Solicitation Sections C through M.docx

SECTION C- DESCRIPTION/SPECIFICATIONS

452.211-72 Statement of Work/Specifications (FEB 1988)

Construction of the Jefferson County Emergency Watershed Protection Program-Floodplain Easement Program (EWPP-EWP) Construction Project, Jefferson County, Wisconsin. The work consists of the following:

· Installation of required erosion control measures

· Tile exploration

· Tile removal and replacement with non-perforated tile

· Tree clearing

· Filling of drainage ditch

· Excavation of material from scrape and borrow areas, and pushing of material to fill ditches

· Seeding of disturbed areas

The Contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified), to perform the Specifications/Drawings referenced in Section J, List of Documents, Exhibits, and Other Attachments.

452.211-73 Attachments to Statements of Work/Specifications (FEB 1988)

The attachments to the Statement of Work/Specifications listed in Section J are hereby made party of this solicitation and any resultant contract.

Biobased Products

The Contractor must comply with Section 9002 of the Farm Security and Rural Investment Act of 2002 (FSRIA), Executive Order (EO) 13423, “Strengthening Federal Environmental, Energy, and Transportation Management,” and the Federal Acquisition Regulation to provide biobased products. The Contractor shall utilize products and material made from biobased materials (e.g., insulating foam, composite panels, and concrete and asphalt release fluids) to the maximum extent possible without jeopardizing the intended end use or detracting from the overall quality delivered to the end user. All supplies and materials shall be of a type and quality that conform to applicable Federal specifications and standards. All supplies and materials to be used in the performance of work described herein are subject to the approval of the Contracting Officer’s Technical Representative (COTR).

The following is an example list of products that may be used in this contract for minor construction for which biobased products are available. The list is not all inclusive. It is desirable that vendors be able to supply the greatest number of biobased products listed meeting the health and environmental specifications.

· Graffiti and grease removers

· Insulating foam

· Concrete and asphalt release fluids

· Fluid-filled transformers

· Wood and concrete sealers

· Composite panels

· Adhesive and mastic removers

· Carpets

· Roof coatings

· Hydraulic fluid

· Water tank coatings

Biobased products that are designated for preferred procurement under USDA’s BioPreferred program must meet the required minimum biobased content as stated in the USDA Final Rule available at www.biopreferred.gov. The Contractor should provide data for their biobased products such as biobased content and source of biobased material (i.e. particular crop or livestock). In addition to the biobased products designated by the U.S. Department of Agriculture in the BioPreferred Program, the Contractor is encouraged to use other commercially available biobased products.

The Contractor shall submit with the initial proposal a complete list of biobased products, indicating the name of the manufacturer, cost of each material, and the intended use of each of the materials that are to be used in carrying out the requirements of the contract. Additionally, the winning Contractor on each anniversary date of the contract shall compile a complete list of biobased products, including the information above, purchased to carry out the contract requirements. The Contractor shall list volume to be used and total cost for each individual product. This information will be used for reporting purposes.

The Contractor shall comply with the provision at FAR 52.223-1, Biobased Product Certification.

The Contractor shall comply with the clause at FAR 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts. Within five (5) calendar days after receipt of a written request from the Contracting Officer, the Contractor shall submit a Minor Construction Plan. This submittal shall be approved by the COTR in writing. The Contractor shall not commence work until this submittal is approved by the COTR in writing. The Plan must be reviewed and updated annually, and as required by the COTR. The Plan must contain and define the following elements:

· The Contractor’s written policy stating its commitment to the use of biobased products, employee health and safety, and sound environmental management practices.

· Detail on how the Contractor intends to keep abreast of the development and increasing availability of designated and non-designated biobased products and how any new or improved products will be incorporated on an ongoing basis into contract performance.

Proposed biobased construction products which must be selected in accordance with the criteria included above. At a minimum, the Plan must identify products by brand name for each of the product types. NOTE: A Contractor may propose more than one product within a product category and/or propose a product or products addressing more than one product category. The product guides which define standard operating procedures for instructing staff in the proper use, storage, and disposal of biobased products; proper maintenance of equipment; and other procedures/instructions to accomplish work under this contract.

