General_Requirements_-_West_Lafayette.pdf

SECTION 010100 - GENERAL REQUIREMENTS

1.1 GENERAL INTENTION

A. Contractor shall completely prepare the site for building operations, and furnish labor and materials and perform work as required by the contract documents.

B. A site visit will be scheduled and described in the solicitation.

C. All employees of general contractor and subcontractors shall comply with ARS security management program, obtain permission of the ARS Location Manager, be identified by project and employer by wearing contractor issued identification badges at all times on ARS property, and restricted from unauthorized access.

D. Prior to commencing work, the general contractor shall provide proof that an OSHA certified “competent person” (CP) (29 CFR 1926.20(b)(2) will maintain a presence at the work site whenever the general or subcontractors are present.

E. Training:

1. All employees of the general contractor or subcontractors shall have the 10-hour OSHA certified Construction Safety course and /or other relevant competency training. Supervisors shall have completed the 30-hour OSHA training.

2. Submit training records of all such employees to the Contracting Officer for approval before the start of work.

1.2 STATEMENT OF BID ITEM

A. Base Bid: BAS Modifications (i.e. install thermostat and controls, add alarm points, rebalance VAVs)

B. Additive Bid Option #1: Address fan cycling, replace fan bearing, replace control valves, replace/adjust

VAV

C. Additive Bid Option #2: Extend exhaust stack. Eliminate supply/exhaust duct cross connection

D. Additive Bid Option #3: Rewire overhead crane

E. Additive Bid Option #4: Install combination emergency eyewash showers

F. Additive Bid Option #5: Rebalance fume hoods. Remove/demolish unused equipment.

1.3 PROJECT COORDINATION:

A. Construction Project Schedule:

1. The Contractor will submit a construction project schedule to the Contracting Officer for approval within 5 days after receiving the Notice to Proceed. The Contractor will not begin actual work until the construction project schedule has been approved by the Contracting Officer.

2. The construction project schedule shall clearly show estimated construction time as well as actual construction time as the work progresses. A Gantt-type chart software shall be used.

3. The Contractor shall submit one electronic copy and one paper copy of the updated construction project schedule with each progress payment request.

B. Contract Inspector’s Daily Report:

Contractor shall submit to the Contracting Officer a daily report listing the names of all those present on the job site each day, along with their Job Classification, hours of work and a brief description of the work performed by each on that day. The Contract Inspector’s Daily Report is to be submitted at the beginning of work each day for the previous day’s work and shall be maintained throughout the term of the contract.

C. Contractor’s Contact Log (Form SF-1413):

The contractor shall provide the Contracting Officer a list of all sub-contractors in a table format listing at least the following (which apply): Company Name, Company Address, Name of Contact person(s), Telephone Numbers, Fax Numbers, and E-mail address. The Contractor shall update the list immediately when subcontractors change or are added.

D. Formal Meetings:

Any meeting (deemed formal by the contractor, the COR, or the Contracting Officer) will have the minutes of said meeting prepared by the contractor (and a copy provided to the Contracting Officer). The minutes will include: Date, Name of Attendees (with contact info), Old Business, and New Business subjects (or narratives). Regardless of who requests a meeting (the COR or the Contractor or the Contracting Officer) the contractor may be required to provide hard copy pictures of the issues to be discussed. Each issue will be linked to a contract specification section number and/or subject area by page number. Issues discussed will also include an action/completion date.

1.4 SAFETY SUBMITTALS

A. Contractor shall submit a "site specific" Safety Plan to the Contracting Officer that describes how the contractor is to comply with all applicable OSHA standards and NFPA codes pertaining to construction work to include, but not limited to: General Safety and Health Provisions, Occupational Health and Environmental Controls, Personal Protective and Life Saving Equipment, Hand and Power Tools, Welding and Cutting, Electrical, Scaffolds, Fall Protection, Demolition, Ladders, Toxic and Hazardous Substances, Respiratory Protection, Hearing Protection. Safety Plan shall identify Contractor and subcontractor employees who are authorized/qualified to perform electrical work. No work shall proceed until written approval of the Safety Plan by the Contracting Officer. Safety Plan shall describe how the Contractor and/or sub-contractors are to secure equipment, supplies, tools, and chemical products. Contractor and/or sub-contractor equipment, supplies, tools, and chemical products are to be under the control of the Contractor at all times, equipment, supplies tools, and chemical products found not to be under the control of the Contractor or sub-contractor may be confiscated and delivered to the Contracting Officer.

