CGC_Kukui_CAT_Engine_Ovhl_COMBINED_SYNOPSIS.doc

COMBINED SYNOPSIS/ SOLICITATION

This is a combined synopsis/solicitation for commercial services prepared in accordance with the format in FAR Subpart12.6, supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotations are being requested and a separate written solicitation will not be issued

The solicitation is issued as a Request for Quotation (RFQ). This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular FAC 2005-101 dated 26 September 2018. This requirement is being solicited as total small business set-aside using FAR Part 12 Acquisition of Commercial Items and FAR 13.5 Simplified Procedures for Certain Commercial Items. The NAICS Code is 336611 - Ship Repair with a small business size standard of 1,250 employees. The solicitation number is 70Z085-19-Q-P4527700.

SCHEDULE OF SUPPLIES/SERVICES: See Attachment 2.

DESCRIPTION OF WORK: This work item describes the requirements for the Contractor to disassemble, clean, inspect, repair and reassemble (Center Section Overhaul) Caterpillar (CAT) Diesel Engine Units and Accessories. That include engine models D3508 Marine Diesel Engine and provide genuine CAT OEM approved parts as necessary for repairs aboard USCGC KUKUI (WLB 203), all in exact accordance with this solicitation and the attached specification. See Attachment 1.

CONTRACT TYPE: This solicitation is a request for quotes (RFQ) that will result in the award of a firm fixed price contract solicited under FAR PART 12 and FAR Subpart 13.5 Simplified Procedures for Certain Commercial Items.

CONTRACT PERIOD OF PERFORMANCE: The performance period for this requirement is 08 April 2019 through 03 May 2019.

PLACE OF PERFORMANCE: The place of performance is at the cutters homeport.

CUTTER’S HOMEPORT: 1480 Seward Avenue, Sitka, AK 99835.

GEOGRAPHICAL RESTRICTION: Restricted to an area no greater than 400 nautical miles (nm) from cutter’s homeport and no open water transits.

QUESTIONS: It is strongly encouraged to submit questions regarding this solicitation by 22 March 2019 at 4:00 PM EDT. After this date, further requests may not be accepted due to time constraints. For questions regarding this solicitation, contact Brian.D.Forstner@uscg.mil and Patrick.D.Brown@uscg.mil.

QUOTATION DUE DATE: Quotations must arrive no later than 29 March 2019 at 2:00 PM EDT; Quotations may be sent via electronic mail (e-mail) to Brian.D.Forstner@uscg.mil and Patrick.D.Brown@uscg.mil.

FAR Clauses In By Reference

FAR 52.215-20

ALT IV

Alt I JUL 1995

FAR Clauses in Full Text

FAR 52.203-17 Contractor Employee Whistleblower Rights and Requirement to Inform

Employees of Whistleblower Rights (DHS-USCG DEVIATION 14-01) (APR 2014)

(a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the enhancement of whistleblower protections for Contractor employees established at 10 U.S.C. 2409 by section 827 of the NDAA for FY 2013 (Pub. L. 112-239) and FAR 3.908.

(b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 10 U.S.C. 2409, as described in section 3.908 of the FAR.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold.

FAR 52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of the Section Chief, CPD, C&P2 and shall not be binding until so approved.

FAR 52.209-7 – INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision—

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than $10,000,000.

If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the Central Contractor Registration database via https://www.acquisition.gov (see 52.204-7).

(End of Provision)

FAR 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS AND STANDARDS AND COMMERCIAL ITEMS DESCRIPTIONS (JUN 1988)

a. Orders for U.S. Coast Guard specification reference drawings must be placed within 10 days of the solicitation issue date. To request drawings, contact the Contract Specialist listed herein. All requests should identify the solicitation number. U.S. Coast Guard specification reference drawings are available in CD-ROM format and are provided free of charge. The CD-ROM(s) contain WINDOWS compliant raster/vector formats (e.g. *.TIF, *.TIF (group4), *.DWG, and *.DWF, etc.).

Drawing measurements should be verified by the Contractor prior to ordering materials.

FAR 52.211-11 – LIQUIDATED DAMAGES – SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEPT 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $500.00 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default – Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default – Fixed-Price Supply and Service clause in this contract.

(End of Clause)

REQUIRED INSURANCE

The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including:

1. Ship Repairer's Liability - $500,000 per occurrence.

2. Comprehensive General Liability - $500,000 per occurrence.

3. Full insurance coverage in accordance with the United States’ Longshoremen's and Harbor Worker's Act.

4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract.

