Amend_1.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION

NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

Amendment 1

SOLICITATION #AG-5F48-S-15-0015

RIVER VALLEY WRP RESTORATION PROJECT

Site Showing was conducted on Wednesday, 6/17/15 beginning at 9am CST. Site Showing participants are listed below:

Aaron Sykes Solutions 101 Jeff Washkovick R&R Wash Materials, Inc.

Roger Thimm Wondra Construction Ben Kinas Kinas Excavating

Amendment 1 also provides:

• updated Section B, Supplies or Services and Prices, which adds line item 7 for Silt Fence

– Removal

• updated Section 5 – Construction Site Pollution, under Special Provisions that addresses Measurement and Payment of Silt Fence.

AMENDMENT 1

PART I – THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICES

RIVER VALLEY WETLAND RESERVE PROGRAM (WRP) RESTORATION PROJECT

WAUSHARA COUNTY, WI

Solicitation requires bidding on all line items, failure to do so will disqualify the bid.

Line Item Description Estimated

Quantity Unit Unit Price Price

001 Mobilization/Demobilization 1 LUMP SUM xxxx

002 Water Control Structure & Pipe 1 LUMP

003 Earth Fill & Excavation 1 LUMP

004 Culvert & WC Structure Removal 1 LUMP

005 Seeding 7 ACRES $

006 Silt Fence 2300 LINEAR FEET xxxx

007 Silt Fence - Removal 2300 LINEAR FEET xxxx

TOTAL BID

PRICE $

FAR 52.211-18 Variation in Estimated Quantity (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

ONE AWARD FOR THE AGGREGATE OF ALL ITEMS WILL BE MADE AS A RESULT OF THIS

SOLICITATION

River Valley WRP - Waushara Page 4 of 28 AG-5F48-S-15-0015

2912 Red Fox Run Portage, WI 53901 Phone: (608) 742-5361 x3 Fax: (608) 742-0194 www.wi.nrcs.usda.gov

River Valley

Wetland Restoration Project 2015

APPLICABLE WISCONSIN CONSTRUCTION SPECIFICATIONS

PROJECT SPECIFICATIONS - Special Provisions

WISCONSIN CONSTRUCTION SPECIFICATION - 2. Excavation

WISCONSIN CONSTRUCTION SPECIFICATION – 5. Construction Site Pollution

WISCONSIN CONSTRUCTION SPECIFICATION - 7. Mobilization & Demobilization

WISCONSIN CONSTRUCTION SPECIFICATION – 15. Plastic Pipe Conduits

WISCONSIN CONSTRUCTION SPECIFICATION – 50. Organic Fill for Ditch Fill or Filling

WISCONSIN CONSTRUCTION SPECIFICATION – 51. Organic fill for embankments

Note: Where the term Technician is used throughout the solicitation and resultant contract, this term shall mean Contracting Officer’s Technical Representative (COTR).

SPECIAL CONSTRUCTION PROVISIONS

Contents: Work under this section is intended to supplement the individual construction specifications.

This section does not relieve the Contractor from fulfilling all items in said sections. The numbers of the section are referenced to those of USDA-NRCS-Wisconsin Section IV Technical Guide – Wisconsin Construction Specifications.

Helping People Help the Land

An Equal Opportunity Provider and Employer http://www.wi.nrcs.usda.gov/

Phone: (608) 742-5361 x3

The Special Procedures items will supplement the standard specifications that are being referenced.

PERMITS

The contractor shall comply in entirety with the requirements of the following permits:

1. WDNR General WPDES Permit for storm water discharge from a construction site.

2. WDNR Chapter 30 Water Quality Certification.

SEEDING

Description of Work

Contractor shall seed disturbed areas of the ditch fills, embankments, scrape areas, and fill areas.

This work shall consist of the site preparation activities and furnishing and installing the necessary vegetative material as specified on the seeding sheet included in the Plan. A pre-planting conference will be held between the Contractor and the COTR or their delegate to discuss the planting operation. Planting will not begin before this meeting.

Measurement and Payment

Seeding will be measured to the nearest 0.1 acre and will be paid based on acres installed for Seeding.

WISCONSIN CONSTRUCTION SPECIFICATIONS

SECTION 2 – EXCAVATION

Measurement and Payment

Excavation will not be measured and will be paid as a lump sum for Excavation/Earthfill.

Water control structures that are not used will be removed and measured and paid as a lump sum when all 14 existing structures are removed.

SECTION 5 – CONSTRUCTION SITE POLLUTION

Silt fence will be measured to the nearest foot and will be paid based on lineal feet installed for Construction Site Pollution Control. Silt fence removal will be measured to the nearest foot and will be paid based on lineal foot removed after vegetation is established. COTR will determine when silt fence can be removed.

SECTION 7 – MOBILIZATION AND DEMOBILIZATION

Mobilization and Demobilization will not be measured and will be paid for at the contract lump sum price for Mobilization.

Phone: (608) 742-5361 x3

SECTION 15 – PLASTIC PIPE CONDUITS

PLASTIC PIPE CONDUITS will not be measured and will be paid as a lump sum for Water Control Structure/Pipe.

SECTION 50 – ORGANIC FILL FOR DITCH FILLS OR FILLING

Earthfill will not be measured and will be paid as a lump sum for Excavation/Earthfill.

SECTION 51 – ORGANIC FILL FOR EMBANKMENTS

Earthfill will not be measured and will be paid as a lump sum for Excavation/Earthfill.

8030 EXCELSIOR DRIVE, SUITE 200

MADISON, WI 53717-2906

See page 2 which provides Site Showing Participants.

Amendment 1 provides an updated Section B, Supplies or Services and Prices, which adds line item 7 for Silt Fence - Removal.

Amendment 1 provides an updated Section 5 - Construction Site Pollution, under Special Provisions that addresses Measurement and Payment of Silt Fence.

Contracting Officer