Attachment C - Additional Terms and Conditions.pdf

Attachment C

80LARC858109Q

NFS CLAUSES

Clauses incorporated by reference:

NASA FAR SUPPLEMENT (48 CFR CHAPTER 18) CLAUSES:

1852.203-71 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS.

(JUL 2023)

1852.215-84 OMBUDSMAN. (NOV 2023)

1852.237-73 RELEASE OF SENSITIVE INFORMATION. (JUN 2005)

(End of by reference clauses)

1852.225-70 EXPORT LICENSES. (FEB 2000)

(a) The Contractor shall comply with all U.S. export control laws and regulations, including the International Traffic in Arms Regulations (ITAR), 22 CFR parts 120-130, and the Export Administration Regulations (EAR), 15 CFR parts 730-799, in the performance of this contract.

In the absence of available license exemptions/exceptions, the Contractor shall be responsible for obtaining the appropriate licenses or other approvals, if required, for exports of hardware, technical data, and software, or for the provision of technical assistance.

(b) The Contractor shall be responsible for obtaining export licenses, if required, before utilizing foreign persons in the performance of this contract, including instances where the work is to be performed on-site at [insert name of NASA installation], where the foreign person will have access to export-controlled technical data or software.

(c) The Contractor shall be responsible for all regulatory record keeping requirements associated with the use of licenses and license exemptions/exceptions.

(d) The Contractor shall be responsible for ensuring that the provisions of this clause apply to its subcontractors.

(End of clause)

1852.225-71 RESTRICTION ON FUNDING ACTIVITY WITH CHINA (FEB 2012)

(DEVIATION)

(a) Definition - "China" or "Chinese-owned company" means the People's Republic of China, any company owned by the People's Republic of China or any company incorporated under the laws of the People's Republic of China.

(b) Public Laws 112-10, Section 1340(a) and 112-55, Section 539, restrict NASA from contracting to participate, collaborate, coordinate bilaterally in any way with China or a Chinese-owned company using funds appropriated on or after April 25, 2011. Contracts for commercial and non developmental items are exempted from the prohibition because they constitute purchase of goods or services that would not involve participation, collaboration, or coordination between the parties.

(c) This contract may use restricted funding that was appropriated on or after April 25, 2011. The contractor shall not contract with China or Chinese-owned companies for any effort related to this contract except for acquisition of commercial and non-developmental items. If the contractor anticipates making an award to China or Chinese-owned companies, the contractor must contact the contracting officer to determine if funding on this contract can be used for that purpose.

(d) Subcontracts - The contractor shall include the substance of this clause in all subcontracts made hereunder.

(End of clause)

1852.232-80 SUBMISSION OF VOUCHERS FOR PAYMENT. (APR 2018)

(a) The designated payment office is the NASA Shared Services Center (NSSC) located at FMD Accounts Payable, Bldg. 1111, Jerry Hlass Road, Stennis Space Center, MS 39529.

(b) Except for classified vouchers, the Contractor shall submit all vouchers and invoices using the steps described at NSSC's Vendor Payment information Web site at:

https://www.nssc.nasa.gov/vendorpayment. Please contact the NSSC Customer Contact Center at 1-877-NSSC123 (1-877-677-2123) with any additional questions or comments.

(c) Payment requests.

(1) The payment periods are stipulated in the payment clause(s) contained in this contract.

(2) Vouchers submitted under cost type contracts and invoices submitted under fixed-price contracts shall include the items delineated in FAR 32.905(b) supported by relevant back-up documentation. Back-up documentation shall include at a minimum, the following information:

(i) Vouchers.

(A) Breakdown of billed labor costs and associated contractor generated supporting documentation for billed direct labor costs to include rates used and number of hours incurred.

(B) Breakdown of billed other direct costs (ODCs) and associated contractor generated supporting documentation for billed ODCs.

(C) Indirect rate(s) used to calculate the amount of billed indirect expenses.

(D) Progress reports, as required.

(ii) Invoices.

(A) Description of goods and services delivered as part of the contract's terms and conditions, including the dates of delivery/performance.

(B) Progress reports, as required.

(C) Date goods and services were performed.

(iii) Fee vouchers.

(A) Listing of all provisionally-billed fee by period or date earned since contract award.

(B) A reconciliation of all billed and earned fee.

(C) A clear explanation of the fee calculations.

(d) Non-electronic payment requests. The Contractor may submit a non-electronic voucher/invoice using the steps for non-electronic payment requests described at https://www.nssc.nasa.gov/vendorpayment, when any of the following conditions are met:

(1) The Contracting Officer administering the contract for payment has determined, in writing, that electronic submission would be unduly burdensome to the Contractor.

(2) The contract includes provisions allowing the contractor to submit vouchers or invoices using the steps for non-electronic payment. In such instances the Contractor agrees to submit non-electronic payment requests using the method or methods specified in Section G of the contract.

(e) Improper vouchers/invoices. The NSSC Payment Office will notify the contractor of any apparent error, defect, or impropriety in a voucher/invoice within seven calendar days of receipt by the NSSC Payment Office. Inquiries regarding requests for payment should be directed to the NSSC as specified in paragraph (b) of this section.

(f) Other payment clauses. In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payment requests.

(g) In the event that amounts are withheld from payment in accordance with provisions of this contract, a separate payment request for the amount withheld will be required before payment for that amount may be made.

CENTER UNIQUE CLAUSES

LARC 52.201-90 NAMING/NUMBERING SCHEME FOR CLAUSES IN FULL TEXT

AND FOR CLAUSES INCORPORATED BY REFERENCE (MAR 2012)

There are various types of clauses contained in the contract. Most clauses will reference a numbered cite such as: Federal Acquisition Regulation (FAR 52.#); NASA FAR Supplement (NFS 1852.#); or Langley Research Center (LaRC 52.#). There are also clauses that have no numbered cite designation. Those clauses were written by LaRC for this specific contract or were written as generic Agency clauses specific for this contract type.

(End of clause)

LARC 52.211-96 DELIVERY REQUIREMENTS (AUG 2021)

a) Delivery is required to be made by November 1, 2024, from the effective date of the contract.

b) Delivery shall be f.o.b. destination to:

National Aeronautics and Space Administration Langley Research Center Landing and Impact Research Facility (LandIR) – Gantry Site Hampton, VA 23681-2199

c) The Contractor shall notify the Contracting Officer's Representative (COR) in writing at least 10 days prior to the scheduled delivery date with a copy of the notification to the Contract Specialist. The notification shall include, as a minimum, the dimensions and weight of each container, the scheduled delivery date, and any Government equipment/service needed for off-loading. Since internal coordination by the Government is necessary to assure the availability of any required Government assistance, failure of the Contractor to comply with this notification requirement may result in delays in unloading the carrier at the f.o.b. destination site and result in additional expenses to the Contractor (e.g., demurrage charges, re-delivery). The Contractor shall make delivery to the f.o.b. destination site between the hours of 8:30 a.m. to 2:30 p.m., Monday through Friday, except for Government holidays, or as otherwise established as a result of the notification requirement cited above.

d) The Contractor shall instruct either its driver or the driver of the commercial carrier to obtain specific routing instructions to the delivery/installation site from the Transportation and Warehousing Section, 4 South Marvin Street, Building 1206, NASA, Langley Research Center.

Failure to do so may cause lack of proper documentation of the delivery and related delays in NASA, Langley Research Center internal processing procedures and payment of the Contractor's invoice(s).

e) At delivery, the Government may provide personnel and equipment; e.g., forklift and/or crane service, if requested by the Contractor. Notwithstanding Government assistance, the Contractor

CENTER UNIQUE CLAUSES

shall retain full responsibility for equipment handling, even if a Contractor's representative is not present during this process.

NFS PROVISIONS

Clauses incorporated by reference:

NASA FAR SUPPLEMENT (48 CFR CHAPTER 18) CLAUSES:

1852.233-70 PROTESTS TO NASA. (DEC 2015)

(End of by reference clauses)

1852.225-72 RESTRICTION ON FUNDING ACTIVITY WITH CHINA -

REPRESENTATION (FEB 2012) (DEVIATION)

(a) Definition - "China" or "Chinese-owned" means the People's Republic of China, any company owned by the People's Republic of China or any company incorporated under the laws of the People's Republic of China.

(b) Public Laws 112-10, Section 1340(a) and 112-55, Section 536, restrict NASA from contracting to participate, collaborate, or coordinate bilaterally in any way with China or a Chinese-owned company with funds appropriated on or after April 25, 2011. Contracts for commercial and non-developmental items are excepted from the prohibition as they constitute purchase of goods or services that would not involve participation, collaboration, or coordination between the parties.

(c) Representation. By submission of its offer, the offeror represents that the offeror is not China or a Chinese-owned company.