FAR 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS (DEVIATION 2018 – O0018) (OCT 2018)

All pages in the quote shall be numbered and identified with the quote’s name and RFQ Number 70Z08519QP45257, FY2019 DS ENGINE OVERHAUL FOR CGC KUKUI. Subsequent revisions should be similarly identified to show revision number and date.

A. REQUIRED DOCUMENTS:

Each quoter shall furnish the information required by the solicitation, which includes:

1. Cover Letter with the contractor’s signature, address, and DUNS number.

2. Attachment 1- Section B Schedule of Supplies/ Services filled out with a cost associated with each CLIN, to include labor.

3. Attachment 3 Past Performance Documentation

4. Small Business Self Certification for applicable set-aside (i.e. HUBZone, Small Business, SDVOSB, 8(a))

5. Welding Certifications and Procedures

6. Proof of Insurance (Statement of Coverage from current Insurance carrier)

7. List the names of ALL Sub-Contractor’s that your company intends to subcontract for the CLIN Item(s) listed in the Schedule of Supplies/Services.

8. All Technical Representative Certifications for BOTH PRIME AND SUBCONTRACTORS as specified in the specification.

9. Completed FAR 52.212-3 Offeror Representations and Certifications – Commercial Items

10. Technical Factor Documentation

B. EVALUATION FACTORS

Factor Title

Page Limit

I

Technical Capability 5 Pages

II

Past Performance 5 Pages

III

Price

None

FACTOR I: TECHNICAL CAPABILITY:

The Contractor shall provide the services of a certified Tech Rep, who is familiar with the Caterpillar marine diesel engine models listed in Paragraph 3.2.1 – 3.2.1.2 of Specification.

· Provide evidence/documentation of being a Caterpillar Dealer

· Provide evidence/documentation of being able to provide OEM Parts

· Provide evidence/documentation of experience working on Model D3508 Engines.

FACTOR II: PAST PERFORMANCE

The offeror shall identify at least two (2) but no more than four (4) relevant (construction, overhaul, repair and alteration of ships) and recent federal, state or local government or private contracts performed during the last three (3) years. Offeror shall submit past performance information on Attachment 3- Past Performance Information Form.

FACTOR III: PRICE

Complete Attachment 1 with prices for all CLINs.

If requested, the Offeror must also submit the following detailed information to support the pricing offer, in addition to completing Schedule B of the solicitation.

Offerors may use their own format for the information required below but it must be easily read and comprehended and identified by individual work item (eg. D-01, D-02):

1. Breakdown for each work item:

(a) Direct labor cost by labor hours and proposed hourly rate(s);

(b) Materials; Subcontracts; Equipment; Other Direct Costs; and Profit, if listed separately -- individually identifying any items which are $500 or greater.

2. Provide a listing by subcontractor with the following information:

(a) Identification of each proposed subcontractor (name, address, phone number) and his small business status.

(b) A brief description of the service or supply, by work item, to be furnished and the proposed price for each.

(c) An explanation of why and how the proposed subcontractor was selected including the extent of competition obtained.

Quotes are required to be submitted to both: Brian.D.Forstner@uscg.mil, and Patrick.D.Brown@uscg.mil Email submission shall not exceed 10 MBS.

PLEASE NOTE: QUOTES THAT DO NOT FOLLOW INSTRUCTION AND OR FAIL TO INCLUDE ALL REQUIRED DOCUMENTS MAY BE CONSIDERED INCOMPLETE AND MAY NOT BE CONSIDERED.

(End of Provision)

FAR 52.212-2 EVALUATION-COMMERCIAL ITEMS (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factor shall be used to evaluate the offer:

Factors:

I. Technical Capability

II. Past Performance

III. Price

The technical and past performance factors are equal in importance. Technical and Past Performance, when combined, are significantly more important than Price. Thus award will be made to the quote that presents the best value, in all factors considered, and may not necessarily be made to the lowest price quote.

Factor I: Technical Capability

The Government will evaluate each offeror’s Technical Capability to determine the offeror’s capacity to perform all the requirements outlined in the Specification.

The offeror’s technical capability will be evaluated according to the following table.

Technical Evaluation Rating

Factor II: Past Performance

The past performance evaluation will take into account the guidelines outlined at FAR 15.305(a)(2) Past Performance Evaluation. The Contractor’s past performance will be evaluated according to the following:

Past Performance Quality Ratings

In evaluating Contractors past performance, the government intends to also review U.S. Coast Guard Contractor Performance Assessment Reports and other existing past performance ratings on relevant contracts. For purposes of this solicitation, “relevant contracts” are defined as contracts performed in the three years preceding the date of this solicitation in which the contractor was the prime contractor performing construction, overhaul, repair and alteration of similarly-sized ships/ vessels. Past performance ratings for contracts that were completed more than three years before the date of the issuance of this solicitation are not considered relevant and will not be evaluated. General trends in a Contractor’s performance will also be considered. Vendors lacking relevant past performance history will not be evaluated favorably or unfavorably on past performance, but will be assigned a Neutral rating.

Factor III: Price

The total evaluated price of the offeror will be determined by totaling the proposed prices of all the Definite and Option Items, plus the composite labor hour extended total, plus lay days and foreseeable costs.

(1) DEFINITE ITEMS: These are the items, which, if there is an award at all, will be awarded. The bid shall be evaluated to include the price for each definite item.

(2) OPTION ITEMS: These are the items, which, if there is an award at all, may be awarded upon completion of open and inspect, or if additional funds become available, of if they are needed. The offer shall be evaluated to include the price for each option item.

(3) COMPOSITE LABOR HOUR RATE: The offer shall be evaluated to include the offer price for the Composite Labor Hour Rate multiplied by the estimated quantity of hours.

(4) LAY DAYS: A lay day is defined as an additional day on a dry dock or marine railway caused by a Government- issued change. The Contracting Officer will evaluate the daily rate for lay days multiplied by the estimated quantity of lay days as stated in the offeror’s Schedule of Services/ Supplies.

(5) FORESEEABLE COSTS: The Contracting Officer will evaluate certain foreseeable costs that will vary with the location of the commercial shipyard to be used by bidders/offerors under this solicitation. Costs will be calculated based on the bidder's/offeror's shipyard location and these costs will be added, for the purposes of evaluation only, to the bidder's/offeror's overall price.

Offeror’s price shall represent the best price in response to the request for quotes. The price shall be evaluated to determine fairness and reasonableness. Award may be made without any type of discussions or negotiations. The Government reserves the right to award to other than the lowest-priced offeror.

DISTANCE FACTOR ADJUSTMENT

In accordance with Coast Guard Acquisition Procedures (CGAP) 3017.9001– Price related factors in the award of vessel repair contracts, foreseeable costs in connection with the differences of shipyard locations in the award of any vessel repair contract conducted away from the vessel’s home pier shall be evaluated in all solicitations for contracts exceeding $100,000.

LOCATION OF OFFEROR’S COMMERCIAL SHIPYARD

In order for the Contracting Officer to evaluate certain foreseeable costs to the Coast Guard that will vary with the location of the commercial shipyard to be used by the offeror, the offeror is required to provide, in the space below, the exact location of the shipyard to be used to perform the services required under this solicitation. The offeror is cautioned that its failure to provide the location of its commercial shipyard in the space provided may result in its quote being declared nonresponsive under the provisions of the terms of this Request for Quote.

Name and Location of Shipyard:

FORESEEABLE COST FACTORS PERTAINING TO DIFFERENT SHIPYARD LOCATIONS

The Contracting Officer will evaluate certain foreseeable costs to the Coast Guard. Those costs will vary based on the location of the offeror’s shipyard and are added to the offeror’s overall bid price or price quote for the purposes of evaluation only. These elements of foreseeable costs consist of the following:

(1) Transit Cost:

Vessel operational cost will be calculated based on one round trip from the vessel's homeport of SITKA, AK to the contractor's facility. Distance will be based on the NOAA publication, “Distance Between U.S. Ports” or other authority (in order of priority), including Army Corp of Engineers or U.S. Navy transit publications, if the shipyard location is not contained in the NOAA publication.

Transit cost to navigate the vessel between its homeport and the contractor's offered place of performance is $0 per nautical mile. The number of nautical miles to transit between the offerors shipyard and the vessel's homeport will be multiplied by the operational cost.

(2) Family Separation Allowance & Homeport Travel:

Crew members with dependents residing within the area of the homeport are entitled do Family Separation Allowance and Homeport Travel Allowance whenever a vessel is overhauled outside of the area of the homeport. The area of the homeport is defined as the area within 50 road miles of the homeport. If the contractor’s facility is the outside of a 50-road mile radius of the vessel’s homeport.

(i) Family Separation Allowance for personnel in accordance with Family Separation Allowance listed under DFAS.mil; Pay & Allowance; Family Separation Allowance for 0 crew members entitled to Family Separation Allowance $0 per day. This entitlement is calculated from the date that the vessel leaves the home port to the transit to the offerors shipyard and the planned date of return to home port after completion of repairs or equipment installation. If the contractor’s facility is less than 50 road miles from the cutter’s homeport, Family Separation allowance will not apply.

(ii) Homeport Travel. Crew’s transportation during overhaul away from home port. As required by 37 USC 406 b and Chapter 7, part F1 of the Joint Federal Travel Regulations (JFTR), on the thirty-first (31) day of a vessel being away from home port, and every (60) days thereafter, all personnel with dependents residing in the area of the home port will be provided round trip coach type airfare to the vessels home port. There will be (1) home port visit(s) during the performance of this contract. The vessel has 0 crew members eligible for Homeport Travel. Airfares will be based on the GSA City Pairs contracted Government YCA Fare (or successor GSA fare source) in effect at the time of receipt of quotes. If there is no GSA contracted rate between the location of the contractor’s shipyard and the homeport the rate will be computed based on commercially available airfares. If the contractor’s facility is less than 50 road miles from the cutter’s homeport, homeport travel will not apply.

(3) Travel and Per Diem Cost:

(i)COR Homeport Travel: There will be a transportation cost for one (1) Contracting Officer's Representative (COR) for 02 round trip(s) between the contractor's offered place of performance and the COR's official duty station (Seattle, WA) at the cost of coach-type airfare. If the contractor’s facility is less than 50 road miles from the CORs official duty station (Seattle, WA), COR Homeport Travel will not apply.

(ii)COR Per Diem: There will be a per diem expense for 30 calendar days to support one (1) COR while in the city of the place of contract performance, to be determined in accordance with the Joint Federal Travel Regulations (JFTR). The cost of car rental for the estimated performance period will also be included. If the contractor’s facility is less than 50 road miles from the CORs official duty station (Seattle, WA), COR Per Diem will not apply.

(iii) Contracting Officer Travel and Per Diem: There will be a transportation cost for Contracting Officer for one (1) three (3) day round trip , between the Contracting Officer's official duty station (Norfolk, VA) and the contractor's offered place of performance at the cost of coach-type airfare and per diem expenses and a rental car. If the contractor’s facility is less than 50 road miles from the Contracting Officer’s official duty station (Norfolk, VA), Contracting Officer Travel and Per Diem will not apply.

(iv) Crew Dining and Lodging: There will be a dining and lodging cost for 0 crew members while in the city of the place of contract performance for the estimated performance period 30 days. The cost of hotel and meals and incidentals expenses (M&IE) shall be calculated in accordance with the Joint Federal Travel Regulations (JFTR). If the contractor’s facility is less than 50 road miles from the cutter’s homeport (Sitka, AK), Crew Dining and Lodging will not apply.

PRE AWARD SURVEY

Prior to a contract being awarded a Pre-Award Survey may be conducted by the US Coast Guard Quality Assurance Team. The survey is used as an indication if a contractor has the qualifications to do the work and that the contractor’s facilities are certified under US Coast Guard specifications. Areas of interest on this survey may include, but are not limited to the following:

1. Performance Plans

2. Quality control or contractor quality assurance Plans

3. Personnel recruitment and training plans

4. Workload factors for manpower utilization

5. Management plan for handling peak workloads

6. Production capability

a. Plant facilities and equipment

b. Purchasing and subcontracting

c. Labor resources

d. Performance record

e. Ability to meet delivery schedules

f. Ability to perform production work in accordance with the specifications.

7. Environmental/energy considerations

8. Plant safety

9. Technical and/or professional abilities

10. Accounting systems

11. Security clearance

12. Government property control

Offerors are advised that accomplishment of this survey is a part of the evaluation process and is not to be construed as an indication that an offeror will receive or is in the best position to receive the resultant award.

b) Options. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer’s specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of Provision)

FAR 52.212-3 Offeror Representations and Certifications—Commercial Items (OCT 2018)

The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at http://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

(a) Definitions. As used in this provision--

“Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means--

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces’ “. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are--

(1) Department of Labor Wage and Hour Division (WHD) for--

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(v) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(vi) The Family and Medical Leave Act; and

(vii) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for--

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(4) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for--

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(5) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(6) Equal Employment Opportunity Commission (EEOC) for--

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

Sensitive technology—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”, “DOL Guidance”, “Enforcement agency”, “Labor compliance agreement”, “Labor laws”, and “Labor law decision”. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ____________. [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [_] is, [_] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not a women-owned small business concern.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [_] is, [_] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: _________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

(i) It [_] is, [_] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: _____________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [_] is, [_] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [_] is, [_] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern…