quantity requirements specified for shop drawings.

1.5.3 Number of Samples SD-04 Samples

a. Submit one sample showing range of variation, of each required item.

One approved sample or set of samples will be retained by approving authority and one will be returned to Contractor. A copy of the transmittal form, marked with review notations including selections by the Contracting Officer, will be returned to the Contractor.

b. Submit one sample panel or provide one sample installation where directed. Include components listed in technical section or as directed. Samples that are intended or permitted to be returned and actually incorporated in the work are so indicated in the individual technical sections. These samples will be returned to the Contractor, at his expense, to be clearly labeled, with installation location recorded. Samples shall be in undamaged condition at the time of installation.

c. Submit one sample installation, where directed.

d. Submit one sample of non-solid materials.

SECTION 01 33 00 Page 5

1.5.4 Number of Copies SD-05 Design Data and SD-07 Certificates

Submit in compliance with quantity requirements specified for shop drawings.

1.5.5 Number of Copies SD-06 Test Reports and SD-09 Manufacturer's Field Reports

Submit in compliance with quantity and quality requirements specified for shop drawings other than field test results that will be submitted with QC reports.

1.5.6 Number of Copies of SD-10 Operation and Maintenance Data

Submit four copies of O&M Data to the Contracting Officer for review and approval.

1.5.7 Number of Copies of SD-01 Preconstruction Submittals and SD-11 Closeout Submittals

Unless otherwise specified, submit five sets of administrative submittals.

1.6 SUBMITTAL REGISTER

Use electronic submittal register form AF 3000. Do not change data which is output in columns (c), (d), (e), and (f) as delivered by Government;

retain data which is output in columns (a), (g), (h), and (i) as approved.

A submittal register showing items of equipment and materials for which submittals are required by the specifications is provided as an attachment. This list may not be all inclusive and additional submittals may be required. Design Engineering shall be responsible for reviewing and approving submittals to ensure that they are in compliance with technical requirements as specified in the SOW.

Complete the following on the register:

Column (f) Contractor Submit Date; Scheduled date for the Contracting Officer to receive submittals.

Construction Management will update the following fields:

Column (g) List date of submittal receipt.

Column (l) List date returned to Contractor.

Contract Officer will fill out Columns (h) through (k).

Column (c): Lists specification section in which submittal is required.

Column (d): Lists each submittal description (SD No. and type, e.g. SD-02 Shop Drawings) required in each specification section.

Column (e): Lists one principal paragraph in specification section where a material or product is specified. This listing is only to facilitate locating submitted requirements. Do not consider entries in column (e) as limiting project requirements.

1.6.1 Use of Submittal Register

Submit submittal register. Submit with QC plan and project schedule.

SECTION 01 33 00 Page 6

Verify that all submittals required for project are listed and add missing submittals. Coordinate and complete the following fields on the register submitted with the QC plan and the project schedule:

Column (a) Activity Number: Activity number from the project schedule.

Column (g) Contractor Submit Date: Scheduled date for approving authority to receive submittals.

Column (h) Contractor Approval Date: Date Contractor needs approval of submittal.

Column (i) Contractor Material: Date that Contractor needs material delivered to Contractor control.

1.6.2 Contractor Use of Submittal Register

Update the following fields with each submittal throughout contract.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (j) Action Code (k): Date of action used to record Contractor's review when forwarding submittals to QC.

Column (l) List date of submittal transmission.

Column (q) List date approval received.

1.6.3 Approving Authority Use of Submittal Register

Update the following fields.

Column (b) Transmittal Number: Contractor assigned list of consecutive numbers.

Column (l) List date of submittal receipt.

Column (m) through (p) List Date related to review actions.

Column (q) List date returned to Contractor.

1.7 SCHEDULING

Schedule and submit concurrently submittals covering component items forming a system or items that are interrelated. Include certifications to be submitted with the pertinent drawings at the same time. No delay damages or time extensions will be allowed for time lost in late submittals. An additional 14 calendar days will be allowed and shown on the register for review and approval.

a. Coordinate scheduling, sequencing, preparing and processing of submittals with performance of work so that work will not be delayed by submittal processing. Allow for potential resubmittal of requirements.

b. Submittals called for by the contract documents will be listed on the register. If a submittal is called for but does not pertain to the contract work, the Contractor is to include the submittal in the

SECTION 01 33 00 Page 7 register and annotate it "N/A" with a brief explanation. Approval by the Contracting Officer does not relieve the Contractor of supplying submittals required by the contract documents but which have been omitted from the register or marked "N/A."

c. Re-submit register and annotate monthly by the Contractor with actual submission and approval dates. When all items on the register have been fully approved, no further re-submittal is required.

d. Carefully control procurement operations to ensure that each individual submittal is made on or before the Contractor scheduled submittal date shown on the approved "Submittal Register."

1.8 GOVERNMENT APPROVING AUTHORITY

When approving authority is Contracting Officer, the Government will:

a. Note date on which submittal was received.

b. Review submittals for approval within scheduling period specified and only for conformance with project design concepts and compliance with contract documents.

c. Identify returned submittals with one of the actions defined in paragraph entitled, "Review Notations," of this section and with markings appropriate for action indicated.

Upon completion of review of submittals requiring Government approval, stamp and date submittals. Four copies of the submittal will be retained by the Contracting Officer and one copy of the submittal will be returned to the Contractor.

1.8.1 Review Notations

Submittals will be returned to the Contractor with the following notations:

a. Submittals marked "approved" or authorize the Contractor to proceed with the work covered.

b. Submittals marked "approved as noted" authorize the Contractor to proceed with the…