The Contractor shall provide data on the quantity and dollar values of biobased products used in this contract. The data will be submitted to the COTR quarterly. A demonstration of proper use, an effective training program, and technical assistance are essential to the success of the purchase and use of some biobased products that may function differently than a conventional product. Therefore we will look for a Contractor who will 1) demonstrate products, and 2) when selected, offer any necessary training to all of the construction staff and 3) be available with technical assistance to trouble shoot problems.

SECTION D – PACKAGING AND MARKING

THERE ARE NO CLAUSES INCLUDED IN THIS SECTION

SECTION E – INSPECTION AND ACCEPTANCE

52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address:

https://acquisition.gov/far/index.html

52.246-12 Inspection of Construction (AUG 1996)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 Commencement, Prosecution, and Completion of Work (APR 1984)

The Contractor shall be required to (a) commence work under this contract within five (5) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than twelve (12) calendar days. The time stated for completion shall include final cleanup of the premises.

52.211-18 Variation in Estimated Quantity (APR 1984) If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

52.236-1 Performance of Work by the Contractor (APR 1984) The Contractor shall perform on the site, and with its own organization, work equivalent to at least fifty (50) percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

SECTION G – CONTRACT ADMINSTRATION DATA

41-52.232-70 Designated Payment Office Contact Point (NRCS, AMB, AUG 1989)

The contact point described below coordinates the issuance of payments under this contract. If payment is not received within five (5) calendar days after the due date specified in the contract, contact the payment office designated below for information on when payment will be made.

USDA-National Finance Center Administrative Payments Branch (APB) Telephone: (800) 421-0323 or (504) 426-6510

If questions arise on the amount paid, contact the Contracting Officer at the number or address shown in the contract.

Tami Lanier

(608) 662-4422, Ext. 225

(608) 608-662-4428 (Fax)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

52.236-13 Accident Prevention (NOV 1991) Alternate 1 (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will—

(1) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) Avoid interruptions of Government operations and delays in project completion dates; and

(3) Control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall—

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR Part 1926 and 29 CFR Part 1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the Contractor orally, with written confirmation, and request immediate initiation of corrective action. This notice, when delivered to the Contractor or the Contractor’s representative at the work site, shall be deemed sufficient notice of the noncompliance and that corrective action is required. After receiving the notice, the Contractor shall immediately take corrective action. If the Contractor fails or refuses to promptly take corrective action, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop work order issued under this clause.

(e) The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

(f) Before commencing the work, the Contractor shall—

(1) Submit a written proposed plan for implementing this clause. The plan shall include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards; and

(2) Meet with representatives of the Contracting Officer to discuss and develop a mutual understanding relative to administration of the overall safety program.

52.252-4 Alterations in Contract (APR 1984)

Portions of this contract are altered as follows:

Clause 52.236-13, Accident Prevention, is altered to include the following:

NRCS Supplement to OSHA, Parts 1910 and 1926, Construction Standards and Interpretations

NATURAL RESOURCES CONSERVATION SERVICE

SUPPLEMENT TO OSHA PARTS 1910 AND 1926

CONSTRUCTION INDUSTRY STANDARDS AND INTERPRETATIONS

(1) Specific reference to the provision or standard in question;

(2) An explanation as to why the waiver is considered justified; and

Copies of OHSA Parts 1910 and 1926, Construction Industry Standards and Interpretations, may be obtained from:

Superintendent of Documents U.S. Government Printing Office Washington, D.C. 20402

NATURAL RESOURCES CONSERVATION SERVICE

SUPPLEMENT TO OSHA PARTS 1910 AND 1926

CONSTRUCTION INDUSTRY STANDARDS AND INTERPRETATIONS

GENERAL CONTRACTOR REQUIREMENTS

1.6 SAFETY INSPECTION

The contractor shall perform frequent and regular safety inspections of the jobsite, materials, and equipment, and shall correct deficiencies.