B. The Contractor shall inspect the entire construction site daily, including days without construction work if there are NFPA 101 Life Safety Code deficiencies existing while construction work is shut down, the results of that inspection shall documented on the attachment “DAILY INSPECTION FORM”, and the form is to be signed and submitted to the Contracting Officer.

C. Contractor shall provide continuous monitoring for noise, dust, chemical vapor generation, volatile organic compounds, and vibration. At no time shall noise exposure to any ARS staff exceed 75 dB.

Contractor shall provide to the Contracting Officer a written weekly update of the all test results and also for proposed work for the subsequent two weeks (a two week “look-ahead”)involving any construction activity that will produce loud noises, heavy vibrations, strong smells, or significant dust inside ARS staff occupied space.

D. Contractor and sub-contractors shall notify in writing the Contracting Officer at least one week prior to executing high risk work (this may be included in the two week “look-ahead” update). High risk work includes, but is not limited to, tasks requiring Lockout/Tag Out, live electrical work, hot work, work at heights, crane operations, and confined space entry. Contractor’s Competent Person shall provide the Contracting Officer written weekly documented safety inspection results.

E. Contractor shall provide to the Contracting Officer for approval, copies of Material Safety Data Sheets

(MSDS) for EVERY CHEMICAL WITHOUT EXCEPTION prior to bringing such chemical on the work site.

F. HOT WORK PERMITS: The Contractor will not be permitted to work without this permit when performing hot work.

1. A Hot Work Permit is required when cutting torch, welding, soldering and/or any other spark or heat producing equipment is to be used. A Hot Work Permit will be requested at least one work day in advance of the proposed work and will be issued only for the period necessary to perform such work.

See Attachment: “Hot Work Permit”

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The General Contractor is responsible for assuring that all sub-contractors working on the project and their employees also comply with these regulations.

B. Contractor Personnel

1. Upon receipt of the Notice to Proceed, the Contractor shall provide information about every employee including that of all sub-contractors who will need access to construction site. Completion of the SF-87 fingerprint cards (2 sets), and successful completion of the background investigation are required before Contractor staff may enter the work site. Not more than 21 (twenty one) calendar days will be required for the Government to complete background investigations after the Government receives all necessary information for each employee. No contract time extension will be granted based on failure of the Contractor to provide complete, accurate and timely information to the Government. All background investigation information shall be provided directly to:

Personnel Security and Suitability Office

5601 Sunnyside Ave Beltsville, MD 20705

2. Every employee of the Contractor or sub-contractor shall go through a security screening to determine their suitability for access to ARS facilities.

a. Conviction of tax evasion may disqualify a person for working on an ARS construction project.

b. Act of violence; arrest for firearms; illegal alien status or any felony conviction or possession of explosives will disqualify any person for working on any ARS construction project.

3. Each employee shall be furnished with a badge by the Government for access to construction site.

This badge must be worn so as to be clearly visible at all times while on the work site.

C. Security Procedures:

1. Contractor’s employees shall not enter the project site without appropriate badges. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. For working outside the “regular hours” as defined in the contract, The Contractor shall give a ten

(10) day notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of ARS premises is allowed without written permission of the Contracting Officer.

4. ARS reserves the right to close down or shut down the project site and order the Contractor’s employees off the premises in the event of a national emergency or Government shutdown. The Contractor may return to the site only with the written approval of the Contracting Officer.

D. Document Control:

1. The Contractor is responsible for safekeeping of all drawings, project manuals and other project information. This information shall be shared only with those with a specific need to accomplish the project.

2. These documents shall not be removed or transmitted from the project site without the written approval of Contracting Officer.

3. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the ARS.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies and Contractor must be on site to receive all deliveries.

2. Separate permits shall be issued for Contractor and its employees for parking in designated areas only.

1.6 FIRE SAFETY

A. Applicable Publications: Publications listed below form part of this Article to extent referenced.

Publications are referenced in text by basic designations only.

1. American Society for Testing and Materials (ASTM):

E84-2007 ..................................Surface Burning Characteristics of Building Materials

2. National Fire Protection Association (NFPA):

10-2006 ....................................Standard for Portable Fire Extinguishers 30-2003 ....................................Flammable and Combustible Liquids Code 51B-2003 ..................................Standard for Fire Prevention During Welding, Cutting and Other Hot

Work 70-2005 ....................................National Electrical Code 241-2004 ..................................Standard for Safeguarding Construction, Alteration, and Demolition

Operations

3. Occupational Safety and Health Administration (OSHA):

29 CFR 1926 ............................Safety and Health Regulations for Construction

B. Fire Safety Plan: Establish and maintain a fire protection program in accordance with 29 CFR 1926. Prior to start of work, prepare a plan detailing project-specific fire safety measures, including periodic status reports, and submit to the Contracting Officer for review for compliance with contract requirements. Prior to any worker for the contractor or subcontractors beginning work, they shall undergo a safety briefing provided by the contractor’s competent person per OSHA requirements. This briefing shall include information on the construction limits, ARS safety guidelines, means of egress, break areas, work hours, locations of restrooms, use of ARS equipment, etc. Documentation shall be provided to the Contracting Officer that individuals have undergone contractor’s safety briefing.

C. Site and Building Access: Maintain free and unobstructed access to facility emergency services and for fire, police and other emergency response forces in accordance with NFPA 241.

D. Separate temporary facilities, such as trailers, storage sheds, and dumpsters, from existing buildings and new construction by distances in accordance with NFPA 241. For small facilities with less than 20 feet exposing overall length, separate by 10 feet.

E. Temporary Heating and Electrical: Install, use and maintain installations in accordance with 29 CFR 1926, NFPA 241 and NFPA 70.

F. Means of Egress: Do not block exiting for occupied buildings, including paths from exits to roads.

Minimize disruptions and coordinate with Contracting Officer.

G. Egress Routes for Construction Workers: Maintain free and unobstructed egress. Inspect daily. Report findings and corrective actions weekly to the Contracting Officer.

H. Fire Extinguishers: Provide and maintain extinguishers in construction areas and temporary storage areas in accordance with 29 CFR 1926, NFPA 241 and NFPA 10.

I. Flammable and Combustible Liquids: Store, dispense and use liquids in accordance with 29 CFR 1926, NFPA 241 and NFPA 30.

J. Existing Fire Protection: Do not impair automatic sprinklers, smoke and heat detection, and fire alarm systems, except for portions immediately under construction, and temporarily for connections. Provide fire watch for impairments more than 4 hours in a 24-hour period. Request interruptions in accordance with Article, OPERATIONS AND STORAGE AREAS, and coordinate with the Contracting Officer. All existing or temporary fire protection systems (fire alarms, sprinklers) located in construction areas shall be tested as coordinated with the Contracting Officer. Parameters for the testing and results of any tests performed shall be recorded by the General Contractor and copies provided to the Contracting Officer.

K. Smoke Detectors: Prevent accidental operation. Provide and remove temporary covers at end of work operations each day. Coordinate with the Contracting Officer.

L. Hot Work: Perform and safeguard hot work operations in accordance with NFPA 241 and NFPA 51B.

Coordinate with the Contracting Officer. Designate contractor's responsible project-site fire prevention program manager to coordinate permit hot work.

M. Fire Hazard Prevention and Safety Inspections: Inspect entire construction area weekly. Coordinate with, and report findings and corrective actions weekly to the Contracting Officer.

N. Smoking: Smoking is prohibited in and adjacent to construction areas inside existing buildings and additions under construction. In separate and detached buildings under construction, smoking is prohibited except in designated smoking rest areas.

O. Dispose of waste and debris in accordance with NFPA 241. Remove from buildings daily.

P. Perform other construction, alteration and demolition operations in accordance with 29 CFR 1926.

1.7 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. The Contractor shall, under regulations prescribed by the Contracting Officer, use only established roadways, or use temporary roadways constructed by the Contractor when and as authorized by the Contracting Officer. When materials are transported in prosecuting the work, vehicles shall not be loaded beyond the loading capacity recommended by the manufacturer of the vehicle or prescribed by any Federal, State, or local law or regulation. When it is necessary to cross curbs or sidewalks, the Contractor shall protect them from damage. The Contractor shall repair or pay for the repair of any damaged curbs, sidewalks, or roads.

C. Working space and space available for storing materials shall be as determined by the Contracting Officer.

D. Workers are subject to rules of the Location applicable to their conduct which shall be provided by the Contracting Officer.

E. Execute work so as to interfere as little as possible with normal functioning of Location as a whole, including operations of utility services, fire protection systems and any existing equipment, and with work being done by others. Use of equipment and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied during construction except as permitted by the Contracting Officer where required by limited working space.

1. Do not store materials and equipment in other than assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by the ARS in quantities sufficient for not more than two work days.

3. Where access by ARS personnel to vacated portions of buildings is not required, storage of

Contractor's materials and equipment may be permitted subject to fire and safety requirements.

F. Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the ARS operations will not be hindered. Contractor shall permit access to ARS personnel through construction areas which serve as routes of access to such affected areas and equipment. Coordinate alteration work in areas occupied by ARS so that operations will continue during the construction period.

G. Utilities Services: Maintain existing utility services for ARS at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services. Where necessary to cut existing water, steam, gases, sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (including telephone), they shall be cut and capped at suitable places where shown; or, in absence of such indication, where directed by the Contracting Officer.

1. No utility service such as water, gas, steam, sewers or electricity, or fire protection systems and communications systems may be interrupted without prior written approval of the Contracting Officer. Electrical work shall be accomplished with all affected circuits or equipment de-energized.

When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without the Contracting Officer’s prior knowledge and written approval.

2. Contractor shall submit a request to interrupt any such services 48 hours in advance of proposed interruption.

3. Contractor will be advised of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of ARS. Interruption time approved by ARS may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 21 calendar days prior to the desired time and shall be performed as directed by the Contracting Officer. It is the Contractor's responsibility to develop a work plan and schedule detailing, at a minimum, the procedures to be employed, the equipment and materials to be used, the mitigating life safety measures to be used during the work, and a schedule defining the duration of the work with milestone subtasks.

5. In case of a contract construction emergency, service will be interrupted on approval of the Contracting Officer. Such approval will be confirmed in writing as soon as practical.

H. To minimize interference of construction activities with flow of ARS traffic, comply with the following:

1. Keep roads, walks and entrances to grounds, to parking and to occupied areas of buildings clear of construction materials, debris and standing construction equipment and vehicles.

I. Coordinate the work for this contract with other construction operations as directed by Contracting Officer. This includes the scheduling of traffic and the use of roadways, as specified in Article, USE OF

ROADWAYS.

1.8 ALTERATIONS

A. Any items required by drawings to be either reused or relocated or both, found to be nonexistent, or in opinion of Contracting Officer, to be in such condition that their use is impossible or impractical, shall be furnished and/or replaced by Contractor with new items in accordance with specifications which will be furnished by Government. Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under provisions of clause entitled "DIFFERING SITE

CONDITIONS" (FAR 52.236-2).

B. Protection: Provide the following protective measures:

1. Wherever existing roof or exterior wall surfaces are disturbed they shall be protected against water infiltration. In case of leaks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, materials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency.

Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protection shall be maintained intact until all work in the area is completed.

C. Final Cleanup:

1. Upon completion of project, or as work progresses, remove all construction debris.

1.9 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse.

Store such items where directed by Contracting Officer.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from ARS property.

1.10 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS

A. The Contractor shall preserve and protect all structures, equipment, and vegetation (such as trees, shrubs, and grass) on or adjacent to the work site, which is not to be removed and which does not unreasonably interfere with the work required under this contract. The Contractor shall only remove trees or parts thereof when specifically authorized to do so, and shall avoid damaging vegetation that will remain in place. If any limbs or branches of trees are broken during contract performance, or by the careless operation of equipment, or by workers, the Contractor shall trim those limbs or branches with a clean cut and paint the cut with a tree-pruning compound as directed by the Contracting Officer.

B. The Contractor shall protect from damage all existing improvements and utilities at or near the work site and on adjacent property of a third party, the locations of which are made known to or should be known by the Contractor. The Contractor shall repair any damage to those facilities, including those that are the property of a third party, resulting from failure to comply with the requirements of this contract or failure to exercise reasonable care in performing the work. If the Contractor fails or refuses to repair the damage promptly, the Contracting Officer may have the necessary work performed and charge the cost to the Contractor. (FAR 52.236-9)

1.11 RESTORATION

A. Remove, cut, alter, replace, patch and repair existing work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, and do not disturb any ducts, plumbing, steam, gas, or electric work without approval of the Contracting Officer. Existing work to be altered or extended and that is found to be defective in any way, shall be reported to the Contracting Officer before it is disturbed. Materials and workmanship used in restoring work shall conform in type and quality to that of original existing construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work complete and undamaged. Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work, shall be patched, repaired, reinstalled, or replaced with new work, and refinished and left in as good condition as existed before commencing work.

C. At Contractor's own expense, Contractor shall immediately restore to service and repair any damage caused by Contractor's workers to existing readily visible piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications systems (including telephone) and which are not scheduled for discontinuance or abandonment.

D. Expense of repairs to such utilities and systems locations of which are unknown will be covered by adjustment to contract time and price in accordance with clause entitled "CHANGES" (FAR 52.243-4) and "DIFFERING SITE CONDITIONS" (FAR 52.236-2).

1.12 AS-BUILT DRAWINGS

A. The Contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of the project, to include all contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the contract drawings. To insure compliance, as-built drawings shall be made available for the Contracting Officer’s review, as often as requested.

C. Contractor shall deliver two approved completed sets of as-built drawings to the Contracting Officer within 15 calendar days after each completed phase and after the acceptance of the project by the Contracting Officer. D. Paragraphs A, B, & C shall also apply to all shop drawings.

1.13 USE OF ROADWAYS

A. For hauling, use only established public roads and roads on ARS property and, when authorized by the Contracting Officer, such temporary roads which are necessary in the performance of contract work.

Temporary roads shall be constructed by the Contractor at Contractor's expense. When necessary to cross curbing, sidewalks, or similar construction, they must be protected by well-constructed bridges.

1.14 TEMPORARY TOILETS

A. Contractor may have use of location restrooms provided they are kept clean and free from construction debris.

1.15 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the contract. Should existing services be inadequate for the Contractor’s purposes without interfering with ARS operations, the Contractor shall provide and pay for their own services. The amount to be paid by the Contractor for chargeable electrical services shall be the prevailing rates charged to the Government. The Contractor shall carefully conserve any utilities furnished without charge.

1.16 TESTS

A. Conduct final tests required in various sections of specifications in presence of an authorized representative of the Contracting Officer. Contractor shall furnish all labor, materials, equipment, instruments, and forms, to conduct and record such tests.

1.17 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operating manuals, verbal instructions and formal training when required by the various sections of the specifications and as hereinafter specified.

1.18 CONSTRUCTION WASTE MANAGEMENT

A. Responsibilities. The contractor shall employ processes that ensure the generation of as little waste as possible and shall avoid the generation of waste due to the following:

1. Over-packaging.

2. Error.

3. Poor planning, layout.

4. Over ordering.

5. Breakage

6. Mishandling.

7. Contamination.

8. Damage from weather.

B. Procedures.

1. Of the inevitable waste that is generated, as many of the waste materials as economically feasible shall be reused, salvaged or recycled.

2. Waste disposal in landfills shall be minimized to the greatest extent possible.

a. Waste Diversion Goals.

(1) Demolition, Major Remodeling: Minimum 10% of total project waste shall be diverted from landfill.

(2) Interior Remodeling: Minimum 10% of total project waste shall be diverted from landfill.

b. The following waste categories, at a minimum, shall be diverted from landfill:

(1) Green waste (biodegradable landscaping materials).

(a) Soil.

(b) Inert material (concrete, asphalt, masonry).

(c) Clean dimensional wood, palette wood.

(d) Engineered wood products: plywood, particle board, I-joists, etc.

(e) Cardboard, paper, packaging.

(f) Asphalt roofing materials.

(g) Insulation.

(h) Gypsum board.

(i) Carpet and pad.

(j) Paint.

(k) Plastics: ABS, PVC.

(l) Beverage containers.

C. Description of Work.

1. Includes:

a. Waste Management Plan development and implementation.

b. Meetings to discuss goals, issues and training for the Waste Management Plan.

c. Techniques to minimize waste generation.

d. Sorting and separation of waste materials.

e. Reuse of salvaged materials on site.

f. Salvage of existing materials and items for reuse or resale.

g. Recycling of materials that cannot be reused or sold.

h. Record keeping of receipts and records of salvaged, recycled or land filled materials.

2. Related Elements:

a. Alternates.

b. Construction Waste Management.

c. Chain Link Fences and Gates.

d. Walk, Road and Parking Appurtenances.

e. Miscellaneous Landscaping Materials.

f. Concrete, Concrete Formwork, and Concrete Reinforcement.

g. Cast-in-Place Concrete.

h. Unit Masonry.

i. Structural Steel.

j. Cold Formed Metal Framing.

k. Metal Fabrications.

l. Rough and Finish Carpentry.

m. Modified Bitumen Roofing.

n. Metal Support Systems.

D. Definitions.

1. Class III Landfill: A landfill that accepts non-hazardous resources such as household, commercial and industrial waste resulting from construction, remodeling, repair and demolition operations.

2. Clean: Untreated and unpainted; uncontaminated with adhesives, oils, solvents, mastics and like products.

3. Construction and Demolition Waste: Includes all non-hazardous resources resulting from construction, remodeling, alterations, repair and demolition operations.

4. Dismantle: The process of parting out a building in such a way as to preserve the usefulness of its materials and components.

5. Disposal: Acceptance of solid wastes at a legally operating facility for the purpose of land filling (includes Class III landfills and inert fills).

6. Inert Backfill Site: A location, other than inert fill or other disposal facility, to which inert materials are taken for the purpose of filling an excavation, shoring or other soil engineering operation.

7. Inert Fill: A facility that can legally accept inert waste, such as asphalt and concrete exclusively for the purpose of disposal.

8. Inert Solids/Inert Waste: Non-liquid solid resources including, but not limited to, soil and concrete that does not contain hazardous waste or soluble pollutants at concentrations in excess of water-quality objectives established by a regional water board, and does not contain significant quantities of decomposable solid resources.

9. Mixed Debris: Loads that include commingled recyclable and non-recyclable materials generated at the construction site.

10. Mixed Debris Recycling Facility: A solid resource processing facility that accepts loads of mixed construction and demolition debris for the purpose of recovering re-usable and recyclable materials and disposing non-recyclable materials.

11. Permitted Waste Hauler: A company that holds a valid permit to collect and transport solid wastes from individuals or businesses for the purpose of recycling or disposal.

12. Recycling: The process of sorting, cleansing, treating, and reconstituting materials for the purpose of using the altered form in the manufacture of a new product. Recycling does not include burning, incinerating or thermally destroying solid waste.

a. On-site Recycling. Materials that are sorted and processed on site for use in an altered state in the work, i.e. concrete crushed for use as a sub-base in paving.

b. Off-site Recycling. Materials hauled to a location and used in an altered form in the manufacture of new products.

13. Recycling Facility: An operation that can legally accept materials for the purpose of processing the materials into an altered form for the manufacture of new products. Depending on the types of materials accepted and operating procedures, a recycling facility may or may not be required to have a solid waste facilities permit or be regulated by the local enforcement agency.

14. Re-Use: Materials that are recovered for use in the same form, on-site or off-site.

15. Return: To give back reusable items or unused products to vendors for credit.

16. Salvage: To remove waste materials from the site for resale or re-use by a third party.

17. Source-Separated Materials: Materials that are sorted by type at the site for the purpose of reuse and recycling.

18. Solid Waste: Materials that have been designated as non-recyclable and are discarded for the purposes of disposal.

19. Transfer Station: A facility that can legally accept solid waste for the purpose of temporarily storing the materials for re-loading onto other trucks and transporting them to a landfill for disposal, or recovering some materials for re-use or recycling.

E. References.

1. Guides. No preference is given to the recycles listed below; they are listed for the convenience of the contractor.

2. Dirt/clean fill.

3. Green/landscaping waste.

4. Concrete, asphaltic concrete.

5. Cardboard, paper, packaging.

6. Clean dimensional wood, palette wood.

7. Usable palettes.

8. Metals from banding, ductwork, piping, rebar, roofing, other trim, steel, iron, galvanized sheet steel, stainless steel, aluminum, copper, zinc, lead, brass, and bronze.

F. Submittals.

1. Waste Management Plan. Prior to any waste removal, the Contractor shall submit their Waste Management Plan to the ARS. The Plan shall contain the following:

a. Analysis of the estimated job site waste to be generated, including types and quantities.

b. Proposed alternatives to land filling. Contractor shall prepare a list of each material proposed to be salvaged, re-used, or recycled during the course of the project.

c. Methods handling of materials to be recycled.

d. On Site:

(1) Materials separation

(2) Materials storage

(3) Materials protection, where applicable

e. Off site:

(1) Provide name of mixed debris recycling facility; include list of materials to be recycled.

f. Procedures. A description of the means to be employed in recycling the above materials consistent with requirements for acceptance by designated facilities.

g. Landfill Options. The name of the landfill(s) where trash will be disposed of.

h. Meetings. Contractor shall conduct Construction Waste Management meetings. Meetings shall include the Subcontractor, the Project Manager and representatives as designated by the Contracting Officer. At a minimum, waste management goals and issues shall be discussed at prebid meetings, pre-construction meetings and regular job-site meetings.

i. Transportation. A description of the means of transportation of the recyclable materials (whether materials will be site-separated and self-hauled to designated facilities, or whether mixed materials will be collected by a waste hauler and removed from the site) and destination of materials.

j. Waste Management Plan Implementation.

(1) Manager. The contractor shall designate an on-site party (or parties) responsible for instructing workers and subcontractors and overseeing and documenting results of the Waste Management Plan for the project.

(2) Distribution. The contractor shall distribute copies of the Waste Management Plan to the Contracting Officer and Location Manager.

(3) Instruction. The contractor shall provide on-site instruction of appropriate separation, handling, recycling, salvage, reuse and return methods to be used by all parties at appropriate stages of the project.

(4) Separation Facilities. The contractor shall lay out and label a specific area to facilitate separation of materials for reuse, salvage, recycling, and return. Recycling and waste bin areas are to be kept neat and clean and clearly marked in order to avoid contamination or mixing of materials.

(5) Hazardous Wastes. Hazardous wastes shall be separated, stored, and disposed of according to local, state and federal regulations.

2. Reports.

a. The Contractor shall submit (monthly, quarterly, at end of job) a Waste Management Progress Report. The report shall contain the amount (in tons or cubic yards) of material land filled from the project, the identity of the landfill, the total amount of tipping fees paid at the landfill and the total disposal cost. Include legible copies of manifests, weight tickets, receipts and invoices.

Manifests shall be from recycle and/or disposal site operators that can legally accept the materials for the purpose of reuse, recycling or disposal.

b. For each material recycled, reused or salvaged from the project, provide the following:

(1) Amount (in tons or cubic yards).

(2) Date removed from the job site.

(3) Receiving party.

(4) Transportation cost.

(5) Amount of any money paid or received for the recycled or salvaged material. Net total cost or savings of salvage or recycling each material. Attach manifests, weight tickets, receipts, and/or invoices. Indicate the project information, including project title, name of company completing form, and beginning and ending dates of period covered by summary form.

HOT WORK PERMIT

NEEDED WHEN ANY SPARK OR HEAT PRODUCING EQUIPMENT IS TO BE USED

Project Name:

Name of Contractor’s Firm:

Contractor Contact Name:

Contractor Contact Telephone Number Date:

Building/Location:

Work To Be Done:

Any Special Precautions:

Fire Watch Required: Yes No The location where the work is to be performed has been examined, necessary precautions have been taken, and permission is granted for this work.

Signed

(Contractor Individual Responsible for Authorizing Hot Work) Permit Expires: (Date)

Time Hot Work Started: Time Hot Work Completed:

FINAL CHECK-UP

Work area and all adjacent areas to which sparks and heat might have spread (including floors above and below and on opposite sides of walls) were inspected 30 minutes after the work was completed and were found fire safe.

Signed___________________ Date __________________ (Contractor’s Fire Watch)

(Page 1 of 2)

ATTENTION

Before approving any cutting and welding permit, the contractor’s authorized representative or their appointee shall inspect the work area and confirm that precautions have been taken to prevent fire in accordance with NFPA Standard No. 51B.

PRECAUTIONS

• Sprinklers are in service where installed

• Cutting and welding equipment in good repair

• Within 35 feet; floors swept clean of combustible, no combustible material or flammable liquids, all wall and floor openings covered, and covers suspended beneath work to collect sparks

• When working on enclosed equipment and in confined space, equipment and area is free of flammable vapors

• Fire watch provided during and 30 minutes after operation (60 minutes for torch applied roofing operations)

• Portable fire extinguisher with adequate rating available in the immediate vicinity

• Standpipe system in service where installed

• Protection of any sprinkler heads when hot work is in close proximity

• Smoking prohibited in immediate vicinity

• Non-combustible shields provided when hot work is done near combustible walls, partitions, floors, roofs

• Prohibition of hot work on pipes contacting combustible walls

• Personnel trained in use of equipment including portable fire extinguishers and sounding a fire alarm

• Final check-up conducted after 30 minute

(Page 2 of 2)

DAILY INSPECTION FORM

INSTRUCTIONS: This form is to be utilized when hazards are posed by NFPA 101 deficiencies or construction activities are in progress. Remediation must be implemented upon project start and continuously enforced through project completion to provide a level of life safety comparable to that described in the Life Safety Code.

Submit completed forms to the Contracting Officer.

Project Name: Project Number:

Construction & Impact Description: Construction Location:

Affected Areas:

Project COR: Project Start Date:

Project Competent Person (CP): Estimated Duration:

Completion Date:

Contractor:

GC Supervisor: Telephone:

Contractor CP:

Inspection Period: Responses:

SUN MON TUE WED THR FRI SAT

1. Are exits readily accessible and provide unobstructed egress?

2. Have alternate exits been established if required due to inaccessibility of existing exits?

3. If alternate exits have been established, are personnel in the area informed and aware of their relocation?

4. Are the existing and relocated exits clearly marked and able to be seen in the event of a fire or emergency?

5. Are evacuation routes posted with follow-up inspections required by construction impact changes in escape routes?

6. Are written procedures and guidelines posted in the immediate and adjacent areas for what to do and who to call in the event of a fire or emergency?

7. Are personnel in immediate/adjacent areas aware and informed in procedures and guidelines to follow in the event of fire or emergency?

8. Is there free and unobstructed access to services for emergency personnel (eg, fire, medical, security)?

9. Are fire alarm (eg, pull station), detection (eg, smoke/heat),suppression (eg, sprinkler, extinguisher) systems in working order, protected and unobstructed with locations identified?

10. If the fire alarm, detection, suppression systems are impaired or temporarily non-functional, has a fire watch for the area, as required or necessary, been trained and established?

11. If the fire alarm, detection, suppression systems are impaired, have measures been taken to provide temporary equivalent equipment and/or systems for adequate protection? Note date for equivalent measures.

12. If the fire alarm, detection, suppression systems are impaired, are equivalent equipment/systems inspected and tested at least monthly?

13. If temporary fire alarm, detection, suppression systems are installed, are personnel in the area aware and trained on how to operate or utilize them in the event of fire or emergency?

14. Has the “No Smoking” policy been posted, implemented and enforced in the construction area?

15. Are temporary partitions built to be fire/smoke tight with fire retardant noncombustible material and inspected daily for integrity?

16. Is construction site access restricted to authorized personnel only including warning signs and secured at the end of each day?

17. Is construction area hazard surveillance conducted daily?

18. Is construction area storage, waste, debris and excess materials being daily managed properly to reduce fire or safety hazards?

19. Are construction activities and materials prosecuted, handled, stored, and secured in an orderly and safe manner?

20. Is the generation, spread and exposure of construction dust, fumes, noise, odor, smoke controlled with appropriate fume, odor, vapor ventilation provided to control noxious, infectious, toxic exposure and store/protect flammable/combustible products?

21. Has a GC Safety Manager been designated with routine site safety meetings conducted to ensure awareness of Life Safety Code?

22. Is personnel protective equipment (e.g., safety glasses, ear plugs, hard hats) required and being used?

23. If there are hand/safety rails, scaffolding or ladders required, are they in place, in good condition and being used in a safe manner?

24. Are the construction site (buildings and exterior grounds) hazards (e.g., fall/trip) guarded and free of potential safety violations?

25. Do electrical panels, temporary wiring, extension cords (3 wire grounded type), tools, and equipment appear to be installed, utilized, and functioning in a safe manner?

26. If there are temporary electrical outlets provided, do they have ground fault protection at the receptacle/panel?

27. If hazardous equipment/systems need to be de-energized, are applicable “Lockout/Tagout” procedures being followed?

28. Are utility services (e.g., electrical, steam, water, waste, gas) properly secured at the end of each day?

29. If there is any hot work (welding, soldering, cutting) being performed within the construction site, have additional fire safety precautions been taken and necessary equipment provided?

30. If there is any hot work (welding, soldering, cutting) being performed on the construction site, has Contracting Officer been notified? Has the Hot Work Permit been approved?

31. If hazardous products are present, are they limited to the amount needed and used daily?

32. Are hazardous products disposed according to EPA requirements?

33. Are all hazardous products present or being used (e.g., flammable, combustible, corrosive, noxious) labeled with MSDS information readily available?

34. If infection control is required, are the appropriate policies and procedures known and being followed?

35. Are all safety incidents documented and reported to the Contracting Officer?

Contractor CP Initials Performing Daily Inspections:

Inspection Comments/Findings: (PROVIDE DETAILED EXPLANATION OF EXCEPTIONS/DEFICIENCIES)

Signature/Date:

Project CP GC Safety Manager

END OF SECTION 01 01 00

Page intentionally left blank