Silver_Sands_State_Park_Contract.docx

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

of Pages

1. REQUEST NO.

AG-1106-S-14-0001

2. DATE ISSUED

12/09/2013

5a. ISSUED BY: USDA-NATURAL RESOURCES CONSERVATION SERVICE 344 Merrow Road, Suite A, Tolland, Connecticut 06084-3917

6. DELIVER BY (Date)

5b. FOR INFORMATION CALL (NO COLLECT CALLS)

7. DELIVERY

[ ] FOB DESTINATION [ ] OTHER (see schedule)

NAME

Alan Leta Contracting Officer

TELEPHONE NUMBER

10. PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS (Date)

January 9, 2014 @ 1:30 p.m.

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local Taxes)

New Haven COUNTY EWP Work consists of furnishing all labor, equipment and materials for Debris Removal in Nettleton Creek, Silver Sands State Park, Milford, Connecticut. All work shall be done in accordance with the attached clauses, specifications and drawings and shall be completed within 60 calendar days.

To submit a quote, complete and return this form, Bid Schedule, and Section K, and forward to the address shown in block 5a by 1:30 p.m. on January 9, 2014.

A site showing for prospective bidders has been scheduled for 12/09/2013 @ 10:00 a.m. Participants will meet. Set GPS for 195 Viscount Drive, Milford, CT. Follow Viscount Dr toward Long Island Sound until you reach the boardwalk. Turn left on the access road that follows the boardwalk and ends at Nettleton Creek where the project is located. Nettleton Creek is on the far western edge of the park very near the property line with the town park immediately adjacent to Silver Sands State Park., Connecticut.

Price Range: Between $100,000 and $250,000

See Sec. B - Bid Schedule

b. 20 CALENDAR DAYS

c. 30 CALENDAR DAYS

d. CALENDAR DAYS

NUMBER

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

SECTION C - DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

SECTION D - PACKAGING AND MARKING

SECTION E - INSPECTION AND ACCEPTANCE

SECTION F - DELIVERIES OR PERFORMANCE

SECTION

H - SPECIAL CONTRACT REQUIREMENTS

PART II -

CONTRACT CLAUSES

I - CONTRACT CLAUSES

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS. . . 27

J - LIST OF ATTACHMENTS

PART IV -

REPRESENTATIONS AND INSTRUCTIONS

K - REPRESENTATIONS, CERTIFICATIONS, AND.

OTHER STATEMENTS OF OFFERORS

SECTION L - INSTRUCTIONS, CONDITIONS, AND

NOTICES TO OFFERORS

SECTION M - EVALUATION FACTORS FOR AWARD

AG-1106-S-14-0001

PART I - THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

---------------------------------------------------------------------- BID SCHEDULE New Haven COUNTY EWP PROJECT, Silver Sands State Park Milford, Connecticut Item No.

Material

Unit

Unit Price

Amount

Total =

AWARD RESTRICTION (AUG 1987 SCS, AMB)

One award for the aggregate of all Items will be made under this solicitation.

SECTION C - DESCRIPTION/SPECIFICATIONS/WORK STATEMENT C.1 AGAR 452.211-72 STATEMENT OF WORK/SPECIFICATIONS (FEB 1988) The Contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified), to perform the Statement of Work/Specifications referenced in Section J.

C.2 AGAR 452.211-73 ATTACHMENTS TO STATEMENT OF WORK/SPECIFICATIONS (FEB 1988)

The attachments to the Statement of Work/Specifications listed in Section J are hereby made part of this solicitation and any resultant contract.

SECTION D - PACKAGING AND MARKING

THERE ARE NO CLAUSES INCLUDED IN THIS SECTION

SECTION E - INSPECTION AND ACCEPTANCE

E.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://www.arnet.gov/far/

SECTION F - DELIVERIES OR PERFORMANCE

F.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://www.arnet.gov/far/

contract within 3 calendar days after the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 60 calendar days after receipt of notice to proceed. The time stated for completion shall include final cleanup of the premises.