1.7 FIRST AID TRAINING

Every contractor foreman's work crew must include an employee who has a current first aid certificate from the Mine Safety and Health Administration, American Red Cross, or other state-approved organization.

1.8 REPORTS.

Each contractor is to maintain an accurate record of all job-related deaths, diseases, or disabling injuries. The records shall be maintained in a manner approved by the contracting officer. A copy of all reports are to be provided to the contracting officer. All fatal or serious injuries are to be reported immediately to the contracting officer, and every assistance is to be given in the investigation of the incident, including submission of a comprehensive narrative report to the contracting officer. Other occurrences with serious accident potential, such as equipment failures, slides, and cave-ins, must also be reported immediately. The contractor is to assist and cooperate fully with the contracting officer in conducting accident investigations. The contracting officer is to be furnished all information and data pertinent to investigation of an accident.

1.9 CERTIFICATION OF INSURANCE

Contractors are to provide the contracting officer or his or her authorized representative with certificates of insurance before the start of operations indicating full compliance with State Worker's Compensation statutes. contracting officer or his or her authorized representative with certificates of insurance before the start of operations indicating full compliance with State Worker's Compensation statutes.

FIRST AID AND MEDICAL FACILITIES

2.1 FIRST AID KITS

A 16-unit first aid kit approved by the American Red Cross is to be provided at accessible, well-identified, locations at the ratio of at least 1 kit for each 25 employees. The first aid kits are to be moisture proof and dust tight, and the contents of the kits are to be replenished as used or as they become ineffective or outdated.

2.2 EMERGENCY FIRST AID

At least one employee certified to administer emergency first aid must be available on each shift and duly designated by the contractor to care for injured employees. The names of the certified employees shall be posted at the jobsite.

2.3 COMMUNICATION AND TRANSPORTATION

Prior to the start of work, the contractor is to make necessary arrangements for prompt and dependable communications, transportation, and medical care for injured employees. At least one stretcher and two blankets shall be readily available for transporting injured employees.

2.4 FIRST AID AND MEDICAL REPORTS

The contractor is to maintain a record system for first aid and medical treatment on the jobsite.

Such records are to be readily available to the contracting officer and are to include—

(a) A daily treatment log listing chronologically all persons treated for occupational injuries and illnesses;

(b) Cumulative record of injury for each individual;

(c) Monthly statistical records of occupational injuries, classified by type and nature of injury; and

(d) Required records for worker's compensation.

2.5 SIGNS AND DIRECTIONAL MARKINGS

Adequate identification and directional markers are to be provided to readily denote the location of all first aid stations.

2.6 EMERGENCY LISTING

A listing of telephone numbers and addresses of doctor, rescue squad, hospital, police, and fire departments is to be provided at all first aid locations.

PHYSICAL QUALIFICATION OF EMPLOYEES

3.1 GENERAL REQUIREMENTS

Persons employed throughout the contract are to be physically qualified to perform their assigned duties. Employees must not knowingly be permitted or required to work while their ability or alertness is impaired by fatigue, illness, or any other reason that may jeopardize themselves or others.

3.2 HOIST OPERATORS

Operators of cranes, cableways, and other hoisting equipment shall be examined annually by a physician and provided with a certification stating that they are physically qualified to safely operate hoisting equipment. The contractor is to submit a copy of each certification to the contracting officer.

3.3 HEAVY EQUIPMENT OPERATORS.

It is recommended that operators of trucks and heavy construction equipment be given physical examinations to determine if they are physically qualified to perform their assigned work without endangering themselves or others.

3.4 MOTOR VEHICLE OPERATORS

Operators of motor vehicles engaged primarily in the transportation of personnel are to be 18 years of age or older and have a valid state operator's permit or license for the equipment being operated. The operators must have passed a physical examination administered by a licensed physician within the past year showing that they are physically qualified to operate vehicles safely.

PERSONAL PROTECTIVE EQUIPMENT

4.1 HARD-HAT AREAS

The entire jobsite, with the exception of offices, shall be considered a hard-hat area. All persons entering the area are, without exception, required to wear hard-hats. The contractor shall provide hard-hats for visitors entering hard-hat areas.

4.1.1 LABELS

Hard-hats shall bear a manufacturer's label indicating design compliance with the appropriate ANSI (American National Standards Institute) Standard.

4.2 POSTING

Signs at least 3 by 4 feet worded as follows with red letters (minimum 6 inches high) and white background shall be erected at access points to designated hard-hat areas:

CONSTRUCTION AREA -- HARD-HAT REQUIRED BEYOND THIS POINT

These signs are to be furnished and installed by the contractor at entries to shops, construction yards, and job access points.

4.3 SAFETY GOGGLES (DRILLERS)

4.3.1 DRILLERS AND HELPERS.

Drillers and helpers operating pneumatic rock drills must wear protective safety goggles.

MACHINERY AND MECHANIZED EQUIPMENT

5.1 SAFE CONDITION

Before any machinery or mechanized equipment is initially used on the job, it must be inspected and tested by qualified personnel and determined to be in safe condition and appropriate for the intended use. Operators shall inspect their equipment prior to the beginning of each shift. Any deficiencies or defects shall be corrected prior to using the equipment. Safety equipment, such as seatbelts, installed on machinery is to be used by equipment operators.

5.2 TAGGING AND LOCKING

The controls of power-driven equipment under repair are to be locked. An effective lockout and tagging procedure is to be established, prescribing specific responsibilities and safety procedures to be followed by the person or persons performing repair work.

5.3 HAUL ROADS FOR EQUIPMENT

5.3.1 ROAD MAINTENANCE

The contractor shall maintain all roadways, including haul roads and access roads, in a safe condition so as to eliminate or control dust and ice hazards. Wherever dust is a hazard, adequate dust-laying equipment shall be available at the jobsite and utilized to control the dust.

5.3.2 SINGLE LANE HAUL ROADS

Single-lane haul roads with two-way traffic shall have adequate turnouts. Where turnouts are not practical, a traffic control system shall be provided to prevent accidents.

5.3.3 TWO-WAY HAUL ROADS

On two-way haul roads, arrangements are to be such that vehicles travel on the right side wherever possible. Signs and traffic control devices are to be employed to indicate clearly any variations from a right-hand traffic pattern. The road shall be wide enough to permit safe passage of opposing traffic, considering the type of hauling equipment used.

5.3.4 DESIGN AND CONSTRUCTION OF HAUL ROADS

Haul road design criteria and drawings, if requested by the contracting officer, are to be submitted for approval prior to road construction. Sustained grades shall not exceed 12 percent and all curves shall have open-sight line with as great a radius as practical. All roads shall be posted with curve signs and maximum speed limits that will permit the equipment to be stopped within one-half the minimum sight distance.

5.3.5 OPERATORS

Machinery and mechanized equipment shall be operated only by authorized, qualified persons.

5.3.6 RIDING ON EQUIPMENT

Riding on equipment by unauthorized personnel is prohibited. Seating and safety belts shall be provided for the operator and all passengers.

5.3.7 GETTING ON OR OFF EQUIPMENT

Getting on or off equipment while the equipment is in motion is prohibited.

5.3.8 HOURS OF OPERATION

Except in emergencies, an equipment operator shall not operate any mobile or hoisting equipment for more than 12 hours without an 8-hour rest interval away from the job.

5.4 POWER CRANES AND HOISTS (truck cranes, crawler cranes, tower cranes, gantry cranes, hammerhead cranes, derricks, cableways, and hoists).

5.4.1 PERFORMANCE TEST

Before initial onsite operation, at 12-month intervals, and after major repairs or modification, power cranes, derricks, cableways, and hoists must satisfactorily complete a performance test to demonstrate the equipment's ability to safely handle and maneuver the rated loads. The tests shall be conducted in the presence of a representative of the contracting officer. Test data shall be recorded and a copy furnished the contracting officer.

5.4.2 PERFORMANCE TEST--Power Cranes (Crawler mounted, truck mounted, and wheel mounted).

The performance test is to be carried out with outriggers set and with a test load weighing 110 percent of the rated capacity when the boom angle is from 30 degrees to 60 degrees above the horizontal. The test is to consist of raising, lowering and braking the load and rotating the test load through 360 degrees at the specified boom angle or radius. Cranes equipped with jibs or boom tip extensions are to be tested using both the main boom and the jib, with an appropriate test load in each case.

5.4.3 PERFORMANCE TEST--Derricks, Gantry Cranes, Tower Cranes, Cableways, and Hoists, Including Overhead Cranes.

5.4.4 BOOM ANGLE INDICATOR

Power cranes (includes draglines) with booms capable of moving in the vertical plane shall be provided with a boom angle indicator in good working order.

5.4.5 CRANE TEST CERTIFICATION

The performance test required by 5.4.2 and 5.4.3 is fulfilled if the contractor provides the contracting officer a copy of the certificate of inspection made within the past 12 months by a qualified person or by a government or private agency satisfactory to the contracting officer.

5.4.6 POSTING FOR HIGH VOLTAGE LINES

A notice of the 10-foot (or greater) clearance required by OSHA 1926.550, Subpart N, shall be posted in the operator's cab of cranes, shovels, boom-type concrete pumps, backhoes, and related equipment.

5.4.7 BOOM STOPS

Cranes or derricks with cable-supported booms, except draglines, shall have a device attached between the gantry of the A-frame and the boom chords to limit the elevation of the boom. The device shall control the vertical motions of the boom with increasing resistance from 83 degrees or less, until completely stopping the boom at not over 87 degrees above horizontal.

5.4.8 SAFETY HOOKS

Hooks used in hoisting personnel or hoisting loads over construction personnel or in the immediate vicinity of construction personnel shall be forged steel equipped with safety keepers. When shackles are used under these conditions, they shall be of the locking type or have the pin secured to prohibit turning.

5.5 ROLLOVER PROTECTIVE STRUCTURES (ROPS)

5.5.1 ROLLOVER PROTECTIVE STRUCTURES

OSHA 1926, Subpart W, Overhead Protection, Sections 1000 and 1002 are applicable regardless of the year in which the equipment was manufactured and regardless of the struck capacity of the equipment.

5.5.2 EQUIPMENT REQUIRING ROPS

The requirement for ROPS meeting 5.5.1 above applies to crawler and rubber-tired tractors such as dozers, push-and-pull tractors, winch tractors, tractors with backhoes, and mowers; off-highway, self-propelled, pneumatic-tired earthmovers, including scrapers, motor graders and loaders; and rollers, compactors, and water tankers (excluding trucks with cabs). These requirements shall also apply to agricultural and industrial tractors and similar equipment.

5.5.3 EQUIPMENT REQUIRING SEATBELTS

The requirements for seatbelts as specified in OSHA 1926, Subpart O, Motor Vehicles, Mechanized Equipment, and Marine Operations, Section 1926.602 shall also apply to self-propelled compactors and rollers, and rubber-tired skid-steer equipment.

LADDERS AND SCAFFOLDING

6.1 LADDERS. OSHA 1926, Subpart L - Section 450

Ladders shall be used as work platforms only when use of small hand tools or handling of light material is involved. No work requiring lifting of heavy materials or substantial exertion shall be done from ladders.

6.2 SCAFFOLDING. OSHA 1926, Subpart L - Section 451.

Scaffolds, platforms or temporary floors shall be provided for all work except that which can be done safely from the ground or similar footing.

6.3 SAFETY BELTS, LIFELINE, AND LANYARDS. OSHA 1926, Subpart E, Section 104. Lifelines, safety belts and lanyards independently attached or attended, shall be used when performing such work as the following when the requirements of 6.1 or 6.2 above cannot be met.

(a) Work on stored material in hoppers, bins, silos, tanks, or other confined spaces.

(b) Work on hazardous slopes, structural steel, or poles; erection or dismantling of safety nets, tying reinforcing bars; and work from Boatswain's chairs, swinging scaffolds, or other unguarded locations at elevations greater than 6 feet.

opening to within 1 foot of the sides of the shaft, unless cages are provided.

452.236-73 Archaeological or Historic Sites (FEB 1988)

If a previously unidentified archaeological or historic site(s) is encountered, the Contractor shall discontinue work in the general area of the site(s) and notify the Contracting Officer immediately.

452.236-74 Control of Erosion, Sedimentation, and Pollution (NOV 1996)

452.236-75 Maximum Workweek – Construction Schedule (NOV 1996)

Within five (5) calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following in writing for approval:

(a) A schedule as required by FAR Clause 52.236-15, Schedules for Construction Contracts; and

The maximum workweek that will be approved is: MONDAY THROUGH FRIDAY, 10 HOURS A DAY.

PART II – CONTRACT CLAUSES

SECTION I – CONTRACT CLAUSES

52.252-2 Clauses Incorporated by Reference (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address:

52.203-15 Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (MAR 2009) 52.204-7 Central Contractor Registration (APR 2008) 52.204-11 American Recovery and Reinvestment Act—Reporting Requirements (MAR 2009) 52.209-6 Protecting the Government’s Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment (SEP 2006) 52.219-28 Post-Award Small Business Program Representation (APR 2009) 52.222-3 Convict Labor (JUN 2003) 52.222-6 Davis-Bacon Act (JUL 2005) 52.222-7 Withholding of Funds (FEB 1988) 52.222-8 Payrolls and Basic Records (FEB 1988) 52.222-9 Apprentices and Trainees (JUL 2005) 52.222-10 Compliance with Copeland Act Requirements (FEB 1988) 52.222-11 Subcontracts (Labor Standards) (JUL 2005) 52.222-12 Contract Termination – Debarment (FEB 1988) 52.222-13 Compliance with Davis-Bacon and Related Act Regulations (FEB 1988) 52.222-14 Disputes Concerning Labor Standards (FEB 1988) 52.222-15 Certification of Eligibility (FEB 1988) 52.222-21 Prohibition of Segregated Facilities (FEB 1999) 52.222-26 Equal Opportunity (MAR 2007) 52.222-27 Affirmative Action Compliance Requirements for Construction (FEB 1999) 52.222-36 Affirmative Action for Workers with Disabilities (JUN 1998) 52.222-50 Combating Trafficking in Persons (FEB 2009) 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts (DEC 2007) 52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997) Alternate I (JUL 1995) 52.223-6 Drug-Free Workplace (MAY 2001) 52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts (MAY 2008) 52.225-5 Trade Agreements (AUG 2009) 52.225-13 Restrictions of Certain Foreign Purchases (JUN 2008) 52.227-4 Patent Indemnity—Construction Contracts (DEC 2007) 52.228-11 Pledges of Assets (AUG 2009) 52.228-12 Prospective Subcontractor Requests for Bonds (OCT 1995) 52.228-14 Irrevocable Letter of Credit (DEC 1999) 52.232-5 Payments under Fixed-Price Construction Contracts (SEP 2002) 52.232-23 Assignment of Claims (JAN 1986) 52.232-27 Prompt Payment for Construction Contracts (OCT 2008) 52.232-33 Payment by Electronic Funds Transfer--Central Contractor Registration (OCT 2003) 52.233-1 Disputes (JUL 2002) Alternate I (DEC 1991) 52.233-3 Protest after Award (AUG 1996) 52.233-4 Applicable Law for Breach of Contact Claim (OCT 2004) 52.236-2 Differing Site Conditions (APR 1984) 52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984) 52.236-5 Material and Workmanship (APR 1984) 52.236-6 Superintendence by the Contractor (APR 1984) 52.236-7 Permits and Responsibilities (NOV 1991) 52.236-8 Other Contracts (APR 1984) 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (APR 1984) 52.236-10 Operations and Storage Areas (APR 1984) 52-236-11 Use and Possession Prior to Completion (APR 1984) 52.236-12 Cleaning Up (APR 1984) 52.236-16 Quantity Surveys (APR 1984) 52.236-17 Layout of Work (APR 1984) 52.236-21 Specifications and Drawings for Construction (FEB 1997) 52.236-26 Preconstruction Conference (FEB 1995) 52.242-14 Suspension of Work (APR 1984) 52.243-5 Changes and Changed Conditions (APR 1984) 52.244-6 Subcontracts for Commercial Items (DEC 2009) 52.248-3 Value Engineering—Construction (SEP 2006) 52.249-1 Termination for Convenience of the Government (Fixed Price) (Short Form) (APR 1984) 52.249-10 Default (Fixed-Price Construction) (APR 1984)

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (FEB 1999)

(a) The offeror’s attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor’s aggregate workforce in each trade on all construction work in the covered area, are as follows:

Jefferson County: 7.0 %

Jefferson County: 6.9 %

These goals are applicable to all the Contractor’s construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor’s compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled “Affirmative Action Compliance Requirements for Construction,” and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor’s goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer’s identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the “covered area” is:

089 Milwaukee, WI:

Non-SMSA Counties: Jefferson

52.225-9 Buy American Act—Construction Materials (FEB 2009)

(a) Definitions. As used in this clause—

“Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 ( 46 U.S.C. App. 1702), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means—

(3) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(4) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

(b) Domestic preference.

(1) This clause implements the Buy American Act (41 U.S.C. 10a - 10d) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to the construction material or components listed by the Government as follows: __NONE __

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that—

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American Act applies, use of foreign construction material is noncompliant with the Buy American Act.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Item 1:

Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.]

[Include other applicable supporting information.]

[* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

52.225-21 Required Use of American Iron, Steel, and Other Manufactured Goods—Buy American Act—Construction Materials (MAR 2009)

(a) Definitions. As used in this clause— “Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States; or

(2) A construction material manufactured in the United States.

“Foreign construction material” means a construction material other than a domestic construction material.

“Manufactured construction material” means any construction material that is not unmanufactured construction material.

“Steel” means an alloy that includes at least 50 percent iron, between .02 and 2 percent carbon, and may include other elements.

“United States” means the 50 States, the District of Columbia, and outlying areas.

“Unmanufactured construction material” means raw material brought to the construction site for incorporation into the building or work that has not been—

(1) Processed into a specific form and shape; or

(2) Combined with other raw material to create a material that has different properties than the properties of the individual raw materials.

(b) Domestic preference.

(1) This clause implements—

(i) Section 1605 of the American Recovery and Reinvestment Act of 2009 (Recovery Act) (Pub. L. 111-5), by requiring, unless an exception applies, that all iron, steel, and other manufactured goods used as construction material in the project are produced in the United States; and

(ii) The Buy American Act (41 U.S.C. 10a - 10d) by providing a preference for unmanufactured domestic construction material.

(2) The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraph (b)(3) and (b)(4) of this clause.

(3) This requirement does not apply to the construction material or components listed by the Government as follows:

_______________NONE___________________________

[Contracting Officer to list applicable excepted materials or indicate “none”]

(4) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(3) of this clause if the Government determines that—

(i) The cost of domestic construction material would be unreasonable.

(A) The cost of domestic iron, steel, or other manufactured goods used as construction material is unreasonable when the cumulative cost of such material will increase the cost of the contract by more than 25 percent;

(B) The cost of unmanufactured construction material is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available quantities and of a satisfactory quality; or

(iii) The application of the restriction of section 1605 of the Recovery Act or the Buy American Act to a particular construction material would be inconsistent with the public interest.

(c) Request for determination of inapplicability of Section 1605 of the Recovery Act or the Buy American Act (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(4) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Cost;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph…