SOLICITATION-COMBINED_SYNOPSIS_TERRAPIN_WPB-87366___DS_FY19.pdf

USCGC TERRAPIN (WPB-87366)

DOCKSIDE REPAIRS

70Z080-19-Q-P4500100

NOTICE FOR FILING AGENCY PROTESTS

United States Coast Guard Ombudsman Program

It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO).

Interested parties are encouraged to seek resolution of their concerns within the USCG as an

Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman.

Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable

Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests.

Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester’s concerns are unresolved, an Independent

Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program.

Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency’s goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted electronically to OPAP@uscg.mil and the

Contracting Officer or by hand delivery to the Contracting Officer.

Election of Forum. After an interested party protests a Coast Guard procurement to the

Contracting Officer or the Ombudsman, and while the protest is pending, the protester agrees not to file a protest with the GAO or other external forum. If the protest is filed with an external forum, the agency protest will be dismissed.

The Ombudsman Hotline telephone number is 202.372.3695.

mailto:OPAP@uscg.mil

This is a combined synopsis/solicitation for commercial items prepared in accordance with

Federal Acquisition Regulation (FAR) subpart 12.6 and subpart 13 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotations are being requested and a written solicitation will not be issued.

Solicitation number 70Z080-19-Q-P4500100 is issued as a Request for Quotation (RFQ).

This solicitation document and incorporated provisions and clauses are those in effect through

Federal Acquisition Circular (FAC) 2005-99 effective June 18, 2018.

The applicable North American Industry Classification Standard Code is 336611. The small business size standard is 1,250 employees. This solicitation is issued as a 100% Total Small

Business Set-Aside. All responsible small business sources may submit a quotation, which shall be considered by the agency.

It is anticipated that one (1) firm fixed price contract will be awarded as a result of this synopsis/solicitation.

PERIOD OF PERFORMANCE: The period of performance for this contract is thirty-two (32) calendar-days beginning 30 October through 08 December 2018. Offerors that have this capability are invited to submit quotations in accordance with the requirements stipulated in this solicitation.

SOLICITATION DOCUMENTS: - separately attached:

Attachment-1: Schedule of Services – Price Schedule

Attachment-2: Statement of Work – Specification

Attachment-3: Technical Evaluation Factors

Attachment-4: Request for Clarification Form

PLACE OF PERFORMANCE: The place of performance will be at the vessel’s home pier located at

USCG Base Seattle, 1519 Alaskan Way South, Seattle WA 98301.

REQUEST FOR DRAWINGS / QUESTIONS: Request drawings or questions for clarification must be sent to Lenore Sevier @ lenore.d.sevier@uscg.mil before 11:00 a.m. on 22 August 2018.

DUE DATE FOR QUOTES: Quotes are due on or before 03 September 2018 at 12:00 a.m.

Eastern Standard Time. The anticipated award date will be after 01 October 2018. E-mail quotations are preferred and may be sent to Lenore Sevier @ lenore.d.sevier@uscg.mil please indicate 70Z080-19-Q-P4500100 in subject line. Quotations may also be mailed to the following address:

US Coast Guard

SLFC/CPD1/PBPL

Attn: Lenore Sevier

300 East Main Street, Suite 600

Norfolk, VA 23510-9102 mailto:lenore.d.sevier@uscg.mil

DESCRIPTION OF WORK:

The proposed contract to be awarded by the United States Coast Guard (USCG) shall be for

Dockside repairs to USCGC TERRAPIN (WPB-87366).

(a) The Contractor shall furnish all necessary labor, material, services, equipment, supplies, power, accessories, facilities and such other things as are necessary, except as otherwise specified, to perform dockside repairs and alterations to the vessel, in accordance with this solicitation and attached specification.

(b) Failure to read the specifications in their entirety will not relieve the offeror from the responsibility for properly estimating the difficulty or price of successfully performing the work.

Failure to do so will be at the offeror's risk.

All quotes submitted in response to this solicitation shall stand firm for 60 calendar days from the response date of this solicitation.

Contractors are responsible for verifying the receipt of their proposal.

*REQUIRED DOCUMENTS:

Each offeror shall submit the documentation required by the solicitation, which includes:

1. Cover letter on company letterhead with offeror’s address, point of contact, phone number, email address, DUNS and any other relevant information.

2. Attachment-1: Complete Schedule of Services - Price Schedule filled out with a cost associated with each CLIN.

3. Completed Attachment-3 Technical Evaluation Factors (as listed under FAR 52.212-2).

4. Past Performance Documentation.

5. Insurance Certificate - Proof of Insurance /Statement of Coverage from current Insurance carrier (see page 7).

Contract Clauses and Provisions

52.212-1 Instructions to Offerors - Commercial Items (Jan 2017)

(f) (1) Late submissions, modifications, revisions, and withdrawals of offers are tailored as follows:

Quotes are due on or before 11:00 AM local time for Norfolk, 03 September 2018. After that time, the Government will begin evaluating quotes, making an award decision, and issuing a purchase order. Quotes submitted after that time may not be considered.

Cost or Pricing Data It is Department of Homeland Security (DHS) policy that pricing for competitive negotiations should be based on adequate price competition. However, in the event only one responsible offeror is obtained as a result of this solicitation, that offeror may be required to submit Data

Other Than Certified Cost or Pricing Data to support price negotiations.

52.212-2 Evaluation—Commercial Items (Oct 2014)

The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following three (3) factors shall be used to evaluate offers:

A. Technical Capabilities (See attachment-3)

B. Past Performance

C. Price

A. Technical Capabilities:

Technical Acceptability will be evaluated to determine an overall rating. This will be determined by evaluating the technical approach of the offeror to provide a sound, compliant approach that meets all requirements listed in the Specification and demonstrates a thorough knowledge and understanding of the requirements. It is the contractor’s responsibility to ensure that their quote clearly demonstrates their ability to perform these requirements. All offerors must provide the following information and documentation with their quotes to be considered technically acceptable:

1. Planning Document: Submit a Planning Document in accordance with 2014 SFLC

Standard Solicitation 0000, Paragraph 3.2.5 Planning document (pgs 11-12) http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-

Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-

Center/Contracting-Links/Standard-Specifications/, outlining the strategy for ensuring that this requirement is completed on or before the contract completion date. The planning document shall include at a minimum:

(a) Proposed schedule, resources, completion-dates, float, and major-milestones for the various tasks required to complete this contract and

(b) Identify a list of items that may pose the most contract schedule risk and approach to mitigate or eliminate each risk.

2. Welding Procedures/Certifications - Submit welding documentation (e.g. WPSs, welder certs, etc.) in accordance with SFLC Standard Specification 0740_STD

(APR 2012) http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for- Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-

Center/Contracting-Links/Standard-Specifications/ specific to your internal or subcontracted staff for the weld joints that will be installed.

3. HVAC Repairs - Contractor certification. Submit the certification of either:

http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/ http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/ http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/ http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/ http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/ http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/

Environmental Protection Compliance -Submit documentation of

Environmental Protection Agency (EPA) certification for each servicing technician

IAW SFLC Standard Specification 0000, Appendix A & B (e.g. résumé w/photo-copy of cert card, etc.).

(a) a qualified independent Paint and Coatings Inspector certified as a

“Specialist” in accordance with NACE or other recognized standard or

(b) if the Prime or Subcontractor is QP1 certified under the Society for

Protective Coatings SSPC-QP 1 certification program in accordance with

SFCL 2014 Standard Specification 6310 (Appendix D5-D6), http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-

Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-

Center/Contracting-Links/Standard-Specifications/

4. WPB-87 MAIN DIESEL ENGINE (MTU) Engine Maintenance Qualification

Requirements. Submit the name and resume of the technical representative performing maintenance and personnel engaged in the supervision of the alignment work. The technical representative shall have experience with MTU marine engines documented on their resume. Personnel engaged in the supervision of the alignment work shall have their experience with engine and reduction gear system documented on their resume.

B. Past Performance:

The Government may utilize any references provided by the Contractor, along with information available from past contracts/orders with the USCG and any information found using sources such as Federal Government sources, Past Performance Information

Retrieval System (PPIRS)/Contractor Performance Assessment Reporting System

(CPARS) to determine if the Contractor has satisfactory or neutral Past Performance. The

Government reserves the right to limit or expand the number of references it decides to contact and to contact references other than those provided by the offeror. The offeror should provide at least three (3) relevant past performance evaluations within the last three (3) years. Past performance less than satisfactory may not be considered for award.

C. Price:

The offeror shall complete the Attachment-1 -Schedule of Services Price Schedule.

Offeror’s price shall represent the best price in response to the request for quote. The price shall be evaluated to determine fairness and reasonableness.

**The relative importance of technical capability and past performance when combined are more important than price** http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/ http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/ http://www.dcms.uscg.mil/Our-Organization/Assistant-Commandant-for-Engineering-Logistics-CG-4-/Logistic-Centers/Surface-Forces-Logistics-Center/Contracting-Links/Standard-Specifications/

Award may be made without any type of discussions or negotiations. This is based on the

Contracting Officer’s determination after an evaluation has been completed on all offers.

(End of provision)

52.212-3 Offeror Representations and Certifications-Commercial Items (Jan 2017)

Alternate I of 52.212-3 (Oct 2014)

An offeror shall complete only paragraphs (b) of this provision if the offeror has completed the annual representations and certificates electronically via http://www.acquisition.gov . If an offeror has not completed the annual representations and certifications electronically at the

System for Award Management (SAM) website, the offeror shall complete paragraphs (c) through (t) of this provision.

(End of Provision)

52.212-4 Contract Terms and Conditions – Commercial Items (Jan 2017) Addendum The paragraphs below are supplemented or added as follows:

Invoicing Instructions The Contractor’s invoice shall be submitted electronically IAW FAR 52.212-4 as follows.

1. Invoices shall be submitted to the USCG Finance Center Website at http://www.fincen.uscg.mil/electron_cg24.htm

2. The web submission requires the Contractor to complete the Invoice Receipt Cover

Form, select the Invoice Routing Code, and attach a PDF file of the invoice and any other supporting documentation.

3. A sample of the Invoice Receipt Cover Form is provided below. Mandatory information to be completed is highlighted in red on the website.

Invoice Routing Code:

(help) Invoice Receipt Date: (help)

Contract Number: (help) Invoice Number: (help)

Requisition Number: (help) Invoice Date: (help)

Delivery/Task Order Number: (help) Invoice Amount: (help)

Discount Terms: % Discount Days

Net Days (help)

Contractor Information Attachment of Official Invoice

Contractor Name: (help)

Submitter Name: (help) http://www.acquisition.gov/ http://www.fincen.uscg.mil/electron_cg24.htm

Submitter Email: (help)

Submitter Phone: (help)

4. The Contractor must select the correct Invoice Routing Code for timely invoice processing. The Invoice Routing Code for this contract is SFLC-1. Failure to do so will delay invoice payment.

5. The Contractor shall attach a single PDF file no larger than 1MB as the official invoice.

Payment Information

All payments will be made electronically IAW FAR 52.232-33.

Required Insurance

Prior to start of performance, the Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.217-95, Liability and Insurance (DEC 2003), and 3052.228-70, Insurance

(DEC 2003) the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including:

1. Ship Repairer's Liability - $500,000 per occurrence.

2. Comprehensive General Liability - $500,000 per occurrence.

3. Full insurance coverage in accordance with the United States’ Longshoremen's and

Harbor Worker's Act.

4. Full insurance coverage in accordance with the State's Workmen's Compensation

Law (or its equivalent) for all places of performance under this contract.

The insurance certificate must provide the name of the US Coast Guard vessel and the contract and/or solicitation number as specifically insured.

Change Request (CR) – Growth Work

(1) The Contractor shall not perform growth work without the Contracting Officer's authorization. This clause applies to Change Requests (CR), also known as growth and emergent work ordered by the Contracting Officer pursuant to the Changes clause or mutually agreed upon by the parties. The contractor shall perform CR at the labor billing rates designated in the Schedule, as described in paragraph (c) of this clause. The CR handling fee designated in the Schedule shall be the sole fee used for direct material purchases and subcontractor handling.

All growth work shall be paid at the prices stated in the Schedule.

(2) The CR labor rate shall be a flat, hourly rate for production labor hours only, to cover the entire effort and shall be burdened to include:

a. Direct production labor hour functions only. Direct production labor hours are hours of skilled labor at the journeyman level expended in direct production. Direct production is defined as work performed by a qualified craftsman that is directly related to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. The following functions are identified as direct production: Abrasive Cleaning/Water Blasting, Tank Cleaning, Welding, Burning, Brazing, Blacksmithing, Machining (inside and outside), Carpentry, Electrical/Electronic Work, Crane Operation, Shipfitting, Lagging/Insulating, Painting, Boilermaking, Pipe Fitting, Engineering (Production), Sheetmetal Work, Staging/Scaffolding, and Rigging.

b. Non-production labor hours (whether charged directly or indirectly by contractor's accounting system) shall be for labor in support of production functions. For purposes of this clause, support functions are defined as functions that do not directly contribute to the alteration, modification, or repair of the item or system identified as needing alteration, modification, or repair. Necessary support functions should be priced into the burdened rate for production labor hours. Examples of support functions include: Testing, Quality Assurance (inspection), Engineering (support), Planning (including involvement of craft foreman/journeyman in planning a task), Estimating (including determination of necessary materials and equipment needed to perform a task), Material Handling, Set-up (moving tools and equipment from shop to ship to perform a task), Fire Watch, General Labor (including general support of journeyman tasks), Cleaning (including debris pickup and removal), Surveying, Security, Transportation, Supervision, and Lofting (sail/pattern making).

(3) Change Requests do not include replacement work performed pursuant to HSAR

3052.217-92 Inspection and Manner of Doing Work clause or HSAR 3052.217-100 Guarantees clause.

(4) It is the Government's intention to award any growth work identified during the repair to the contractor, if a fair and reasonable price can be negotiated for such work, based upon

Schedule rates. If a fair and reasonable price cannot be negotiated, the Government may, at its discretion, obtain services outside of the contract. Such services may be performed while the ship is undergoing repair in the contractor's facility pursuant to the Access to Vessels clause.

(5) Change requests can be transmitted electronically by using email. The bullets below display the process of how change requests are to be followed during the availability:

Change Request (CR) Process will occur in the following order:

a. Condition Found Report (CFR)-Generated by the Contractor and provided to COR

b. Condition Report Reply(CRR)-Generated by the COR and provided to Contractor

c. Change Request- CR and IGE are generated by the COR and forwarded to KO

d. COR provides copy of Change Request to the Contractor

e. Contractor’s Proposal- Provided to the KO for the identified tasking on CR

f. Negotiations- If needed, take place to establish pricing

g. Approved Work Request- Forwarded to Contractor and COR by the KO

h. Modification to Contract- The KS/KO will issue a modification covering all CR’s

(6) The contractor shall submit to the Contracting Officer the following information in all CR proposals:

a. Number of labor hours estimated; broken down by specific direct production labor category.

b. Material estimates, individually broken out and priced. When requested by the

Contracting Officer, material quotes shall be provided.

c. Subcontractor estimates, individually broken out and priced along with the actual subcontractor quotes. The requirement to submit subcontractor quotes may be waived if deemed appropriate by the Contracting Officer.

d. Any proposed changes to the Schedule of Work.

(7) The contractor shall not be entitled to payment for any hours ordered pursuant to this clause until such time as a written contract modification is executed.

Schedule of work

(1) Notwithstanding other requirements specified in this contract, the contractor shall provide to the Contracting Officer and COR the following documents within three (3) working days of the vessel's arrival at the contractor's facility for dry-dock availabilities and at the arrival conference for dockside availabilities:

a. Production Schedule.

b. Work Package Network.

c. Total Manpower Loading Curve.

d. Trade Manning Curves.

e. Subcontracting List.

(2) The Production Schedule shall list the earliest, latest, and scheduled start and completion date for each work item awarded and shall identify the critical path. The Work Package Network shall show the work items, milestones, key events, and activities and shall clearly identify the critical path. The Total Manpower Loading Curve shall show the required manning for the duration of the contract. The Trade Manning Curves shall show the required manning for each trade for the duration of the contract. The Subcontracting List shall show work items, milestones, key events, and activities to be accomplished by subcontractors.

(3) Additional Item Requirements ordered and agreed upon, whether or not yet formalized via a change order (contract modification), shall be added to the Production Schedule, Trade

Manning Curves, and Subcontracting List and submitted to the Contracting Officer and COR at each weekly Progress Meeting. Any anticipated or unanticipated deviation (greater than two (2) calendar days) from the Production Schedule shall be immediately brought to the attention of the

Contracting Officer and COR.

(4) Any deviation in the Production Schedule which results in a delay in the completion of work on a vessel past the established performance period completion date may entitle the

Government to remedies for late performance under subparagraph (f) of this clause titled

Excusable delays.

Delivery and Shifting of the Vessel

(1) The Government shall deliver the vessel to the contractor, at the location specified in the contract.

(2) Whether the specified location of performance is the contractor's own facility or any other authorized facility, it shall be understood to mean the fairway of the facility. The contractor shall provide necessary tugs and pilot services to move the vessel from the fairway to the pier or dock, and, upon completion of all work, from the pier or dock to the fairway of the facility.

(3) While the vessel is in the possession of the contractor, any necessary movement of the vessel incidental to the work specified in the contract shall be furnished by the contractor without additional charge to the Government.

Access to the Vessel

(1) As authorized by the Contracting Officer, a reasonable number of officers, employees and personnel designated by the Government, or representatives of other contractors and their subcontractors shall have admission to the facility and access to the vessel at all reasonable times to perform and fulfill their respective obligations to the Government on a noninterference basis.

The contractor shall make reasonable arrangements to provide access for these personnel to office space, work areas, storage or shop areas, and other facilities and services reasonable and necessary to perform their duties. All such personnel shall comply with contractor rules and regulations governing personnel at its shipyard, including those regarding safety and security.

(2) The contractor further agrees to allow a reasonable number of officers, employees, and designated personnel of offerors on other contemplated work, the same privileges of admission to the contractor's facility and access to the vessel(s) on a noninterference basis, subject to contractor rules and regulations governing personnel in its shipyard, including those regarding safety and security.

Temporary Services

(1) Temporary services are services incidental to the performance of work which are required in the schedule or specifications to be provided by the contractor. Temporary services may include the furnishing of water, electricity, telephone service, toilet facilities, garbage removal, office space, parking places or similar facilities.

(2) If performance time is extended due to Government-caused delay, the contractor may request an equitable adjustment for providing temporary services at the rate stated in the

Schedule.

Contract Deficiency Report

The Contracting Officer or Contracting Officer’s Representative (COR) may issue a Contract

Deficiency Report (CDR), SFLC Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COR. The COR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor and Availability Program Manager. The

Contracting Officer will render a final determination and provide it to the Contractor and COR in writing.

(End of FAR 52.212-4 Addendum)

52.212-5 Contract Terms and Conditions Required To Implement Statutes or

Executive Orders—Commercial Items (Jul 2018)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or

Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or

Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further

Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (JUL 2018) (Section 1634 of Pub. L.

115-91).

https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1158787 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1159972

(3) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov

2015).

(4) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(5) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004)(Public Laws 108-

77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the

Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

_X_ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C.

3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and

Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

X__ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards

(Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery

Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

_X_ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with

Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility

Matters (Jul 2013) (41 U.S.C. 2313).

__ (10) [Reserved].

__ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15

U.S.C. 657a).

__ (ii) Alternate I (Nov 2011) of 52.219-3.

__ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business

Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)

(15 U.S.C. 657a).

__ (ii) Alternate I (JAN 2011) of 52.219-4.

__ (13) [Reserved] https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1146366 https://www.acquisition.gov/sites/default/files/current/far/html/52_233_240.html#wp1113329 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t29t32+1665+30++%2831%29%20%20AND%20%28%2831%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_233_240.html#wp1113344 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1137622 http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1141983 http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1144881 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1141649 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1151163 https://www.acquisition.gov/sites/default/files/current/far/html/52_200_206.html#wp1151299 https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1140926 https://www.acquisition.gov/sites/default/files/current/far/html/52_207_211.html#wp1145644 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135955 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135955 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135970 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1135970

_X_ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C.

644).

__ (ii) Alternate I (Nov 2011).

__ (iii) Alternate II (Nov 2011).

__ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C.

644).

__ (ii) Alternate I (Oct 1995) of 52.219-7.

__ (iii) Alternate II (Mar 2004) of 52.219-7.

_X_ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C.

637(d)(2) and (3)).

__ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Nov 2016) of 52.219-9.

__ (iii) Alternate II (Nov 2016) of 52.219-9.

__ (iv) Alternate III (Nov 2016) of 52.219-9.

__ (v) Alternate IV (Nov 2016) of 52.219-9.

__ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

__X (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)).

__ (20) 52.219-16, Liquidated Damages—Subcon-tracting Plan (Jan 1999) (15 U.S.C.

637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside

(Nov 2011) (15 U.S.C. 657 f).

X__ (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15

U.S.C. 632(a)(2)).

__ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically

Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small

Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15

U.S.C. 637(m)).

_X_ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

_X_ (26) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jan 2018)

(E.O. 13126).

X__ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

_X_ (28) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

__ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212).

X__ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C.

793).

__ (31) 52.222-37, Employment Reports on Veterans (FEB 2016) (38 U.S.C. 4212).

https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136004 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136017 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136017 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136017 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136032 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136058 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136174 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136175 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136186 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1136387 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1139913 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t13t16+492+90++%2815%29%20%20AND%20%28%2815%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1144950 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_217_221.html#wp1144420 http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147479 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147630 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147656 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1147711 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1158632 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1162802 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t29t32+2+78++%2829%29%20%20AND%20%28%2829%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t29t32+2+78++%2829%29%20%20AND%20%28%2829%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1148123

__ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations

Act (Dec 2010) (E.O. 13496).

_X_ (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__ (34) 52.222-54, Employment Eligibility Verification (OCT 2015). (Executive Order

12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

__ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–

Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential

Hydrofluorocarbons (JUN 2016) (E.O. 13693).

__ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (JUN 2016) (E.O. 13693).

__ (38)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (JUN 2014)

(E.O.s 13423 and 13514).

__ (ii) Alternate I (Oct 2015) of 52.223-13.

__ (39)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (JUN 2014) (E.O.s

13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-14.

__ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42

U.S.C. 8259b).

__ (41)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products

(OCT 2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

X__ (42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While

Driving (AUG 2011) (E.O. 13513).

__ (43) 52.223-20, Aerosols (JUN 2016) (E.O. 13693).

__ (44) 52.223-21, Foams (JUN 2016) (E.O. 13693).

__ (45)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

__ (ii) Alternate I (JAN 2017) of 52.224-3.

__ (46) 52.225-1, Buy American—Supplies (May 2014) (41 U.S.C. chapter 83).

__ (47)(i) 52.225-3, Buy American—Free Trade Agreements—Israeli Trade Act (May

2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1160019 https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1151848 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1151848 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_222.html#wp1156645 https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2022_18.html#wp1089948 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168892 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168892 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168917 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168928 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168933 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1168933 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1194330 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1194330 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1194323 http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1179078 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1179078 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1188603 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1189174 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1197699 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1192898 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1192900 http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 http://uscode.house.gov/ http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t17t20+1727+50++%2819%29%20%20AND%20%28%2819%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t17t20+1727+50++%2819%29%20%20AND%20%28%2819%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/

U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-

283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I (May 2014) of 52.225-3.

__ (iii) Alternate II (May 2014) of 52.225-3.

__ (iv) Alternate III (May 2014) of 52.225-3.

__ (48) 52.225-5, Trade Agreements (OCT 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

__X (49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the

Department of the Treasury).

__ (50) 52.225-26, Contractors Performing Private Security Functions Outside the United

States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for

Fiscal Year 2008; 10 U.S.C. 2302 Note).

__ (51) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C.

5150).

__ (52) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov

2007) (42 U.S.C. 5150).

__ (53) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41

U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (54) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

X__ (55) 52.232-33, Payment by Electronic Funds Transfer—System for Award

Management (Jul 2013) (31 U.S.C. 3332).

__ (56) 52.232-34, Payment by Electronic Funds Transfer—Other than System for Award

Management (Jul 2013) (31 U.S.C. 3332).

__ (57) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (58) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (59) 52.242-5, Payments to Small Business Subcontractors (JAN 2017)(15 U.S.C.

637(d)(12)).

__ (60)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb

2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

__ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495).

http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169038 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169151 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t17t20+1727+50++%2819%29%20%20AND%20%28%2819%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t17t20+1727+50++%2819%29%20%20AND%20%28%2819%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1169608 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1192524 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t09t12+1445+65++%2810%20U.S.C.%202302%20Note%29%20%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1173773 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_223_226.html#wp1173393 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t41t42+250+1286++%2842%29%20%20AND%20%28%2842%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153230 http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153252 http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153351 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3332&num=0&edition=prelim https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153375 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3332&num=0&edition=prelim https://www.acquisition.gov/sites/default/files/current/far/html/52_232.html#wp1153445 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section3332&num=0&edition=prelim https://www.acquisition.gov/sites/default/files/current/far/html/52_233_240.html#wp1113650 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t05t08+2+3++%285%29%20%20AND https://www.acquisition.gov/sites/default/files/current/far/html/52_241_244.html#wp1128833 https://www.acquisition.gov/sites/default/files/current/far/html/52_247.html#wp1156217…