F.3 ACTUAL DAMAGES--CONSTRUCTION

(a) If the Contractor fails to complete the work within the time specified in the contract, or any extension, the Contractor shall pay to the Government as actual damages, the total expenses for the COR and Inspector. These expenses shall include but is not limited to the salary and travel costs associated with this project.

(b) If the Government terminates the Contractor's right to proceed, the resulting damage will consist of actual damages until such reasonable time as may be required for final completion of the work together with any increased costs occasioned the Government in completing the work.

(c) If the Government does not terminate the Contractor's right to proceed, the resulting damage will consist of actual damages until the work is completed or accepted.

SECTION G - CONTRACT ADMINISTRATION DATA

G.1 SCSAR 4I-52.232-70 DESIGNATED PAYMENT OFFICE CONTACT POINT (SCS, AMB, AUG 1989)

The contact point described below coordinates the issuance of payments under this contract. If payment is not received within 7 days after the due date specified in the contract, contact the payment office designated below for information on when payment will be made.

Budget Officer Sue Merrell USDA-Natural Resources Conservation Service 344 Merrow Road, Suite A Tolland, Connecticut

(860) 871-4062

If questions arise on the amount paid, contact the Contracting Officer at the number or address shown in the contract.

SECTION H - SPECIAL CONTRACT REQUIREMENTS

H.1 AGAR 452.236-73 ARCHEOLOGICAL OR HISTORIC SITES (FEB 1988)

If a previously unidentified archeological or historic site(s) is encountered, the Contractor shall discontinue work in the general area of the site(s) and notify the Contracting Officer immediately.

H.2 AGAR 452.236-74 CONTROL OF EROSION, SEDIMENTATION, AND POLLUTION (NOV 1996)

(a) Operations shall be scheduled and conducted to minimize erosion of soils and to prevent silting and muddying of streams, rivers, irrigation systems, and impoundments (lakes, reservoirs, etc.).

(b) Pollutants such as fuels, lubricants, bitumens, raw sewage, and other harmful materials shall not be discharged on the ground; into or nearby rivers, streams, or impoundments; or into natural or man-made channels. Wash water or waste from concrete or aggregate operations shall not be allowed to enter live streams prior to treatment by filtration, settling, or other means sufficient to reduce the sediment content to not more than that of the stream into which it is discharged.

(c) Mechanized equipment shall not be operated in flowing streams without written approval by the Contracting Officer.

H.3 AGAR 452.236-75 MAXIMUM WORKWEEK - CONSTRUCTION SCHEDULE (NOV 1996) Within 10 calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following in writing for approval:

(a) A schedule as required by FAR clause 52.236-15, "Schedules for Construction Contracts" and

(b) The hours (including the daily starting and stopping times) and days of the week the Contractor proposes to carry out the work.

The maximum workweek that will be approved is ten (10) hours per day, Monday through Saturday.

H.4 AGAR 452.236-76 SAMPLES AND CERTIFICATES (FEB 1988)

When required by the specifications or the Contracting Officer, samples, certificates, and test data shall be submitted after award of the contract, prepaid, in time for proper action by the Contracting Officer or his/her designated representative. Certificates and test data shall be submitted in triplicate to show compliance of materials and construction specified in the contract

H.5 52.236-13 ACCIDENT PREVENTION (ALTERNATE 1)(NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will—

(1) safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) avoid interruptions of Government operations and delays in project completion dates; and

(3) control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall--

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR part 1926 and 29 CFR part 1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the Contractor orally, with written confirmation, and request immediate initiation of corrective action. This notice, when delivered to the Contractor or the Contractor's representative at the work site, shall be deemed sufficient notice of the noncompliance and that corrective action is required. After receiving the notice, the Contractor shall immediately take corrective action. If the Contractor fails or refuses to promptly take corrective action, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop work order issued under this clause.

(e) The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

(f) Before commencing the work, the Contractor shall--

(1) Submit a written proposed plan for implementing this clause.

The plan shall include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards; and

(2) Meet with representatives of the Contracting Officer to discuss and develop a mutual understanding relative to administration of the overall safety program.

(g) As provided for in (b)(3) above, the contractor shall also comply with the NRCS Supplement to OSHA Parts 1910 and 1926, which is made a part of this contract.

H.6 NATURAL RESOURCES CONSERVATION SERVICE SUPPLEMENT TO OSHA PARTS 1910 AND 1926

CONSTRUCTION INDUSTRY STANDARDS AND INTERPRETATIONS

The contractor shall comply with OSHA (Occupational Safety and Health Administration) Parts 1910 and 1926, Construction Industry Standards and Interpretations, and with this supplement.

Requests for variances or waiver from this supplement are to be made to the contracting officer in writing supported by evidence that every reasonable effort has been made to comply with the contractual requirements. A written request for a waiver or a variance shall include-

(1) Specific reference to the provision or standard in question;

(2) An explanation as to why the waiver is considered justified; and

(3) The contractor's proposed alternative, including technical drawings, materials, or equipment specifications needed to enable the contracting officer to render a decision.

No waiver or variance will be approved if it endangers any person. The contractor shall not proceed under any requested revision of provision until the contracting officer has given written approval. The contractor is to hold and save harmless the Natural Resources Conservation Service free from any claims or causes of action whatsoever resulting from the contractor or subcontractors proceeding under a waiver or approved variance.

Copies of OSHA Parts 1910 and 1926, Construction Industry Standards and Interpretations, may be obtained from:

Superintendent of Documents U.S. Government Printing Office Washington, D.C. 20402

NATURAL RESOURCES CONSERVATION SERVICE SUPPLEMENT TO OSHA PARTS 1910 AND 1926

CONSTRUCTION INDUSTRY STANDARDS AND INTERPRETATIONS

GENERAL CONTRACTOR REQUIREMENTS:

1.1 SAFETY PROGRAM. Each contractor is to demonstrate that he or she has facilities for conducting a safety program commensurate with the work under contract. The contractor is to submit in writing a proposed comprehensive safety program to the contracting officer for approval before the start of construction operations. The program is to specifically state what provisions the contractor proposes to take for the health and safety of all employees, including subcontractors and rental equipment operators. The program shall be site specific and provide details relevant to the work to be done, the hazards associated with the work, and the actions that will be necessary to minimize the identified hazards.

1.2 PRECONSTRUCTION SAFETY MEETING. Representatives for the contractor are to meet with the contracting officer (CO) or the CO's representative before the start of construction to discuss the safety program and the implementation of all health and safety standards pertinent to the work under this contract.

1.3 JOINT SAFETY POLICY COMMITTEE. The contractor or designated on-site representative is to participate in monthly meetings of a joint Safety Policy Committee, composed of the Natural Resources Conservation Service (Contracting Local Organization in locally awarded contracts) and contractor supervisory personnel. At these meetings the contractor's project manager and the contracting officer will review the effectiveness of the contractor's safety effort, resolve current health and safety problems, and coordinate safety activities for upcoming work.

1.4 SAFETY PERSONNEL. Each contractor is to designate a competent supervisory employee satisfactory to the contracting officer to administer the safety program.

1.5 SAFETY MEETINGS. A minimum of one "on-the-job" or "toolbox" safety meeting is to be conducted each week by all field supervisors or foremen and attended by mechanics and all construction personnel at the jobsite. The contractor is to also conduct regularly scheduled supervisory safety meetings at least monthly for all levels of job supervision.

1.6 SAFETY INSPECTION. The contractor shall perform frequent and regular safety inspections of the jobsite, materials, and equipment, and shall correct deficiencies.

1.7 FIRST AID TRAINING. Every contractor foreman's work crew must include an employee who has a current first aid certificate from the Mine Safety and Health Administration, American Red Cross, or other state-approved organization.

1.9 CERTIFICATION OF INSURANCE. Contractors are to provide the contracting officer or his or her authorized representative with certificates of insurance before the start of operations indicating full compliance with State Worker's Compensation statutes, as well as other certificates of insurance required under the contract.

FIRST AID AND MEDICAL FACILITIES:

2.3 COMMUNICATION AND TRANSPORTATION. Prior to the start of work, the contractor is to make necessary arrangements for prompt and dependable communications, transportation, and medical care for injured employees. At least one stretcher and two blankets shall be readily available for transporting injured employees.

2.4 FIRST AID AND MEDICAL REPORTS. The contractor is to maintain a record system for first aid and medical treatment on the jobsite. Such records are to be readily available to the contracting officer and are to include--

(a) A daily treatment log listing chronologically all persons treated for occupational injuries and illnesses;

(b) Cumulative record of injury for each individual;

(c) Monthly statistical records of occupational injuries, classified by type and nature of injury; and

(d) Required records for worker's compensation.

2.5 SIGNS AND DIRECTIONAL MARKINGS. Adequate identification and directional markers are to be provided to readily denote the location of all first aid stations.

2.6 EMERGENCY LISTING. A listing of telephone numbers and addresses of doctor, rescue squad, hospital, police, and fire departments is to be provided at all first aid locations.

PHYSICAL QUALIFICATIONS OF EMPLOYEES:

3.1 GENERAL REQUIREMENTS. Persons employed throughout the contract are to be physically qualified to perform their assigned duties. Employees must not knowingly be permitted or required to work while their ability or alertness is impaired by fatigue, illness, or any other reason that may jeopardize themselves or others.

3.2 HOIST OPERATORS. Operators of cranes, cableways, and other hoisting equipment shall be examined annually by a physician and provided with a certification stating that they are physically qualified to safely operate hoisting equipment. The contractor is to submit a copy of each certification to the contracting officer.

3.3 HEAVY EQUIPMENT OPERATORS. It is recommended that operators of trucks and heavy construction equipment be given physical examinations to determine if they are physically qualified to perform their assigned work without endangering themselves or others.

3.4 MOTOR VEHICLE OPERATORS. Operators of motor vehicles engaged primarily in the transportation of personnel are to be 18 years of age or older and have a valid state operator's permit or license for the equipment being operated. The operators must have passed a physical examination administered by a licensed physician within the past year showing that they are physically qualified to operate vehicles safely.

PERSONAL PROTECTIVE EQUIPMENT:

4.1 HARDHAT AREAS. The entire jobsite, with the exception of offices, shall be considered a hardhat area. All persons entering the area are, without exception, required to wear hardhats. The contractor shall provide hardhats for visitors entering hardhat areas.

4.1.1 LABELS. Hardhats shall bear a manufacturer's label indicating design compliance with the appropriate ANSI (American National Standards Institute) standard.

4.2 POSTING. Signs at least 3 by 4 feet worded as follows with red letters (minimum 6 inches high) and white background shall be erected at access points to designated hardhat areas:

CONSTRUCTION AREA - HARDHATS REQUIRED BEYOND THIS POINT

These signs are to be furnished and installed by the contractor at entries to shops, construction yards, and job access points.

4.3 SAFETY GOGGLES (DRILLERS)

4.3.1 DRILLERS AND HELPERS. Drillers and helpers operating pneumatic rock drills must wear protective safety goggles.

MACHINERY AND MECHANIZED EQUIPMENT:

5.1 SAFE CONDITION. Before any machinery or mechanized equipment is initially used on the job, it must be inspected and tested by qualified personnel and determined to be in safe operating condition and appropriate for the intended use. Operators shall inspect their equipment prior to the beginning of each shift. Any deficiencies or defects shall be corrected prior to using the equipment. Safety equipment, such as seatbelts, installed on machinery is to be used by equipment operators.

5.2 TAGGING AND LOCKING. The controls of power-driven equipment under repair are to be locked. An effective lockout and tagging procedure is to be established, prescribing specific responsibilities and safety procedures to be followed by the person or persons performing repair work. Mixer barrels are to be securely locked out before permitting employees to enter them for cleaning or repair.

5.3 HAUL ROADS FOR EQUIPMENT

5.3.1 ROAD MAINTENANCE. The contractor shall maintain all roadways, including haul roads and access roads, in a safe condition so as to eliminate or control dust and ice hazards. Wherever dust is a hazard, adequate dust-laying equipment shall be available at the jobsite and utilized to control the dust.

5.3.2 SINGLE-LANE HAUL ROADS. Single-lane haul roads with two-way traffic shall have adequate turnouts. Where turnouts are not practical, a traffic control system shall be provided to prevent accidents.

5.3.3 TWO-WAY HAUL ROADS. On two-way haul roads, arrangements are to be such that vehicles travel on the right side wherever possible. Signs and traffic control devices are to be employed to indicate clearly any variations from a right-hand traffic pattern. The road shall be wide enough to permit safe passage of opposing traffic, considering the type of hauling equipment used.

5.3.4 DESIGN AND CONSTRUCTION OF HAUL ROADS. Haul road design criteria and drawings, if requested by the contracting officer, are to be submitted for approval prior to road construction. Sustained grades shall not exceed 12 percent and all curves shall have open-sight line with as great a radius as practical. All roads shall be posted with curve signs and maximum speed limits that will permit the equipment to be stopped within one-half the minimum sight distance.

5.3.5 OPERATORS. Machinery and mechanized equipment shall be operated only by authorized qualified persons.

5.3.6 RIDING ON EQUIPMENT. Riding on equipment by unauthorized personnel is prohibited. Seating and safety belts shall be provided for the operator and all passengers.

5.3.7 GETTING ON OR OFF EQUIPMENT. Getting on or off equipment while the equipment is in motion is prohibited.

5.3.8 HOURS OF OPERATION. Except in emergencies, an equipment operator shall not operate any mobile or hoisting equipment for more than 12 hours without an 8-hour rest interval away from the job.

5.4 POWER CRANES AND HOISTS (TRUCK CRANES, CRAWLER CRANES, TOWER CRANES, GANTRY CRANES, HAMMERHEAD CRANES, DERRICKS, CABLEWAYS, AND HOISTS)

5.4.1 PERFORMANCE TEST. Before initial on-site operation, at 12-month intervals, and after major repairs or modification, power cranes, derricks, cableways, and hoists must satisfactorily complete a performance test to demonstrate the equipment's ability to safely handle and maneuver the rated loads. The tests shall be conducted in the presence of a representative of the contracting officer. Test data shall be recorded and a copy furnished the contracting officer.

5.4.2 PERFORMANCE TEST--POWER CRANES (CRAWLER MOUNTED, TRUCK MOUNTED, AND WHEEL MOUNTED). The performance test is to be carried out with outriggers set and with a test load weighing 110 percent of the rated capacity when the boom angle is from 30° to 60° above the horizontal. The test is to consist of raising, lowering and braking the load and rotating the test load through 360° at the specified boom angle or radius. Cranes equipped with jibs or boom tip extensions are to be tested using both the main boom and the jib, with an appropriate test load in each case.

5.4.3 PERFORMANCE TEST--DERRICKS, GANTRY CRANES, TOWER CRANES, CABLEWAYS, AND HOISTS, INCLUDING OVERHEAD CRANES. This equipment is to be performance tested with a test load weighing 110 percent of the rated load. In testing cableways, the test load is to be traveled to the upstream and downstream limits of travel and thoroughly performance tested in at least three travel positions, including both limits of travel.

5.4.4 BOOM ANGLE INDICATOR. Power cranes (including draglines) with booms capable of moving in the vertical plane shall be provided with a boom angle indicator in good working order.

5.4.5 CRANE TEST CERTIFICATION. The performance test required by 5.4.2 and 5.4.3 is fulfilled if the contractor provides the contracting officer a copy of the certificate of inspection made within the past 12 months by a qualified person or by a government or private agency satisfactory to the contracting officer.

5.4.6 POSTING FOR HIGH VOLTAGE LINES. A notice of the 10-foot (or greater) clearance required by OSHA 1926.550, Subpart N, shall be posted in the operator's cab of cranes, shovels, boom-type concrete pumps, backhoes, and related equipment.

5.4.7 BOOM STOPS. Cranes or derricks with cable-supported booms, except draglines, shall have a device attached between the gantry of the A-frame and the boom chords to limit the elevation of the boom. The device shall control the vertical motions of the boom with increasing resistance from 83° or less, until completely stopping the boom at not over 87° above horizontal.

5.4.8 SAFETY HOOKS. Hooks used in hoisting personnel or hoisting loads over construction personnel or in the immediate vicinity of construction personnel shall be forged steel equipped with safety keepers. When shackles are used under these conditions, they shall be of the locking type or have the pin secured to prohibit turning.

5.5 ROLLOVER PROTECTIVE STRUCTURES (ROPS)

5.5.1 ROLLOVER PROTECTIVE STRUCTURES. OSHA 1926, Subpart W, Overhead Protection, Sections 1001 and 1002 are applicable regardless of the year in which the equipment was manufactured and regardless of the struck capacity of the equipment.

5.5.2 EQUIPMENT REQUIRING ROPS. The requirement for ROPS meeting 5.5.1 above applies to crawler and rubber-tired tractors such as dozers, push-and-pull tractors, winch tractors, tractors with backhoes, and mowers; off-highway, self-propelled, pneumatic-tired earthmovers, including scrapers, motor graders and loaders; and rollers, compactors, water tankers (excluding trucks with cabs). These requirements shall also apply to agricultural and industrial tractors and similar equipment.

5.5.3 EQUIPMENT REQUIRING SEATBELTS. The requirements for seatbelts as specified in OSHA Subpart 0, Motor Vehicles, Mechanized Equipment, and Marine Operations, Section 1926.602 shall also apply to self-propelled compactors and rollers, and rubber-tired skid-steer equipment.

LADDERS AND SCAFFOLDING:

6.1 LADDERS. OSHA 1926, Subpart L - Section 450. Ladders shall be used as work platforms only when use of small hand tools or handling of light material is involved. No work requiring lifting of heavy materials or substantial exertion shall be done from ladders.

6.2 SCAFFOLDING. OSHA 1926, Subpart L - Section 451. Scaffolds, platforms or temporary floors shall be provided for all work except that which can be done safely from the ground or similar footing.

6.3 SAFETY BELTS, LIFELINE, AND LANYARDS. OSHA 1926, Subpart E, Section 104. Lifelines, safety belts and lanyards independently attached or attended, shall be used when performing such work as the following when the requirements of 6.1 or 6.2 above cannot be met.

(a) Work on stored material in hoppers, bins, silos, tanks, or other confined spaces.

(b) Work on hazardous slopes, structural steel, or poles; erection or dismantling of safety nets, tying reinforcing bars; and work from Boatswain's chairs, swinging scaffolds, or other unguarded locations at elevations greater than 6 feet.

(c) Work on skips and platforms used in shafts by crews when the skip or cage does not block the opening to within 1 foot of the sides of the shaft, unless cages are provided.

PART II - CONTRACT CLAUSES SECTION I - CONTRACT CLAUSES

I.1 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://www.arnet.gov/far/

I. FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES NUMBER TITLE DATE

52.204-10

52.204-13 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS CENTRAL CONTRACTOR REGISTRATION

AUG

DEC

MAINTENANCE

52.209-6

PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

DEC

CONTRACTORS DEBARRED, SUSPENDED,

OR PROPOSED FOR DEBARMENT

52.209-10

PROHIBITION ON CONTRACTING WITH

MAY

INVERTED DOMESTIC CORPORATIONS

52.219-6

NOTICE OF TOTAL SMALL BUSINESS

NOV

SET-ASIDE

52.222-1

NOTICE TO THE GOVERNMENT

FEB

OF LABOR DISPUTES

52.222-3

CONVICT LABOR

JUN

52.222-6

DAVIS-BACON ACT

JUL

52.222-7

WITHHOLDING OF FUNDS

FEB

52.222-8

PAYROLLS AND BASIC RECORDS

JUN

52.222-9

APPRENTICES AND TRAINEES

JUL

52.222-10

COMPLIANCE WITH COPELAND

ACT REQUIREMENTS

52.222-11

SUBCONTRACTS (LABOR STANDARDS)

JUL

52.222-12

CONTRACT TERMINATION - DEBARMENT

FEB

52.222-13

COMPLIANCE WITH DAVIS-BACON AND

RELATED ACT REGULATIONS

52.222-14

DISPUTES CONCERNING LABOR

STANDARDS

52.222-15

CERTIFICATION OF ELIGIBILITY

FEB

52.222-21

PROHIBITION OF SEGREGATED

FACILITIES

52.222-26

EQUAL OPPORTUNITY

MAR

52.222-27

AFFIRMATIVE ACTION COMPLIANCE

REQUIREMENTS FOR CONSTRUCTION

52.222-36

AFFIRMATIVE ACTION FOR WORKERS

OCT

WITH DISABILITIES

52.222-50

COMBATING TRAFFICKING IN PERSONS

FEB

52.223-2

AFFIRMATIVE PROCUREMENT OF

JUL

BIOBASED PRODUCTS UNDER SERVICE

AND CONSTRUCTION CONTRACTS

52.223-3

52.223-6

HAZARDOUS MATERIAL IDENTIFICATION AND MATERIAL SAFETY DATA

ALTERNATE I (JUL 1995) DRUG-FREE WORKPLACE

JAN

MAY

DESIGNATED ITEMS IN SERVICE

AND CONSTRUCTION CONTRACTS

BAN TEXT MESSGING WHILE DRIVING

CONTRACTS

FOR BONDS

CONSTRUCTION CONTRACTS

CONTRACTS

TRANSFER—CENTRAL CONTRACTOR

REGISTRATION

CONTRACT CLAIM

AFFECTING THE WORK

STRUCTURES, EQUIPMENT, UTILITIES

AND IMPROVEMENTS

POSSESSION

CONTRACTS

CONSTRUCTION

GOVERNMENT (FIXED-PRICE)(SHORT FORM)

(* Applicable if contract award exceeds $10,000) (** Applicable if contract award exceeds $30,000) (*** Applicable if contract is awarded to an individual) (**** Applicable to Emergency Watershed Protection Projects) I.2 52.225-9 BUY AMERICAN ACT – CONSTRUCTION MATERIALS (SEP 2010) (a) Definitions. As used in this clause-- “Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and (iii)Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the end product.

“Domestic construction material” means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if— (i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the Buy American Act (41 U.S.C. 10a-10d) by providing a preference for domestic construction material.

In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

( NONE – or the CO is to list applicable excepted materials )

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act.

(1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award.

If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American Act applies, use of foreign construction material is noncompliant with the Buy American Act.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Item 1:

Foreign construction Material Domestic construction Material

Item 2:

Foreign construction Material Domestic construction Material

*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary. Include other applicable supporting information.

(Applicable if contract award exceeds $30,000.00)

I.3 52.228-13 ALTERNATIVE PAYMENT PROTECTIONS (JULY 2000)

(a) The Contractor shall submit one of the following payment protections: a payment bond; or an irrevocable letter of credit.

(b) The amount of the payment protection shall be 100 percent of the contract price.

(c) The submission of the payment protection is required within 10 days of contract award.

(d) The payment protection shall provide protection for the full contract performance period plus a one-year period.

(e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties.

(f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement.

I.4 52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984) The Contractor shall perform on the site, and with its own organization, work equivalent to at least 20 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

I.5 52.252-4 ALTERATIONS IN CONTRACT (APR 1984) Portions of this contract are altered as follows:

ADDED - NRCS Supplement to OSHA, Parts 1910 and 1926, Construction Standards and Interpretations

I.6 52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Agriculture Acquisition Regulation (48 CFR Chapter 4) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

DELINQUENT STATUS FOR CORPORATE APPLICANTS (DEVIATION 2012-01) (FEB 2012)

(a) This award is subject to the provisions contained in the Agriculture, Rural Development, Food and Drug Administration, and Related Agencies Appropriations Act, 2012, P.L. No. 112-55, Division A, Sections 738 and 739 regarding corporate felony convictions and corporate federal tax delinquencies.

Accordingly, by accepting this award the contractor acknowledges that it –

(1) does not have a tax delinquency, meaning that it is not subject to any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, and

(2) has not been convicted (or had an officer or agent acting on its behalf convicted) of a felony criminal violation under any Federal or State law within 24 months preceding the award, unless a suspending and debarring official of the United States Department of Agriculture has considered suspension or debarment of the awardee, or such officer or agent, based on these convictions and/or tax delinquencies and determined that suspension or debarment is not necessary to protect the interests of the Government.

(b) If the awardee fails to comply with these provisions, NRCS may terminate this contract for default and may recover any funds the awardee has received in violation of sections 738 or 739.

I.8 AGAR 452.232-70 REIMBURSEMENT FOR BOND PREMIUMS--FIXED-PRICE CONSTRUCTION CONTRACTS (NOV 1996)

The Contract Price includes the total amount for premiums that the Contractor attributes to the furnishing of performance and payment bonds required by the contract. Reimbursement for bond premiums under the clause at FAR 52.232-5, Payments Under Fixed-Price Construction Contracts, shall not cover any amount therefor not included in the contract price.

I.9 SCSAR 4I-52.232-72 OTHER INVOICING REQUIREMENTS UNDER PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (SCS, AMB, JULY 1993)

(a) In addition to the information required in clause 52.232-27, the contractor shall provide the following:

AG-1106-S-14-0001

I.7

AGAR 452.209-71

ASSURANCE REGARDING FELONY CONVICTION OR TAX

submitted to the Contracting Officer and to the copy submitted to the Contracting Officer's Representative.

(i) Evidence that the Contractor has acquired title to materials when the Contractor is requesting payment for materials on- site or if specifically authorized in this contract, for materials off-site. The invoice or other evidence should be identified by the bid item (CLIN) to which they apply.

(b) The data required in 52.232-27(a)(2)(iii), (a)(2)(iv) and above shall be identified by bid item number (CLIN) given in Section B of this contract and include the quantity performed, the unit price and the invoice total for that bid item.

(c) The invoice must show the billing period.

(d) Other data as described below: Substantiation of the amounts requested must include, as a minimum:

(1) An itemization of the amounts requested related to the various elements of work (bid items) required by the contract covered by the payment request.

(2) Additional supporting data in a form and detail required by the Contracting Officer:

(i) A copy of the payrolls and statements of compliance not previously submitted, to include the period of time covered by the invoice period.

(ii) The information as specified in (d)(1) must be submitted to the NRCS Construction Inspector at the project site three

(3) days prior to the submission of the complete invoice to the Contracting Officer and the Contracting Officer's Representative.

(e) The FINAL invoice submitted for payment shall contain the following RELEASE OF CLAIMS statement:

I, (Name of Contractor) do hereby release the United States of America from any and all claims of any character whatsoever arising under and by virtue of Contract No. (Identify the Contract) dated (date) as amended, except as herein stated.

( Date of Release ) ( Signature of Contractor )

I.10 SCSAR 4I-52.249-70 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (SCS, AMB, JULY 1993)

(a) This clause specifies the procedure for determination of time extensions for unusually severe weather in accordance with the Clause entitled, DEFAULT (FIXED PRICE CONSTRUCTION). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.